P2331623SPC.pdf

DEPARTMENT OF HOMELAND SECURITY

UNITED STATES COAST GUARD

SHORE INFRASTRUCTURE LOGISTICS CENTER

SPECIFICATIONS

FOR

BUZZARD’S BAY ENTRANCE LT TWR REPAIRS

FOR

ANT WOODS HOLE

WOODS HOLE, MA

PSN 2331623

BRIAN BAFFER GERRY GOSSELIN

A. A. JACOBS

UNITED STATES COAST GUARD

CIVIL ENGINEERING UNIT PROVIDENCE

475 KILVERT STREET, SUITE 100

WARWICK, RHODE ISLAND 02886

Buzzard Bay ENT LT TWR Repairs 2331623 ANT Woods Hole

Table of Contents

Summary of Work 011100

Work Restrictions 011400

Construction Schedule/Schedule of Values 013200

Submittal Procedures 013300

Safety and Occupational Health Requirements 013529

Temporary Facilities And Controls 015000

Temporary Environmental Controls 015719

Closeout Procedures 017700

Operation & Maintenance Data 017823

Demolition 024100

Welding, Structural 050523

Metal: Miscellaneous and Fabrication 055000

Coating of Steel Waterfront Structures 099713.26

Existing Conditions Appendix A

Reference Drawings Appendix B

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/10

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by the basic designation only.

MILITARY SPECIFICATIONS (MIL)

MIL-I-16165 (Rev. E) Shielding Harness, Shielding Items and Shielding Enclosures for use in Reduction of Interference from Engine Electrical Systems

MILITARY STANDARDS (MIL-STS)

MIL-STD-461E (Rev. D) Control of Electromagnetic

Interference Emissions and Susceptibility

MIL-STD-462 (Rev. D) Electromagnetic Interference

Characteristics

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes the following and incidental related work.

a. Knife Edge and WTD: The knife edge and water tight door (WTD) to the stairway of the structure shall be removed and replaced as indicated on the drawings.

b. Coating System: The coating system shall be scraped, cleaned and a new coating system shall be applied at the indicated portions of the structure on the drawings.

c. Hand Rails: replace the entire handrail system on the main deck at EL +10’, boat landings (2), boat landing ladders (2) and overboard ladders (4). Install missing handrail sockets and install new sockets for all ladders (12). Additionally replace all hardware for the grating and handrail system as the original drawings indicate whether or not it is currently missing.

d. Remove all guano on the structure in accordance with federal, state and local regulations.

1.2.2 Location

The work shall be located at the Buzzard Bay Entrance Light at latitude 41° 23’ 49.118”N and longitude 071° 02’ 04.886”W, approximately as indicated on the drawings. The exact location will be shown by the Contracting Officer.

SECTION 01 11 00 Page 2

1.3 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.4 SUPERVISION

Have at least one qualified supervisor capable of reading, writing, and conversing fluently in the English language on the job site during working hours. In addition, if a Quality Control (QC) representative is required on the contract, then that individual shall also have fluent English communication skills.

1.5 CONTRACT DRAWINGS

The following drawings accompany this specification and are a part thereof.

DRAWING LIST:

G-001 Title Sheet 1 of 4

A-201 Proposed Coating Plan 2 of 4

A-501 Proposed Plan EL +10’ 3 of 4

A-502 Proposed WTD Detail 4 of 4

One set of full size contract drawings, maps, and specifications will be furnished to the Contractor without charge. Reference publications will not be furnished.

Contractor shall immediately check furnished drawings and notify the Government of any discrepancies.

1.6 PRECONSTRUCTION CONFERENCE

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer at their location discretion to discuss and develop a mutual understanding relative to the administration of the value engineering and safety program, preparation of the schedule prices, shop drawings, and other submittals, scheduling programming, and prosecution of the work. Major subcontractors who will engage in the work shall also attend.

1.7 INSPECTION

SECTION 01 11 00 Page 3

The Contractor shall keep the Contracting Officer or duly appointed representative fully informed of contract operations and plans so that a representative may arrange to be present at various times that work is being performed.

1.7.1 Contractor’s Daily Log

The Contractor shall be complete the USCG Daily Log form at the end of each working day and deliver it to the Government Inspector. The Government Inspector will attest to its accuracy by initialing the form and forwarding that form to CEU Providence. The form will be provided to the Contractor by the Contracting Officer’s Representative.

1.7.2 Transportation to the Work Site

The Contractor shall accommodate requests from the Contracting Officer, or duly appointed representatives, for transportation to and from the work site. These transportation requests may be coordinated with the contractors normal trips back and forth from the work site, provided such coordination doesn’t delay the inspection by more than 4 hours.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

--End of Section--

SECTION 01 14 00 Page 1

SECTION 01 14 00

WORK RESTRICTIONS

02/10

1.1 CONTRACTOR ACCESS AND USE OF PREMISES

1.1.1 Project Regulations

Ensure that Contractor personnel employed on the project become familiar with and obey all project regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Do not enter any restricted areas unless required to do so and until cleared for such entry. The Contractor's equipment shall be conspicuously marked for identification.

1.1.2 Working Hours

Regular working hours shall consist of an 8 1/2 hour period established by the Contracting Officer Monday through Friday, excluding Government holidays.

1.1.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work shall be lighted in a manner approved by the Contracting Officer.

1.1.4 Occupied and Existing Building[s]

The Contractor shall be working in an existing structure, which is not occupied, however, still operational, such as fog and light signals.

1.1.5 Utility Cutovers and Interruptions

Operation of Station Utilities: The Contractor shall not operate nor disturb the setting of control devices in the station utilities system, including electrical services. The contractor is responsible any utility requirements to complete the work, which includes, but not limited to: water, sewage and electrical.

1.1.6 Transportation to the Work Site

The Contractor shall accommodate requests from the Contracting Officer, or duly appointed representatives, for transportation to and from the work site. These transportation requests may be coordinated with the contractors normal trips back and forth from the work site, provided such coordination doesn’t delay the inspection by more than 4 hours.

SECTION 01 14 00 Page 2

1.2 SECURITY REQUIREMENTS

1.2.1 Staging Area

The contractor is responsible for following any federal, state and local regulations at their determined staging area. If the contractor requests to utilize a Coast Guard facility, the contractor shall let the Contracting Officer know within 30 calendar days, but the Contracting Officer is not required to let the contractor to use such facilities, and the contractor is responsible for finding such an area for a staging area, and include price in the bid.

1.2.2 Parking

The contractor is responsible for following any federal and local parking regulations at their determined staging area.

Section 01 32 00 Page 1

SECTION 01 32 00

CONSTRUCTION SCHEDULE/SCHEDULE OF VALUES

02/10

1.1 SUBMITTALS

Submit the following in accordance with Section 01 33 00, "Submittal Procedures."

SD-01 Preconstruction Submittals

Construction Schedule

Schedule of Values

1.2 CONSTRUCTION SCHEDULE

At the Pre-Construction Conference, submit a Construction Schedule and Schedule of Values in accordance with FAR Clause 52.236.15. The Schedule of Values shall be based on the actual breakdown of the bid price. The cost of insurance shall not be listed as a separate item but included as part of each item of work. The actual cost of bonds may be paid as the first progress payment when a receipt from the bonding company is presented to the Contracting Officer. For contracts under $25,000, a Schedule of Values is not required. In addition, keep the Government Inspector informed daily of the expected delivery dates for major pieces of equipment and materials.

The Construction Schedule shall clearly indicate the start and completion dates of major work components. The Schedule of Values shall clearly indicate unit value of all major work components.

The Construction Schedule shall incorporate at a minimum the following activities:

a. Mobilization

b. Demobilization

c. Pre-Construction Submittals

d. Work Activities

e. In-Progress Submittals

f. Final Government Inspection

g. Close-Out Submittals; i.e. Testing Balancing Reports, Warranties, Operation and Maintenance Manuals, Posted Instructions

h. As-Built Drawings

i. Factors which Constitute Potential Interruptions to Station Operations

Section 01 32 00 Page 2

Pre-Construction Submittals are those activities which encompass the obtaining, submission, review and approval of submittals necessary prior to the start of the related site work. Contractor shall annotate all such activities into the progress schedule with their forecasted time periods.

These activity periods shall not be exclusive of the contract performance period. No site work shall commence until the respective submittals have been approved.

The value of all major work components within the project shall be identified on the Schedule of Values on a unit quantity and unit cost basis, e.g. number of squares and cost per square of roofing, number of lineal feet and cost per lineal foot of conduit, number of panels and cost per panel etc. Lump sum items shall only be paid for when 100% complete.

Do not include mobilization and demobilization line items on the Schedule of Values.

The Construction Schedule and Schedule of Values as approved by the Government is not a substitute for quantities conveyed by the specification and drawings and those required for a complete job.

Omissions and errors on the Construction Schedule and Schedule of Values are the responsibility of the Contractor.

Payments will not be made until the schedule of prices has been submitted to and approved by the Contracting Officer.

1.3 UPDATED SCHEDULES

Update the construction schedule and equipment delivery schedule at monthly intervals or when schedule has been revised. Reflect any changes occurring since the last update. Submit copies of the purchase orders and confirmation of the delivery dates as directed.

3.1 PROGRESS UPDATES

3.1.1 General

A revised Construction Schedule/Schedule of Values shall be issued by the Contractor on a monthly basis. In addition, any revisions to the Construction Schedule/Schedule of Values such as modifications or delays shall be reflected by Contractor submission of an updated Construction Schedule/Schedule of Values.

3.1.2 Modifications

When a modification is issued by the Government, record the modification as the last activity of the Construction Schedule and Schedule of Values and include the value of the modification. Adjust the Schedule of Values to reflect the inclusion of the modification. Revise the Construction Schedule portion of the form to annotate the progress change. Enter all modifications in this manner in sequential order.

SECTION 01 33 00 Page 1

SECTION 01 33 00

SUBMITTAL PROCEDURES

1.1 DEFINITIONS

1.1.1 Submittal

Shop drawings, product data, samples, and administrative submittals presented for review and approval. Contract Clauses "FAR 52.236-5, Material and Workmanship," paragraph (b) and "FAR 52.236-21, Specifications and Drawings for Construction," paragraphs (d), (e), and (f) apply to all "submittals."

