ISO206-24.pdf

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NO.

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

RFQ IFB RFP

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

29. AWARD OF CONTRACT: REF. OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NAICS:

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

Coll. No.

8 (A)

EDWOSB

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

ISO206-24

Kimberly Schwinn 202-305-3730

COCO 100

COCO

321000101

Misc 400 First Street NW Washington DC 20534

UNICOR FPI CENTRAL ACCOUNTS PAYABLE

PO BOX 11849

LEXINGTON, KY 40578-1849

1620000187 See Section B

UNICOR FUNDS 15X4500 FUNDS SHALL BE OBLIGATED BY INDIVIDUAL DELIVERY ORDERS AND NOT BY THE CONTRACT ITSELF

Kimberly Schwinn

X

333415

02/02/2024

03/04/2024

2:00 PM

COCO

UNICOR, FPI CENTRAL OFFICE

400 1ST ST NW

WASHINGTON DC 20534-0004

UNICOR, FPI CENTRAL OFFICE

400 1ST ST NW

WASHINGTON DC 20534-0004

02/02/2024

UNICOR, FPI CENTRAL OFFICE

400 1ST ST NW

WASHINGTON DC 20534-0004

02/02/2024

1250 Emp

TERMS OF DELIVERY ARE F.O.B. DESTINATION TO:

AFRL – Bldg. 13 101W. Eglin Blvd Eglin AFB, Fl 32542

Solicitation is issued as a firm fixed price delivery-definite quantity type contract.

SOLICITATION IS 100% SET-ASIDE FOR SMALL BUSINESS.

QUESTIONS PERTAINING TO THIS SOLICITATION WILL ONLY BE ADDRESSED

IN WRITING VIA EMAIL TO: Kimberly.Schwinn2@usdoj.gov

QUESTIONS WILL ONLY BE ACCEPTED IN WRITING AND WILL NOT BE

ACCEPTED AFTER FRIDAY, FEBRUARY 09, 2023 at 10:00 AM EST.

QUESTIONS AND RESPONSES WILL BE POSTED VIA AMENDMENT www.sam.gov

NO PHONE CALLS PLEASE.

For a list, description and total estimated quantities of all items, refer to Section B.

UNICOR’s desired delivery is 180 calendar days or sooner from receipt of each delivery order issued.

Vendors shall submit signed and dated offers by email to Kimberly Schwinn, Kimberly.Schwinn2@usdoj.gov

Offers shall be submitted on the SF1449. OMB Clearance 1103- 0018.

The date and time for receipt of proposals is Monday, March 04, 2024 at 2:00 PM EST. Offer must indicate Solicitation No.

ISO206-24, time specified for receipt of offer, name, address and telephone number of offeror, technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation, terms of any expressed warranty, price and any discount terms. Offer must include acknowledgment of all amendments, if any.

THE FOLLOWING INFORMATION IS REQUIRED TO BE COMPLETED BY THE

OFFEROR:

SAM UNIQUE ENTITY NUMBER:_______________________________________

DJU1620000187 Page 2 of 35

VENDOR'S POINT OF CONTACT: _____________________________________

VENDOR'S TELEPHONE & FAX NUMBER: _____________________________

VENDOR'S EMAIL ADDRESS: ________________________________________

VENDOR'S BUSINESS SIZE (i.e. SMALL, LARGE, ETC.):

By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.

_______________________________________________ Signature

The Administrative Contracting officer is Kimberly Schwinn at Kimberly.Schwinn2@usdoj.gov

DJU1620000187 Page 3 of 35

SECTION B

SUPPLIES OR SERVICES AND PRICES/COSTS

Item No. SUPPLIES OR SERVICE Quantity U/M UNIT PRICE AMOUNT IN US$ Delivery Date

00001 ICSG-0001 2 EA 09/03/2024

20-Ton TRANE PRECEDENT AIR CONDITIONER ON A MOBILE TRAILER - 2 EACH

Contractor shall provide a trailer mounted TRANE Precedent 20-Ton mobile

Air Conditioner with the following attributes. (See attached drawing)

20-Ton Precedent Air Conditioner

20 Ton DX Cooling

Standard Efficiency<(>,<)>

R410A or R454B Refrigerant

Symbio 700

Manual Outside Air Damper

Standards Panels with 2inch MERV 8 Filter

Condenser CompleteCoat TM

Horizontal Conversion Panel (Field Installed)

Trailer to support Air Conditioner/Transformer/Accessories – Contractor shall provide a trailer and install the air conditioner, transformer, and accessories. (See attached drawing)

Trailer capable of holding the above-mentioned equipment.

