Solicitation.pdf

SOLICITATION,OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IFBP02070900001

X SEALED BID (IFB)

NEGOTIATED (RFP)

2. TYPE OF SOLICITATION 3. DATE ISSUED

10/19/2009

OMB Clearance Control Number : 1103-0018

IMPORTANT -The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

2NT

CODE ALX

Federal Bureau of Prisons Field Acquisition Office - USA Section ROUTE 15 - 2 Miles North of Allenwood Allenwood, PA 17810

7. ISSUED BY

Federal Bureau of Prisons Field Acquisition Office - USA Section

ROUTE 15

2 MILES NORTH OF ALLENWOOD

Allenwood, PA 17810

8. ADDRESS OFFER TO

9. FOR INFORMATION CALL: a. NAME

Robert J. Kruskie

b. TELEPHONE NO. (Include area code)(NO COLLECT CALLS)

(570) 547-1990 x4485

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

The selected contractor shall provide all materials, labor, and equipment to construct a walk-in freezer at USP Lewisburg, PA. PLEASE

COMPLETE THE FOLLOWING ITEMS: DUNS NUMBER_______________

TAX IDENTIFICATION NUMBER______________

11. The Contractor shall begin performance calendar days and complete it within calendar days after receiving10 90 award, X notice to proceed. This performance period is X mandatory negotiable. (See __________________________.)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS? (If "YES," indicate within how many calendar days after award in Item 12b).

X YES NO

12b. CALENDAR DAYS

Sealed offers in original and copies to perform the work required are due at the place specified in item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

1 14:00a.

11/19/2009

b. An offer guarantee X is, is not required.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or byc.

60d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

13. ADDITIONAL SOLICITATION REQUIREMENTS

NSN 7540-01-155-3212 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

IFBP02070900001 Page 1 of 31

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ___________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

17.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified) 27

ITEM

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE LEW

Federal Bureau of Prisons USP Lewisburg

PO BOX 1000

Lewisburg, PA 17837

Federal Bureau of Prisons USP Lewisburg

PO BOX 1000

Lewisburg, PA 17837

27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return __________ copies to issuing office) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No futher contractual document is necessary.

30a.NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

Robert Kruskie

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 4-85)BACK

IFBP02070900001 Page 2 of 31

Table of Contents

Section Description Page Number

1 Solicitation, Offer and Award 2 Commodity or Services Schedule 3 Special Contract Requirements

FAO-0001 Bonds FAO-0002 Magnitude FAO-0003 Size Standard FAO-0004 Liquidated Damages FAO-0005 Required Insurance FAO-0006 Inspection of Work FAO-0007 Pre-Construction Conference FAO-0008 Material Approval Submittal FAO-0009 Preparation of Progress Schedules and Reports FAO-0010 Work Hours FAO-0011 Contraband FAO-0012 Explosives FAO-0013 Parking and Temporary Office FAO-0014 Safety and Accident Prevention FAO-0015 Inspecting The Site FAO-0016 Payment Services FAO-0017 Request for Final Inspection FAO-0018 Drawings FAO-0019 Contract Security (3000-03 Human Resource Management Manual) FAO-0025 Assignment of Contract Administration Office and Functions

4 Contract Clauses 52.21-603-70 Contract Monitor (CM) (AUG 2008) 52.24-403-70 Notice of Contractor Personnel Security Requirements (OCT 2005)

52.27-103-72 DOJ RESIDENCY REQUIREMENT BUREAU OF PRISONS (JUNE 2004)

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984) 52.211-12 Liquidated Damages--Construction(Sept 2000) 52.222-39 Notification of Employee Rights Concerning Payment of Union Dues or Fees (Dec 2004) 15 52.225-9 Buy American Act--Construction Materials (Feb 2009) 2852.223-70 Unsafe Conditions Due to the Presence of Hazardous Materials (JAR 2852.223-70) (June 1996) FAO-0020 Changes FAO-0021 Changes--Supplement

5 Attachments 6 Solicitation Provisions

52.27-103-71 FAITH-BASED AND COMMUNITY-BASED ORGANIZATIONS (AUG 2005). . . 22

52.216-1 Type of Contract (Apr 1984) 52.222-5 Davis-Bacon Act -- Secondary Site of the Work (July 2005) 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (Feb 1999) 52.225-10 Notice of Buy American Act Requirement--Construction Materials (Feb 2009) 52.233-2 Service of Protest (Sept 2006) 52.236-27 Site Visit (Construction) (Feb 1995) Alternate I (Feb 1995) 52.252-1 Solicitation Provisions Incorporated by Reference (Feb 1998) 2852.233-70 Protests Filed Directly with the Department of Justice (Jan 1998) FAO-0022 Equitable Adjustments: Waiver and Release of Claims

7 Representations and Certifications 52.204-8 Annual Representations and Certifications (Feb 2009) FAO-0023 Contractor's Certification FAO-0024 Business Management Questionnaire

IFBP02070900001 Page 3 of 31

Section 2 - Commodity or Services Schedule

This project will be constructed in accordance with the specification (Attachment 2). There are no drawings located in Attachment 3.

