HC101320QA330 amendment.pdf
PDF 9 KB Posted
- Solicitation number
- HC101320QA330
- Issued by
-
Defense Information Systems Agency
About this file
This document is an amendment to a solicitation for a 10 Gigabit Ethernet over Optical Transport Network (OTN) IP backbone circuit. The amendment corrects the diversity requirement reference and extends the quote due date to April 8, 2020. The circuit is required between two buildings in Corpus Christi Naval Air Station, Texas and Fort Sam Houston, Texas. Telecommunications providers must meet a maximum 10 millisecond round trip delay and 3 millisecond jitter. Quotes are due by April 8th and must include total fiber miles, routing drawings showing end-to-end diversity is met with at least 50 meter separation, and pricing in CLINs for recurring and non-recurring charges. The Defense Information Systems Agency is the contracting agency.
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
IQO INQUIRY
FM: PL8211
TO: Contractors
DATE (MM/DD/YYYY): 3/9/2020
SUBJECT: HC101320QA330-0001 Amend: 0001
A. TYPE ACTION: ADMIN AMEND
1. PURPOSE: *** THE PURPOSE OF AMENDMENT HC101320QA330-0001 IS TO: ***
1) CORRECT THE DIVERSITY REQUIREMENT FROM HC101319QA230 /TSR
RU08JUL196285 TO HC101319QB230 /TSR RU08JUL196285.
2) EXTEND SOLICITATION DUE DATE TO : 08 APRIL 2020.
*** ALL ELSE REMAINS THE SAME. ***
SUBMIT A QUOTE TO PROVIDE, INSTALL AND MAINTAIN A 10GB (GIGABIT ETHERNET)
OVER OTN (OTU-2) IP BACKBONE CIRCUIT BETWEEN BLDG: 1846; RM: 217, 2nd FL; 540 FIRST STREET SE; CORPUS CHRISTI NAVAL AIR STA, TX, 78419 AND BLDG: 1062, RM: EQUIP, 1st
FL; 1062 GORGAS CIRCLE; FORT SAM HOUSTON, TX, 78234.
2. TELECOMM PROVIDER MUST PROVIDE THE TOTAL FIBER MILES AND ROUND TRIP
DELAY (RTD) FROM THE CUSTOMER "A" LOCATION TO THE CUSTOMER "Z" LOCATION.
CONTRACTORS SHALL MEET ROUND TRIP DELAY (RTD) OF 10 MILLISECONDS. ROUND TRIP
DELAY VARIANCE (JITTER) SHALL BE NO MORE THAN 3MS.
3. EACH CONTRACTOR IS RESPONSIBLE FOR READING AND COMPLYING WITH ALL
TECHNICAL ASPECTS OF THIS SOLICITATION, TO INCLUDE READING AND AGREEING
WITH THE STANDARD PROVISIONS, ATTACHMENTS LISTING SPECIFIC TECHNICAL
REQUIREMENTS, PRICE QUOTE REQUIREMENTS, AND REQUESTED SERVICE DATE.
FAILURE TO READ AND ADHERE TO ANY PORTION OF THE INQUIRY SHALL RENDER THE
QUOTE NON-COMPLIANT AND RESULT IN IT BEING EXCLUDED FROM EVALUATION AND
AWARD.
4. THE SERVICE DATE TO BE MET IS: 24 JULY 2020 (SIP). THE GOVERNMENT ASSUMES
THAT CONTRACTORS HAVE CONSIDERED ALL ISSUES THAT MAY IMPACT THE SERVICE
DATE. THE GOVERNMENT MAY CANCEL, TERMINATE, OR REQUEST CONSIDERATION
IAW STANDARD PROVISION 42 FOR FAILURE TO MEET CONTRACTUAL SERVICE DATE OR
COMPLY WITH ANY CONTRACT TERMS OR CONDITIONS.
5. CONTRACTORS SHALL SUBMIT QUOTES IAW STANDARD PROVISION 04. QUOTES SHALL
INCLUDE SUFFICIENT DETAIL FOR EFFECTIVE EVALUATION AND SHOULD NOT SIMPLY
REPHRASE OR RESTATE THE GOVERNMENT REQUIREMENTS. RATHER, THEY MUST
PROVIDE CONVINCING RATIONALE TO ADDRESS HOW THE CONTRACTOR INTENDS
TO MEET THE REQUIREMENT. IN RESPONSE TO THIS SOLICITATION, NO TERMS OR
CONDITIONS PLACED UPON THE GOVERNMENT, NOR ASSUMPTIONS WILL BE ACCEPTED.
HC101320QA330-0001
RESPONSES TO CONTRACTORS ARE ENCOURAGED TO SUBMIT QUESTIONS AND REQUEST
CLARIFICATIONS OF THE REQUIREMENT (S) BEFORE SUBMITTING QUOTES. QUESTIONS
SHALL BE SUBMITTED TO CONTRACT SPECIALIST AND CONTRACTING OFFICER DURING
THE SOLICITATION PHASE ONLY, AND RESPONSES FOR ALL INTERESTED PARTIES WILL BE
POSTED TO FEDBIZOPPS.
6. THIS REQUIREMENT MUST BE WORKED IN CONJUNCTION WITH SOLICITATION
HC101319QB230 /TSR RU08JUL196285 AND MUST BE ENGINEERED AND PROVISIONED
TOTALLY DIVERSE END TO END FROM THE GOVERNMENT SERVICE DELIVERY POINTS
(SDP) FROM SOLICITATION HC101319QB230 /TSR RU08JUL196285; MEANING THE PHYSICAL
PATHS ARE TOTALLY SEPARATE INCLUDING MAN HOLES, CONDUIT, CENTRAL OFFICE
LOCATIONS, AND FIBER BUILDS. ADDITIONALLY AS A MINIMUM MUST HAVE 50 METERS
PHYSICAL SEPARATION FROM SOLICITATION HC101319QB230 /TSR RU08JUL196285.
7. CONTRACTOR SHALL PROVIDE COLOR POWERPOINT DRAWINGS SHOWING THE
ROUTES FROM THE COMMERCIAL DEMARKS TO THE SUPPORTING CENTRAL OFFICES AND/
OR WIRING CENTERS, ENSURING THE PHYSICAL END TO END DIVERSITY REQUIREMENTS
ARE BEING MET. DRAWINGS MUST INCLUDE SEPARATION DISTANCES, TOTAL FIBER MILES
AND ROUND TRIP DELAY BASED ON ACTUAL DISTANCE IN MILES. REFER TO STANDARD
PROVISION 39 FOR SPECIFIC DOCUMENTATION REQUIREMENTS. SAMPLE DRAWINGS ARE
INCLUDED THE ATTACHMENTS.
8. PRE AWARD SITE SURVEYS ARE AUTHORIZED (AT CONTRACTOR EXPENSE) WITH LOCAL
POCS AT EACH GOVERNMENT SITE. IT IS HIGHLY RECOMMENDED THAT AT A MINIMUM,
CONTRACTORS CONDUCT PHONE SURVEYS TO ADEQUATELY ASSESS THE MAGNITUDE OF
THE WORK TO BE PERFORMED IN DETERMINING THEIR PRICE STRATEGY.
9. ESTABLISH TSP: TSP0JTLL2-01
M. ADDITIONAL INFORMATION:
3. TSR NUMBER: RU09JUL196290A
4. CCSD: DIR3BEM5
Z. DITCO CONTACT:
Andrew Fernandez
618-418-6194 andrew.r.fernandez.civ@mail.mil
Dale L. Rupright
DITCO Contracting Officer
Unless otherwise specified, all other terms and conditions are unchanged.
Paragraph M.5.DIVERSITY REQUIREMENTS change from:
HC101319QA230 /TSR RU08JUL196285
To:
HC101319QB230/TSR RU08JUL196285
Paragraph V.QUOTE DUE DATE AND TIME change from:
Mar 26, 2020 3:00:00 PM CDT
To:
Apr 8, 2020 3:00:00 PM CDT
File details come from the government source that posted it. Updated .