Pintle hook tongue connection

Trailer Leveling Jacks

Mounted storage box for 100’ of 24” flex ducting, and 100” of 4

DJU1620000187 Page 4 of 35 conductor power cable

208/460 Volt 150 Kva transformer mounted to trailer

200 Amp Manual transfer switch

600 Amp 208 3phase disconnect with 450 Amp fuses

150 Amp circuit breaker with NEMA 3R enclosure

Grounding system for trailer

Portable system components will be provided with a 1-year parts only warranty

Contractor shall provide all specifications for the AC unit and trailer with their proposals.

00002 ICSG-0001 2 EA 09/03/2024

CATERPILLAR (OR EQUILAVENT) 35 KVA MOBILE GENERATOR- 2 EACH

Caterpillar 35 Kva mobile generator (OR EQUILAVENT)

27 eKW (35 kVa) rating prime

60 Hz frequency

120-600 V voltage

Diesel fuel operated and tank to last for approximately 24 hours

63 dB(A) noise rating (with enclosure)

Contractor shall provide all specifications for the mobile generator with their proposals.

00003 ICSG-0001 1 EA 09/03/2024

BID OPTION -WARRANTIES

Provide detailed bid options plans for extended warranties.

DJU1620000187 Page 5 of 35

5 Year Parts and Labor Warranty/5-year service agreement

Contractor shall provide warranty package options for an extended parts and labor for the generator and air conditioner.

5-year parts and warranty on the air conditioner and generator set

5-year service agreement to provide annual maintenance on the air conditioner and generator set.

DJU1620000187 Page 6 of 35

SUMMARY OF WORK

Project Title: Mobile Air Conditioning & Generator Units

1. PURPOSE OF SECTION: The purpose of this section is to provide the Contractor with a Statement of Objectives (SOO) for the above-mentioned project.

2. PROJECT SCOPE: The project is located at Eglin AFB (Main Base), Florida. The Contractor shall be required to furnish all materials, equipment, plant, labor, and personnel necessary to provide and deliver equipment required in this contract in accordance with the contract requirements.

The Contractor shall deliver, to building 13 on Eglin AFB Florida, the following mobile air Conditioning units & generator systems.

All Deliveries will be done during the AFRL/RWOI established work hours, from 0700-1500 Mon- Fri.

20-Ton Mobile TRANE Air Conditioning units (2 ea.)

35 Kva Mobile Caterpillar Deisel Generator (2 ea.)

3. EXISTING CONDITIONS: N/A

4. SPECIAL INSTRUCTIONS: N/A

5. PRINCIPAL FEATURES: Principal features of work are as follows for 2 complete mobile Air Conditioning units:

CLIN 01 -20-Ton TRANE AC MOBILE TRAILER - 2 EACH

20-Ton TRANE Precedent Air Conditioner on a mobile trailer– Contractor shall provide a trailer mounted TRANE Precedent 20- Ton mobile Air Conditioner with the following attributes. (See attached drawing)

20-Ton Precedent Air Conditioner 20 Ton DX Cooling Standard Efficiency, R410A or R454B Refrigerant Symbio 700 Manual Outside Air Damper Standards Panels with 2inch MERV 8 Filter Condenser CompleteCoat TM

DJU1620000187 Page 7 of 35

Horizontal Conversion Panel (Field Installed)

Trailer to support Air Conditioner/Transformer/Accessories – Contractor shall provide a trailer and install the air conditioner, transformer, and accessories. (See attached drawing)

Trailer capable of holding the above-mentioned equipment.

Pintle hook tongue connection Trailer Leveling Jacks Mounted storage box for 100’ of 24” flex ducting, and 100” of 4 conductor power cable 208/460 Volt 150 Kva transformer mounted to trailer 200 Amp Manual transfer switch 600 Amp 208 3phase disconnect with 450 Amp fuses 150 Amp circuit breaker with NEMA 3R enclosure Grounding system for trailer Portable system components will be provided with a 1-year parts only warranty

Contractor shall provide all specifications for the AC unit and trailer with their proposals.

