J-1_21-17-827PAT002-Specifications_as_of_14_Jun_17.pdf

DEPARTMENT OF HOMELAND SECURITY

UNITED STATES COAST GUARD

AVIATION TRAINING CENTER

MOBILE, ALABAMA 36608-8322

SPECIFICATIONS

FOR

SAM PN: 7088488

MAJOR M&R MEDICAL CLINIC (S24)

AT

AVIATION TRAINING CENTER

MOBILE, AL

JUNE 13, 2017

Major M&R_Medical Clinic_(S24) 7088488

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 16.00 20 SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

01 33 00 SUBMITTAL PROCEDURES

01 33 29 SUSTAINABILITY REPORTING

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.10 20 QUALITY CONTROL FOR MINOR CONSTRUCTION

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 82 13.00 10 ASBESTOS ABATEMENT

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

DIVISION 05 - METALS

05 40 00 COLD-FORMED METAL FRAMING

05 51 33 METAL LADDERS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

06 20 00 FINISH CARPENTRY

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 14 00 WOOD DOORS

08 33 13 COILING COUNTER DOORS

08 51 13 ALUMINUM WINDOWS

08 81 00 GLAZING

DIVISION 09 - FINISHES

09 29 00 GYPSUM BOARD

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 68 00 CARPETING

09 90 00 PAINTS AND COATINGS

DIVISION 11 - EQUIPMENT

PROJECT TABLE OF CONTENTS Page 1

11 72 13 MEDICAL EQUIPMENT, MISCELLANEOUS

DIVISION 12 - FURNISHINGS

12 21 00 WINDOW BLINDS

12 35 70 HEALTHCARE CASEWORK

DIVISION 22 - PLUMBING

22 00 70 PLUMBING, HEALTHCARE FACILITIES

22 66 53.00 40 LABORATORY CHEMICAL-WASTE AND VENT PIPING

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 08 00.00 10 COMMISSIONING OF HVAC SYSTEMS

23 09 13 INSTRUMENTATION AND CONTROL DEVICES FOR HVAC

23 09 23.13 20 BACnet DIRECT DIGITAL CONTROL SYSTEMS FOR HVAC

23 37 13.00 40 DIFFUSERS, REGISTERS, AND GRILLS

23 73 13.00 40 MODULAR INDOOR CENTRAL-STATION AIR-HANDLING UNITS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

26 05 19.00 10 INSULATED WIRE AND CABLE

26 05 71.00 40 LOW VOLTAGE OVERCURRENT PROTECTIVE DEVICES

26 24 16.00 40 PANELBOARDS

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

26 52 00.00 40 EMERGENCY LIGHTING

26 53 00.00 40 EXIT SIGNS

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

ADDENDUM - RESULTS OF MOLD SURVEY

ADDENDUM - ASBESTOS CONTAINING MATERIAL (ACM) AND LEAD BASE PAINT SURVEY

27 51 16 RADIO AND PUBLIC ADDRESS SYSTEMS

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

Building S24 is a single-story building of masonry construction with a built-up roof system over a metal deck and steel frame construction. The original building was constructed in 1968 with an addition of the dental clinic and pharmacy completed in 2004. The complete facility is approximately 12,500 square feet.

The proposed work will replace the electrical system Federal Pacific

Electric Co. panels, abate asbestos containing mastic under non-asbestos floor tiles, improve building air quality by replacing air handling units, reconfigure spaces for optimal functionality, update aged interior finishes to patient room and administrative area, replace roofing and windows, and all other ancillary work. The necessary work is broken down into the following disciplines/categories:

BASE BID ITEM 1:

ELECTRICAL WORK: Demolish existing electrical panels and components noted on drawings sheets 40-47 as base bid items. Install new Main

Distribution Panel, lighting and power panels, LED light fixture panels, duplex receptacle, and exit signs. Remove and re-install lightning protection system.

FIRE ALARM WORK: Remove existing fire alarm panel and associated cabinets from telecommunication closet and relocate to hallway noted in drawings sheet 46.Provide new horn and strobe in hallways areas noted in contract drawings.

INTERIOR ARCHITECTURAL WORK: The basic work associated with the areas identified in drawings sheets 1-6, 8, 9, & 11 includes the following:

complete removal of floor tiles and gypsum ceiling, limited demolition and reconfiguration of walls associated with new pharmacy, medical laboratory and main conference room; installation of acoustical grid ceiling system and new hospital grade resilient flooring and carpet tiles; creation of a new nurse station; & the update of interior finishes for all patient rooms and identified office to include replacement of identified doors & frames;

new medical casework for examination rooms, medical laboratory, and pharmacy.

MECHANICAL WORK: This work is to accommodate the reconfiguration of patient rooms, offices, conference room, and medical laboratory. Work will include the demolition of identified exhaust duct systems, ceiling diffusers, dampers, wall return air grills, and associated ductwork.

Upgrade existing Siemens's Bacnet HVAC direct digital controls to

Siemens’s Bacnet HVAC direct digital controls.

Complete commissioning of existing and new HVAC components.

Removal and installation of new crawl space duct insulation.

SECTION 01 11 00 Page 2

WINDOW WORK: Replace all anodized aluminum windows identified on drawings sheet 14 with new 1/2" laminated glass, anodized aluminum fixed windows.

Provide window blinds, stool and all ancillary work.

PLUMBING WORK: Demolish examination room's sinks and laboratory toilet plumbing fixtures. Install new fixtures in accordance with contract documents. Install new laboratory and pharmaceutical sinks. Provide all necessary ancillary work.

TELECOMMUNICATION WORK: Relocate existing telephone node and all ancillary phone equipment to new telecommunication closet wall.

Provide wire basket cable tray for new CAT5 cable and new shielded PA speakers cable. Provide new PA speakers, telecom jacks and conference room audio visual outlets to locations identified in contract drawings.

ROOF WORK: Demolish medical wing Modified Bitumen (MB) roof and internal gutters. Install new 1/8" to 1/4" sloped MB roof and gutter system on medical wing. Demolish and rebuild medical wing fascia and soffit in accordance with contract drawings. Repair dental wing MB roof blisters.

Provide a unit price per square foot to repair dental wing blistered Modified Bitumen roof membrane.

BID OPTION 1 - NEW RECEPTION AREA FLOORING WORK: Demolish and replace dental wing Vinyl Composition Tile (VCT) and carpet. Install new hospital grade resilient flooring and carpet tiles. Cut opening in existing wall and provide new door and frame.

BID OPTION 2 – DENTAL WING WORK: Provide the following in the Dental Wing:

Janitorial Closet: Relocate existing dental wing janitorial closet to medical wing room identified in contract drawings. Demolish existing floor and install new VCT. Install new mop sink, ancillary plumbing and new shelving. Demolish and cap existing supply ductwork. Provide new exhaust grill and connect to existing exhaust ductwork. Central Sterilization Room

(CSR) Dirty/Clean Room Work: Provide new door to existing door frame leading to clean room. Provide specimen access door/panel in existing wall between dirty and clean room. DENTAL LABORATORY WORK: Provide new laboratory casework. Install new fume hood. Install new flooring.

Provide dental sink, fixtures and necessary plumbing rough-in. Relocate existing dental plaster trap. DENTAL X-RAY AND STORAGE WORK: Provide new laboratory casework. Install new fume hood. Install new flooring. Provide dental sink, fixtures and necessary plumbing rough-in. Relocate existing dental plaster trap.

BID OPTION 3 - REPLACE MECHANICAL ROOM AIR HANDLING UNITS (AHU) WORK:

Replace existing AHU1 and AHU2 identified in contract drawings.

Provide all ancillary work necessary for a complete job.

1.1.2 Location

The work is located at the building S24, Aviation Training Center, 8501

Tanner Williams Road, Mobile AL 36608.

1.2 CONTRACT DRAWINGS

The following drawings accompany this specification and are a part thereof.

Drawing No. S247088488XXX

Sheets 1 through 47

BASE BID ITEM 2:

SECTION 01 11 00 Page 3

1.3 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract.

Before work is started, arrange with the Contracting Officer Representative

(COR) a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer Representative (COR) to be salvaged remain the property of the Government. Segregate, itemize, deliver and off-load the salvaged property at the Government designated storage area located within 1 mile of the construction site.

Provide a salvage plan, listing material and equipment to be salvaged, and their storage location. Maintain property control records for material or equipment designated as salvage. Use a system of property control that is approved by the Contracting Officer. Store and protect salvaged materials and equipment until disposition by the Contracting Officer.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

-- End of Section --

SECTION 01 14 00

WORK RESTRICTIONS

PART 1 GENERAL

1.1 CONTRACTOR ACCESS AND USE OF PREMISES

1.1.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Mark Contractor equipment for identification.

1.1.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.1.1.2 Identification Badges and Installation Access

Application for and use of badges will be as directed. Obtain access to the installation by participating in the Rapidgate program, or by obtaining passes each day from the Base Pass and Identification Office.

Costs for obtaining passes through Rapidgate are the responsibility of the Contractor. One-day passes, issued through the Base Pass and Identification Office, will be furnished without charge.

a. Rapidgate Program: Rapidgate is a voluntary program in which Contractor personnel who enroll, and are approved, are subsequently granted access to the installation for a period up to one year, or the length of the contract, whichever is less, and are not required to obtain a new pass from the Base Pass and Identification Office for each visit. The Government performs background screening and credentialing. Throughout the year the Contractor employee must continue to meet background screening standards. Periodic background screenings are conducted to verify continued Rapidgate participation and installation access privileges. Under the Rapidgate program, no commercial vehicle inspection is required, other than for Random Anti-Terrorism Measures (RAM) or in the case of an elevation of Force Protection Conditions (FPCON). Information on costs and requirements to participate and enroll in CACS is available at http://www.rapidgate.com or by calling 1-877-727-4342.

b. One-Day Passes: Participation in the Rapidgate is not mandatory, and if the Contractor chooses to not participate, the Contractor's personnel will have to obtain daily passes, be subject to mandatory vehicle inspection, and will have limited access to the installation.

The Government will not be responsible for any cost or lost time associated with obtaining daily passes.

SECTION 01 14 00 Page 1

1.1.1.3 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.1.2 Working Hours

Regular working hours must consist of an 8 1/2 hour period, between 7 a.m.

and 3:30 p.m., Monday through Friday, excluding Government holidays.

1.1.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer.

1.1.4 Occupied Building

The Contractor shall be working in an existing building which is occupied.

Provide dust covers or protective enclosures to protect existing work that remains and Government material located in the phased area during the construction period.

The Government will remove and relocate other Government property in the areas of the building scheduled to receive work.

1.1.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required paragraph 1.1.3 WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, PA and internet are considered utility cutovers pursuant to the paragraph

1.1.3 WORK OUTSIDE REGULAR HOURS.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 2

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are Submittals with an "S" are for inclusion in the Sustainability Notebook, in conformance with Section 01 33 29 SUSTAINABILITY REPORTING. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

View Location Map; G

Progress and Completion Pictures; G

SD-04 Samples

Color Boards; G

1.3 FIRST TIER CONTRACTOR REQUIREMENTS FOR ASBESTOS CONTAINING MATERIALS

Accomplish all contract requirements of Section 02 82 16.00 20 ENGINEERING

CONTROL OF ASBESTOS CONTAINING MATERIALS, 02 82 13.00 10 ASBESTOS

ABATEMENT, assigned to the Private Qualified Person, Designated Competent Person, directly with a first tier subcontractor.

1.4 SUPERVISION

1.4.1 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of contract work. In addition, if a Quality Control (QC) representative is required on the contract, then that individual must also have fluent English communication skills.

1.4.2 Superintendent Qualifications

The project superintendent must have a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects

SECTION 01 30 00 Page 1 similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

For routine projects where the superintendent is permitted to also serve as the Quality Control (QC) Manager as established in Section 01 45 00.00 20 QUALITY CONTROL, the superintendent must have qualifications in accordance with that section.

1.4.3 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to insure timely completion. Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.5 PRECONSTRUCTION

After award of the contract but prior to commencement of any work at the site, a meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the value engineering and safety program, preparation of the schedule of prices or earned value report, shop drawings, and other submittals, scheduling programming, prosecution of the work. Major subcontractors who will engage in the work shall also attend.

1.6 ELECTRONIC MAIL (E-MAIL) ADDRESS

Establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments as text files, pdf files, and other similar formats. Within 10 days after contract award, provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use email to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes or terrorist threats.

Multiple email addresses are not allowed.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 2

SECTION 01 32 16.00 20

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Construction Schedule; G

SD-07 Certificates

Monthly Updates

1.2 ACCEPTANCE

Prior to the start of work, prepare and submit to the Contracting Officer for acceptance a construction schedule in the form of a Network Analysis Schedule (NAS).

1.3 SCHEDULE FORMAT

1.3.1 Schedule Submittals and Procedures

Submit Network Analysis Schedules (NAS) and updates in hard copy and on electronic media that is acceptable to the Contracting Officer. Submit an electronic back-up of the project schedule in an import format compatible with the Government's scheduling program.

1.4 SCHEDULE MONTHLY UPDATES

Update the Construction Schedule at monthly intervals or when the schedule has been revised. The updated schedule must be kept current, reflecting actual activity progress and plan for completing the remaining work. Submit copies of purchase orders and confirmation of delivery dates as directed by the Contracting Officer.

a. Narrative Report: Provide with schedule updates. Identify and justify;

(1) Progress made in each area of the project

(2) Critical Path

(3) Date/time constraint(s), other than those required by the contract

(4) Changes in the following; added or deleted activities, original and remaining durations for activities that have not started, logic, milestones, planned sequence of operations, and critical path

SECTION 01 32 16.00 20 Page 1

(5) Status of Contract Completion Date and interim milestones;

(6) Current and anticipated delays (describe cause of delay and corrective actions(s) and mitigation measures to minimize);

(7) Description of current and future schedule problem areas.

Each entry in the narrative report must cite the respective Activity ID and Activity Description, the date and reason for the change, and description of the change.

1.5 3-WEEK LOOK AHEAD SCHEDULE

Prepare and issue a 3-Week Look Ahead schedule to provide a more detailed day-to-day plan of upcoming work identified on the Construction Schedule.

Additionally, include upcoming outages, closures, preparatory meetings, and initial meetings. Identify critical path activities on the Three-Week Look Ahead Schedule. The detail work plans are to be gantt chart type.

Activities must not exceed 5 working days in duration and have sufficient level of detail to assign crews, tools and equipment required to complete the work. Deliver one electronic file of the 3-Week Look Ahead Schedule to the Contracting Officer no later than 8 a.m. each Monday, and review during the weekly CQC Coordination or Production Meeting.

1.6 CORRESPONDENCE AND TEST REPORTS:

All correspondence (e.g., letters, Requests for Information (RFIs), e-mails, meeting minute items, Production and QC Daily Reports, material delivery tickets, photographs) must reference Schedule Activities that are being addressed. All test reports (e.g., concrete, soil compaction, weld, pressure) must reference Schedule Activities that are being addressed.

1.7 ADDITIONAL SCHEDULING REQUIREMENTS

Any references to additional scheduling requirements, including systems to be inspected, tested and commissioned, that are located throughout the remainder of the Contract Documents, are subject to all requirements of this section.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 32 16.00 20 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to start of construction (work).

Certificates of insurance

Surety bonds

List of proposed Subcontractors

List of proposed products

Construction progress schedule

Network Analysis Schedule (NAS)

Submittal register

Schedule of prices or Earned Value Report

Health and safety plan

Work plan

Quality Control(QC) plan

Environmental protection plan

SD-02 Shop Drawings

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

SD-04 Samples

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

SECTION 01 33 00 Page 1

SD-05 Design Data

SD-06 Test Reports

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that the product, system, or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits.

Text of posted operating instructions.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (MSDS)concerning impedances, hazards and safety precautions.

SD-10 Operation and Maintenance Data

Data that is furnished by the manufacturer, or the system provider, to the equipment operating and maintenance personnel, including manufacturer's help and product line documentation necessary to maintain and install equipment. This data is needed by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

This data is intended to be incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction

SECTION 01 33 00 Page 2 contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

1.1.2 Approving Authority

For all "G" submittals the Contracting Officer is the approving authority.

1.1.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals , except those SD-01 Pre-Construction Submittals noted above , construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor QC approval.

Submittals with an "S" are for inclusion in the Sustainability Notebook, in conformance to Section 01 33 29 SUSTAINABILITY REPORTING. Submit the following in accordance with this section.

SD-01 Preconstruction Submittals

Submittal Register

1.3 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

1.3.1

Sustainability Reporting Submittals (S)

Submittals for Guiding Principle Validation (GPV) or Third Party Certification (TPC) are indicated with an "S" designation. Submit the information required by the technical sections that demonstrates compliance with the sustainable requirement, and for inclusion in the Sustainability Notebook as required by Section 01 33 29 SUSTAINABILITY REPORTING. A full submittal for an item may be provided under another SD; however, for the "S" submittal, only provide that portion of the submittal that demonstrates compliance with the sustainable requirement. If the sustainable submittal does require Government Approval, it may be tagged under another SD with a "G."

Schedule submittals for these items throughout the course of construction as provided; do not wait until closeout.

1.4 INFORMATION ONLY SUBMITTALS

Normally submittals for information only will not be returned. Approval of the Contracting Officer is not required on information only submittals.

The Government reserves the right to require the Contractor to resubmit any item found not to comply with the contract. This does not relieve the Contractor from the obligation to furnish material conforming to the plans and specifications; will not prevent the Contracting Officer from requiring removal and replacement of nonconforming material incorporated in the work.

SECTION 01 33 00 Page 3

1.5 VARIATIONS

Variations from contract requirements require both Contractors Designer of Record (DOR) and Government approval.

1.5.1 Considering Variations

Discussion with Contracting Officer prior to submission, after consulting with the DOR, will help ensure functional and quality requirements are met and minimize rejections and re-submittals. When contemplating a variation which results in lower cost, consider submission of the variation as a Value Engineering Change Proposal (VECP).

Specifically point out variations from contract requirements in transmittal letters. Failure to point out deviations may result in the Government requiring rejection and removal of such work at no additional cost to the Government.

1.5.2 Proposing Variations

When proposing variation, deliver written request to the Contracting Officer, with documentation of the nature and features of the variation and why the variation is desirable and beneficial to Government, including the DOR's written analysis and approval. If lower cost is a benefit, also include an estimate of the cost savings. In addition to documentation required for variation, include the submittals required for the item.

Clearly mark the proposed variation in all documentation.

1.5.3 Review Schedule Extension

In addition to normal submittal review period, a period of 10 working days will be allowed for consideration by the Government of submittals with variations.

1.6 GOVERNMENT APPROVING AUTHORITY

When approving authority is Contracting Officer, the Government will:

a. Note date on which submittal was received from QC Manager .

b. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

c. Identify returned submittals with one of the actions defined in paragraph REVIEW NOTATIONS and with markings appropriate for action indicated.

Upon completion of review of submittals requiring Government approval, stamp and date submittals.

1.6.1 Review Notations

Submittals will be returned to the Contractor with the following notations:

a. Submittals marked "approved" or "accepted" authorize the Contractor to proceed with the work covered.

SECTION 01 33 00 Page 4

b. Submittals marked "approved as noted" or "approved, except as noted, resubmittal not required," authorize the Contractor to proceed with the work covered provided he takes no exception to the corrections.

c. Submittals marked "not approved" or "disapproved," or "revise and resubmit," indicate noncompliance with the contract requirements or design concept, or that submittal is incomplete. Resubmit with appropriate changes. No work shall proceed for this item until resubmittal is approved.

1.7 DISAPPROVED OR REJECTED SUBMITTALS

Make corrections required by the Contracting Officer. If the Contractor considers any correction or notation on the returned submittals to constitute a change to the contract drawings or specifications; notice as required under the FAR clause entitled CHANGES, is to be given to the Contracting Officer. Contractor is responsible for the dimensions and design of connection details and construction of work. Failure to point out deviations may result in the Government requiring rejection and removal of such work at the Contractor's expense.

If changes are necessary to submittals, make such revisions and submission of the submittals in accordance with the procedures above. No item of work requiring a submittal change is to be accomplished until the changed submittals are approved.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 33 00 Page 5

(a) (b) (c) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r)

Line

Acti vity

Trans-mittal #

Specification Section

SD

# Submittal Description Item Submitted

Paragraph

Classificati on: GOVT or A/E Revwr Submit

Approval Needed

By

Material Needed

By Action Code

Date Of Action

Date FWD to APPR / Auth Date RCD From

CONTR

Date FWD To

Other Revwr

Date

RCD

From Other Revwr

Action Code

Date Of Action

Mailed To

CONTR/

Date RCD From

APPR

Authority Remarks

1 01 30 00 01 Preconstruction Submittals View Location Map G

2 01 30 00 01 Preconstruction Submittals Progress and Completion Pictures G

3 01 30 00 04 Samples Color Boards G

4 01 32 16.00 20 01 Preconstruction Submittals Construction Schedule 1.2 G

5 01 32 16.00 20 07 Certificates Monthly Updates 1.4

6 01 33 00 01 Preconstruction Submittals Submittal Register

7 01 33 29 01 Preconstruction Submittals Preliminary Sustainability Notebook G

8 01 33 29 01 Preconstruction Submittals Preliminary High Performance and Sustainable Building Checklist

9 01 33 29 11 Closeout Submittals Final Sustainability Notebook G

10 01 33 29 11 Closeout Submittals Final High Performance and Sustainable Building Checklist G

11 01 45 00.10 20 01 Preconstruction Submittals QC Plan 1.6 G

12 01 78 00 03 Product Data Warranty Management Plan 1.5.1

13 01 78 00 03 Product Data Warranty Tags 1.5.4

14 01 78 00 03 Product Data Final Cleaning 3.3

15 01 78 00 03 Product Data Spare Parts Data 1.4

16 01 78 00 08 Manufacturer’s Instructions Instructions 1.5.1

17 01 78 00 10 Operation and Maintenance Data Operation and Maintenance Manuals 3.2 G

18 01 78 00 11 Closeout Submittals As-Built Drawings 3.1 G

19 01 78 00 11 Closeout Submittals Record Drawings G

20 01 78 00 11 Closeout Submittals As-Built Record of Equipment and Materials

21 01 78 00 11 Closeout Submittals Construction Contract Specifications

22 01 78 00 11 Closeout Submittals Certification of EPA Designated Items 2.1 G

23 01 78 23 10 Operation and Maintenance Data O&M Database 1.4 G

24 01 78 23 10 Operation and Maintenance Data Training Plan Fire Alaram System G

25 02 82 13.00 10 02 Shop Drawings Detailed Drawings 1.4 G

26 02 82 13.00 10 03 Product Data Asbestos Waste Shipment Records 3.6.2.1 G

27 02 82 13.00 10 03 Product Data Weight Bills and Delivery Tickets 1.1

28 02 82 13.00 10 03 Product Data Respiratory Protection Program 1.9.1 G

29 02 82 13.00 10 03 Product Data Cleanup and Disposal 3.6 G

30 02 82 13.00 10 03 Product Data Qualifications G

31 02 82 13.00 10 03 Product Data Training Program 1.10

32 02 82 13.00 10 03 Product Data Licenses, Permits and Notifications

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

33 02 82 13.00 10 03 Product Data Asbestos Management Plan 3.6.2.2 G

34 02 82 13.00 10 06 Test Reports Exposure Assessment and Air Monitoring 3.5

35 02 82 13.00 10 06 Test Reports Local Exhaust System

36 02 82 13.00 10 07 Certificates Encapsulants G

37 02 82 13.00 10 07 Certificates Medical Surveillance Requirements 1.9

38 04 20 00 03 Product Data Hot Weather Procedures 1.4.1 G

39 04 20 00 03 Product Data Cold Weather Procedures G

40 04 20 00 03 Product Data Clay or Shale Brick 2.1.2 G

41 04 20 00 03 Product Data Salvaged Brick 2.1.2.1 G

42 04 20 00 04 Samples Clay or Shale Brick 2.1.2 G

43 04 20 00 08 Manufacturer’s Instructions Admixtures for Masonry Mortar

44 04 20 00 08 Manufacturer’s Instructions Admixtures for Grout

45 04 20 00 10 Operation and Maintenance Data Take-Back Program

46 04 20 00 11 Closeout Submittals Clay Units S

47 04 20 00 11 Closeout Submittals Recycled Content S

48 05 40 00 02 Shop Drawings Framing Components G

49 05 40 00 03 Product Data Studs, Joists

50 05 40 00 07 Certificates Load-Bearing Cold-Formed Metal Framing

51 05 40 00 07 Certificates Welds

52 05 40 00 11 Closeout Submittals Recycled Content of Steel Products S

53 05 51 33 02 Shop Drawings Ladders 2.3

54 05 51 33 03 Product Data Ladders 2.3

55 05 51 33 07 Certificates Fabricator Certification for Ladder Assembly 1.3

56 06 10 00 02 Shop Drawings Nailing Strips 2.2.1 G

57 06 10 00 06 Test Reports Preservative-treated

58 06 10 00 07 Certificates Forest Stewardship Council (FSC) Certification

59 06 10 00 07 Certificates Preservative treatment 1.7

60 06 10 00 10 Operation and Maintenance Data Plastic

61 06 10 00 11 Closeout Submittals Local/Regional Materials 1.10.1

62 06 10 00 11 Closeout Submittals Plastic Lumber

63 06 10 00 11 Closeout Submittals Adhesives 2.4.2

64 06 20 00 02 Shop Drawings Detail Drawings Indicating All Wood Assemblies 1.3 G

65 06 20 00 03 Product Data Wood Products 2.2 G

66 06 20 00 03 Product Data Countertops 2.3 G

67 06 20 00 03 Product Data Engineered G

68 06 20 00 03 Product Data Treated Wood Products 1.4 G

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

69 06 20 00 03 Product Data Hardware and Accessories 2.7 G

70 06 20 00 03 Product Data Reduce Volatile Organic Compounds (VOC) Contents 2.1.1 G

71 06 20 00 03 Product Data Biobased Content 2.1.2 G

72 06 20 00 03 Product Data Recycled Content 2.1.3 G

73 06 20 00 04 Samples Samples 1.5 G

74 06 20 00 07 Certificates Certificates of Grade 1.7.1 G

75 06 20 00 07 Certificates Compliance 1.7.1 G

76 06 20 00 07 Certificates Certification of Sustainable Wood 1.7.1 G

77 06 20 00 11 Closeout Submittals Certification of Sustainable Wood 1.7.1 S

78 06 20 00 11 Closeout Submittals Reduce Volatile Organic Compounds (VOC) Contents 2.1.1

79 06 20 00 11 Closeout Submittals Biobased Content 2.1.2

80 06 20 00 11 Closeout Submittals Recycled Content 2.1.3

81 07 21 16 03 Product Data Blanket Insulation 2.2

82 07 21 16 03 Product Data Sill Sealer Insulation 2.3

83 07 21 16 03 Product Data Vapor Retarder

84 07 21 16 03 Product Data Pressure Sensitive Tape

85 07 21 16 03 Product Data Accessories 2.5

86 07 21 16 08 Manufacturer’s Instructions Insulation 3.3.1

87 07 21 16 11 Closeout Submittals Recycled Content for Insulation Materials 2.1.1 S

88 07 21 16 11 Closeout Submittals Reduce Volatile Organic Compounds

(VOC) 2.1.2 S

89 07 22 00 02 Shop Drawings Insulation Board Layout 1.3 G

90 07 22 00 02 Shop Drawings Verification of Existing Conditions 1.3 G

91 07 22 00 03 Product Data Insulation 2.2 G

92 07 22 00 03 Product Data Protection Board 1.4 G

93 07 22 00 03 Product Data Fasteners 2.4 G

94 07 22 00 03 Product Data Asphalt 1.10.1 G

95 07 22 00 03 Product Data Asphalt 2.3.2 G

96 07 22 00 06 Test Reports Flame Spread Rating 1.8.1 G

97 07 22 00 07 Certificates Volatile Organic Compounds (VOC) Content 1.9 G

98 07 22 00 07 Certificates Installer Qualifications 1.6 G

99 07 22 00 07 Certificates Certificates Of Compliance For Felt Materials

100 07 22 00 07 Certificates G]

101 07 22 00 08 Manufacturer’s Instructions Fasteners 2.4 G

102 07 22 00 08 Manufacturer’s Instructions Insulation 2.2 G

103 07 22 00 11 Closeout Submittals Volatile Organic Compounds (VOC) Content 1.9

104 07 52 00 02 Shop Drawings Roof plan 1.4.6 G

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

105 07 52 00 03 Product Data Modified Bitumen Sheets 2.1 G

106 07 52 00 03 Product Data Asphalt 2.3

107 07 52 00 03 Product Data Primer 2.5 G

108 07 52 00 03 Product Data Modified Bitumen Roof Cement 2.6 G

109 07 52 00 03 Product Data Pre-Manufactured Accessories 2.9

110 07 52 00 03 Product Data Fasteners And Plates 2.8 G

111 07 52 00 03 Product Data Warranty 1.9 G

112 07 52 00 05 Design Data Wind Uplift Calculations 1.4.5 G

113 07 52 00 07 Certificates Qualification of Manufacturer 1.4.1

114 07 52 00 07 Certificates Qualification of Applicator 1.4.2

115 07 52 00 07 Certificates Qualification of Engineer of Record 1.4.3

116 07 52 00 07 Certificates Bill of Lading 1.5.1

117 07 52 00 07 Certificates Wind Uplift Resistance 1.4.5 G

118 07 52 00 07 Certificates Fire Resistance 1.4.4 G

119 07 52 00 08 Manufacturer’s Instructions Modified Bitumen Membrane Application 3.3.3 G

120 07 52 00 08 Manufacturer’s Instructions Flashing 3.3.4 G

121 07 52 00 08 Manufacturer’s Instructions Fasteners 2.8.1

122 07 52 00 11 Closeout Submittals Warranty 1.9

123 07 52 00 11 Closeout Submittals Information Card 3.8

124 07 52 00 11 Closeout Submittals Instructions To Government Personnel 3.7

125 07 60 00 02 Shop Drawings Covering on flat, sloped, or curved surfaces 3.1.15 G

126 07 60 00 02 Shop Drawings Gutters 3.1.12 G

127 07 60 00 02 Shop Drawings Downspouts 3.1.13 G

128 07 60 00 02 Shop Drawings Expansion joints 3.1.16 G

129 07 60 00 02 Shop Drawings Gravel stops and fascias 3.1.10 G

130 07 60 00 02 Shop Drawings Splash pans 3.1.14 G

131 07 60 00 02 Shop Drawings Flashing for roof drains G

132 07 60 00 02 Shop Drawings Base flashing 3.1.9 G

133 07 60 00 02 Shop Drawings Counterflashing G

134 07 60 00 02 Shop Drawings Flashing at roof penetrations 3.1.17 G

135 07 60 00 02 Shop Drawings Reglets G

136 07 60 00 02 Shop Drawings Scuppers G

137 07 60 00 02 Shop Drawings Copings G

138 07 60 00 02 Shop Drawings Drip edge 3.1.11 G

139 07 60 00 02 Shop Drawings Conductor heads

140 07 60 00 02 Shop Drawings Open valley flashing G

141 07 60 00 02 Shop Drawings Eave flashing G

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

142 07 60 00 11 Closeout Submittals Quality Control Plan 3.5

143 07 92 00 03 Product Data Sealants 2.1 G

144 07 92 00 03 Product Data Primers 2.2 G

145 07 92 00 03 Product Data Bond Breakers 2.3 G

146 07 92 00 03 Product Data Backstops 2.4 G

147 07 92 00 03 Product Data Field Adhesion 3.1 G

148 07 92 00 07 Certificates Sealant 3.4.7 G

149 07 92 00 07 Certificates Primers 2.2 G

150 07 92 00 07 Certificates Bond Breakers 2.3 G

151 07 92 00 07 Certificates Volatile Organic Compounds (VOC) Content 1.4 G

152 07 92 00 07 Certificates Volatile Organic Compounds (VOC) Content 2.1.1 G

153 07 92 00 11 Closeout Submittals Volatile Organic Compounds (VOC) Content 1.4 S

154 07 92 00 11 Closeout Submittals Volatile Organic Compounds (VOC) Content 2.1.1 S

155 08 11 13 02 Shop Drawings Doors 2.1 G

156 08 11 13 02 Shop Drawings Doors 2.1 G

157 08 11 13 02 Shop Drawings Frames 2.3 G

158 08 11 13 02 Shop Drawings Frames 2.3 G

159 08 11 13 02 Shop Drawings Accessories

160 08 11 13 03 Product Data Doors 2.1 G

161 08 11 13 03 Product Data Frames 2.3 G

162 08 11 13 03 Product Data Accessories

163 08 14 00 02 Shop Drawings Doors 2.1 G

164 08 14 00 03 Product Data Doors 2.1 G

165 08 14 00 03 Product Data Accessories

166 08 14 00 03 Product Data Water-resistant sealer 2.2.7

167 08 14 00 03 Product Data warranty 1.6

168 08 14 00 03 Product Data Sound transmission class rating G

169 08 14 00 03 Product Data Certification 1.3

170 08 14 00 03 Product Data Local/Regional Materials 1.4

171 08 14 00 04 Samples Door finish colors 2.2.6.3 G

172 08 14 00 06 Test Reports Cycle-slam 2.3

173 08 14 00 06 Test Reports Hinge loading resistance 2.3

174 08 33 13 02 Shop Drawings Detail Drawings 1.3 G

175 08 33 13 03 Product Data Warranty 1.5

176 08 33 13 03 Product Data Rolling Counter Doors 2.1

177 08 33 13 03 Product Data Installation 3.1

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

178 08 33 13 03 Product Data Cleaning 3.3

179 08 33 13 11 Closeout Submittals Rolling Counter Door (Non-Rated)

180 08 51 13 02 Shop Drawings Windows 2.2 G

181 08 51 13 02 Shop Drawings Fabrication Drawings 1.9

182 08 51 13 03 Product Data Windows 2.2 G

183 08 51 13 03 Product Data Fasteners 2.3.3 G

184 08 51 13 03 Product Data Window Performance 1.10 G

185 08 51 13 03 Product Data Weatherstripping 2.3.2 G

186 08 51 13 03 Product Data Thermal Performance 1.10.4 G

187 08 51 13 04 Samples Finish Sample

188 08 51 13 05 Design Data Structural Calculations for Deflection 2.2 G

189 08 51 13 06 Test Reports Minimum Condensation Resistance Factor 1.4.2

190 08 51 13 10 Operation and Maintenance Data Windows 2.2 G

191 08 51 13 10 Operation and Maintenance Data Plastic Identification

192 08 81 00 02 Shop Drawings Installation

193 08 81 00 04 Samples Tape 2.3.3

194 08 81 00 04 Samples Sealant 2.3.1.1

195 08 81 00 08 Manufacturer’s Instructions Setting and Sealing Materials 2.3

196 08 81 00 08 Manufacturer’s Instructions Glass Setting 3.2

197 09 29 00 03 Product Data Water-Resistant Gypsum Backing Board 2.1.2

198 09 29 00 03 Product Data Certification 1.3

199 09 29 00 03 Product Data Gypsum Board 2.1.1

200 09 29 00 03 Product Data Joint Treatment Materials 2.1.3

201 09 29 00 03 Product Data Local/Regional Materials 1.6.1

202 09 29 00 03 Product Data Environmental Data 1.6.2

203 09 29 00 08 Manufacturer’s Instructions Material Safety Data Sheets 2.1

204 09 29 00 10 Operation and Maintenance Data Manufacturer maintenance instructions 2.1

205 09 29 00 11 Closeout Submittals Local/Regional Materials 1.6.1

206 09 29 00 11 Closeout Submittals Gypsum Board 2.1.1

207 09 29 00 11 Closeout Submittals Adhesives 2.1.5

208 09 51 00 02 Shop Drawings Approved Detail Drawings 1.2

209 09 51 00 03 Product Data Acoustical Ceiling Systems

210 09 51 00 03 Product Data Certification 1.4

211 09 51 00 04 Samples Acoustical Units 2.1

212 09 51 00 04 Samples Acoustic Ceiling Tiles

213 09 51 00 06 Test Reports Fire Resistive Ceilings

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

214 09 51 00 06 Test Reports Ceiling Attenuation Class and Test

215 09 51 00 07 Certificates Acoustical Units 2.1

216 09 51 00 07 Certificates Acoustic Ceiling Tiles

217 09 65 00 02 Shop Drawings Resilient Flooring and Accessories 2.9 G

218 09 65 00 03 Product Data Resilient Flooring and Accessories 2.9 G

219 09 65 00 03 Product Data Adhesives 2.5

220 09 65 00 03 Product Data Sheet Vinyl Flooring 2.1

221 09 65 00 03 Product Data Wall Base 2.2

222 09 65 00 03 Product Data Local/Regional Materials

223 09 65 00 03 Product Data Environmental Data 1.2.1

224 09 65 00 04 Samples Resilient Flooring and Accessories 2.9 G

225 09 65 00 06 Test Reports Moisture, Alkalinity and Bond Tests 3.3 G

226 09 65 00 08 Manufacturer’s Instructions Surface Preparation 3.2 G

227 09 65 00 08 Manufacturer’s Instructions Installation 3.1 G

228 09 65 00 10 Operation and Maintenance Data Resilient Flooring and Accessories 2.9 G

229 09 65 00 11 Closeout Submittals LEED Documentation 1.3

230 09 68 00 02 Shop Drawings Installation Drawings G

231 09 68 00 02 Shop Drawings Moldings 2.4 G

232 09 68 00 03 Product Data Carpet 2.1 G

233 09 68 00 03 Product Data Moldings 2.4 G

234 09 68 00 03 Product Data Physical Characteristics 2.1.1

235 09 68 00 03 Product Data Local/Regional Materials 1.2.1

236 09 68 00 03 Product Data Environmental Data 1.2.2

237 09 68 00 04 Samples Carpet 2.1 G

238 09 68 00 04 Samples Moldings 2.4 G

239 09 68 00 06 Test Reports Moisture and Alkalinity Tests 3.2 G

240 09 68 00 07 Certificates Carpet 2.1

241 09 68 00 07 Certificates Regulatory Requirements 1.5

242 09 68 00 08 Manufacturer’s Instructions Surface Preparation 3.1

243 09 68 00 08 Manufacturer’s Instructions Installation 3.4

244 09 68 00 10 Operation and Maintenance Data Carpet 2.1 G

245 09 68 00 10 Operation and Maintenance Data Cleaning and Protection 3.5 G

246 09 68 00 10 Operation and Maintenance Data Maintenance Service

247 09 68 00 11 Closeout Submittals LEED Documentation 1.3

248 09 68 00 11 Closeout Submittals Local/Regional Materials 1.2.1

249 09 90 00 02 Shop Drawings Piping identification

250 09 90 00 02 Shop Drawings stencil

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

251 09 90 00 03 Product Data Certification 1.4.2

252 09 90 00 03 Product Data Local/Regional Materials 1.9.1

253 09 90 00 03 Product Data Environmental Data

254 09 90 00 03 Product Data Materials 2.1

255 09 90 00 03 Product Data Coating 2.1 G

256 09 90 00 03 Product Data Manufacturer's Technical Data Sheets 2.1

257 09 90 00 04 Samples Color 1.11 G

258 09 90 00 07 Certificates Applicator's qualifications 1.3

259 09 90 00 07 Certificates Qualification Testing 1.4.1.2 G

260 09 90 00 08 Manufacturer’s Instructions Application instructions 3.2.1

261 09 90 00 08 Manufacturer’s Instructions Mixing

262 09 90 00 08 Manufacturer’s Instructions Manufacturer's Material Safety Data Sheets 1.7.2

263 09 90 00 10 Operation and Maintenance Data Coatings: 2.1 G

264 11 72 13 02 Shop Drawings Specimen Cabinet G

265 11 72 13 02 Shop Drawings Autopsy Table, Tank Type G

266 11 72 13 02 Shop Drawings Autopsy Table, L-shape G

267 11 72 13 02 Shop Drawings Autopsy Table, Movable System G

268 11 72 13 02 Shop Drawings Narcotic Cabinet G

269 11 72 13 02 Shop Drawings Clock G

270 11 72 13 02 Shop Drawings Medicine Center 2.2.1 G

271 11 72 13 03 Product Data items 2.2 G

272 11 72 13 10 Operation and Maintenance Data Autopsy Table, Tank Type G

273 11 72 13 10 Operation and Maintenance Data Autopsy Table, L-shape G

274 11 72 13 10 Operation and Maintenance Data Autopsy Table, Movable System G

275 11 72 13 10 Operation and Maintenance Data Clock G

276 12 21 00 02 Shop Drawings Installation 3.3

277 12 21 00 03 Product Data Window Blinds 2.1 G

278 12 21 00 03 Product Data Installation 3.3

279 12 21 00 03 Product Data Certification 1.4

280 12 21 00 04 Samples Window Blinds 2.1 G

281 12 21 00 06 Test Reports Window Blinds 2.1

282 12 21 00 08 Manufacturer’s Instructions Window Blinds 2.1 G

283 12 21 00 10 Operation and Maintenance Data Window Blinds 2.1 G

284 12 35 70 02 Shop Drawings Approved Detail Drawings 2.1 G

285 12 35 70 03 Product Data Casework 2.1

286 12 35 70 04 Samples Casework 2.1 G

287 12 35 70 04 Samples Wall Hung Cabinets 3.1.1 G

TITLE: Major M&R_Medical Clinic_(S24)

SUBMITTAL REGISTER

JOB NAME:

LOCATION:

CONTRACT NO:

CONTRACTOR:

APPROVING AUTHORITY

(d)

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

288 12 35 70 04 Samples Floor Mounted Cabinets 3.1.2 G

289 12 35 70 04 Samples Countertops 3.1.3 G

290 12 35 70 04 Samples Laminated Plastic Sheets G

291 12 35 70 07 Certificates Certification 1.3

292 22 00 70 02 Shop Drawings Plumbing System G

293 22 00 70 03 Product Data Local/Regional Materials 1.2.1.1

294 22 00 70 03 Product Data Environmental Data

295 22 00 70 03 Product Data Pipe and Fittings 2.4 G

296 22 00 70 03 Product Data Valves 2.9 G

297 22 00 70 03 Product Data Plumbing Fixtures 2.10 G

298 22 00 70 03…