N0016725Q1015.pdf

This is a combined synopsis/solicitation for commercial items prepared in accordance with Federal Acquisition Regulation (FAR) Subpart 12.6, as supplemented with additional information included in this notice. The Naval Surface Warfare Center Carderock Division (NSWCCD) intends to solicit only one source under the authority of FAR Part 13.106-1(b) the Contracting Officer has determined that circumstances of the contract action deem only one source reasonably available. The Government intends to solicit with 4D Technologies for a 4D InSpecXL Surface Gage and BackPack Kit W/ Surface Pro. The NAICS code is 333310 and the Small Business Size Standard is 1000.

The provisions and clauses included and/or incorporated in this solicitation document are those in effect through the Federal Acquisition Circular. This RFQ incorporates all provisions and clauses in effect through Federal Acquisition Circular FAC 2025-03 and the Defense Federal Acquisition Regulation Supplement (DFARS) DPN 20250117. SEE ATTACHED SOLICITATION FOR CLAUSES AND

PROVISIONS.

Interested parties may identify their interest to this requirement by submitting a capabilities statement no later than 12:00 PM on 4/16/25. This notice of intent is NOT a request for competitive quotes. However, all responses received by 4/16/25 will be considered by the Government. A determination by the Government not to compete this proposed purchase order based upon responses to this notice is solely within the discretion of the Government. Information received will normally be considered solely for the purpose of determining whether to conduct a competitive procurement. All responses shall include price(s), FOB point, a point of contact, name and phone number, GSA contract number (if applicable), business size, and payment terms. Each response must clearly indicate the capability of the quoter to meet all specifications and requirements.

Responses to this notice are due on or before 12:00 PM ET 4/16/25 by email at steven.besanko@navy.mil.

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

4D InSpecXL Surface Gage & BackPack Kit

MIPR M954504568957

Internal Number: 1023574493 Pricing Arrangement: Firm Fixed Price

1 Each

167Wh InSpec Back-up Battery Kit

MIPR M954504568957

Internal Number: 1023574485 Pricing Arrangement: Firm Fixed Price

1 Each

Set of fold mirrors for InSpecXL includes 2x 35mm zero-phase mirrors v-groove focus aid and case

MIPR M954504568957

Internal Number: 1023574489 Pricing Arrangement: Firm Fixed Price

1 Each

ISO-Compliant Certified Height Standard M954504568957

Internal Number: 1023574491 Pricing Arrangement: Firm Fixed Price

1 Each

Spare Replacement End Face Glass and nose piece M954504568957

Internal Number: 1023574487 Pricing Arrangement: Firm Fixed Price

1 Each

N0016725Q1015

Section C - Description/Specifications/Statement of Work

The 4D InsSpecXL supporting equipment must include:

- A field usable optical gauge using project structured light to measure surfaces in 3D with microscopic resolution.

- A 0.6" x0.6" field of view

- A vertical resolution better than 0.0003" and a lateral resolution less than 10 microns

- User interface with HD1080 touch-screen, including measurement and analysis software

- Ability to provide 2D and 3D displays, filtering, thresholds and masking tools make it easy to highlight and quantify surface shape and texture

- Ethernet cable tether

- Benchtop stand for setting focus and placing parts for repetitive measures

- Fold mirrors (2, 35mm zero phase mirrors)

- ISO-compliant certified height standard for system verification

- Spare end face glass and nose piece

The 4D InSpecXL requires use of the Microsoft Windows 10 Secure Host Baseline Version 2H2:

Comes with Operating Hardware (SurfacePro)

Digital download of the software shall be enabled within 15 days of contract award. The download of the software module will be coordinated by NSWCCD Code 613 with Onto Innovation.