CLIN 02 - CATERPILLAR 35 KVA MOBILE GENERATOR (or equivalent)

XQ35 Tier 4 Final – Contractor shall provide a 35 KVA mobile generator set sized to operate a 20-Ton air conditioner.

Caterpillar 35 Kva mobile generator (or equivalent) 27 eKW (35 kVa) rating prime 60 Hz frequency 120-600 V voltage Diesel fuel operated and tank to last for approximately 24 hours 63 dB(A) noise rating (with enclosure)

Contractor shall provide all specifications for the mobile generator with their proposals.

6. RECOMMENDED PERFORMANCE PERIOD: 180 calendar days or best delivery. Provide schedule.

DJU1620000187 Page 8 of 35

DJU1620000187 Page 9 of 35

DJU1620000187 Page 10 of 35

DJU1620000187 Page 11 of 35

DJU1620000187 Page 12 of 35

PART I: INFORMATION

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation;

offers are being requested and a written solicitation will not be issued. The solicitation number is ISO206-24 and this solicitation is issued as a Request For Proposals (RFP). The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2024-

02. The North American Industry Classification System code is 333415 - Air-Conditioning and Warm Air Heating Equipment and Commercial and Industrial Refrigeration Equipment Manufacturing.

This requirement is 100% set-aside for small business; small business size standard for this solicitation is 1,250 employees.

UNICOR, Federal Prison Industries, Inc., intends to enter into a firm-fixed-price, definite delivery-definite quantity contract for the following commercial item(s):

SEE SECTION B FOR LIST OF ITEMS/0001-0003

ALL ITEMS WILL BE AWARDED TO ONE OFFEROR. FAILURE TO SUBMIT AN

OFFER ON ALL ITEMS MAY PREVENT AN OFFER FROM BEING CONSIDERED

FOR AWARD.

NOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:

In the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Administrative Contracting Officers at UNICOR in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.

Contractor agrees that FPI is in the category of the most favored or best commercial customer category of the Contractor and as such, the Contractor will:

During the contract period, the Contractor shall report to the Contracting Officer all price reductions offered to the category of customers that are considered by the Contractor to be their most favored or best commercial customer.

DJU1620000187 Page 13 of 35

1. A price reduction shall apply to purchases under this contract if, after the award date, the Contractor-

i) Revises downward its commercial catalog, price list, schedule, etc., to its best commercial customers (or category of customers) below the awarded price under this contract;

ii) Grants more favorable discounts or terms and conditions to its best commercial customers than those contained in this contract that would result in prices below the awarded price under this contract, an/or

iii) Grants special discounts to its best commercial customer (or category of customers) that would result in prices lower than the awarded price under this contract.

2. The Contractor shall offer the price reduction to FPI with the same effective date, and for the same time period, as extended to the commercial customer (or category of customers).

The Contractor may offer the Contracting Officer a voluntary price reduction at any time during the contract period.

The Contractor shall notify the Contracting Officer of any price reduction subject to this clause as soon as possible, but not later than 15 calendar days after its effective date.

Packaging shall comply with the specifications of ASTM D-3951- 95, standard practice for commercial packages

INVOICES ARE TO BE EMAILED TO:

Chuck Retherford, Civ, USAF charles.retherford.1@us.af.mil

Yvette Hairston-Mercer yvette.hairston-mercer@usdoj.gov

PART II: FAR CLAUSES

52.204-4, Printed or Copied Double-Sided on Recycled Paper, MAY 2011)

52.212-4, Contract Terms and Conditions - Commercial Items (DEC 2022).

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Products and Commercial Services (Dec 2023)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in

DJU1620000187 Page 14 of 35 this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) ( 31 U.S.C.

3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.]

_X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (June 2020), with Alternate I (JUN 2020) (41 U.S.C.

4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct

(NOV 2021) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American

DJU1620000187 Page 15 of 35

Recovery and Reinvestment Act of 2009 (NOV 2023) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

_X_ (4) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

_X_ (5) 52.204-10, Reporting Executive Compensation and First- Tier Subcontract Awards (JUN 2020) (Pub. L. 109-282) (31 U.S.C.

6101 note).

__ (6) [Reserved].

__ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (9) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

___(10) 52.204–28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (DEC 2023) ( Pub. L. 115– 390, title II).

__ (11) (i) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (DEC 2023) ( Pub. L. 115–390, title II).

__ (ii) Alternate I (Dec 2023) of 52.204–30.

_X_ (12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (NOV 2021) (31 U.S.C. 6101note).

_X_ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

__ (14) [Reserved].

__ (15) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) (15 U.S.C.657a).

__ (16) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2022) (if the offeror

DJU1620000187 Page 16 of 35 elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (17) [Reserved]

_X_ (18) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C.644).

__ (ii) Alternate I (Mar 2020) (52.219-6)

__ (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-7.

__ (20) 52.219-8, Utilization of Small Business Concerns (Sep 2023) (15 U.S.C. 637(d)(2) and (3)).

__ (21) (i) 52.219-9, Small Business Subcontracting Plan (Sep 2023) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Jun 2020) of 52.219-9.

__ (v) Alternate IV (SEP 2023) of 52.219-9.

__ (22) (i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

(ii) Alternate I (Mar 2020) of 52.219-13.

_X_ (23) 52.219-14, Limitations on Subcontracting (OCT 2022) (15 U.S.C.637(a)(14)).

__ (24) 52.219-16, Liquidated Damages-Subcontracting Plan (SEPT 2021) (15 U.S.C. 637(d)(4)(F)(i)).

__ (25) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (OCT 2022) (15 U.S.C. 657f).

_X_ (26) (i) 52.219-28, Post Award Small Business Program Representation (SEP 2023) (15 U.S.C. 632(a)(2)).

(ii) Alternate I (MAR 2020) of 52.219-28.

__ (27) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (OCT 2022) (15 U.S.C. 637(m)).

__ (28) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) (15 U.S.C.

637(m)).

DJU1620000187 Page 17 of 35

__ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C. 644(r)).

_X_ (30) 52.219-33, Nonmanufacturer Rule (SEP 2021) (15 U.S.C.

637(a)(17)).

_X_ (31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

_X_ (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (NOV 2023) (E.O.13126).

_X_ (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X_ (34) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

__ (ii) Alternate I (Feb 1999) of 52.222-26.

_X_ (35) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

__ (ii) Alternate I (Jul 2014) of 52.222-35.

_X_ (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C.793).

__ (ii) Alternate I (Jul 2014) of 52.222-36.

_X_ (37) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

_X_ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

X_(39) (i) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter78 and E.O. 13627).

__ (40) 52.222-54, Employment Eligibility Verification (MAY 2022). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

X__ (41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C.

6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

DJU1620000187 Page 18 of 35

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C.

6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

_X_ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

_X_ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O.

13693).

__ (44) (i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (45) (i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

X__ (46) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b).

__ (47) (i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

_X (48) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Jun 2020) (E.O. 13513).

_X_ (49) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

__ (50) 52.223-21, Foams (Jun 2016) (E.O. 13693).

__ (51) (i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

__ (52) 52.225-1, Buy American-Supplies (OCT 2022) (41 U.S.C.

chapter 83).

__ (ii) Alternate I (Oct 2022) of 52.225-1.

__(53) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108- 286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

DJU1620000187 Page 19 of 35

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (Dec 2022) of 52.225-3.

__ (iv) Alternate III (NOV 2023) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (54) 52.225-5, Trade Agreements (NOV 2023) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X (55) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (56) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

__ (57) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (58) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

__ (59) 52.229-12, Tax on Certain Foreign Procurements (FEB 2021).

__ (60) 52.232-29, Terms for Financing of Purchases of Commercial Items (NOV 2021) (41 U.S.C.4505, 10 U.S.C.2307(f)).

___ (61) 52.232-30, Installment Payments for Commercial Items (NOV 2021) (41 U.S.C.4505, 10 U.S.C.2307(f)).

_X_ (62) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2018) (31 U.S.C. 3332).

__ (63) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C.3332).

_X_ (64) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C.3332).

__ (65) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (66) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

DJU1620000187 Page 20 of 35

__ (67) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

__ (iii) Alternate II (NOV 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

__ (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

__ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

__ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services- Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-55, Minimum Wages Under Executive Order 13658 (JAN 2022).

__ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph

(d) if this contract was awarded using other than sealed bid, is

DJU1620000187 Page 21 of 35 in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items.

Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct

(NOV 2021) ( 41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (NOV 2023) ( 41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by KasperskyLab Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain

DJU1620000187 Page 22 of 35

Telecommunications and Video Surveillance Services or Equipment.

(NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (JUN 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii)

(A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (DEC 2023) ( Pub. L. 115–390, title II).

(B) Alternate I (DEC 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (SEP 2023) ( 15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(x) 52.222-26, Equal Opportunity (SEP 2015) (E.O.11246).

(xi) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities

(JUN 2020) ( 29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222- 40.

(xv) 52.222-41, Service Contract Labor Standards (AUG 2018) ( 41 U.S.C. chapter 67).

(xvi)

(A) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O 13627).

(B) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) ( 41 U.S.C. chapter 67).

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services- Requirements (MAY 2014) ( 41 U.S.C. chapter 67).

(xix) 52.222-54, Employment Eligibility Verification (MAY 2022) (E.O. 12989).

(xx) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (JAN 2022).

(xxi) 52.222-62, Paid Sick Leave Under Executive Order 13706

(JAN 2022) (E.O. 13706).

DJU1620000187 Page 23 of 35

(xxii)

(A) 52.224-3, Privacy Training (Jan 2017) ( 5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) ( 42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph

(c) of 52.232-40.

(xxvi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) ( 46 U.S.C. 55305 and 10 U.S.C.

2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

52.216-20, Definite Quantity (OCT 1995) – applies until seventy-five (75) calendar days after contract validity end date.

52.229-3 Federal, State, and Local Taxes. (Feb 2013)

52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004);

52.246-15, Certificate of Conformance (APR 1984) With the original invoice, the vendor will furnish the original Certificate of Conformance that will be signed by the person who has certification authority with their title and position included. A copy of this Certificate of Conformance and the packing slip will accompany each shipment. The furnishing of the Certificate of Conformance will be a condition of acceptance at destination and payment will not be made until it is received. Inspection and acceptance will be by FPI.

Awardee must maintain documented evidence that demonstrates the traceability of the materials that the Awardee provides for this contract/purchase order. The Awardee's Certificate of Conformance shall only be signed by the individual who is the Awardee's authorized Quality Representative, or acting Quality

DJU1620000187 Page 24 of 35

Representative.

52.247-34, F.O.B. Destination (Nov 1991). delivery shall be FOB destination to AFRL – Bldg. 13 101 W. Eglin Blvd Eglin AFB, Fl 32542

52.252-2, Clauses Incorporated By Reference (Feb 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

___________www.acquisition.gov__________________

JAR 2852.201-70 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (JAN

1985)

(a) Mark Lynch, 850-882-4620, is hereby designated to act as Contracting Officer's Representative (COR) under this contract.

(b) The COR is responsible, as applicable, for: receiving all deliverables, inspecting and accepting the supplies or services provided hereunder in accordance with the terms and conditions of this contract; providing direction to the contractor which clarifies the contract effort fills in details or otherwise serves to accomplish the contractual Scope of Work; evaluating performance; and certifying all invoices/vouchers for acceptance of the supplies or services furnished for payments.

(c) The COR does not have the authority to alter the contractor's obligations under the contract, and/or modify any of the expressed terms, conditions, specifications, or cost of the agreement. If as a result of technical discussions, it is desirable to alter/change contractual obligations or the Scope of Work, the Contracting Officer shall issue such changes in writing and signed.

2852.233-70 PROTESTS FILED DIRECTLY WITH THE DEPARTMENT OF

JUSTICE

(JAN 1998)

(a) The following definitions apply in this provision:

(1) "Agency Protest Official" means the official, other than the contracting officer, designated to review and decide procurement protests filed with a contracting activity of the Department of Justice.

(2) "Deciding Official" means the person chosen by the protestor to decide the agency protest; it may be either the Contracting

DJU1620000187 Page 25 of 35

Officer or the Agency Protest Official.

(3) "Interested Party" means an actual or prospective offeror whose direct economic interest would be affected by the award of a contract or by the failure to award a contract.

(b) A protest filed directly with the Department of Justice must:

(1) Indicate that it is a protest to the agency.

(2) Be filed with the Contracting Officer.

(3) State whether the protestor chooses to have the Contracting Officer or the Agency Protest Official decide the protest. If the protestor is silent on this matter, the Contracting Officer will decide the protest.

(4) Indicate whether the protestor prefers to make an oral or written presentation of arguments in support of the protest to the deciding official.

(5) Include the information required by FAR 33.103(d)(2):

(i) Name, address, facsimile number and telephone number of the protestor.

(ii) Solicitation or contract number.

(iii) Detailed statement of the legal and factual grounds for the protest, to include a description of resulting prejudice to the protestor.

(iv) Copies of relevant documents.

(v) Request for a ruling by the agency.

(vi) Statement as to the form of relief requested.

(vii) All information establishing that the protestor is an interested party for the purpose of filing a protest.

(viii) All information establishing the timeliness of the protest.

(c) An interested party filing a protest with the Department of Justice has the choice of requesting either that the Contracting Officer or the Agency Protest Official decide the protest.

(d) The decision by the Agency Protest Official is an alternative to a decision by the Contracting Officer. The Agency Protest Official will not consider appeals from the Contracting Officer's decision on an agency protest.

(e) The deciding official must conduct a scheduling conference with the protestor within five (5) days after the protest is filed. The scheduling conference will establish deadlines for oral or written arguments in support of the agency protest and for agency officials to present information in response to the protest issues. The deciding official may hear oral arguments in support of the agency protest at the same time as the scheduling conference, depending on availability of the necessary parties.

(f) Oral conferences may take place either by telephone or in person. Other parties may attend at the discretion of the deciding official.

DJU1620000187 Page 26 of 35

(g) The protestor has only one opportunity to support or explain the substance of its protest. Department of Justice procedures do not provide for any discovery. The deciding official may request additional information from either the agency or the protestor. The deciding official will resolve the protest through informal presentations or meetings to the maximum extent practicable.

(h) An interested party may represent itself or be represented by legal counsel. The Department of Justice will not reimburse the protester for any legal fees related to the agency protest.

(i) The Department of Justice will stay award or suspend contract performance in accordance with FAR 33.103(f). The stay or suspension, unless over-ridden, remains in effect until the protest is decided, dismissed, or withdrawn.

(j) The deciding official will make a best effort to issue a decision on the protest within twenty (20) days after the filing date. The decision may be oral or written.

(k) The Department of Justice may dismiss or stay proceeding on an agency protest if a protest on the same or similar basis is filed with a protest forum outside the Department of Justice.

PART III: PROVISIONS

52.204-7, System for Award Management (Oct 2018) 52.204-24, Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021) The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Products or Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision— Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential

DJU1620000187 Page 27 of 35 component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

DJU1620000187 Page 28 of 35

(d) Representation. The Offeror represents that—

(1) It □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that— It □ does, □ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

DJU1620000187 Page 29 of 35

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-26, Covered Telecommunications Equipment or Services- Representation (OCT 2020)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c)

(1) Representation. The Offeror represents that it □ does, □ does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

DJU1620000187 Page 30 of 35

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it □ does, □ does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.211-6, Brand Name or Equal (AUG 1999).

52.212-1, Instructions to Offerors – Commercial Products and Commercial Services (SEPT 2023).

52.212-2, Evaluation - Commercial Items (OCT 2014), significant evaluation factors are Technical Factors (GO/NO GO Factor- Brand Name Trane for 20-Ton TRANE AC, specifications for all additional equipment) Schedule, Past Performance, and Price.

Technical Factors, Schedule, and Past performance are significantly more important than price. Quality, delivery, and customer service will be evaluated under past performance. The Government may make award without discussions; therefore, the offeror’s initial offer should contain their best pricing.

Award will be based on the best value to the Government considering the evaluation factors listed above. Best value may be determined using trade-offs among the evaluation factors, so that award may be made to other than the lowest-priced or highest…