JOSHUA APPLEBY DS FY26 Combined Synopsis Solicitation .docx

COMBINED SYNOPSIS/ SOLICITATION

This is a combined synopsis/solicitation for commercial services prepared in accordance with the format in FAR Subpart 12.6, supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested, and a separate written solicitation will not be issued.

The solicitation is issued as a Request for Quotation (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular FAC 2025-05 effective 08 August 2025. This requirement is being solicited as a HUBZone Set-Aside using FAR Part 12 Acquisition of Commercial Items and FAR 13.5 Simplified Procedures for Certain Commercial Items and certain aspects of FAR Part 15. The NAICS Code is 336611 – Ship Repair with a small business size standard of 1,300 employees. The solicitation number is 70Z08525QIBCT0022.

SCHEDULE OF SUPPLIES/SERVICES: See Attachment 1.

DESCRIPTION OF WORK: The contractor to provide all necessary materials, equipment, personnel as necessary to perform dockside repairs to the U.S. Coast Guard Cutter JOSHUA APPLEBY (WLM 175) is a 175ft Keeper Class, and is currently home-ported in Pensacola, Florida, all in exact accordance with this solicitation and the attached specification. See Attachment 2.

CONTRACT TYPE: This solicitation is a request for quotes (RFQ) that will result in the award of a firm fixed price contract solicited under FAR PART 12 and FAR Subpart 13.5 Simplified Procedures for Certain Commercial Items, subject to availability of funds.

CONTRACT PERIOD OF PERFORMANCE: The performance period for this requirement starts on or about 06 January 2026 and with a projected end date on or about 24 February, 2026.

PLACE OF PERFORMANCE: 211South Avenue C, Pensacola, FL 32508

QUESTIONS: It is strongly encouraged to submit questions regarding this solicitation by 08 October 2025 at 2:00 PM EST to allow adequate time for response. After this date further requests may not be accepted due to time constraints. Submit questions to Sandra.a.martinez and Jayne.gluck@uscg.mil.

using Attachment 4 - Request for Clarification.

QUOTATION DUE DATE: Your quotation must arrive no later than 20 October, 2025, at 4:00 pm Eastern Time; Quotations should be sent via electronic mail (e-mail) to Jayne.gluck@uscg.mil.

and Sandra.a.martinez@uscg.mil.

QUOTES MUST BE VALID FOR 120 DAYS.

ANTICIPATED AWARD DATE: The anticipated date of award is on or by 24 November 2025.

70Z08525QIBCT0022

USCGC JOSHUA APPLEBY (WLM 175) DS FY26

FAR Clauses In By Reference

below)

SEP 2023

Data Alternate I

FEB 2021

ALT I JUL 1995

Subcontractors

MAR 2023

FAR Clauses incorporated by Full Text

FAR 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (APRIL 2024) REV-01(DHS-USCG DEVIATION 14-01)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the enhancement of whistleblower protections for Contractor employees established at 10 U.S.C. 2409 by section 827 of the NDAA for FY 2013 (Pub. L. 112-239) and FAR 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section (FAR) 3.908.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold, as defined in FAR 2.101 on the date of subcontract award.

(End of Clause)

FAR 52.211-11 – LIQUIDATED DAMAGES – SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEPT 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $500.00 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default – Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default – Fixed-Price Supply and Service clause in this contract.

(End of Clause)

FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS (NOV 2023) ADDENDUM

INVOICE PAYMENT INSTRUCTIONS.

1. The Contractor shall prepare a proper invoice IAW FAR clause 52.212-4, and in addition to the information required by FAR 52.212-4(g) as cited in the contract. All invoices shall be itemized to correlate to the Schedule of Supplies/Services.

The Government will make payment under this contract based on a percentage or stage of completion. The Contractor may invoice each contract line item (CLIN) as work progresses. The amount invoiced shall be calculated based on those prices stipulated in the contract Schedule of Supplies/Services as follows:

A CLIN may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that CLIN have no limitation as to the percentage of completion required before invoicing. (The minimum percentage of completion (25%) to be reached prior to billing each CLIN may be waived by the Contracting Officer on a case-by-case basis for large dollar CLINS.)