Requirements 4DInSpecXL Surface Gage, BackPack Kit with Surface Pro

Section D - Packaging and Marking

Section E - Inspection and Acceptance

Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Destination Instructions: TBD

DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500 MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Email: TBD

Inspection and Acceptance Location

Both Destination Instructions: TBD

DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500 MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Email: TBD

Inspection and Acceptance Location

Both Destination Instructions: TBD

DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500 MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Email: TBD

Inspection and Acceptance Location

Both Destination Instructions: TBD

DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500 MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Email: TBD

Inspection and Acceptance Location

Both Destination Instructions: TBD

DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500 MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Email: TBD

Section F - Deliveries or Performance

Contractor Destination

Line Item Delivery Schedule Quantity Address and POC Special Handling/Notes

Delivery On Or Before Delivery Date 01 May 2025

1 Each Ship To DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500

MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Telephone: TBD

FoB Details Contractor Destination

Delivery On Or Before Delivery Date 01 May 2025

1 Each Ship To DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500

MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Telephone: TBD

Delivery On Or Before Delivery Date 01 May 2025

1 Each Ship To DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500

MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Telephone: TBD

FoB Details Contractor Destination

Delivery On Or Before Delivery Date 01 May 2025

1 Each Ship To DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500

MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Telephone: TBD

FoB Details Contractor Destination

Delivery On Or 1 Each Ship To

Before Delivery Date 01 May 2025

DoDAAC: N00167 CountryCode: USA

NSWC CARDEROCK

CARDEROCK DIVISION BLDG 143, 9500

MACARTHUR BOULEVARD

BETHESDA, MD 20817-5700

UNITED STATES

TBD, TBD

Telephone: TBD

FoB Details Contractor Destination

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.247-34 F.o.b. Destination. Nov 1991

Section G - Contract Administration Data

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF payment instructions.

WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

Invoice and Receiving Report (COMBO)

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF Document routing.

when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC N62825

Issue By DoDAAC N00167

Admin DoDAAC N00167

Inspect By DoDAAC N00167

Ship To Code N00167

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

Ademola Oriowo at 301-503-0809 or by email at ademola.m.oriowo.civ@us.navy.mil

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Additional Regulation or Supplemental Clauses Incorporated by Full Text

G-232-H002 H002 PAYMENT INSTRUCTIONS (NAVSEA) (FEB 2024) (Feb 2024)

Payment office allocation methods can be found in the table at DFARS PGI 204.7108(b)(2) (https://www.acq.osd.mil/dpap /dars/pgi/pgi_htm/current/PGI204_71.htm#payment_instructions).

(End of text)

G-242-W001 CONTRACT ADMINISTRATION FUNCTIONS (NAVSEA) (OCT 2018) (Oct 2018)

(a) In accordance with FAR 42.302(a) all functions listed are delegated to the ACO except the following items to be retained by the PCO:

n/a

(b) In accordance with FAR 42.302(b), the following additional functions are delegated to the ACO:

n/a

(End of Text)

G-242-H002 HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (JUL 2021) (Jul 2021)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods. Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor's expense with no cost or liability to the U.

S. Government.

(b) The federal Government observes public Holidays that have been established under 5 U.S.C. 6103. The actual date of observance foreach of the holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company's established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. TheContracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

(f) The hours of operation are as follows:

AREA FROM TO

West Bethesda MD 0800 1400

(g) All deliveries to the Receiving Officer, Bethesda, MD, shall be made Monday through Friday from 0800 to 1400, local time. Deliveries will not be accepted after 1400. No deliveries will be accepted on federal government holidays.

(End of Text)

G-242-H001 GOVERNMENT CONTRACTADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2023)

(Oct 2023)

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND RESPONSIBILITIES (NAVSEA)

(OCT 2018)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel - that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

N0016725Q1015 https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays/ https://www.opm.gov/policy-data-oversight/pay-leave/federal-holidays

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Name: Kristen Duhaime Address:

904 Corporate Ln.

Chesapeake, VA 23320

E-mail: kristen.duhaime@navy.mil

(ii) The Contract Specialist is:

Name: Steven Besanko Address:

9500 MacArthur Blvd.

Bethesda, MD 20817 E-mail: steven.besanko@navy.mil

(d) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is:

Name: [ * ] Address:

[ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx];

E-mail: [ * ]

(e) The Contractor's point of contact for performance under this contract is:

Name: [ * ] Address:

[ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx];

E-mail: [ * ]

[ * ] To be completed at contract award

(End of text)

Section H - Special Contract Requirements

Section I - Contract Clauses

Termination for Convenience of the Government (Fixed-Price) (Short Form) (Apr 1984)

The Contracting Officer, by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the rights, duties, and obligations of the parties, including compensation to the Contractor, shall be in accordance with part 49 of the Federal Acquisition Regulation in effect on the date of this contract.

(End of clause)

Termination for Convenience of the Government (Fixed-Price) (Apr 2012)

(a)The Government may terminate performance of work under this contract in whole or, from time to time, in part if the Contracting Officer determines that a termination is in the Government's interest. The Contracting Officer shall terminate by delivering to the Contractor a Notice of Termination specifying the extent of termination and the effective date.

(b)After receipt of a Notice of Termination, and except as directed by the Contracting Officer, the Contractor shall immediately proceed with the following obligations, regardless of any delay in determining or adjusting any amounts due under this clause:

(1)Stop work as specified in the notice.

(2)Place no further subcontracts or orders (referred to as subcontracts in this clause) for materials, services, or facilities, except as necessary to complete the continued portion of the contract.

(3)Terminate all subcontracts to the extent they relate to the work terminated.

(4)Assign to the Government, as directed by the Contracting Officer, all right, title, and interest of the Contractor under the subcontracts terminated, in which case the Government shall have the right to settle or to pay any termination settlement proposal arising out of those terminations.

(5)With approval or ratification to the extent required by the Contracting Officer, settle all outstanding liabilities and termination settlement proposals arising from the termination of subcontracts; the approval or ratification will be final for purposes of this clause.

(6)As directed by the Contracting Officer, transfer title and deliver to the Government-

(i)The fabricated or unfabricated parts, work in process, completed work, supplies, and other material produced or acquired for the work terminated;

and

(ii)The completed or partially completed plans, drawings, information, and other property that, if the contract had been completed, would be required to be furnished to the Government.

(7)Complete performance of the work not terminated.

(8)Take any action that may be necessary, or that the Contracting Officer may direct, for the protection and preservation of the property related to this contract that is in the possession of the Contractor and in which the Government has or may acquire an interest.

(9)Use its best efforts to sell, as directed or authorized by the Contracting Officer, any property of the types referred to in paragraph (b)(6) of this clause; provided, however, that the Contractor (i)is not required to extend credit to any purchaser and (ii) may acquire the property under the conditions prescribed by, and at prices approved by, the Contracting Officer. The proceeds of any transfer or disposition will be applied to reduce any payments to be made by the Government under this contract, credited to the price or cost of the work, or paid in any other manner directed by the Contracting Officer.

(c)The Contractor shall submit complete termination inventory schedules no later than 120 days from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 120-day period.

(d)After expiration of the plant clearance period as defined in Subpart 49.001 of the Federal Acquisition Regulation, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality, of termination inventory not previously disposed of, excluding items authorized for disposition by the Contracting Officer. The Contractor may request the Government to remove those items or enter into an agreement for their storage. Within 15 days, the Government will accept title to those items and remove them or enter into a storage agreement. The Contracting Officer may verify the list upon removal of the items, or if stored, within 45 days from submission of the list, and shall correct the list, as necessary, before final settlement.

(e)After termination, the Contractor shall submit a final termination settlement proposal to the Contracting Officer in the form and with the certification prescribed by the Contracting Officer. The Contractor shall submit the proposal promptly, but no later than 1 year from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 1-year period. However, if the Contracting Officer determines that the facts justify it, a termination settlement proposal may be received and acted on after 1 year or any extension. If the Contractor fails to submit the proposal within the time allowed, the Contracting Officer may determine, on the basis of information available, the amount, if any, due the Contractor because of the termination and shall pay the amount determined.

N0016725Q1015 https://www.acquisition.gov/far/part-49#FAR_Part_49 https://www.acquisition.gov/far/49.001#FAR_49_001

(f)Subject to paragraph (e) of this clause, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount to be paid or remaining to be paid because of the termination. The amount may include a reasonable allowance for profit on work done. However, the agreed amount, whether under this paragraph (f) or paragraph (g) of this clause, exclusive of costs shown in paragraph (g)(3) of this clause, may not exceed the total contract price as reduced by (1) the amount of payments previously made and (2) the contract price of work not terminated. The contract shall be modified, and the Contractor paid the agreed amount. Paragraph (g) of this clause shall not limit, restrict, or affect the amount that may be agreed upon to be paid under this paragraph.

(g)If the Contractor and the Contracting Officer fail to agree on the whole amount to be paid because of the termination of work, the Contracting Officer shall pay the Contractor the amounts determined by the Contracting Officer as follows, but without duplication of any amounts agreed on under paragraph (f) of this clause:

(1)The contract price for completed supplies or services accepted by the Government (or sold or acquired under paragraph (b)(9) of this clause) not previously paid for, adjusted for any saving of freight and other charges.

(2)The total of-

(i)The costs incurred in the performance of the work terminated, including initial costs and preparatory expense allocable thereto, but excluding any costs attributable to supplies or services paid or to be paid under paragraph (g)(1) of this clause;

(ii)The cost of settling and paying termination settlement proposals under terminated subcontracts that are properly chargeable to the terminated portion of the contract if not included in subdivision (g)(2)(i) of this clause; and

(iii)A sum, as profit on subdivision (g)(2)(i) of this clause, determined by the Contracting Officer under 49.202 of the Federal Acquisition Regulation, in effect on the date of this contract, to be fair and reasonable; however, if it appears that the Contractor would have sustained a loss on the entire contract had it been completed, the Contracting Officer shall allow no profit under this subdivision (g)(2)(iii) and shall reduce the settlement to reflect the indicated rate of loss.

(3)The reasonable costs of settlement of the work terminated, including-

(i)Accounting, legal, clerical, and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data;

(ii)The termination and settlement of subcontracts (excluding the amounts of such settlements); and

(iii)Storage, transportation, and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory.

(h)Except for normal spoilage, and except to the extent that the Government expressly assumed the risk of loss, the Contracting Officer shall exclude from the amounts payable to the Contractor under paragraph (g) of this clause, the fair value as determined by the Contracting Officer, for the loss of the Government property.

(i)The cost principles and procedures of part 31 of the Federal Acquisition Regulation, in effect on the date of this contract, shall govern all costs claimed, agreed to, or determined under this clause.

(j)The Contractor shall have the right of appeal, under the Disputes clause, from any determination made by the Contracting Officer under paragraph (e), (g), or (l) of this clause, except that if the Contractor failed to submit the termination settlement proposal or request for equitable adjustment within the time provided in paragraph (e) or (l), respectively, and failed to request a time extension, there is no right of appeal.

(k)In arriving at the amount due the Contractor under this clause, there shall be deducted-

(1)All unliquidated advance or other payments to the Contractor under the terminated portion of this contract;

(2)Any claim which the Government has against the Contractor under this contract; and

(3)The agreed price for, or the proceeds of sale of, materials, supplies, or other things acquired by the Contractor or sold under the provisions of this clause and not recovered by or credited to the Government.

(l)If the termination is partial, the Contractor may file a proposal with the Contracting Officer for an equitable adjustment of the price(s) of the continued portion of the contract. The Contracting Officer shall make any equitable adjustment agreed upon. Any proposal by the Contractor for an equitable adjustment under this clause shall be requested within 90 days from the effective date of termination unless extended in writing by the Contracting Officer.

(m)

(1)The Government may, under the terms and conditions it prescribes, make partial payments and payments against costs incurred by the Contractor for the terminated portion of the contract, if the Contracting Officer believes the total of these payments will not exceed the amount to which the Contractor will be entitled.

(2)If the total payments exceed the amount finally determined to be due, the Contractor shall repay the excess to the Government upon demand, together with interest computed at the rate established by the Secretary of the Treasury under 50 U.S.C. App.1215(b)(2). Interest shall be computed for the period from the date the excess payment is received by the Contractor to the date the excess is repaid. Interest shall not be charged on any excess payment due to a reduction in the Contractor's termination settlement proposal because of retention or other disposition of termination inventory until 10 days after the date of the retention or disposition, or a later date determined by the Contracting Officer because of the circumstances.

N0016725Q1015 https://www.acquisition.gov/far/49.202#FAR_49_202 https://www.acquisition.gov/far/part-31#FAR_Part_31

(n)Unless otherwise provided in this contract or by statute, the Contractor shall maintain all records and documents relating to the terminated portion of this contract for 3 years after final settlement. This includes all books and other evidence bearing on the Contractor's costs and expenses under this contract. The Contractor shall make these records and documents available to the Government, at the Contractor's office, at all reasonable times, without any direct charge. If approved by the Contracting Officer, photographs, microphotographs, or other authentic reproductions may be maintained instead of original records and documents.

(End of clause)

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.204-13 System for Award Management Maintenance. Oct 2018 52.211-15 Defense Priority and Allocation Requirements. Apr 2008 52.212-4 Contract Terms and Conditions-Commercial Products and Commercial Services. Nov 2023 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023 252.225-7048 Export-Controlled Items. Jun 2013 252.232-7010 Levies on Contract Payments. Dec 2006 252.246-7008 Sources of Electronic Parts. Jan 2023

FAR Clauses Incorporated by Full Text

52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders - Commercial Products and Commercial Services.

(DEVIATION 2025-O0003)

(Jan 2025) Deviation 2025-O0003 (Mar 2025)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE

ORDERS--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (MAY 2024)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.C.

3801).

(6) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (NOV 2021) (41 U.S.C.

4704 and 10 U.S.C. 4655).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) (41 U.S.C. 3509).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

___ (4) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) (41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community--see FAR 3.900(a).

___ (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note).

___ (6) [Reserved]

___ (7) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

___ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111- 117, section 743 of Div. C).

___ (9) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117- 328).

___ (10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders--Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (DEC 2023) (Pub. L. 115-390, title II).

___ (11)(i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders--Prohibition. (DEC 2023) (Pub. L. 115-390, title

II).

___ (ii) Alternate I (DEC 2023) of 52.204-30.

___ (12) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) (31 U.S.C. 6101 note).

___ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018) (41 U.S.C.

2313).

____ (14) [Reserved]

____ (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) (15 U.S.C. 657a).

____ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

____ (17) [Reserved]

____ (18)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-6.

____ (19)(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

____ (ii) Alternate I (MAR 2020) of 52.219-7.

____ (20) 52.219-8, Utilization of Small Business Concerns (FEB 2024) (15 U.S.C. 637(d)(2) and (3)).

____ (21)(i) 52.219-9, Small Business Subcontracting Plan (SEP 2023) (15 U.S.C. 637(d)(4)).

____ (ii) Alternate I (NOV 2016) of 52.219-9.

____ (iii) Alternate II (NOV 2016) of 52.219-9.

____ (iv) Alternate III (JUN 2020) of 52.219-9.

____ (v) Alternate IV (SEP 2023) of 52.219-9.

____ (22) (i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) (15 U.S.C. 644(r)).

____ (ii) Alternate I (MAR 2020) of 52.219-13.

____ (23) 52.219-14, Limitations on Subcontracting (OCT 2022) (15 U.S.C. 657s).

____ (24) 52.219-16, Liquidated Damages--Subcontracting Plan (SEP 2021) (15 U.S.C. 637(d)(4)(F)(i)).

____ (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (FEB 2024) (15 U.S.C. 657f).

____ (26) (i) 52.219-28, Post-Award Small Business Program Rerepresentation (FEB 2024) (15 U.S.C. 632(a)(2)).

____ (ii) Alternate I (MAR 2020) of 52.219-28.

____ (27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (OCT 2022) (15 U.S.C. 637(m)).

____ (28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) (15 U.S.C. 637(m)).

____ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) (15 U.S.C. 644(r)).

____ (30) 52.219-33, Nonmanufacturer Rule (SEP 2021) (15 U.S.C. 657s).

X (31) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

X (32) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (FEB 2024) (E.O. 13126).

____ (33) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

X (34)(i) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

____ (ii) Alternate I (FEB 1999) of 52.222-26.

____ (35)(i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

____ (ii) Alternate I (JUL 2014) of 52.222-35.

____ (36)(i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

____ (ii) Alternate I (JUL 2014) of 52.222-36.

____ (37) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

____ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

X (39)(i) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627).

____ (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

____ (40) 52.222-54, Employment Eligibility Verification (MAY 2022). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in

FAR 22.1803.)

____ (41)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (MAY 2008) (42 U.S.

C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

____ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (MAY 2024) (42 U.S.C. 7671, et seq.).

____ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (MAY 2024) (42 U.S.C. 7671, et seq.).

____ (44) 52.223-20, Aerosols (MAY 2024) (42 U.S.C. 7671, et seq.).

____ (45) 52.223-21, Foams (MAY 2024) (42 U.S.C. 7671, et seq.).

____ (46) 52.223-23, Sustainable Products and Services (MAY 2024) (E.O. 14057, 7 U.S.C. 8102, 42 U.S.C. 6962, 42 U.S.C.

8259b, and 42 U.S.C. 7671l).

____ (47) (i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

____ (ii) Alternate I (JAN 2017) of 52.224-3.

____ (48) (i) 52.225-1, Buy American--Supplies (OCT 2022)) (41

U.S.C. chapter 83).

____ (ii) Alternate I (OCT 2022) of 52.225-1.

____ (49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (NOV 2023) (19 U.S.C. 3301 note, 19 U.S.

C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108- 77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

____ (ii) Alternate I [Reserved].

____ (iii) Alternate II (DEC 2022) of 52.225-3.

____ (iv) Alternate III (FEB 2024) of 52.225-3.

____ (v) Alternate IV (OCT 2022) of 52.225-3.

____ (50) 52.225-5, Trade Agreements (NOV 2023) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X (51) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

____ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

____ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (NOV 2007) (42 U.S.C. 5150).

____ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007) (42 U.S.C. 5150).

____ (55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (MAY 2024) (E.O. 13513).

____ (56) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

____ (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (NOV 2021) (41 U.

S.C.4505, 10 U.S.C. 3805).

____ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (NOV 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

X (59) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (OCT 2018) (31 U.S.C. 3332).

____ (60) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (JUL 2013) (31 U.S.

C. 3332).

____ (61) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

____ (62) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

____ (63) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(13)).

____ (64) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631).

____ (ii) Alternate I (APR 2003) of 52.247-64.

____ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: [Contracting Officer check as appropriate.]

_____ (1) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67).

_____ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

_____ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY 2014) (29 U.S.

C 206 and 41 U.S.C. chapter 67).

_____ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-- Requirements (MAY 2014) (41 U.S.C. chapter 67).

_____ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022) (E.O. 13658).

_____ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

_____ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause--

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) (41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) (41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii)(A) 52.204-30, Federal Acquisition Supply Chain Security Act Orders--Prohibition. (DEC 2023) (Pub. L. 115-390, title II).

(B) Alternate I (DEC 2023) of 52.204-30.

(viii) 52.219-8, Utilization of Small Business Concerns (FEB 2024) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(x) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

(xi) 52.222-35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xv) 52.222-41, Service Contract Labor Standards (AUG 2018), (41 U.S.C. chapter 67).

(xvi) _____ (A) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627).

_____ (B) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67.)

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-- Requirements (MAY 2014) (41 U.S.C. chapter 67)

(xix) 52.222-54, Employment Eligibility Verification (MAY 2022) (E. O. 12989).

(xx) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022) (E.O. 13658).

(xxi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2022) (E.O. 13706).

(xxii) (A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (JUN 2020) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

N0016725Q1015 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_222_62 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_224_3 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_224_3

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) (31 U.S.C. 3903 and 10 U.S.

C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxvi) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (NOV 2021) (46 U.S.C. 55305 and 10 U.S.C.

2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial…