20RJR77_sol.pdf

CODE

(Hour)

PAGE(S)

until 03:00 PM local time 23 Apr 2020

X

A X B X C X D

EX

X

G F 60 - 80

81 - 95 X H 96 - 102 danielle.julian-klie@navy.mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA FAR (48 CFR) 53.214(c)

DOA 6 1 102

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

N00164 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and 1 copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

DANIELLE M JULIAN-KLIER 812-854-4929

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

2 - 5

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

6 - 13 14 - 15

J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

16 - 17 18 - 19

X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 20 - 28 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 29 - 30 X M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIONS AND INSTRUCTIONS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

31 - 58

PART II - CONTRACT CLAUSES

NAVAL SURFACE WARFARE CENTER CRANE DIV

D. JULIAN-KLIER (812-854-4929)

BLDG 3373

300 HWY 361

CRANE IN 47522-5001

812-854-4929

FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

09 Mar 2020

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

N0016420RJR77

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QTY U/I UNIT PRICE AMOUNT

0001 FIRST ARTICLE TESTING

Each

First Article Testing IAW ADL 53711-5355908, SPEC OES-PRF-0139 dated , QAP, SQAP and all associated drawings. A qty of 65 grenades shall be provided for FAT.

*See Pricing Matrix Below

PSC: 1330

FOB: Destination

FFP

0002 GRENADE, 9-BANG FLASH

BANG

IAW SPEC OES-PRF-0139 dated 27 June 2019, ADL 53711-5355908, QAP, SQAP and all associated drawings *See Pricing Matrix Below

Note: The minimum order quantity for this CLIN is 1,000 units with a maximum order quantity of 50,000 Units per delivery order.

0003 GRENADE, 9-BANG FLASH

BANG INERT

drawings.

Manufacture an inert model of Production CLIN 0002 utilizing all components that make up the production unit on CLIN 0002 with the exception that all energetic materials shall be replaced with similar density inert materials.The inert model shall include all the applicable markings included on the production unit.

*See Pricing Matrix Below

Note: The minimum order quantity for this CLIN is 1 unit with a maximum order quantity of 20 Units per delivery order.

0004 GRENADE, 9-BANG FLASH

BANG CUTAWAY INERT

drawings

Manufacture an inert cutaway model of Production CLIN 0002 utilizing all components that make up the production unit on CLIN 0002 with the exception that all energetic materials shall be replaced with similar density inert materials. The inert model shall include all the applicable markings included on the production unit. The grenade shall have a 90 degree section removed, leaving a 270 degree section for display of internal parts.

*See Pricing Matrix Below

Note: The minimum order quantity for this CLIN is 1 unit with a maximum order quantity of 20 Units per delivery order.

0005 DATA

Lot

Technical Data Requirements for CLINs 0001 thru 0004 in accordance with (IAW) SPEC OES-PRF-0139 dated 27 June 2019, ADL 53711-5355908, QAP, SQAP, Contract Data Requirements List (CDRLs), DD1423 A001 thru A015 provided in Section J, and applicable DID(s).

CLIN 0005 is NOT SEPARATELY PRICED.

IDC CONSTRAINTS

CONTRACT MINIMUM/MAXIMUM QUANTITY AND CONTRACT VALUE

The minimum quantity and contract value for all orders issued against this contract shall not be less than the minimum quantity and contract value stated in the following table. The maximum quantity and contract value for all orders issued against this contract shall not exceed the maximum quantity and contract value stated in the following table.

MINIMUM

QUANTITY

MAXIMUM

AMOUNT

65 grenades (First Article)

$16,000,000.00

PRICING MATRICES

NOTE: Offerors may propose different quantity/price break points than those listed below, and are encouraged to do so, if it will facilitate optimal pricing.

CLIN 0001 – FIRST ARTICLE TESTING

QTY YEAR

YEAR

YEAR

YEAR

YEAR

1 Lot of 65

CLIN 0002 – GRENADE, 9-BANG FLASH BANG

QTY YEAR

YEAR

YEAR

YEAR

YEAR

1,000-5,000 5,001-10,000 10,001-25,000 25,001- 50,000

CLIN 0003 – GRENADE, 9-BANG FLASH BANG INERT

QTY YEAR

YEAR

YEAR

YEAR

YEAR

1-4

5-10 11-20

CLIN 0004 – GRENADE, 9-BANG FLASH BAND CUTAWAY

INERT

QTY YEAR

YEAR

YEAR

YEAR

YEAR

1-4 5-10 11-20

Section C - Descriptions and Specifications

CLAUSES INCORPORATED BY FULL TEXT

C-247-H001 PERMITS AND RESPONSIBILITIES (NAVSEA) (DEC 2018)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits for complying with any applicable Federal, State, and Municipal laws, codes, and regulations for shipping and transportation including, but not limited to, any movement over public highways of overweight/over dimensional materials.

(End of text)

C-246-H002 GOVERNMENT USE OF CONTRACTOR’S INSPECTION EQUIPMENT (NAVSEA) (OCT 2018)

The contractor's gages, measuring, and testing devices shall be made available to the Government when required to determine contractor conformance with contract requirements. If conditions warrant, the contractor’s personnel shall be made available for operation of such devices and for verification of their accuracy and condition.

C-242-H001 EXPEDITING CONTRACT CLOSEOUT (NAVSEA) (OCT 2018)

(a) As part of the negotiated fixed price or total estimated amount of this contract, both the Government and the Contractor have agreed to waive any entitlement that otherwise might accrue to either party in any residual dollar amount of $1,000 or less at the time of final contract closeout. The term "residual dollar amount" shall include all money that would otherwise be owed to either party at the end of the contract, except that, amounts connected in any way with taxation, allegations of fraud and/or antitrust violations shall be excluded. For purposes of determining residual dollar amounts, offsets of money owed by one party against money that would otherwise be paid by that party may be considered to the extent permitted by law.

(b) This agreement to waive entitlement to residual dollar amounts has been considered by both parties. It is agreed that the administrative costs for either party associated with collecting such small dollar amounts could exceed the amount to be recovered.

C-233-H001 DOCUMENTATION OF REQUESTS FOR EQUITABLE ADJUSTMENT--BASIC (NAVSEA) (OCT 2018)

(a) For the purposes of this special contract requirement, the term "change" includes not only a change that is made pursuant to a written order designated as a "change order" but also (1) an engineering change proposed by the

Government or by the Contractor and (2) any act or omission to act on the part of the Government in respect of which a request is made for equitable adjustment.

(b) Whenever the Contractor requests or proposes an equitable adjustment of $100,000 or more per vessel in respect to a change made pursuant to a written order designated as a "change order" or in respect to a proposed engineering change and whenever the Contractor requests an equitable adjustment in any amount in respect to any other act or omission to act on the part of the Government, the proposal supporting such request shall contain the following information for each individual item or element of the request:

(1) A description (i) of the work required by the contract before the change, which has been deleted by the change, and (ii) of the work deleted by the change which already has been completed. The description is to include a list of components, equipment, and other identifiable property involved. Also, the status of manufacture, procurement, or installation of such property is to be indicated. Separate description is to be furnished for design and production work.

Items of raw material, purchased parts, components and other identifiable hardware, which are made excess by the change and which are not to be retained by the Contractor, are to be listed for later disposition;

(2) Description of work necessary to undo work already completed which has been deleted by the change;

(3) Description of work not required by the terms hereof before the change, which is substituted or added by the change. A list of components and equipment (not bulk materials or items) involved should be included. Separate descriptions are to be furnished for design work and production work;

(4) Description of interference and inefficiencies in performing the change;

(5) Description of each element of disruption and exactly how work has been, or will be disrupted:

(i) The calendar period of time during which disruption occurred, or will occur;

(ii) Area(s) aboard the vessel where disruption occurred, or will occur;

(iii) Trade(s) disrupted, with a breakdown of manhours for each trade;

(iv) Scheduling of trades before, during, and after period of disruption;

(v) Description of measures taken to lessen the disruptive effect of the change;

(6) Delay in delivery attributable solely to the change;

(7) Other work attributable to the change;

(8) Supplementing the foregoing, a narrative statement of the direct "causal" relationship between any alleged Government act or omission and the claimed consequences therefor, cross-referenced to the detailed information provided as required above; and

(9) A statement setting forth a comparative enumeration of the amounts "budgeted" for the cost elements, including the material costs, labor hours and pertinent indirect costs, estimated by the Contractor in preparing its initial and ultimate proposal(s) for this contract, and the amounts claimed to have been incurred and/or projected to be incurred corresponding to each such "budgeted cost" elements.

(c) Each proposal in excess of $100,000 submitted in support of a claim for equitable adjustment under any requirement of this contract shall, in addition to the information required by paragraph (b) hereof, contain such information as the Contracting Officer may require with respect to each individual claim item.

(d) It is recognized that individual claims for equitable adjustment may not include all of the factors listed in paragraph

(b) above. Accordingly, the Contractor is required to set forth in its proposal information only with respect to those factors which are comprehended in the individual claim for equitable adjustment. In any event, the information furnished hereunder shall be in sufficient detail to permit the Contracting Officer to cross-reference the claimed increased costs, or delay in delivery, or both, as appropriate, submitted pursuant to paragraph (c) of this requirement, with the information submitted pursuant to paragraph (b) hereof.

C-227-H008 GOVERNMENT-INDUSTRY DATA EXCHANGE PROGRAM (NAVSEA) (DEC 2018)

(a) The contractor shall actively participate in the Government Industry Data Exchange Program in accordance with the GIDEP Operations Manual, S0300-BT-PRO-010. The contractor shall submit information concerning critical or major nonconformances, as defined in FAR 46.407/DFARS 246.407, to the GIDEP information system.

(b) The contractor shall insert paragraph (a) of this clause in any subcontract when deemed necessary. When so inserted, the word "contractor" shall be changed to "subcontractor."

(c) The contractor shall, when it elects not to insert paragraph (a) in a subcontract, provide the subcontractor any GIDEP data which may be pertinent to items of its manufacture and verify that the subcontractor utilizes any such data.

(d) The contractor shall, whether it elects to insert paragraph (a) in a subcontract or not, verify that the subcontractor utilizes and provides feedback on any GIDEP data that may be pertinent to items of its manufacture."

(e) GIDEP materials, software and information are available without charge from:

GIDEP Operations Center P.O. Box 8000 Corona, CA 92878-8000 Phone: (951) 898-3207

FAX: (951) 898-3250

Internet: http://www.gidep.org

C-223-W001 ACCIDENT REPORTING (NAVSEA) (OCT 2018)

(a) In accordance with DFARS 252.223-7002 (d), the Contractor shall immediately notify the Administrative Contracting Officer (ACO) and Procuring Contracting Officer (PCO) following an accident or incident. Also, the Contractor shall provide a written report within (insert number of days) days of the accident or incident containing, at a minimum, the following:

(1) Location, date and local time of the occurrence;

(2) Category of accident (fire, explosion, natural disaster, etc.);

(3) Identification of equipment, material and type of activity involved;

(4) Contract number;

(5) Procuring activity (name of PCO and ACO);

(6) Narrative of occurrence, including cause(s), if known;

(7) Personnel involved and degree of injury, if any. Specify whether Contractor and/or Government personnel;

(8) Assessment of damage. Estimate in dollars for contractor and/or government owned material, property, equipment;

(9) Was a news release made? If so, by whom? If not, will a news release be made?

(10) Was a request made for any assistance?

(11) Will there be any effect on production? If so, explain in detail.

(12) Corrective action taken, if any.

(13) Name and title of person submitting this report.

(b) The Contractor shall forward weekly written reports to the ACO and PCO until the accident or incident no longer affects production or when contract deliveries are on schedule.

C-227-H006 DATA REQUIREMENTS (NAVSEA) (OCT 2018)

The data to be furnished hereunder shall be prepared in accordance with the Contract Data Requirements List, DD Form 1423, Exhibit(s) A, attached hereto.

(End of Text)

C-223-H003 EXCLUSION OF MERCURY (NAVSEA) (MAR 2019)

(a) Definitions. As used in this text:

Article means a manufactured item other than a fluid or particle: (i) which is formed to a specific shape or design during manufacture; (ii) which has end use function(s) dependent in whole or in part upon its shape or design during end use; and (iii) which under normal conditions of use does not release more than very small quantities, e.g., minute or trace amounts of a hazardous chemical, and does not pose a physical hazard or health risk to employees.

Boundary of containment means a continuous tight seal (barrier) to prevent the release of functional mercury during normal operation and maintenance. Examples include the exterior of a fluorescent lamp, glass capsule of a mercury switch, and container for mercury reagents. A double boundary of containment consists of two independent seals.

Functional mercury means mercury or mercury compound(s) contained in equipment that is required for the equipment to operate properly, such as that found in mercury switches, fluorescent lamps, flat-panel monitors, thermostats, thermostat probes, small coin type batteries, barometers, and dental amalgams.

Hardware means any article, container, piece of material, individual part, subassembly, assembly, component, or system to which mercury control requirements apply.

Mercury-free means hardware that does not contain functional mercury and is not contaminated by mercury or mercury compounds.

Portable means items that are frequently transported during normal operation. Desk lamps, shop lights, and hand-held instruments are considered portable, while bulbs in stationary light fixtures are not. In general, items that require transport only during maintenance, installation, and removal of the items are not considered portable.

(b) The Contractor, and all subcontractors and vendors, shall ensure that mercury or mercury containing compounds are not intentionally added to, or come in direct contact with, hardware or supplies furnished under this contract.

(1) The Contractor shall ensure that mercury and mercury compounds are not taken onboard naval vessels by Contractor, subcontractor, or vendor personnel except for functional mercury used in batteries, dental amalgams, fluorescent lamps, flat-panel monitors, required instruments, sensors or controls, weapon systems, and chemical analysis reagents specified by the Naval Sea Systems Command (NAVSEA).

(2) Portable fluorescent lamps and portable instruments containing elemental mercury must be shock-proof in accordance with MIL-DTL-901E entitled Requirements for Shock Tests, H.I. (High Impact) Shipboard Machinery, Equipment, and Systems and have mercury enclosed by a double boundary of containment. Some devices with liquid crystal display (LCD) screens utilize a fluorescent bulb backlight to illuminate the LCD screen.

No additional restrictions or controls apply to devices with LCD screens; however, the Contractor shall remove the LCD screen and seal it in plastic following any evidence that the backlight failed.

(3) For Submarines, any use of mercury containing items must be approved as required by the Nuclear Powered Submarine Atmosphere Control Manual (S9510-AB-ATM-010/U) Volume 1.

(4) The Contractor shall ensure that mercury and mercury compounds do not contact hardware surfaces in systems covered by NAVSEA Manual NAVSEA 0989-064-3000 entitled Cleanliness Requirements for Nuclear Propulsion Plant Maintenance and Construction, submarine air systems, level I systems per NAVSEA Publication 0948-LP-045-7010, NAVSEA Material Control Standard, or the submarine safety program (SUBSAFE) surfaces during maintenance or repair. Such hardware is designated as mercury-free. The Contractor shall ensure that all other hardware that could be structurally degraded by contamination with elemental mercury or reactive mercury compounds is separated from it by sufficient distance, or boundaries of containment that effectively prevents contact in all but the most extreme circumstances.

(5) The Contractor shall check any hardware surfaces in the above systems which are known or suspected to have come in contact with mercury or mercury compounds for evidence of structural degradation and external mercury contamination. The existence of external mercury contamination can be determined following MIL-STD-2041D entitled Control of Detrimental Materials.

(6) The presence of mercury in a product may be determined by checking product labeling on material safety data sheets or safety data sheets. Chemical analysis is not required.

(7) The Contractor shall dispose of any mercury and mercury compounds in accordance with OPNAV Manual (OPNAV M-5090.1) entitled Environmental Readiness Program Manual of 10 January 2014.

(8) If the use of mercury or mercury compounds cannot be avoided, a risk assessment and waiver request, if required, must be performed and submitted per the NAVSEA Hazardous Material Avoidance Process (T9070-AL- DPC-020/077-2). For systems covered by the NAVSEA Manual NAVSEA 0989-064-3000 entitled Cleanliness Requirements for Nuclear Propulsion Plant Maintenance and Construction, submit the risk assessment and waiver request, if required to Nuclear Propulsion (NAVSEA 08).

(c) In all cases where mercury or a mercury compound has contacted hardware surfaces required to be mercury-free the Contractor shall immediately provide a report to the NAVSEA Dry Environmental Systems and Hazardous Materials (NAVSEA 05P5) via the cognizant contract administration safety office. Reports concerning systems covered by NAVSEA Manual 0989-064-3000 must include NAVSEA Nuclear Propulsion Directorate (SEA 08) in the distribution. Reports must be in letter form and include the date and details of the contact, the surfaces contacted, the recovery actions taken, and the status of the affected surfaces.

C-215-H002 CONTRACTOR PROPOSAL (NAVSEA) (OCT 2018)

(a) Performance of this contract by the Contractor shall be conducted and performed in accordance with the detailed obligations to which the Contractor committed itself in Proposal dated in response to Solicitation No.

N0016420RJR77.

(b) The technical volume(s) of the Contractor's proposal is(are) hereby incorporated by reference and made subject to the "Order of Precedence" (FAR 52.215-8) clause of this contract. Under the "Order of Precedence" clause, the technical volume(s) of the Contractor's proposal referenced herein is (are) hereby designated as item (f) of the clause, following "the specifications" in the order of precedence.

C-211-H018 APPROVAL BY THE GOVERNMENT (NAVSEA) (JAN 2019)

Approval by the Government as required under this contract and applicable specifications shall not relieve the Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such approval.

C-211-H017 UPDATING SPECIFICATIONS AND STANDARDS (NAVSEA) (DEC 2018)

The contractor may request that this contract be updated to include the current version of the applicable specification or standard if the update does not affect the form, fit or function of any deliverable item or increase the cost/price of the item to the Government. The contractor should submit update requests to the Procuring Contracting Officer with copies to the Administrative Contracting Officer and cognizant program office representative for approval. The contractor shall perform the contract in accordance with the existing specifications and standards until notified of approval/disapproval of its request to update by the Procuring Contracting Officer. Any approved alternate specifications or standards will be incorporated into the contract.

C-209-H001 FIRST ARTICLE (CONTRACTOR TESTING) (NAVSEA) (OCT 2018)

(a) The First Article shall conform in every respect to the requirements of this contract. The First Article shall be manufactured with tools, materials, and methods which are the same as the tools, material and methods which will be used to manufacture the production units. All items delivered under the contract shall be manufactured under the same conditions and quality established by the First Article. Any changes to tools, material, or methods after the first article approval shall be documented by the contractor and approved by the Contracting Officer before they are used.

(b) The Contractor shall make a record of all data obtained during such tests in a form similar to the guidance provided in MIL-HDBK-831A.

(c) Pursuant to paragraph (e) of the clause entitled "First Article Approval--Contractor Testing" (FAR 52.209-3), the First Article shall not be delivered as part of the production quantity.

C-209-H003 WAIVER OF FIRST ARTICLE REQUIREMENTS (NAVSEA) (OCT 2018)

If the First Article is waived by the Government, the Contractor shall deliver supplies that are identical or substantially identical to those previously accepted by the Government under the following contract(s):

(Offeror to fill in contract number(s), as applicable. See Section M)

C-204-H001 USE OF NAVY SUPPORT CONTRACTORS FOR OFFICIAL CONTRACT FILES (NAVSEA)

(OCT 2018)

(a) NAVSEA may use a file room management support contractor, hereinafter referred to as "the support contractor", to manage its file room, in which all official contract files, including the official file supporting this procurement, are retained. These official files may contain information that is considered a trade secret, proprietary, business sensitive or otherwise protected pursuant to law or regulation, hereinafter referred to as “protected information”. File room management services consist of any of the following: secretarial or clerical support; data entry; document reproduction, scanning, imaging, or destruction; operation, management, or maintenance of paper-based or electronic mail rooms, file rooms, or libraries; and supervision in connection with functions listed herein.

(b) The cognizant Contracting Officer will ensure that any NAVSEA contract under which these file room management services are acquired will contain a requirement that:

(1) The support contractor not disclose any information;

(2) Individual employees are to be instructed by the support contractor regarding the sensitivity of the official contract files;

(3) The support contractor performing these services be barred from providing any other supplies and/or services, or competing to do so, to NAVSEA for the period of performance of its contract and for an additional three years thereafter unless otherwise provided by law or regulation; and,

(4) In addition to any other rights the contractor may have, it is a third party beneficiary who has the right of direct action against the support contractor, or any person to whom the support contractor has released or disclosed protected information, for the unauthorized duplication, release, or disclosure of such protected information.

(c) Execution of this contract by the contractor is considered consent to NAVSEA's permitting access to any information, irrespective of restrictive markings or the nature of the information submitted, by its file room management support contractor for the limited purpose of executing its file room support contract responsibilities.

(d) NAVSEA may, without further notice, enter into contracts with other contractors for these services. Contractors should enter into separate non-disclosure agreements with the file room contractor. Contact the Procuring Contracting Officer for contractor specifics. However, any such agreement will not be considered a prerequisite before information submitted is stored in the file room or otherwise encumber the government.

C-202-H001 ADDITIONAL DEFINITIONS–BASIC (NAVSEA) (OCT 2018)

(a) Department - means the Department of the Navy.

(b) Commander, Naval Sea Systems Command - means the Commander of the Naval Sea Systems Command of the Department of the Navy or his duly appointed successor.

(c) References to The Federal Acquisition Regulation (FAR) - All references to the FAR in this contract shall be deemed to also reference the appropriate sections of the Defense FAR Supplement (DFARS), unless clearly indicated otherwise.

(d) National Stock Numbers - Whenever the term Federal Item Identification Number and its acronym FIIN or the term Federal Stock Number and its acronym FSN appear in the contract, order or their cited specifications and standards, the terms and acronyms shall be interpreted as National Item Identification Number (NIIN) and National Stock Number (NSN) respectively which shall be defined as follows:

(1) National Item Identification Number (NIIN). The number assigned to each approved Item Identification under the Federal Cataloging Program. It consists of nine numeric characters, the first two of which are the National Codification Bureau (NCB) Code. The remaining positions consist of a seven digit non-significant number.

(2) National Stock Number (NSN). The National Stock Number (NSN) for an item of supply consists of the applicable four-position Federal Supply Class (FSC) plus the applicable nine-position NIIN assigned to the item of supply.

Section D - Packaging and Marking

D-211-H001 PACKAGING OF DATA (NAVSEA) (OCT 2018)

Data to be delivered by Integrated Digital Environment (IDE) or other electronic media shall be as specified in the contract.

All unclassified data to be shipped shall be prepared for shipment in accordance with best commercial practice.

Classified reports, data, and documentation shall be prepared for shipment in accordance with National Industrial Security Program Operating Manual (NISPOM), DOD 5220.22-M dated 28 February 2006 incorporating Change 2 dated 18 May 2016.

D-223-W001 EXPLOSIVE OR HAZARDOUS MATERIALS--PACKAGING & LABELING (NAVSEA) (OCT

(a) Packaging, Packing, Marking and Labeling of Explosive materials to be shipped by any mode or combination of transportation modes shall be prepared (properly classed, described, packaged, marked, labeled, placarded, etc.) for shipment in accordance with all applicable Department of Transportation/Department of Defense regulations in effect at time of shipment.

(b) In the event of a conflict between specific requirements in the contract or order and existing applicable regulations, the regulations take precedence. Under no circumstance shall the contractor knowingly use materials, markings or procedures that are not in accordance with law and regulations applicable to the mode of transportation employed.

Mode of Transportation/Applicable Regulation

1. Domestic Highway/A

2. Domestic Commercial Air/A, B

3. Export Surface/A, C, E

4. Export Commercial Air/A, B, E

5. Export Military Air/D, E

List of Regulations

A. Code of Federal Regulations Title 49 B. International Air Transport Association (IATA) Dangerous Goods Regulation C. International Maritime Organization (IMO) Dangerous Goods Regulation D. Air Force Joint Manual (AFJAM) Preparation of Hazardous Materials for Military Air Shipment E. Export shipments are also subject to the domestic regulations indicated to transport the material to the port of embarkation (POE).

(c) Markings listed below are a minimum for acceptance of the material:

1. Proper Shipping Name

2. UN Number

3. Name and Address of Shipper and Consignee

(d) Additional Required Markings for EXPLOSIVE Material:

1. National Stock Number __________________or Local Stock Number _____________________

2. Material Item Nomenclature

3. Lot # / Quantity contained in this package

4. Net Explosive Weight / Gross Weight of Package

(e) A packing list must be placed on the outside of the package with the shipping papers (i.e. DD 250, DD 1149, etc.)

enclosed. The shipping papers must include the technical point of contact at Destination for Delivery. All other documentation should be placed in a separate packing list.

D-247-W001 PROHIBITED PACKING MATERIALS (NAVSEA) (OCT 2018)

The use of asbestos, excelsior, newspaper or shredded paper (all types including waxed paper, computer paper and similar hygroscopic or non-neutral material) is prohibited. In addition, the use of yellow wrapping or packaging material is prohibited except where used for the containment of radioactive material. Loose fill polystyrene is prohibited for shipboard use.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Origin Government Destination Government 0002 Origin Government Destination Government 0003 Origin Government Destination Government 0004 Origin Government Destination Government 0005 N/A N/A N/A Government

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996 52.246-16 Responsibility For Supplies APR 1984 252.229-7007 Verification of United States Receipt of Goods JUN 1997

E-246-H013 INSPECTION AND ACCEPTANCE OF DATA (NAVSEA) (OCT 2018)

Inspection and acceptance of all data shall be as specified on the attached Contract Data Requirements List(s), DD Form 1423.

E-246-H016 INSPECTION AND ACCEPTANCE OF F.O.B. DESTINATION DELIVERIES (NAVSEA) (OCT

Item(s) CLINs 0001-0004 - Inspection and acceptance shall be made at destination by a representative of the Government.

E-246-H022 INSPECTION AND TEST RECORDS (NAVSEA) (JAN 2019)

Inspection and test records shall, as a minimum, indicate the nature of the observations, number of observations made, and the number and type of deficiencies found. Data included in inspection and test records shall be complete and accurate, and shall be used for trend analysis and to assess corrective action and effectiveness. The data shall, on request, be identified and made available for on-site review by the Contracting Officer or designated Government representative.

E-246-W007 NOTIFICATION OF INSPECTION OR TEST (NAVSEA) (OCT 2018)

The Contractor agrees to notify the Requiring Technical Activity and Purchasing Contracting Officer, in writing, when the material will be inspected and/or tested. A minimum of 14working days is required to arrange such a visit.

E-246-H020 QUALITY MANAGEMENT SYSTEM REQUIREMENTS (NAVSEA) (OCT 2018)

The Contractor shall provide and maintain a quality management system that, as a minimum, adheres to the requirements of ASQ/ANSI/ISO 9001:2015 “Quality Management Systems – Requirements” and supplemental requirements imposed by this contract. The quality management system procedures, planning, and all other documentation and data that comprise the quality management system shall be made available to the Government for review. Existing quality documents that meet the requirements of this contract may continue to be used. The Government may perform any necessary inspections, verifications, and evaluations to ascertain conformance to requirements and the adequacy of the implementing procedures. The Contractor shall flow down such standards, as applicable, to lower-tier subcontractors under instances covered in FAR 52.246-11(b) or at the direction of the Contracting Officer. The Government reserves the right to disapprove the quality management system or portions thereof when it fails to meet the contractual requirements.

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 430 dys. AFATA NAVAL SURFACE WARFARE CENTER

CRANE DIV

M/F: JUD PADGETT (BLDG 3395)

EXPLOSIVES - BLDG 2390

300 HWY 361

CRANE IN 47522-5001

812-854-1020

N00164

0002 245 dys. ADC (SAME AS PREVIOUS LOCATION)

0003 245 dys. ADC (SAME AS PREVIOUS LOCATION)

0004 245 dys. ADC (SAME AS PREVIOUS LOCATION)

0005 IAW DD1423s 1 Lot IAW DD1423s N00164

52.211-17 Delivery of Excess Quantities SEP 1989 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.247-34 F.O.B. Destination NOV 1991 52.247-52 Clearance and Documentation Requirements-Shipments to

DOD Air or Water Terminal Transshipment Points

FEB 2006

252.223-7003 Changes In Place Of Performance--Ammunition And Explosives

DEC 1991

F-242-H001 CONTRACTOR NOTICE REGARDING LATE DELIVERY (NAVSEA) (OCT 2018)

In the event the contractor anticipates or encounters difficulty in complying with the contract delivery schedule or date, the contractor shall immediately notify, in writing, the Contracting Officer and the cognizant Contract Administration Services Office, if assigned. The notice shall give the pertinent details; however, such notice shall not constitute a waiver by the Government of any contract delivery schedule, or of any rights or remedies provided by law or under this contract.

F-247-H001 DELIVERY OF DATA (NAVSEA) (OCT 2018)

All data to be furnished under this contract shall be delivered prepaid to the destination(s) and at the time(s) specified on the Contract Data Requirements List(s), DD Form 1423.

F-211-W001 PARTIAL DELIVERIES (NAVSEA) (OCT 2018)

Partial deliveries will not be accepted without specific approval from the Contracting Officer.

Section G - Contract Administration Data

G-242-H002 HOURS OF OPERATION AND HOLIDAY SCHEDULE (NAVSEA) (OCT 2018)

(a) The policy of this activity is to schedule periods of reduced operations or shutdown during holiday periods.

Deliveries will not be accepted on Saturdays, Sundays or Holidays except as specifically requested by the [insert activity name]. All goods or services attempted to be delivered on a Saturday, Sunday or Holiday without specific instructions from the Contracting Officer or his duly appointed representative will be returned to the contractor at the contractor’s expense with no cost or liability to the U.S. Government.

(b) The federal Government observes the following holidays:

HOLIDAYS*

New Year's Day Martin Luther King's Birthday Presidential Inauguration Day (Washington DC metro area only) President's Day Memorial Day Independence Day Labor Day Columbus Day Veteran's Day Thanksgiving Day Christmas Day

* Except for the Presidential Inauguration Day, if the actual date falls on a Saturday, the holiday will be observed the preceding Friday. If the holiday falls on a Sunday, the observance shall be on the following Monday.

The actual date of observance for each of the above holidays, for a specific calendar year, may be obtained from the OPM website at OPM.GOV or by using the following direct link: https://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays/#url.

(c) Delayed Opening, Early Dismissal and Closure of Government Facilities. When a Government facility has a delayed opening, is closed or Federal employees are dismissed early (due to severe weather, security threat, security exercise, or a facility related problem) that prevents personnel from working, onsite contractor personnel regularly assigned to work at that facility shall follow the same reporting and/or departure directions given to Government personnel. The contractor shall not direct charge to the contract for such time off, but shall follow parent company policies regarding taking leave (administrative or other). Non-essential contractor personnel, who are not required to remain at or report to the facility, shall follow their parent company policy regarding whether they should go/stay home or report to another company facility. Subsequent to an early dismissal, delayed opening, or during periods of inclement weather, onsite contractors should monitor the OPM website as well as radio and television announcements before departing for work to determine if the facility is closed or operating on a delayed arrival basis.

(d) When Federal employees are excused from work due to a holiday or a special event (that is unrelated to severe weather, a security threat, or a facility related problem), on site contractors shall continue working established work hours or take leave in accordance with parent company policy. Those contractor employees who take leave shall not direct charge the non-working hours to the contract. Contractors are responsible for predetermining and disclosing their charging practices for early dismissal, delayed openings, or closings in accordance with the FAR, applicable cost accounting standards, and the company’s established policy and procedures. Contractors shall follow their disclosed charging practices during the contract period of performance, and shall not follow any verbal directions to the contrary. The Contracting Officer will make the determination of cost allowability for time lost due to facility closure in accordance with FAR, applicable Cost Accounting Standards, and the Contractor's established accounting policy and procedures.

(e) If you intend to visit the Contracts Office, it is advised that you call for an appointment at least 24 hours in advance.

G-242-H001 GOVERNMENT CONTRACT ADMINISTRATION POINTS-OF-CONTACT AND

RESPONSIBILITIES (NAVSEA) (OCT 2018)

(a) The Government reserves the right to administratively substitute any of the points of contact listed below at any time.

(b) The contracting officer is the only person authorized to change this contract or orders issued thereunder. The Contractor shall not comply with any order, direction or request of Government personnel

- that would constitute a change - unless it is issued in writing and signed by the Contracting Officer or is pursuant to specific authority otherwise included as part of this contract. If, in the opinion of the contractor, an effort outside the existing scope of this contract is requested, the contractor shall promptly comply with the Notification of Changes clause of this contract.

(c) The points of contact are as follows:

(i) The Procuring Contracting Officer (PCO) is:

Name: [ * ]

Address:

[ *Street ] [ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx]; FAX: (Area Code) xxx- [xxxx] E-mail: [ * ]

(ii) The Contract Specialist is:

Address:

[ *Street ] [ *City, State, Zip ]

(iii) The Administrative Contracting Officer (ACO) is:

Address:

[ *Street ] [ *City, State, Zip ] Phone: (Area Code) xxx- [xxxx];

(d) The Contracting Officer’s Representative (COR) is the contracting officer’s appointed representative for technical matters. The COR is not a contracting officer and does not have the authority to direct the accomplishment of effort which is beyond the scope of the contract or to otherwise change any contract requirements. An informational copy of the COR appointment letter, which provides a delineation of COR authority and responsibilities, will be provided upon award of this contract.

The Contracting Officer’s Representative (COR) is:

Address:

[ *Street ] [ *City, State, Zip ]

(e) The Alternate Contracting Officer’s Representative (ACOR) is responsible for COR responsibilities and functions in the event that the COR is unavailable due to leave, illness, or other official business. The ACOR is appointed by the contracting officer; a copy of the ACOR appointment will be provided upon award of this contract.

The Alternate Contracting Officer’s Representative (ACOR) is:

Address:

[ *City, State, Zip ]

(f) The Technical Point of Contact (TPOC) is the contracting officer’s representative for technical matters when a COR is not appointed. The TPOC is responsible for technical issues of contract administration, such as providing all items of Government Furnished Information (GFI), Government Furnished Material (GFM) and Government Furnished Equipment (GFE) if specified in the contract as well as the inspection and acceptance of all contract deliverables.

The Technical Point of Contact (TPOC) is:

Address: [ *Street ] [ *City, State, Zip ]

(g) The Alternate Technical Point of Contact (ATPOC) is responsible for TPOC responsibilities and functions in the event that the TPOC is unavailable due to leave, illness, or other official business.

The Alternate Technical Point of Contact (ATPOC) is:

Address:

[ *City, State, Zip ]

(h) The Ombudsman will review complaints from the contractors and ensure that all contractors are afforded a fair opportunity to be considered, consistent with the procedures in the contract.

The Ombudsman is:

Address:

[ *Street ] [ *City, State, Zip ]

(i) The Authorized Ordering Person(s) for Per-Call Maintenance is responsible for issuing and maintaining records for any per-call orders for remedial maintenance placed under this contract. No per-call order shall be placed outside the scope of this contract and the cumulative total of all orders shall not be in excess of any not-to-exceed amount specified in the contract. Per-call orders shall not, in any way, modify any terms and conditions of the contract.

(j) The Authorized Ordering Person(s) for Per-Call Maintenance is:

Address:

[ *Street ] [ *City, State, Zip ]

(k) The Contractor's point of contact for performance under this contract is:

Title: [ * ] Address:

[ *Street ] [ *City, State, Zip ]

[ * ] To be completed at contract award

G-242-W001 CONTRACT ADMINISTRATION FUNCTIONS (NAVSEA) (OCT 2018)

(a) In accordance with FAR 42.302(a) all functions listed are delegated to the ACO except the following items to be retained by the PCO:

[ List specific functions that will be retained by the PCO]

(b) In accordance with FAR 42.302(b), the following additional functions are delegated to the ACO:

[ List any additional functions that will be delegated to the ACO]

G-232-H005 SUPPLEMENTAL INSTRUCTIONS REGARDING INVOICING (NAVSEA) (JAN 2019)

(a) For other than firm fixed priced contract line item numbers (CLINs), the Contractor agrees to segregate costs incurred under this contract/task order (TO), as applicable, at the lowest level of performance, either at the sub line item number (SLIN) or CLIN level, rather than at the total contract/TO level, and to submit invoices reflecting costs incurred at that level. Supporting documentation in Wide Area Workflow (WAWF) for invoices shall include summaries of work charged during the period covered as well as overall cumulative summaries by individual labor categories, rates, and hours (both straight time and overtime) invoiced; as well as, a cost breakdown of other direct costs (ODCs), materials, and travel, by technical instruction (TI), SLIN, or CLIN level. For other than firm fixed price subcontracts, subcontractors are also required to provide labor categories, rates, and hours (both straight time and overtime) invoiced; as well as, a cost breakdown of ODCs, materials, and travel invoiced. Supporting documentation may be encrypted before submission to the prime contractor for WAWF invoice submittal.

Subcontractors may email encryption code information directly to the Contracting Officer and Contracting Officer Representative (COR). Should the subcontractor lack encryption capability, the subcontractor may also email detailed supporting cost information directly to the Contracting Officer and COR; or other method as agreed to by the Contracting Officer.

(b) Contractors submitting payment requests and receiving reports to WAWF using either Electronic Data Interchange (EDI) or Secure File Transfer Protocol (SFTP) shall separately send an email notification to the COR and Contracting Officer on the same date they submit the invoice in WAWF. No payments shall be due if the contractor does not provide the COR and Contracting Officer email notification as required herein.

G-232-H002 PAYMENT INSTRUCTIONS AND CONTRACT TYPE SUMMARY FOR PAYMENT

OFFICE (NAVSEA) (JUN 2018)

(a) The following table of payment office allocation methods applies to the extent indicated.

For Government Use Only

Contract/Order Payment Clause

Type of Payment Request

Su pp ly

Se rv ic e

C on st ru ct io n

Payment Office Allocation Method

52.212-4 (Alt I), Contract Terms and Conditions— Commercial Items 52.216-7, Allowable Cost and Payment 52.232-7, Payments under Time-and-Materials and Labor-Hour Contracts

Cost Voucher X X N/A Line item specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-1, Payments Navy Shipbuilding Invoice (Fixed Price)

X N/A N/A Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

Contract/Order Payment Clause

Type of Payment Request

Su ic e

C on st ru ct io n

Payment Office Allocation Method

52.232-1, Payments;

52.232-2, Payments under Fixed-Price Research and Development Contracts;

52.232-3, Payments under Personal Services Contracts;

52.232-4, Payments under Transportation Contracts and Transportation-Related Services Contracts; and 52.232-6, Payments under Communication Service Contracts with Common Carriers

Invoice X X N/A Line Item Specific proration. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN on the deliverable line or deliverable subline item for which payment is requested.

52.232-5, Payments Under Fixed-Price Construction Contracts

Construction Payment Invoice

N/A N/A X Line Item specific by fiscal year. If there is more than one ACRN within a deliverable line or deliverable subline item, the funds will be allocated using the oldest funds. In the event of a deliverable line or deliverable subline item with two ACRNs with the same fiscal year, those amounts will be prorated to the available unliquidated funds for that year.

52.232-16, Progress Payments

Progress Payment*

X X N/A Contract-wide proration. Funds shall be allocated in the same proportion as the amount of funding currently unliquidated for each ACRN. Progress Payments are considered contract level financing, and the “contract price” shall reflect the fixed price portion of the contract per FAR 32.501-3.

52.232-29, Terms for Financing of Purchases of Commercial Items;

52.232-3…