The contractor must furnish the appropriate bid, performance and payment bonds on the forms located in Attachment 4

Item

No.

Supplies/Services Quantity Unit of

Issue

Unit Price Cost Amount

MAINTENANCE/REPAIR/ALTERATION OF PENAL FACILITY :

Walk-in Freezer at USP Lewisburg, PA 1.000000 JB

The successful contractor shall be responsible for all applicable federal, state and local taxes . No tax exemption certificate will be issued by the Federal Bureau of Prisons. RP Number: 0196-9

IFBP02070900001 Page 4 of 31

Section 3 - Special Contract Requirements

FAO-0001 Bonds

(a) Bid Guarantee. Each bidder shall submit with his bid a Bid Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government, or other security as provided in contract provision 52.228-1, in the form of twenty percent (20) of the bid price or not to exceed $3,000,000. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be ex-pressed in dollars and cents. A bid bond is not required for bids of $100,000 or less. (FAR 28.102-1)

(b) Performance and Payment Bonds. Within 10 days after award the contractor shall execute and submit to the Contracting Officer two bonds, each with good and sufficient surety or sureties acceptable to the Government, as follows; a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25A). The penal sums of such bonds will be as follows: (Not required for contracts of $100,000.00 or less)

(1) Performance Bond: The penal sum of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bond: The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

( c ) For construction contracts greater than $30,000 but not greater than $100,000, the Contracting Officer shall select two or more of the following payment protections, giving particular consideration to inclusion of an irrevocable letter of credit as one of the selected alternatives (FAR 28.102-1(b)(1):

(1) A Payment Bond;

(2) An irrevocable letter of credit (ILC);

(3) A tripartite escrow agreement;

(4) A Certificate of Deposit; or

(5) A deposit of the types of security listed in 28.204-1 and 28.204-2.

(d) Individual Sureties.

(1) Bidders may elect to furnish individual surety bonds. If individual surety bonds are furnished for bid bonds, payment or perform-ance bonds, the individual sureties must submit their bonds proof of ownership and value of the assets which they claim in their net worth at time of bid opening. The Government's preferred method of proof is to have a statement of net worth prepared by a Certified Public Accountant (CPA) in accordance with Generally Accepted Accounting Principles (GAAP). Statements from a CPA that con-tain disclaimers are not acceptable. The statement of net worth on the Standard Form 28, Affidavit of Individual Surety, is insufficient and will not be accepted without additional proof of value and ownership.

(2) Bidders are cautioned that individual sureties must provide complete and detailed information in Block 9 of Standard Form 28 con-cerning other contracts on which they have provided bonds. This information shall include contract number, contract location, amount, and type of bond and telephone number of the involved contracting office. Failure to provide the proof and information required may result in rejection of the bid or termination of the contract for failure to provide adequate bonds.

FAO-0002 Magnitude

The magnitude of this project is between $250,000.00 and $500,000.00.

FAO-0003 Size Standard

IFBP02070900001 Page 5 of 31

The small business size standard is $33.5 million average annual receipts for an offeror’s preceeding three fiscal years. The North American Industrial Classification System (NAICS) code for this acquisition is 236220.

FAO-0004 Liquidated Damages

Liquidated damages in the amount of $325.00 shall be assessed for each day of delay (see Clause 52.211-12, Liquidated Damages - Construction).

FAO-0005 Required Insurance

See FAR 52.228-5, Insurance - Work on a Government Installation.

(a) The contractor shall, at his own expense, provide and maintain during the entire performance of this contract at least the kinds and minimum amounts of insurance required in the Schedule or elsewhere in the contract.

TYPE AMOUNT

(1) WORKERS COMPENSATION & EMPLOYER'S

LIABILITY $100,000.00

The required Workmen's Compensation Insurance shall extend to cover employee's liability for accidental bodily injury or death and for occupational disease with a minimum liability of $100,000.00.

(2) COMPREHENSIVE GENERAL LIABILITY with a minimum limit of:

Per accident or occurrence for bodily injury $500,000.00

This insurance shall include contractor's protective and contractual liability.