In addition to the information required by FAR 52.212-4 (g) Invoices shall include:

Contract Number, Delivery Order/Task Order Number, DOC Number Name and Address of the Contractor Invoice Number and Invoice Date DUNS Number Name of the Contract Specialist and Contracting Officer’s Invoice Routing Code (IRC): SFLC-2 Period of Performance for Work Invoiced Indicate Small Business Status Indicate if Final Invoice, the Contractor’s final invoice submitted under the contract must be marked as follows: “THIS INVOICE CONSTITUTES THE FINAL INVOICE – UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER” (to be assigned upon contract award).

The percentage of completion for each CLIN identified;

Vessel name The overall percentage and dollar amount previously billed, currently billed and unbilled, Shipping and Payment Terms Name, title, phone number, and mailing address of person to be notified in the event of a defective invoice.

All information must be included in an invoice for it to constitute a proper invoice. All improper invoices will be rejected which could delay payment.

2. The Contractor shall forward invoices via e-mail: Abram.P.Fernandez@uscg.mil. and Sandra.a.martinez@uscg.mil. or in person to the Contracting Officer’s Technical Representative (COR).

3. The COR shall review and verify invoices, sign the invoice and return the invoice to the Contractor.

· Invoices for contracts awarded in FY22 or later will be processed in the Invoice Processing Platform (IPP) or MarkView.

· IPP is a secure, web-based service that manages invoicing from award through payment notification.

· MarkView is an invoice imagining and approval system integrated with the Accounts Payable (AP) module in FSMS.

· Invoices for FY22 or later awards that meet an exemption or the KO has agreed to the vendor submitting invoices outside of IPP will be processed in MarkView after the vendor sends the invoice to the applicable email established by FINCEN (emails can be found on the FINCEN website).

· If the vendor will be submitting invoices through IPP and:

· If there is a COR on the contract:

· Vendor will submit the invoice through IPP.

· The COR will be notified that there is an invoice for them to review in IPP.

· The COR will review the invoice, edit the distributions, if necessary, and approve/reject the invoice.

· If there are multiple distributions (LOAs) on a single CLIN, IPP will use a sequential method to distribute the funds to the 1st distribution until it is fully expended, then move on to the 2nd distribution until it is fully expended, and so on. If the invoice amounts should not be distributed in this manner, the COR can edit the distributions to apply the invoice amounts as needed.

· If the COR does not take action on the invoice within 3 days, a notification will be sent to the KO so the KO can take action on the invoice or work with the COR to get them to take action on the invoice.

· If the vendor will be submitting invoices through IPP and:

· Once the invoice is approved in IPP, it will be sent to FSMS.

· Once in FSMS, the invoice will go directly to the ACO(s) at FINCEN for final approval.

· The FINCEN ACO(s) will perform the final approval of the invoice and notification will be sent to Treasury to make payment to the vendor.

If the vendor will be submitting invoices directly to FINCEN for processing through MarkView and:

· If there is a COR on the contract:

· Vendor will submit the invoice directly to FINCEN via the applicable email.

· The FINCEN Accounting Technicians will reach out to the COR to provide matching guidance through the comment functionality in MarkView.

· Once they receive matching guidance, the FINCEN Accounting Technician will match the invoice to the award and send it to the COR for approval.

· COR will approve/reject the invoice.

· If approved, it will go to the ACO(s) at FINCEN for final approval.

· If rejected, it will go back to the vendor to make corrections or cancel.

· If the COR does not take action on the invoice within 3 days, a notification will be sent to the KO so the KO can take action on the invoice or work with the COR to get them to take action on the invoice. NOTE: This functionality will not be available in MarkView at go live, but it is should be available soon after.

· The FINCEN ACO(s) will perform the final approval of the invoice and notification will be sent to Treasury to make payment to the vendor.

Who will the vendor work with if they have issues in IPP? For issues with IPP, the vendors will work directly with the IPP Help Desk.

· Toll-free number: 866-973-3131

· Email address: IPPCustomerSupport@fiscal.treasury.gov

· Hours of operation: Monday through Friday (excluding bank holidays) from 8:00 am - 6:00 pm ET

· FINCEN will send vendor information to IPP. If the vendor is already registered in IPP, they will not need to take any action. If the vendor is not registered in IPP, they will get 2 emails from IPP with their user ID, password, and instructions on how to finish their registration.

Who will the vendor work with if they have issues with a payment? IPP will contain payment information that is sent from FSMS, but the IPP Help Desk will not be able to assist the vendor with the payment. Based on this, the vendor will need to work with the KO and FINCEN for payment issues.

· FINCEN Customer Service by phone: 757-523-6940

· FINCEN Customer Service by email: FIN-SMB-Customerservice@uscg.mil

· For additional contact information, please see the FINCEN Customer Service web page.

A copy of the invoice and any supporting documentation shall also be e-mailed to the following individuals:

Abram.P.Fernandez@uscg.mil AND Sandra.a.Martinez@uscg.mil.

Invoices shall only include work that has been incorporated via contract modification. Only the Contracting Officer is able to authorize work and issue any modifications; therefore, payments will not be made for any work to which a modification has not been properly executed. Invoices submitted for payment that includes such a request will be reduced by the unmodified amount

NOTE: 10% OF THE TOTAL CONTRACT PRICE WILL BE WITHHELD UNTIL ALL DELIVERABLES, REQUIRED BY THE CONTRACT, ARE RECEIVED AND ACCEPTED.

FURTHER CONSIDERATIONS WITH INVOICING:

In accordance with the Prompt Payment Act, for the purposes of determining a payment due date and the date on which interest will begin to accrue if a payment is late, a proper invoice shall be deemed to have been received:

(1) On the later of:

(i) For invoices electronically transmitted by the Contractor via web based submission, the date a transmission is received by the designated billing office, and receipt confirmation is provided to the designated recipient; or

(ii) The seventh day after the date on which the property is actually delivered or performance of the services is actually completed; unless—

The agency has actually accepted the property or services before the seventh day in which case the acceptance date shall substitute for the seventh day after the delivery date; or A longer acceptance period is specified in the contract, in which case the date of actual acceptance or the date on which such longer acceptance period ends shall substitute for the seventh day after the delivery date;

(2) On the date of delivery, when the contract specifies that the delivery ticket may serve as an invoice.

(3) Web based submission by the Contractor and receipt confirmation does not reflect Government review or acceptance of the invoice.

All payments for partial performance rendered by the Government under this contract are based on the assumption that the Contractor will, in good faith, execute and honor all payment terms entered into between it, the Prime Contractor, and any subcontractor thereof in the performance of this contract. The Contractor hereby acknowledges the Government’s right to reduce or suspend progress payments based on non-payment in accordance with any payment terms of the subcontract agreement.

Any amount deemed not payable will be deducted from the Contractor’s invoice. Deducted amounts may be resubmitted on the next invoice for reconsideration.

ACCESS TO VESSEL

(a) A reasonable number of officers, employees, and associates of the Government, or other prime Contractors with the Government, and their subcontractors, shall, as authorized by the Contracting Officer, have, at all reasonable times, admission to the plant, and access to vessel(s) to perform and fulfill their respective obligations to the Government on a noninterference basis. Work hours for the vessel will be discussed at the Arrival Conference. Any work performed outside of those hours will be allowed at the sole discretion of the Contracting Officer.

The Contractor shall make reasonable arrangements with the Government or Contractors of the Government, as shall have been identified and authorized by the Contracting Officer, to be given admission to the Contractor's facilities and access to the vessel(s) and to office space, work areas, storage or shop areas, or other facilities and services, necessary for the performance of their respective responsibilities and reasonable to their performance. All such above personnel shall be required to comply with all Contractor rules and regulations governing personnel at its shipyard, including those relative to safety and security.

(b) The Contractor further agrees, as authorized by the Contracting Officer, to afford to a reasonable number of officers, employees, and associates of bidders on other contemplated work, the same privileges of admission to the Contractor's plant and access to the vessel(s) on a noninterference basis subject to all Contractor rules and regulations governing personnel in its shipyard, including those relative to safety and security.

INDEMNIFICATION FOR ACCESS TO VESSELS

Notwithstanding any provision in the "Access to Vessels" clause, or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other prime Contractors with the Government and their subcontractors, and officers, employees, and associates of offeror on other contemplated work, admission to the Contractor's facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price.

INSPECTIONS

Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements. Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract.

The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation.

GROWTH WORK

(a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre- priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair.

(b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an SFLC 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal.

(c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor and shall be included in the Composite Labor Rate. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC.

Provide your G&A:______& Profit:________Percentage for Growth Work

DISCOVERIES AND CHANGES TO CONTRACT:

Change requests can be transmitted electronically by using email. The bullets below display the process of how work requests are to be followed during the availability:

Change Request Process will occur in the following order:

1. Condition Found Report (CFR)-Generated by the Contractor and provided to COR

2. Condition Found Report Reply(CFRR)-Generated by the COR and provided to Contractor

3. Change Request- CR and IGE are generated by the COR and forwarded to KO

4. COR provides copy of Change Request to the Contractor

5. Contractor’s Proposal- Provided to the KO for the identified tasking on WR

6. Negotiations- If needed, take place to establish pricing

7. Approved Work Request- Forwarded to Contractor and COR by the KO

8. Modification to Contract- The KS/KO will issue a modification covering all CR’s

In order to determine price reasonableness: All change requests that list sub-contracting and/or material must have a written proposal from the sub-contractor or the company providing the material with complete, detailed information (listing number of hours/price per hour; each part/component & associated cost; and an estimated shipping cost).

Condition Found Report, Change Orders will be transmitted electronically by using email. The below display the process of how these documents are to be followed for the duration of the contract performance period:

(a) Condition Found Report (CFR) - All readings and inspections are to be taken within 24 hours after the machinery or system is opened. All reports of reading and inspections required by the specifications shall be submitted to the COR in writing using a "Condition Found Report (CFR)" form, within 24 hours after the readings and/or inspections are made.

Promptness in taking and reporting readings is particularly important for underbody work items such as shaft bearing or rudder bearing clearances. Often during the progress of a work item, conditions are discovered by the contractor which is considered abnormal for reasons of safety, expected reliability, health, or habitability. These conditions must be brought to the attention of the Coast Guard using a CFR. Details provided by the Contractor in a CFR are important because the CFR may result in a contract change. To speed the contract change progress, the Contractor should include in his/her CFR the following details as a minimum:

(i) A sequential number.

(ii) The contract item which the "CFR" relates to.

(iii) A clear statement, definition, and description of the condition found, including but not limited to frame numbers, part numbers, materials and dimensions as appropriate.

(iv) A proposed or recommended repair to correct the defective condition.

(v) Indicate whether the report requires Cost Guard action, or if it is provided "for info" only. If action is required, indicate the response time required by the Coast Guard and whether or not a contract extension would be needed if the additional work is authorized.

(vi) A space on the form for the Coast Guard to make comments.

(vii) All CFR's will be dated, submitted, and signed by a representative of the Contractor. Contracting Officer’s Representative (COR) will respond to the Contractor’s within 24 hours of receiving a Condition Found Report. A copy of ALL condition found reports shall be retained in the Cutter’s file.

Change Requests must be submitted by the COR to the contractor within 24 hours after responding to the CFR. Contractor must submit proposal to the Contracting Officer within 72 hours receipt of the Change Request.

A modification will be issued to incorporate and implement all approved changes.

COMPOSITE LABOR RATE:

The composite labor rate offered shall be the sole labor hour rate used to price the Prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the Prime Contractor's direct labor associated with such changes under this contract.

(a) The composite labor hour rate shall represent total compensation for the following:

(1) direct labor wages and salaries;

(2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits;

(3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment;

(4) all indirect costs such as overhead and general and administrative expense;

(5) any port or association fees, rents, or other levies;

(6) profit (fee);

(7) all direct and indirect costs and profit associated with the following support functions:

(8) all consumables;

(b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated.

(c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services, is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government’s best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised.

MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE OF A SHIP REPAIR CONTRACT

1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed.

2. The items listed in the specification, as government furnished property will be provided in the quantities designated. Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc. The Contractor shall sign for all government furnished property using either a DD Form 1149, entitled, “Requisition and Invoice/Shipping Document” or a DD Form 1348, entitled, “Issue Release/Receipt Document”. A copy of the DD 1149 or DD 1348 must be sent within 48 hours of receipt of property, to the designated Government Property Administrator. The name of the individual assigned as Property Administrator will be furnished to the Contractor at time of award. The Contractor shall not take receipt of property that is not listed in the specification, has not been previously identified as becoming part of the contract (via contract modification) or which otherwise cannot be identified. Such irregularities shall be immediately reported to the Property Administrator.

3. The Contractor shall complete the report provided herein, entitled, “Government Property Report”. This report is intended as a living document whereby relevant fields shall be filled in, maintained and kept current at all times. All property described in paragraph 1 (a and b) above shall be reported on the report. At contract completion the Contractor and the Property Administrator shall ensure that all fields are appropriately completed. A signature block is provided at the end of the report for both parties to attest to the report's accuracy and completeness. The Government Property Report shall clearly delineate the complete track that all Government property took over the course of the contract. This completed report must accompany the Contractor's final invoice. Final payment may be delayed, without penalty of interest, until such time as the report is received. A separate copy of the completed report and any final DD 1149s or DD 1348s executed, as a result of carrying out disposition instructions shall be provided to the Property Administrator.

4. Pursuant to the Government Property Clause the authority to render disposition instructions of Government property associated with this contract is delegated to the Property Administrator. The Contractor shall comply with all instructions in the contract for the return of government property to the Coast Guard. This includes government property taken off the vessel (shafts, propellers, etc.), government property returned to the vessel (special tools, etc.) or surplus government property not used during performance of the contract.

CONTRACTING OFFICER’S AUTHORITY

No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof.

CONTRACTING OFFICER’S REPRESENTATIVE (COR):

The COR is a Government employee designated in writing by the Contracting Officer to act as a technical advisor for the Contracting Officer for services/items within the scope of the contract. The COR performs functions such as review and/or inspection and acceptance of supplies and services and of a technical nature. A designation letter will set forth the name of the COR and the authorities and limitations of the COR under the contract. This person does not have a warrant that provides the authority to contractually commit the Government or to modify any terms and conditions of a contract.

COR: Abram P Fernandez Telephone # (727) 502-1569 E-Mail: Abram.P.Fernandez@uscg.mi

CONTRACTOR PERFORMANCE EVALUATION

(a) GENERAL: The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror’s past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award.

(b) NOTIFICATION: Upon completion of the contract, the Contractor will be notified of the assessment. The Contractor will be allowed 30 days to respond to the SLFC’s assessment of its performance entered into CPARS. The Contractor’s response, if any, will be made part of the CPAR system at https://www.cpars.gov/index.htm.

(c) INFORMATION: Information included in the CPAR may include, but is not limited to, the Contractor’s record of conforming to contract requirements and to standards of good workmanship; the Contractor’s record of forecasting and controlling costs; the Contractor’s adherence to contract schedules, including the administrative aspects of performance; the Contractor’s history of reasonable and cooperative behavior and commitment to customer satisfaction; the Contractor’s record of integrity and business ethics, and generally, the Contractor’s business-like concern for the interest of the customer.

(d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the Contractor.

CONTRACT DEFICIENCY REPORT

The Contracting Officer or Contracting Officer’s Representative (COR) may issue a Contract Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COR. The COR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COR in writing.

(End of Clause)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (JAN 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] _X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

__ (4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

_X_ (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (6) [Reserved].

_X_ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

_X_ (9) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

__ (10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (Dec 2023) ( Pub. L. 115–390, title II).

__ (11)

(i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

_X_ (ii) Alternate I (Dec 2023) of 52.204-30.

__ (12) 52.209-6, Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Jan 2025) ( 31 U.S.C. 6101 note).

_X_ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) ( 41 U.S.C. 2313).

__ (14) [Reserved].

X (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) ( 15 U.S.C. 657a).

__ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (17) [Reserved] __ (18) _ (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-6.

__ (19)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-7.

_X_ (20) 52.219-8, Utilization of Small Business Concerns (Jan 2025)( 15 U.S.C. 637(d)(2) and (3)).

__ (21)

(i) 52.219-9, Small Business Subcontracting Plan (Jan 2025) ( 15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Jun 2020) of 52.219-9.

__ (v) Alternate IV (Jan 2025) of 52.219-9.

__ (22)

(i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

__ (ii) Alternate I (Mar 2020) of 52.219-13.

_X_ (23) 52.219-14, Limitations on Subcontracting (Oct 2022) (15 U.S.C. 657s).

__ (24) 52.219-16, Liquidated Damages—Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)).

__ (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (Feb 2024) (15 U.S.C. 657f).

__ (26) __X_(i) 52.219-28, Postaward Small Business Program Rerepresentation (Jan 2025) (15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (Mar 2020) of 52.219-28.

__ (27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

__ (28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C. 637(m)).

__ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) ( 15 U.S.C. 644(r)).

__ (30) 52.219-33, Nonmanufacturer Rule (Sep 2021) ( 15 U.S.C. 637(a)(17)).

_X_ (31) 52.222-3, Convict Labor (Jun 2003) (E.O. 11755).

_X_ (32) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2025)( E.O. 13126).

_X_ (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

__ (34) _X(i) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

__ (ii) Alternate I (Feb 1999) of 52.222-26.

__ (35) _X (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) ( 38 U.S.C. 4212).

__ (ii) Alternate I (Jul 2014) of 52.222-35.

_X (36) _X (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) ( 29 U.S.C. 793).

__ (ii) Alternate I (Jul 2014) of 52.222-36.

_X_ (37) 52.222-37, Employment Reports on Veterans (Jun 2020) ( 38 U.S.C. 4212).

_X_ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

__ (39) _X_(i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (40) 52.222-54, Employment Eligibility Verification (Jan 2025) ( Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__ (41)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

_X_ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) ( 42 U.S.C. 7671, et seq.).

_X_ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (44) 52.223-20, Aerosols (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (45) 52.223-21, Foams (May 2024) ( 42 U.S.C. 7671, et seq.).

__ (46) 52.223-23, Sustainable Products and Services (May 2024) ( E.O. 14057, 7 U.S.C. 8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

__ (47)

(i) 52.224-3 Privacy Training (Jan 2017) ( 5 U.S.C. 552 a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

__ (48)

(i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83).

__ (ii) Alternate I (Oct 2022) of 52.225-1.

__ (49)

(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (Jan 2025) of 52.225-3.

__ (iv) Alternate III (Feb 2024) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (50) 52.225-5, Trade Agreements (NOV 2023) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X_ (51) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

__ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

__ (55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) ( E.O. 13513).

__ (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

__ (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

__ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

_X_ (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct2018) ( 31 U.S.C. 3332).

__ (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (61) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (62) 52.239-1, Privacy or Security Safeguards (Aug 1996) ( 5 U.S.C. 552a).

__ (63) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities (Nov 2024) (Sections 1821-1826, Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

__ (64) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

__ (65)

(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) ( 46 U.S.C. 55305 and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

__ (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.] __ (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter67).

__ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

__ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

__ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

__ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C. 1792).

__ (10) 52.247-69, Reporting Requirement for U.S.-Flag Air Carriers Regarding Training to Prevent Human Trafficking (Jan 2025) ( 49 U.S.C. 40118(g)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii)

(A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

(B) Alternate I (Dec 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (Jan 2025) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(x) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(xi) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xv) 52.222-41, Service Contract Labor Standards (Aug 2018) ( 41 U.S.C. chapter 67).

(xvi)