1.1.2 Types of Submittals

All submittals are classified as indicated in paragraph "Submittal Descriptions (SD)". Submittals also are grouped as follows:

a. Shop drawings: As used in this section, drawings, schedules, diagrams, and other data prepared specifically for this contract, by contractor or through contractor by way of subcontractor, manufacturer, supplier, distributor, or other lower tier contractor, to illustrate portion of work.

b. Product data: Preprinted material such as illustrations, standard schedules, performance charts, instructions, brochures, diagrams, manufacturer's descriptive literature, catalog data, and other data to illustrate portion of work, but not prepared exclusively for this contract.

c. Samples: Physical examples of products, materials, equipment, assemblies, or workmanship that are physically identical to portion of work, illustrating portion of work or establishing standards for evaluating appearance of finished work or both.

d. Administrative submittals: Data presented for reviews and approval to ensure that administrative requirements of project are adequately met but not to ensure directly that work is in accordance with design concept and in compliance with contract documents.

1.1.3 Submittal Descriptions (SD)

Construction Progress Schedule Submittal register Schedule of values Health and safety plan Work plan Quality control plan Environmental protection plan

SECTION 01 33 00 Page 2

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the contractor for integrating the product or system into the project.

Drawings prepared by or for the contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

Field samples and mock-ups constructed on the project site establish standards by which the ensuring work can be judged. Includes assemblies or portions of assemblies which are to be incorporated into the project and those which will be removed at conclusion of the work.

SD-05 Design Data

Calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports

SECTION 01 33 00 Page 3

Daily checklists

Final acceptance test and operational test procedure

SD-07 Certificates

Statements signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a supplier, installer or subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and Material Safety Data sheets concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative to confirm compliance with manufacturer's standards or instructions.

Factory test reports.

SD-10 Operation and Maintenance Data

Data intended to be incorporated in operations and maintenance manuals.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

As-built drawings

Special warranties

Posted operating instructions

Training plan

1.1.4 Approving Authority

Person authorized to approve submittal.

1.1.5 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce construction and materials, SECTION 01 33 00 Page 4 products, equipment, and systems incorporated or to be incorporated in such construction.

1.2 SUBMITTALS

Submit the following in accordance with the requirements of this section.

Submittal register

1.3 USE OF SUBMITTAL REGISTER

Prepare and maintain submittal register, as the work progresses. Do not change data in columns (a), (b), (c), and (d) as delivered by government.

1.3.1 Submittal Register

Submit submittal register. Verify that all submittals required for project are listed and add missing submittals. Complete the following on the register:

Column (e) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

1.4 PROCEDURES FOR SUBMITTALS

1.4.1 Reviewing, Certifying, Approving Authority

Government organization shall be responsible for reviewing and certifying that submittals are in compliance with contract requirements. Approving authority on submittals is the Project Manager unless otherwise specified for specific submittal.

1.4.2 Constraints

a. Submittals listed or specified in this contract shall conform to provisions of this section, unless explicitly stated otherwise.

b. Submittals shall be complete for each definable feature of work;

components of definable feature interrelated as a system shall be submitted at same time.

c. When acceptability of a submittal is dependent on conditions, items, or materials included in separate subsequent submittals, submittal will be returned without review.

d. Approval of a separate material, product, or component does not imply approval of assembly in which item functions.

1.4.3 Scheduling

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential requirements to resubmit.

SECTION 01 33 00 Page 5

b. Except as specified otherwise, allow review period, beginning with receipt by approving authority, that includes at least 10 working days. Period of review for each resubmittal is the same as for initial submittal.

1.4.4 Variations

Variations from contract requirements require Government approval pursuant to contract Clause entitled "FAR 52.236-21, Specifications and Drawings for Construction" and will be considered where advantageous to government.

1.4.4.1 Proposing Variations

When proposing variation, deliver written request to the contracting officer, with documentation of the nature and features of the variation and why the variation is desirable and beneficial to government. If lower cost is a benefit, also include an estimate of the cost saving. In addition to documentation required for variation, include the submittals required for the item. Clearly mark the proposed variation in all documentation.

1.4.4.2 Warranting That Variation Are Compatible

When delivering a variation for approval, contractor warrants that this contract has been reviewed to establish that the variation, if incorporated, will be compatible with other elements of work, and deliver the same service life and performance.

1.4.4.3 Review Schedule Is Modified

In addition to normal submittal review period, a period of 5 working days will be allowed for consideration by the Government of submittals with variations.

1.4.5 Contractor's Responsibilities

a. Determine and verify field measurements, materials, field construction criteria; review each submittal; and check and coordinate each submittal with requirements of the work and contract documents.

b. Transmit submittals to Contracting Officer in accordance with schedule on approved Submittal Register, and to prevent delays in the work, delays to government, or delays to separate contractors.

c. Advise contracting officer of variation, as required by paragraph entitled "Variations."

d. Correct and resubmit submittal as directed by approving authority.

When resubmitting disapproved transmittals or transmittals noted for resubmittal, the contractor shall provide copy of that previously submitted transmittal including all reviewer comments for use by approving authority. Direct specific attention in writing or on resubmitted submittal, to revisions not requested by approving authority on previous submissions.

e. Furnish additional copies of submittal when requested by contracting officer, to a limit of 4 copies per submittal.

SECTION 01 33 00 Page 6

f. Complete work which must be accomplished as basis of a submittal in time to allow submittal to occur as scheduled.

g. Ensure no work has begun until submittals for that work have been returned as "approved," except to the extent that a portion of work must be accomplished as basis of submittal.

1.4.6 Government Responsibilities

a. Note date on which submittal was received from contractor on each Contract Item Approval Request Form.

b. Review each submittal; and check and coordinate each submittal with requirements of work and contract documents.

c. Review submittals for conformance with project design concepts and compliance with contract documents.

d. Ensure that material is clearly legible.

e. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

f. Identify returned submittals with one of the actions defined in paragraph entitled "Actions Possible" and with markings appropriate for action indicated.

1.4.7 Actions Possible

Submittals will be returned with one of the following notations:

a. Submittals marked "approved" "approved as submitted" authorize contractor to proceed with work covered.

b. Submittals marked "approved" "see below" authorize contractor to proceed with work as noted provided contractor takes no exception to the notations.

c. Submittals marked "disapproved" indicate submittal is incomplete or does not comply with design concept or requirements of the contract documents and shall be resubmitted with appropriate changes. No work shall proceed for this item until resubmittal is approved.

1.5 FORMAT OF SUBMITTALS

1.5.1 Transmittal Form

Transmit each submittal electronically, unless otherwise noted in the submittal register and/or where electronic submission is not feasible (i.e.

samples), to office of approving authority. The maximum file size that may be emailed is 10 MB; anything larger must be submitted hard copy or on a CD.

Transmit submittals with transmittal form prescribed by contracting officer and standard for project. The transmittal form shall identify contractor, indicate date of submittal, and include information prescribed by transmittal form and required in paragraph entitled "Identifying

SECTION 01 33 00 Page 7

Submittals." Process transmittal forms to record actions regarding sample panels and sample installations. Note: Submittals requiring hard copy submission shall be provided with carbon copy transmittal form provided by the government.

1.5.2 Identifying Submittals

Identify submittals, except sample panel and sample installation, with the following information on each separate component of each submittal and transmittal form. The maximum file size for electronic submittals shall be no larger than 10 MB. Identify each copy of each submittal identically, with the following:

a. Project title and location.

b. Construction contract number.

c. Section number of the specification section by which submittal is required.

d. Submittal description (SD) number of each component of submittal.

e. When a resubmission, alphabetic suffix on submittal description, for example, SD-10A, to indicate resubmission.

f. Name, address, and telephone number of subcontractor, supplier, manufacturer and any other second tier contractor associated with submittal.

g. Product identification and location in project.

1.5.3 Format for Product Data

a. Present product data submittals for each section. Include table of contents, listing page and catalog item numbers for product data.

b. Indicate, by prominent notation, each product which is being submitted; indicate specification section number and paragraph number to which it pertains.

c. Supplement product data with material prepared for project to satisfy submittal requirements for which product data does not exist. Identify this material as developed specifically for project.

1.5.4 Format for Shop Drawings

a. Shop drawings shall not be less than 8 1/2 by 11 inches nor more than 30 by 42 inches.

b. Present 8 1/2 by 11 inches sized shop drawings as part of the submittals required by section. Present larger drawings in sets.

c. Include on each drawing the drawing title, number, date, and revision numbers and dates, in addition to information required in paragraph entitled "Identifying Submittals."

SECTION 01 33 00 Page 8

d. Dimension drawings, except diagrams and schematic drawings; prepare drawings demonstrating interface with other trades to scale. Shop drawing dimensions shall be the same unit of measure as indicated on the contract drawings. Identify materials and products for work shown.

1.5.5 Format of Samples

a. Furnish samples in sizes below, unless otherwise specified or unless the manufacturer has prepackaged samples of approximately same size as specified:

(1) Sample of Equipment or Device: Full size.

(2) Sample of Materials Less Than 2 by 3 inches: Built up to 8 1/2 by 11 inches.

(3) Sample of Materials Exceeding 8 1/2 by 11 inches: Cut down to 8 1/2 by 11 inches and adequate to indicate color, texture, and material variations.

(4) Sample of Linear Devices or Materials: 10 inch length or length to be supplied, if less than 10 inches. Examples of linear devices or materials are conduit and handrails.

(5) Sample of Non-Solid Materials: Pint. Examples of non-solid materials are sand and paint.

(6) Color Selection Samples: 2 by 4 inches.

(7) Sample Panel: 4 by 4 feet.

(8) Sample Installation: 100 square feet.

b. Samples Showing Range of Variation: Where variations are unavoidable due to nature of the materials, submit sets of samples of not less than three units showing extremes and middle of range.

c. Reusable Samples: Incorporate returned samples into work only if so specified or indicated. Incorporated samples shall be in undamaged condition at time of use.

d. Recording of Sample Installation: Note and preserve the notation of area constituting sample installation but remove notation at final clean up of project.

e. When color, texture or pattern is specified by naming a particular manufacturer and style, include one sample of that manufacturer and style, for comparison.

1.5.6 Format of Administrative Submittals

a. When submittal includes a document which is to be used in project or become part of project record, other than as a submittal, do not apply contractor's approval stamp to document, but to a separate sheet accompanying document.

SECTION 01 33 00 Page 9

1.6 QUANTITY OF SUBMITTALS

1.6.1 Number of Copies of Product Data

a. When hard copy submission is required, submit four copies of submittals of product data.

1.6.2 Number of Copies of Shop Drawings

Submit shop drawings in compliance with quantity requirements specified for product data.

1.6.3 Number of Samples

a. Submit two samples, or two sets of samples showing range of variation, of each required item. One approved sample or set of samples will be retained by approving authority and one will be returned to contractor.

b. Submit one sample panel. Include components listed in technical section or as directed.

c. Submit one sample installation, where directed.

d. Submit one sample of non-solid materials.

1.6.4 Number of Copies of Administrative Submittals

a. Unless otherwise specified, submit administrative submittals compliance with quantity requirements specified for product data.

SUBMITTAL

REGISTER

BUZZARD'S BAY

ENTR LT TWR

REPAIR

ANT WOODS HOLE TOWER 2331623

Specification Section Number or Item Number

SD No., and Type of Submittal Material or Product

Spec.

Para graph Number

Planned Submittal Date

Date Fwd to Appr Auth /Date Recd From Contr

Date Fwd to Other Reviewer

Date Recd From Other Reviewer

Action Code

Date of Action

Mailed to Contr / Recd From Appr Auth

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j)

01 32 00 Construction Schedule of Values

SD-01, Preconstruction Submittals 1.1

Construction Schedule/Schedule of Values

1.1

01 35 29 Health and Safety requirements

SD-01, Preconstruction Submittals

1.2

2 Accident Prevention Plan 1.2

3 Activity Hazard Analysis 1.2

SD-11 Closeout Submittals 1.2

Daily Confined Space Entry

Permit 1.2

5 Reports 1.2

6 Crane Reports 1.2

7 Crane Critical Lift Plan 1.2

8 Certificate of Compliance 1.2

01 57 19 Temporary Environmental

Controls

SD-01, Preconstruction Submittals 1.2

9 Construction Site Plane 1.2

01 57 19 Temporary Environmental

Controls

SD-01, Preconstruction Submittals 1.3

10 Environmental Protection Plan 1.3

11 Oil Splill Prevention Plan 1.3

12 Debris Control Plan 1.3

13 Dirt and Dust Control Plan 1.3

SD-11, Closeout Submittals 1.3

14 Preconstruction Survey 1.3

15 Solid waste disposal permit 1.3

Waste determination documentation 1.3

Disposal documentation for hazardous and regulated waste

1.3

Contractor 40 CFR employee training records

1.3

19 Regulatory Notification 1.3

20 Solid waste disposal report 1.3

Contractor Hazardous Material Inventory Log

1.3

01 77 00 Closeout Procedures

SD-10 Operation and Maintenance Data 1.1

22 Equipment/product Warranty List 1.1

SD-11 Closeout Submittals 1.1

23 As-Built drawings 1.1

24 Record of Materials 1.1

09 97 13.26 Coating of Steel Waterfront

Structures

SD-01, Preconstruction Submittals 1.2

25 Material, equipment and fixture 1.2

26 Safety Plan 1.2

27 Quality Assurance Plan 1.2

SD-03 Product Data 1.2

26 Paint Removal Products 1.2

27 Paint Specifications 1.2

SD-04 Samples 1.2

28 Color 1.2

29 Manufacturer's Samples 1.2

SD-07 Certificates 1.2

30 Aplicator's Qualifications 1.2

31 Evidence of Acceptable Variation 1.2

SD-08 Manufacturer's Instructions 1.2

32 Manufacturer's Instructions 1.2

Manufacturer's Material Safety

Data Sheets (MSDS) 1.2

Environmental Conditions For

Applying Paint 1.2

SD-11 Closeout Submittals 1.2

35 Nace Inspector Reports 1.2

02 41 00 Demolition SD-01 Preconstruction Submittals 1.3

36 Existing Conditions 1.3

SD-07 Certificates 1.3

37 Demolition Plan 1.3

SD-11 Closeout Submittals 1.3

38 Receipts 1.3

05 05 23 Welding, Structural SD-03 Product Data

1.4

Welding Procedure

Qualifications 1.4

Welder, Welding Operator, and

Tacker Qualification 1.4

41 Inspector Qualification 1.4

42 Previous Qualifications 1.4

43 Pre-qualified Procedures 1.4

SD-06 Test Reports 1.4

44 Quality Control 1.4

45 Nondestructive Examination 1.4

SD-07 Certificates 1.4

Certified Welding Procedure

Specifications (WPS) 1.4

Certified Brazing Procedure

Specifications (BPS) 1.4

Certified Procedure Qualification

Records (PQR) 1.4

Certified Welder Performance

Qualifications (WPQ) 1.4

Certified Brazer Performance

Qualifications (BPQ) 1.4

05 50 00 Metal:

Miscellaneous and

Fabrications SD-02 Shop Drawings 1.2

Fabrication drawings of stainless steel handrails 1.2

Fabrication drawings of structural steel door frames 1.2

Access doors and panels, installation drawings 1.2

SD-03 Product Data 1.2

54 Access doors and panels 1.2

55 Handrails 1.2

56 Structural steel door frames 1.2

SECTION 01 35 29 Page 1

SECTION 01 35 29

SAFETY AND OCCUPATIONAL HEALTH REQUIREMENTS

11/07

1 GENERAL

The publications listed below form a part of this specification to the

AMERICAN NATIONAL STANDARDS INSTITUTE (ANSI)

ANSI A10.32 (2004) Personal Fall Protection - Safety

Requirements for Construction and Demolition

ANSI A10.34 (2001; R 2005) Protection of the Public on or

Adjacent to Construction Sites

ANSI Z359.1 (1992; Errata 1994; R 1999) Safety

Requirements for Personal Fall Arrest Systems, Subsystems and Components

AMERICAN SOCIETY OF MECHANICAL ENGINEERS (ASME)

ASME B30.22 (2005) Articulating Boom Cranes

ASME B30.3 (2004) Construction Tower Cranes

ASME B30.5 (2004) Mobile and Locomotive Cranes

ASME B30.8 (2004) Floating Cranes and Floating Derricks

CODE OF FEDERAL REGULATIONS (CFR)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1910.146 Permit-required Confined Spaces

29 CFR 1919 Gear Certification

29 CFR 1926 Safety and Health Regulations for

Construction

29 CFR 1926.500 Fall Protection

CORPS OF ENGINEERS (COE)

EM 385-1-1 (2003) Safety -- Safety and Health

Requirements

SECTION 01 35 29 Page 2

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 10 (2006; Errata 2006) Standard for Portable

Fire Extinguishers

NFPA 241 (2004) Safeguarding Construction, Alteration, and Demolition Operations

NFPA 51B (2003) Fire Prevention During Welding, Cutting, and Other Hot Work

NFPA 70 (2005; TIA 2005) National Electrical Code

NFPA 70E (2004; AMD 2004) Electrical Safety in the

Workplace

1.2 SUBMITTALS

Accident Prevention Plan (APP)

Activity Hazard Analysis (AHA)

Daily Confined Space Entry Permit

Submit one copy of each permit attached to each Daily Production Report.

Reports

Submit reports as their incidence occurs, in accordance with the requirements of the paragraph entitled, "Reports."

Crane Reports

Crane Critical Lift Plan

Certificate of Compliance

1.3 QUALITY ASSURANCE

1.3.1 Meetings

The Safety Officer shall attend the pre-construction conference.

1.3.1.1 Weekly Safety Meetings

Hold weekly at the project site. Attach minutes showing contract title, signatures of attendees and a list of topics discussed to the QC Contractor Quality Control daily report.

SECTION 01 35 29 Page 3

1.3.1.2 Work Phase Meetings

The appropriate AHA shall be reviewed and attendance documented by the Contractor at the preparatory, initial, and follow-up phases of quality control inspection.

1.3.1.3 New Employee Indoctrination

New employees will be informed of specific site hazards before they begin work. Documentation of this orientation shall be kept on file at the project site.

1.3.2 Certifications

1.3.2.1 Accident Prevention Plan (APP)

Submit the APP at least 15 calendar days prior to start of work at the job site, following Appendix A of EM-385-1-1. Make the APP site specific.

Submit the AHA for review at least 15 calendar days prior to the start of each phase. Format subsequent AHA as amendments to the APP. In accordance with contract quality control requirements each AHA will be reviewed during an on-site preparatory inspection.

1.4 ACCIDENT PREVENTION PLAN (APP)

Prepare the APP in accordance with EM-385-1-1 Table 1-1. Include the associated AHA and other specific plans, programs and procedures detailed in Paragraphs 01.A.09 and 01.A.10 of EM-385-1-1, some of which are listed below.

1.4.1 Contents of the Accident Prevention Plan

a. Name and safety related qualifications of safety officer (including training and any certifications).

b. Qualifications of competent and of qualified persons.

c. Identity of the individual who will complete exposure data (hours worked); accident investigations, reports and logs; and immediate notification of accidents to include subcontractors.

d. Emergency response plan. Conform to EM-385-1-1, paragraph 01.E and include a map denoting the route to the nearest emergency care facility with emergency phone numbers. Contractor may be required to demonstrate emergency response.

e. Confined Space Entry Plan. Identify the qualified person's name and qualifications, training, and experience. Delineate the qualified person's authority to direct work stoppage in the event of hazardous conditions. Include procedure for rescue by contractor personnel and the coordination with emergency responders. (If there is no confined space work, include a statement that no confined space work exists and none will be created.)

f. Hazardous Material Use. Provisions to deal with hazardous

SECTION 01 35 29 Page 4 materials, pursuant to the Contract Clause "FAR 52.223-3, Hazardous Material Identification and Material Safety Data." and the following:

(1) Inventory of hazardous materials to be introduced to the site with estimated quantities.

(2) Plan for protecting personnel and property during the transport, storage and use of the materials.

(3) Emergency procedures for spill response and disposal, including a site map with approximate quantities on site at any given time. The site map will be attached to the inventory, showing where the hazardous substances are stored.

(4) Material Safety Data Sheets for inventoried materials not required in other section of this specification.

(5) Labeling system to identify contents on all containers on-site.

(6) Plan for communicating high health hazards to employees and adjacent occupants.

g. Hazardous Energy Control Plan. For hazardous energy sources, comply with EM-385-1-1, paragraph 12.A.07.

h. Critical Lift Plan. Weight handling critical lift plans shall be prepared and signed in accordance with EM-385-1-1, paragraph 16.c.18.

i. Fall Protection and Prevention (FP&P) Plan. The plan shall be site specific and address all fall hazards in the work place. It shall address how to protect and prevent workers from falling to lower levels when they are exposed to fall hazards above 6 feet. A qualified person shall prepare the plan. The plan shall include fall protection and prevention systems, equipment and methods employed, responsibilities, rescue and escape equipment and operations, training requirements, and monitoring methods. FP&P Plan shall be revised [once every six months] for lengthy projects, to reflect any new changes during the course of construction, due to changes of personnel, equipment, systems or work habits.

j. Silica Exposure Reduction. The plan shall include specific procedures to prevent employee silica inhalation exposures.

o. Training Records and Requirements. List of mandatory training and certifications which are applicable to this project (e.g. explosive actuated tools, confined space entry, fall protection, crane operation, vehicle operator, forklift operators, personal protective equipment); list of requirements for periodic retraining/certification; outline requirements for supervisory and employee safety meetings.

p. Severe Weather Plan. Procedures of ceasing on-site operations during lightning or upon reaching maximum allowed wind velocities.

SECTION 01 35 29 Page 5

q. Emergency Lighting and Power Systems Plan (e.g. periodic testing of batteries for emergency lighting.)

1.5 ACTIVITY HAZARD ANALYSIS (AHA)

Prepare for each phase of the work. As a minimum, define activity being performed, sequence of work, specific hazards anticipated, control measures to eliminate or reduce each hazard to acceptable levels, training requirements for all involved, and the competent person in charge of that phase of work. For work with fall hazards, including fall hazards associated with scaffold erection and removal, identify the appropriate fall arrest systems. For work with materials handling equipment, address safeguarding measures related to materials handling equipment. For work requiring excavations, include excavation safeguarding requirements. The appropriate AHA shall be reviewed and attendance documented by the Contractor at the preparatory, initial, and follow-up phases of quality control inspection.

2 PRODUCTS

Not Used.

3 EXECUTION

3.1 CONSTRUCTION

Comply with EM-385-1-1, NFPA 241, the accident prevention plan, the activity hazard analysis and other related submittals and activity fire and safety regulations.

3.1.1 Hazardous Material Exclusions

Notwithstanding any other hazardous material used in this contract, radioactive materials or instruments capable of producing ionizing/non-ionizing radiation as well as materials which contain asbestos, mercury or polychlorinated biphenyls, di-isocynates, lead-based paint are prohibited.

Exceptions to the use of any of the above excluded materials may be considered by Contracting Officer upon written request by Contractor.

3.1.2 Unforeseen Hazardous Material

The design should have identified materials such as PCB, lead paint, and friable and nonfriable asbestos. If additional material, not indicated, that may be hazardous to human health upon disturbance during construction operations is encountered, stop that portion of work and notify the Contracting Officer immediately. Within 14 calendar days the contractor will determine if the material is hazardous. If material is not hazardous or poses no danger, the Government will direct the Contractor to proceed without change. If material is hazardous and handling of the material is necessary to accomplish the work, the Government will issue a modification pursuant to "FAR 52.243-4, Changes" and "FAR 52.236-2, Differing Site Conditions."

SECTION 01 35 29 Page 6

3.2 PERSONNEL PROTECTION

3.2.1 Hazardous Noise

Provide hazardous noise signs, and hearing protection, wherever equipment and work procedures produce sound-pressure levels greater than 85 dBA steady state or 140 dBA impulse, regardless of the duration of the exposure.

3.2.2 Fall Protection

Enforce use of the fall protection device designated for each specific work activity in the FP&P plan and/or AHA all times when an employee is on a surface 6 feet or more above lower levels. Personal fall arrest systems are required when working from an articulating or extendible boom, scissor lifts, swing stages, or suspended platform. Fall protection must comply with ANSI A10.32.

3.3 SCAFFOLDING

Employees shall be provided with a safe means of access to the work area on the scaffold. Climbing of any scaffold braces or supports not specifically designed for access is prohibited. Stair towers or ladders built into scaffold systems in accordance with EM 385-1-1 Appendix J are required for work platforms greater than 20 feet in height. Contractor shall ensure that employees that are qualified perform scaffold erection. Do not use scaffold without the capability of supporting at least four times the maximum intended load or without appropriate fall protection as delineated in the accepted fall protection plan. Minimum platform size shall be based on the platform not being greater in height than three times the dimension of the smallest width dimension for rolling scaffold. Some Baker type scaffolding has been found not to meet these requirements. Stationary scaffolds must be attached to structural building components to safeguard against tipping forward or backward. Special care shall be given to ensure scaffold systems are not overloaded. Outrigger brackets used to extend scaffold platforms on self supported scaffold systems for the storage of material is prohibited.

The first tie-in shall be at the height equal to 4 times the width of the smallest dimension of the scaffold base.

3.4 ELECTRICAL

3.4.1 Conduct of Electrical Work

The Contracting Officer will not accept an outage request until the Contractor satisfactorily documents that the circuits have been clearly identified. When racking in or live switching of circuit breakers, no additional person other than the switch operator will be allowed in the space during the actual operation. Plan so that work near energized parts is minimized to the fullest extent possible. Use of electrical outages clear of any energized electrical sources is the preferred method.

3.4.2 Portable Extension Cords

Portable extension cords are not encouraged, however, still authorized.

Compressed air tools are preferred and mandatory if operator is not on a designated deck or landing deck. Portable extension cords shall be sized in accordance with manufacturer ratings for the tool to be powered.

SECTION 01 35 29 Page 7

3.5 WORK IN CONFINED SPACES

Comply with the requirements in Section 06.I of EM-385-1-1. Any potential for a hazard in the confined space requires a permit system to be used.

a. Entry Procedures. Prohibit entry into a confined space by personnel for any purpose, including hot work, until the qualified person has conducted appropriate tests to ensure the confined or enclosed space is safe for the work intended and that all potential hazards are controlled or eliminated and documented. (See Section 06.I.05 of EM-385-1-1 for entry procedures.) All hazards pertaining to the space shall be reviewed with each employee during review of the AHA.

b. Forced air ventilation is required for all confined space entry operations and the minimum air exchange requirements must be maintained.

c. Include training information for employees who will be involved as entrant attendants for the work. Conform to Section 06.I.06 of EM- 385-1-1.

d. Entry Permit. Use ENGFORM 5044-R or other form with the same minimum information for the Daily Confined Space Entry Permit, completed by the qualified person. Post the permit in a conspicuous place close to the confined space entrance.

3.6 CRYSTALLINE SILICA

Grinding, abrasive blasting, and foundry operations of construction materials containing crystalline silica, shall comply with OSHA regulations, such as 29 CFR 1910.94, and EM-385-1-1, (Appendix C). The Contractor shall develop and implement effective exposure control and elimination procedures to include dust control systems, engineering controls, and establishment of work area boundaries, as well as medical surveillance, training, air monitoring, and personal protective equipment.

3.7 HOUSEKEEPING

3.7.1 Clean-up

All debris in work areas shall be cleaned up daily and removed from the job site daily or more frequently as necessary. Construction debris may be temporarily located in an approved location; however debris/garbage accumulation must be removed at the end of each work day.

Section 01 50 00 Page 1

SECTION 01 50 00

TEMPORARY FACILITIES AND CONTROLS

5/10

1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the

FEDERAL HIGHWAY ADMINISTRATION (FHWA)

FHWA MUTCD (1988) Manual on Uniform Traffic Control

Devices

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (1999) National Electrical Code

NFPA 241 (1996) Safeguarding Construction, Alteration, and Demolition Operations

1.2 SUBMITTALS

Construction site plan

1.3 CONSTRUCTION SITE PLAN

Prior to the start of work, submit a site plan showing the locations of temporary facilities (including layouts and details, equipment and material storage area (onsite and offsite), and access and haul routes used for this contract. Show locations of safety and construction fences, site trailers, construction entrances, trash dumpsters, temporary sanitary facilities, and worker parking areas.

1.4 TEMPORARY UTILITIES

1.4.1 Contractor Utilities

The Contractor shall provide his own utilities.

1.5 WEATHER PROTECTION

Take necessary precautions to ensure critical openings in the building to the structure are monitored carefully. Take immediate actions required to seal off such openings when rain or other detrimental weather is imminent, Section 01 50 00 Page 2 and at the end of each workday. Ensure that the openings are completely sealed off to protect materials and equipment in the structure from damage.

1.5.1 Structure and Site Storm Protection

When a warning of gale force winds is issued, take precautions to minimize danger to persons, and protect the work and nearby Government property.

Precautions shall include, but are not limited to, closing openings;

removing loose materials, tools and equipment from exposed locations; and removing or securing scaffolding and other temporary work. Close openings in the work when storms of lesser intensity pose a threat to the work or any nearby Government property.

1.6 STORAGE AREAS

Contractor shall be responsible for security of his property. The Contract Clause entitled "FAR 52.236-10, Operations and Storage Areas" and the following apply:

1.6.1 Storage Size and Location

There is no storage capability for the contractor on the structure.

1.7 TEMPORARY SANITARY FACILITIES

Provide adequate sanitary conveniences of a type approved for the use of persons employed on the work, properly secluded from public observation, and maintained in such a manner as required and approved by the Contracting Officer. Maintain these conveniences at all times without nuisance. Upon completion of the work, remove the conveniences from the premises, leaving the premises clean and free from nuisance. Dispose of sewage through connection to a municipal, district, or station sanitary sewage system.

Where such systems are not available, use chemical…