(3) COMPREHENSIVE AUTOMOBILE LIABILITY with the following minimum limits:

Per person $200,000.00

Per Occurrence for Bodily Injury $500,000.00

Per Occurrence for Property Damage $ 20,000.00

(b) Before commencing work under this contract, the contractor shall certify to the Contracting Officer in writing that the required in-surance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective (1) for such period as the laws of the State in which this contract is to be performed, or (2) until 30 days after insurer or the contractor gives written notice to the Contracting Of-ficer, whichever period is longer.

( c ) The contractor shall insert the substance of this clause, including this paragraph c, in subcontracts under this contract that require work on a Government Institution and shall require subcontractors to provide and maintain insurance required in the Schedule or else-where in the contract. The contractor shall maintain a copy of all subcontractor's proofs of required insurance, and shall make copies available to the Contracting Officer upon request.

FAO-0006 Inspection of Work

IFBP02070900001 Page 6 of 31

This provision in no way authorizes anyone other than the Contracting Officer to commit the Government to changes in the terms of the contract. In the event it is determined necessary to designate a Contracting Officer's Representative (COR) for this contract, such designation shall be by a separate letter to the individual selected with a copy furnished to the contractor.

FAO-0007 Pre-Construction Conference

(a) A pre-construction conference will be held prior to construction, at the institution, between institution officials and the Contractor's representative to discuss general rules and regulations, including tool control, fraternization, conduct, dining facilities, review of the contract documents, etc. Minutes of this conference will be made, covering all items discussed, with copies distributed to all of those in attendance, and to the Regional Facilities Administrator.

(b) The Contractor shall familiarize himself/herself with all procedures involved in normal institution routines. Any requirements which may constitute a problem or result in conflict, will be brought to the attention of the Contracting Officer or his representative for determination.

FAO-0008 Material Approval Submittal

Within 10 calendar days after commencement of work or as otherwise established by the Contracting Officer, all materials and articles requiring approval, as contemplated by the Materials and Workmanship clause, shall be submitted by the contractor using the forms furnished at the Preconstruction Conference.

FAO-0009 Preparation of Progress Schedules and Reports

The reports contemplated by the clause herein entitled "Schedules for Construction Contracts" shall be accomplished on and in ac-cordance with instructions pertaining to the forms, Construction Progress Chart and Contract Progress Report. A revised progress schedule is required at each progress meeting.

FAO-0010 Work Hours

The project schedule is based on a normal forty (40) hour work week, eight (8) hours per day, Monday through Friday, excluding Fed-eral holidays. The Project Representative shall establish the work hour time frames for the duration of the project, subject to the ap-proval of the Contracting Officer. Work hours and work days may be altered only with a 48 hour advance approval of the Contracting Officer.

NOTE: Access to the site will be available during normal working hours except during emergencies. It shall be the responsibility of the Contractor to familiarize himself, his employees, and his subcontractors of the working hours and conditions in the correctional fa-cility, as working hours may not constitute a full eight hour day. The Government assumes no responsibility to the Contractor nor to any of his subcontractors for shorter hours due to institutional emergencies or entry and/or exit of workers necessitated by normal in-stitution routines. The procedures and institutional entrance/exit routines applicable to this project will be explained at both the pre-bid conference/site visit and the pre-construction meeting.

FAO-0011 Contraband

The Contractor shall inform his employees that intoxicating beverages, drugs, weapons, etc., will not be allowed on the site. Introduc-tion of contraband shall be subject to the penalties prescribed by Title 18 USC-1791.

FAO-0012 Explosives

The use of explosives is absolutely forbidden without written authorization from the Contracting Officer.

FAO-0013 Parking and Temporary Office

Parking will be available at the site to the extent it does not interfere with construction activities. Otherwise, parking shall be provided for by the Contractor, at his expense, off the site for workmen employed on the project. Any temporary field office used by the Contractor shall be located in an area approved by the Project Representative.

IFBP02070900001 Page 7 of 31

FAO-0014 Safety and Accident Prevention

In performing work under this contract the contractor shall:

(a) Conform to the specific safety requirements established by this contract;

(b) Comply with the safety rules of the Government institution that concern related activities not directly addressed in this contract;

( c ) Take all reasonable steps and precautions to prevent accidents and preserve the life and health of contractor and Government per-sonnel performing or in anyway coming in contact with the performance of this contract; and

(d) Take such additional immediate precautions as the Contracting Officer may reasonably require for safety and accident prevention purposes.

FAO-0015 Inspecting The Site

The site is located at:

United States Penitentiary (USP) Lewisburg

2400 Robert Miller Jr., Drive

Lewisburg, PA 17837

FAO-0016 Payment Services

(a) Application for payments in original and 3 copies shall be prepared on AIA (American Institute of Architects) Form G- 702 "Application and Certificate for Payment" and submitted to the Contracting Officer. The contractor may use another form; however, it shall contain similar information within the AIA Form G-702. The Contracting Officer will indicate his ap-proval of the amount of payment by signing and forwarding the application and certificate as follows:

Original: Accounting Supervisor

Copy to: Contractor, Contract File, Project Representative, Project Manager, Architect/Engineer

FAO-0017 Request for Final Inspection

The Contractor shall give the Project Representative at least 10 days advanced written notice of the date on which the work will be fully completed and ready for final inspection.

FAO-0018 Drawings

Five sets of all shop drawings, where indicated in the specifications, as finally approved are required to be furnished upon completion of work.

FAO-0019 Contract Security (3000-03 Human Resource Management Manual)

The following security measures will be applied to all contract employees who will be working under the terms of the contract:

National Crime Information Center (NCIC) Check

Name Check

Fingerprint Check (FD-258)

Completed OF-306, Declaration for Federal Employment, and Appropriate Resume or Optional Application

Completion of the Contract Pre-employment Form

Release of Information

FAO-0025 Assignment of Contract Administration Office and Functions

Pursuant to FAR 42.201 and 42.202, the assigned Contract Administration Office is listed in Block 26 of the Standard Form 1442 Back. This assignment carries with it the authority to perform all of the contract administration functions listed in FAR 42.302(a) and

IFBP02070900001 Page 8 of 31

42.302(b) to the extent that those functions apply to the contract.

IFBP02070900001 Page 9 of 31

Section 4 - Contract Clauses

Clauses By Reference

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.arnet.gov/far

Clause Title Date

52.253-1 Computer Generated Forms (Jan 1991) 11/08/2006

52.249-2 Alt I Termination for Convenience of the Government (Fixed-Price) (May 2004)- Alternate

I (Sept 1996)

11/08/2006

52.249-10 Default (Fixed-Price Construction) (Apr 1984) 11/08/2006

52.248-3 Value Engineering--Construction (Sept 2006) 11/08/2006

52.244-6a Subcontracts for Commercial Items (AUG 2009)

52.243-4 Changes (June 2007) 06/01/2007

52.242-14 Suspension of Work (Apr 1984) 11/08/2006

52.242-13 Bankruptcy (July 1995) 11/08/2006

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

(Apr 1984)

11/08/2006

52.236-8 Other Contracts (Apr 1984) 11/08/2006

52.236-7 Permits and Responsibilities (Nov 1991) 11/08/2006

52.236-6 Superintendence by the Contractor (Apr 1984) 11/08/2006

52.236-5 Material and Workmanship (Apr 1984) 11/08/2006

52.236-3 Site Investigation and Conditions Affecting the Work (Apr 1984) 11/08/2006

52.236-26 Preconstruction Conference (Feb 1995) 11/08/2006

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997)- Alternate I (Apr 1984) 11/08/2006

52.236-2 Differing Site Conditions (Apr 1984) 11/08/2006

52.236-17 Layout of Work (Apr 1984) 11/08/2006

52.236-15 Schedules for Construction Contracts (Apr 1984) 11/08/2006

52.236-14 Availability and Use of Utility Services (APR 1984) The government will furnish electricity, water and sewer.

07/14/2009

IFBP02070900001 Page 10 of 31

Clause Title Date

52.236-13 Accident Prevention (Nov 1991) 11/08/2006

52.236-12 Cleaning Up (Apr 1984) 11/08/2006

52.236-11 Use and Possession Prior to Completion (Apr 1984) 11/08/2006

52.236-10 Operations and Storage Areas (Apr 1984) 11/08/2006

52.233-4 Applicable Law for Breach of Contract Claim (Oct 2004) 11/08/2006

52.233-3 Protest after Award (Aug 1996) 11/08/2006

52.233-1 Alt I Disputes (July 2002)- Alternate I (Dec 1991) 03/23/2009

52.232-5 Payments under Fixed-Price Construction Contracts (Sept 2002) 11/08/2006

52.232-33 Payment by Electronic Funds Transfer--Central Contractor Registration (Oct 2003) 09/19/2008

52.232-27 Prompt Payment for Construction Contracts (Oct 2008) 12/02/2008

52.232-23 Assignment Of Claims (Jan 1986) 11/08/2006

52.232-17 Interest (Oct 2008) 09/17/2008

52.229-3 Federal, State and Local Taxes (Apr 2003) 11/21/2008

52.228-5 Insurance - Work on a Government Installation (Jan 1997) 11/08/2006

52.228-2 Additional Bond Security (Oct 1997) 11/08/2006

52.228-15 Performance and Payment Bonds--Construction (Nov 2006) 01/11/2007

52.228-14 Irrevocable Letter of Credit (Dec 1999) 11/08/2006

52.228-12 Prospective Subcontractor Requests for Bonds (Oct 1995) 11/08/2006

52.228-11a Pledges of Assets (SEP 2009)

52.227-4 Patent Indemnity--Construction Contracts (Dec 2007) 11/07/2007

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (Dec 2007) 11/07/2007

52.227-1 Authorization and Consent (Dec 2007) 09/19/2008

52.225-13 Restrictions on Certain Foreign Purchases (June 2008) 06/12/2008

52.223-6 Drug Free Workplace (May 2001) 11/08/2006

52.223-5 Pollution Prevention and Right-to-Know Information (Aug 2003) 11/08/2006

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction

Contracts. (Dec 2007)

11/07/2007

52.222-9 Apprentices and Trainees (July 2005) 11/08/2006

52.222-8 Payrolls and Basic Records (Feb 1988) 11/08/2006

52.222-7 Withholding of Funds (Feb 1988) 11/08/2006

52.222-6 Davis Bacon Act (July 2005) 11/08/2006

52.222-54a Employment Eligibility Verification (JAN 2009)

IFBP02070900001 Page 11 of 31

52.222-50 Combating Trafficking in Persons (Feb 2009) 01/20/2009

52.222-4 Contract Work Hours and Safety Standards Act - Overtime Compensation (July

2005)

11/08/2006

52.222-37 Employment Reports on Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Sept 2006)

11/08/2006

52.222-36 Affirmative Action for Workers with Disabilities (June 1998) 11/08/2006

52.222-35 Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era and

Other Eligible Veterans (Sept 2006)

11/08/2006

52.222-3 Convict Labor (June 2003) 11/08/2006

52.222-27 Affirmative Action Compliance Requirements for Construction (Feb 1999) 11/08/2006

52.222-26 Equal Opportunity (Mar 2007) 09/26/2008

52.222-21 Prohibition of Segregated Facilities (Feb 1999) 11/08/2006

52.222-15 Certification of Eligibility (Feb 1988) 11/08/2006

52.222-14 Disputes Concerning Labor Standards (Feb 1988) 11/08/2006

52.222-13 Compliance with Davis-Bacon and Related Act Regulations (Feb 1988) 11/08/2006

52.222-12 Contract Termination-Debarment (Feb 1988) 11/08/2006

52.222-11 Subcontracts (Labor Standards) (July 2005) 11/08/2006

52.222-10 Compliance with Copeland Act Requirements (Feb 1988) 11/08/2006

52.222-1 Notice to the Government of Labor Disputes (Feb 1997) 11/08/2006

52.219-8 Utilization of Small Business Concerns (May 2004) 11/08/2006

52.219-6 Notice of Total Small Business Set-Aside (June 2003) 09/05/2008

52.219-28 Post-Award Small Business Program Rerepresentation (Apr 2009) 03/24/2009

52.219-14 Limitations on Subcontracting (Dec 1996) 11/08/2006

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors

Debarred, Suspended, or Proposed for Debarment (Sept 2006)

11/08/2006

52.204-9 Personal Identity Verification of Contractor Personnel. (Sept 2007) 08/17/2007

52.204-7 Central Contractor Registration (Apr 2008) 04/22/2008

52.204-4 Printed or Copied Double-Sided on Recycled Paper (Aug 2000) 11/08/2006

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II (Apr 1984) 11/08/2006

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (Jan

1997)

11/08/2006

52.203-7 Anti-Kickback Procedures (Jul 1995) 11/08/2006

IFBP02070900001 Page 12 of 31

52.203-6 Restrictions On Subcontractor Sales To The Government (Sept 2006) 11/08/2006

52.203-5 Covenant Against Contingent Fees (Apr 1984) 11/08/2006

52.203-3 Gratuities (Apr 1984) 11/08/2006

52.203-12 Limitation On Payments To Influence Certain Federal Transactions (Sept 2007) 08/17/2007

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity (Jan 1997) 11/08/2006

52.202-1 Definitions (July 2004) 09/15/2008

52.21-603-70 Contract Monitor (CM) (AUG 2008)

(a)Mr. Edward Cuff ,Construction Representative , USP Lewisburg,(570) 522-7861, is hereby designated as the Contract Monitor (CM) under this contract.

(b) The CM is responsible, as applicable, for: receiving all deliverables, inspecting and accepting the supplies or services provide here-under in accordance with the terms and conditions of this contract; providing direction to the contractor which clarifies the contractor effort, fills in details or otherwise serves to accomplish the contractual Scope of Work; evaluating performance; and certifying all in-voices/vouchers for acceptance of the supplies or services furnished for payment.

(c) The CM does not have the authority to alter the contractor's obligations under the contract, and/or modify any of the expressed terms, conditions, specifications, or cost of the agreement. If as a result of technical discussions it is desirable to alter/change contrac-tual obligations or the Scope of Work, the Contracting Officer shall issue such changes.

52.24-403-70 Notice of Contractor Personnel Security Requirements (OCT 2005)

Compliance with Homeland Security Presidential Directive-12 (HSPD-12) and Federal Information Processing Standard Publication 201 (FIPS 201) 1 entitled "Personal Identification Verification (PIV) for Federal Employees and Contractors," Phase I.1. Long-Term Contractor Personnel:

In order to be compliant with HSPD-12/PIV I, the following investigative requirements must be met for each new long-term 2 con-tractor employee whose background investigation (BI) process begins on or after October 27, 2005:a. Contractor Personnel must present two forms of identification in original form prior to badge issuance (acceptable documents are listed in Form I-9, OMB No.

1615-0047, "Employment Eligibility Verification," and at least one document must be a valid State or Federal government-issued pic-ture ID);

b. Contractor Personnel must appear in person at least once before a DOJ official who is responsible for checking the identification documents. This identity proofing must be completed sometime during the clearance process but prior to badge issuance and must be documented by the DOJ official;

c. Contractor Personnel must undergo a BI commensurate with the designated risk level associated with the duties of each position.

Outlined below are the minimum BI requirements for each risk level:

• High Risk - Background Investigation (5 year scope)

• Moderate Risk - Limited Background Investigation (LBI) or Minimum Background Investigation (MBI)

• Low Risk - National Agency Check with Inquiries (NACI) investigation

d. The pre-appointment BI waiver requirements for all position sensitivity levels are a:

1) Favorable review of the security questionnaire form; 2) Favorable fingerprint results; 3) Favorable credit report, if required;3 4) Waiver request memorandum, including both the Office of Personnel Management schedule date and position sensitivity/risk level;

and 5) Favorable review of the National Agency Check (NAC) 4 portion of the applicable BI that is determined by position sensitivity/ risk level.

A badge may be issued following approval of the above waiver requirements.If the NAC is not received within five days of OPM's scheduling date, the badge can be issued based on a favorable review of the Security Questionnaire and the Federal Bureau of Invest-igation Criminal History Check (i.e., fingerprint check results). e. Badge re-validation will occur once the investigation is completed and favorably adjudicated. If the BI results so justify, badges issued under these procedures will be suspended or revoked.2. Short- Term Contractor Personnel:

It is the policy of the DOJ that short-term contractors having access to DOJ information systems and/or DOJ facilities or space for six months or fewer are subject to the identity proofing requirements listed in items 1a. and 1b. above. The pre-appointment waiver re-quirements for short-term contractors are:

a. Favorable review of the security questionnaire form; b. Favorable fingerprint results; c. Favorable credit report, if required;5 and d.

IFBP02070900001 Page 13 of 31

Waiver request memorandum indicating both the position sensitivity/risk level and the duration of the appointment. The commensur-ate BI does not need to be initiated.

A badge may be issued following approval of the above waiver requirements and the badge will expire six months from the date of is-suance. This process can only be used once for a short-term contractor in a twelve month period. This will ensure that any consecutive short-term appointments are subject to the full PIV-I identity proofing process.

For example, if a contractor employee requires daily access for a three or four-week period, this contractor would be cleared according to the above short-term requirements. However, if a second request is submitted for the same contractor employee within a twelve-month period for the purpose of extending the initial contract or for employment under a totally different contract for another three or four-week period, this contractor would now be considered "long-term" and must be cleared according to the long-term requirements as stated in this interim policy.

3. Intermittent Contractors:

An exception to the above-mentioned short-term requirements would be intermittent contractors.

a. For purposes of this policy, "intermittent" is defined as those contractor employees needing access to DOJ information systems and/ or DOJ facilities or space for a maximum of one day per week, regardless of the duration of the required intermittent access. For ex-ample, the water delivery contractor that delivers water one time each week and is working on a one-year contract.

b. Contractors requiring intermittent access should follow the Department's escort policy. Please reference the August 11, 2004, and January 29, 2001, Department Security Officer policy memoranda that conveys the requirements for contractor facility escorted ac-cess.

c. Due to extenuating circumstances, if a component requests unescorted access or DOJ IT system access for an intermittent contract-or, the same pre-employment background investigation waiver requirements that apply to short-term contractors are required.

d. If an intermittent contractor is approved for unescorted access, the contractor will only be issued a daily badge. The daily badge will be issued upon entrance into a DOJ facility or space and must be returned upon exiting the same facility or space.

e. If an intermittent contractor is approved for unescorted access, the approval will not exceed one year. If the intermittent contractor requires unescorted access beyond one year, the contractor will need to be re-approved each year. 4. An individual transferring from another department or agency shall not be re-adjudicated provided the individual has a current (within the last five years), favorably adjudicated BI meeting HSPD-12 and DOJ's BI requirements.

5. The DOJ's current escorted contractor policy remains unchanged by this acquisition notice.

Notes:

1. FIPS 201 is available at: www.csrc.nist.gov/publications/fips/fips201/FIPS-201-022505.pdf

2. Under HSPD-12, long-term contractors are contractors having access to DOJ information systems and/or DOJ facilities or space for six months or longer. The PIV-I identity proofing process, including initiation and adjudication of the required background investiga-tion, is required for all new long-term contractors regardless of whether it is the current practice to issue a badge. The second phase of HSPD-12 implementation (PIV-II) requires badge issuance to all affected long-term contractors.

3. For contractors in position sensitivity/risk levels above level 1, a favorable review of a credit check is required as part of the pre-appointment waiver package.

4. In order to avoid a delay in the hiring process, components should request an Advance NAC Report when initiating investigations to OPM. Per OPM ' s instructions, to obtain an Advance NAC Report, a Code " 3" must be placed in block " B " of the " Agency Use Only " section of the investigative form. This report is available for all case types.

5.For contractors in position sensitivity/risk levels above level 1, a favorable review of a credit check is required as part of the pre-appointment waiver package.

[End of Clause]

52.27-103-72 DOJ RESIDENCY REQUIREMENT BUREAU OF PRISONS (JUNE 2004)

For three of the five years immediately prior to submission of an offer/bid/quote, or prior to performance under a contract or commit-ment, individuals or contractor employees providing services must have:

1. Legally resided in the United States (U.S.); 2. worked for the U.S. overseas in a Federal or military capacity; or 3. been a dependent of a Federal or military employee serving overseas.

If the individual is not a U.S. citizen, they must be from a country allied with the U.S. The following website provides current inform-ation regarding allied countries: http://www.opm.gov/employ/html/citizen.htm

By signing this contract or commitment document, or by commencing performance, the contractor agrees to this restriction.

[End of Clause]

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

IFBP02070900001 Page 14 of 31

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor re-ceives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 calen-dar days after receipt of the notice to proceed.* The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calen-dar date.

52.211-12 Liquidated Damages--Construction(Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $325.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is com-pleted. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.222-39 Notification of Employee Rights Concerning Payment of Union Dues or Fees (Dec 2004)

(a) Definition. As used in this clause--

"United States"means the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.

(b) Except as provided in paragraph (e) of this clause, during the term of this contract, the Contractor shall post a notice, in the form of a poster, informing employees of their rights concerning union membership and payment of union dues and fees, in conspicuous places in and about all its plants and offices, including all places where notices to employees are customarily posted. The notice shall include the following information (except that the information pertaining to National Labor Relations Board shall not be included in notices posted in the plants or offices of carriers subject to the Railway Labor Act, as amended (45 U.S.C. 151-188)).

Notice to Employees--

Under Federal law, employees cannot be required to join a union or maintain membership in a union in order to retain their jobs. Un-der certain conditions, the law permits a union and an employer to enter into a union-security agreement requiring employees to pay uniform periodic dues and initiation fees. However, employees who are not union members can object to the use of their payments for certain purposes and can only be required to pay their share of union costs relating to collective bargaining, contract administration, and grievance adjustment.

If you do not want to pay that portion of dues or fees used to support activities not related to collective bargaining, contract adminis-tration, or grievance adjustment, you are entitled to an appropriate reduction in your payment. If you believe that you have been re-quired to pay dues or fees used in part to support activities not related to collective bargaining, contract administration, or grievance adjustment, you may be entitled to a refund and to an appropriate reduction in future payments.

For further information concerning your rights, you may wish to contact the National Labor Relations Board (NLRB) either at one of its Regional offices or at the following address or toll free number:

National Labor Relations Board

Division of Information

1099 14th Street, N.W.

Washington, DC 20570

1-866-667-6572

1-866-316-6572 (TTY)

To locate the nearest NLRB office, see NLRB's website at http://www.nlrb.gov.

(c) The Contractor shall comply with all provisions of Executive Order 13201 of February 17, 2001, and related implementing regula-tions at 29 CFR Part 470, and orders of the Secretary of Labor.

(d) In the event that the Contractor does not comply with any of the requirements set forth in paragraphs (b), (c), or (g), the Secretary may direct that this contract be cancelled, terminated, or suspended in whole or in part, and declare the Contractor ineligible for fur-ther Government contracts in accordance with procedures at 29 CFR Part 470, Subpart B Compliance Evaluations, Complaint Invest-igations and Enforcement Procedures. Such other sanctions or remedies may be imposed as are provided by 29 CFR Part 470, which implements Executive Order 13201, or as are otherwise provided by law.

(e) The requirement to post the employee notice in paragraph (b) does not apply to:

(1) Contractors and subcontractors that employ fewer than 15 persons;

(2) Contractor establishments or construction work sites where no union has been formally recognized by the Contractor or certified as the exclusive bargaining representative of the Contractor's employees;

IFBP02070900001 Page 15 of 31

(3) Contractor establishments or construction work sites located in a jurisdiction named in the definition of the United States in which the law of that jurisdiction forbids enforcement of union-security agreements;

(4) Contractor facilities where upon the written request of the Contractor, the Department of Labor Deputy Assistant Secretary for Labor-Management Programs has waived the posting requirements with respect to any of the Contractor's facilities if the Deputy As-sistant Secretary finds that the Contractor has demonstrated that -

(i) The facility is in all respects separate and distinct from activities of the Contractor related to the performance of a contract; and

(ii) Such a waiver will not interfere with or impede the effectuation of the Executive order; or

(5) Work outside the United States that does not involve the recruitment or employment of workers within the United States.

(f) The Department of Labor publishes the official employee notice in two variations; one for contractors covered by the Railway Labor Act and a second for all other contractors. The Contractor shall--

(1) Obtain the required employee notice poster from the Division of Interpretations and Standards, Office of Labor-Management Standards, U.S. Department of Labor, 200 Constitution Avenue, NW, Room N-5605, Washington, DC 20210, or from any field office of the Department's Office of Labor-Management Standards or Office of Federal Contract Compliance Programs;

(2) Download a copy of the poster from the Office of Labor-Management Standards website at http://www.olms.dol.gov; or

(3) Reproduce and use exact duplicate copies of the Department of Labor's official poster.

(g) The Contractor shall include the substance of this clause in every subcontract or purchase order that exceeds the simplified acquisi-tion threshold, entered into in connection with this contract, unless exempted by the Department of Labor Deputy Assistant Secretary for Labor-Management Programs on account of special circumstances in the national interest under authority of 29 CFR 470.3(c). For indefinite quantity subcontracts, the Contractor shall include the substance of this clause if the value of orders in any calendar year of the subcontract is expected to exceed the simplified acquisition threshold. Pursuant to 29 CFR Part 470, Subpart B- Compliance Eval-uations, Complaint Investigations and Enforcement Procedures, the Secretary of Labor may direct the Contractor to take such action in the enforcement of these regulations, including the imposition of sanctions for noncompliance with respect to any such subcontract or purchase order. If the Contractor becomes involved in litigation with a subcontractor or vendor, or is threatened with such involve-ment, as a result of such direction, the Contractor may request the United States, through the Secretary of Labor, to enter into such lit-igation to protect the interests of the United States.

(End of clause)

52.225-9 Buy American Act--Construction Materials (Feb 2009)

(a) Definitions. As used in this clause--

"Commercially available off-the-shelf (COTS) item" --

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

"Component" means an article, material, or supply incorporated directly into a construction material.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are dis-crete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and dis-tinct construction material regardless of when or how the individual parts or components of those systems are delivered to the con-struction site. Materials purchased directly by the Government are supplies, not construction material.

"Cost of components" means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transporta-tion costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of com-ponents does not include any costs associated with the manufacture of the construction material.

"Domestic construction material means"--

IFBP02070900001 Page 16 of 31

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its compon-ents. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

"Foreign construction material" means a construction material other than a domestic construction material.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material.

In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to the construction material or components listed by the Government as follows:

NONE

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that--

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or incon-sistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include ad-equate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign con-struction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless…