FY24 Simplified Acquisition Construction BPA - Addendum to GSA 300.pdf

GSA Blanket Purchase Agreement No. GSA Contract No.

R1 Simplified Acquisition Construction BPA — EXHIBIT D (4/2024) (Order Form Addendum to GSA 300) Page 1 of 13

ADDENDUM TO GSA FORM 300

Region 1 Simplified Acquisition Construction BPA Order Form

1. Project Information

1.1 Project Summary

[Contracting Officer to insert project specific Project Summary. Do NOT insert SBU information into this Contract document. SBU information should be included in attachments only.]

1.2 Period of Performance

(a) In accordance with FAR 52.211-10, Commencement, Prosecution, and Completion of

Work, the Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than .* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(b) If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, FAR 52.211-10 shall be supplemented by its Alternate I, and the following paragraph shall be added to the basic clause:

☐ [Check if applicable] The completion date is based on the assumption that the successful offeror will receive the notice to proceed by [Contracting Officer insert date if box is checked]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(c) As defined in GSAR 552.211-10(a)(1), for the purposes of FAR 52.211-10, Commencement, Prosecution and Completion of Work, and, if applicable, FAR 52.211-12, Liquidated Damages-Construction, the work shall be deemed complete when it is

“substantially complete.” The Contractor shall diligently prosecute the Work so as to achieve Substantial Completion of the Work within the time specified in paragraph (a) of this Section.

(Order Form Addendum to GSA 300) Page 2 of 13

(d) The Contractor shall achieve Contract Completion, as the term is defined in this GSAR

552.211-70 Substantial Completion, within [Contracting Officer insert number] calendar days of Substantial Completion.

1.3 Project Schedule

(a) The Project Schedule shall be a rational, reasonable and realistic plan for completing the

Work, and conform to requirements specified in this clause and elsewhere in this Contract.

(b) The Contractor understands and acknowledges that the preparation and proper management of the Project Schedule is a material component of the Work, and that the

Contract price includes all costs of compliance with Project Schedule requirements.

(c) The Project Schedule shall depict all major activities necessary to complete the Work.

(d) Prior to NTP, the Contractor shall submit its Project Schedule to the Contracting Officer.

The Contractor shall submit the Project Schedule in PDF and hardcopy print format.

(e) The Project Schedule shall incorporate both major tasks as well as milestone events specified in the Contract, including, as applicable, NTP, Substantial Completion, and milestones related to specified work phases and site restrictions. The Project Schedule shall also include Contractor-defined milestones to identify target dates for critical events, based upon the Contractor's chosen sequence of work and be linked to the tasks that drive those milestones.

(f) Unless a shorter period for updates is specified elsewhere, the Contractor shall update the

Project Schedule weekly to reflect its actual progress in completing the Work, and submit the updated Project Schedule to the Contracting Officer.

(g) If the Contractor revises the Project Schedule after initial submission, the Contractor shall provide in writing to the Contracting Officer a narrative describing the substance of the revision, the rationale for the revision, and the impact of the revision on the projected substantial completion date.

(h) If at any time the Contracting Officer finds that the Project Schedule does not comply with any Contract requirement, the Contractor shall, upon written notice of exceptions taken by the Contracting Officer, revise the Project Schedule, adjust activity progress, or provide sufficient information demonstrating compliance.

(i) If the Contractor fails to sufficiently address the Contracting Officer's exceptions to the

Project Schedule within [Contracting Officer insert appropriate time frame] calendar days of written notice of same, the Contracting Officer may withhold retainage until the

Project is Substantially Complete or until such time as the Contractor has complied with

Project Schedule requirements.

(j) The Contracting Officer shall be entitled, but not required, to rely upon the Project Schedule to evaluate the Contractor's progress, evaluate entitlement to extensions of time, and determine the criticality or float of any activities described in such Project Schedule.

(Order Form Addendum to GSA 300) Page 3 of 13

1.4 Work Conditions/Site Requirements

[Contracting Officer to insert project specific work conditions and/or site requirements. Refer to Division 1 specification for further guidance.]

1.5 Authorized Individuals

(a) This Contract is between the United States of America, acting by and through the

Administrator of General Services (GSA), and the Contractor (the Parties). References in this Contract to "the Owner" or "the Government" shall be understood to refer to GSA. The following individual is designated as the only GSA “authorized individual” under this

Contract, unless other warranted contracting officers are designated in writing:

Authorized Individual’s Information:

Name:

Address:

Telephone:

Email:

(b) For the applicable authorities and limitations see Exhibit B, Section 3 of the Blanket

Purchase Agreement, GSAR 552.236-70.

1.6 Liquidated Damages

(a) ☐ [Check if applicable] The clause entitled “Liquidated Damages-Construction” at FAR

52.211-12 and its supplement at GSAR 552.211-12 are hereby incorporated by reference.

The Contractor acknowledges that time is of the essence for the performance of the Work, and that determining actual damages from delay would be extremely difficult and impractical. In accordance with FAR 52.211-12, Liquidated Damages-Construction, as supplemented by GSAR 552.211-12, Liquidated Damages-Construction, if the Contractor fails to achieve substantial completion of the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of

[Contracting Officer insert amount if box is checked] for each calendar day following the required completion date that the work is not substantially complete.

(b) If the clauses FAR 52.211-12 and GSAR 552.211-12 are checked as applicable and incorporated by the paragraph above, the clause entitled “Time Extensions” at GSAR

552.211-13 is hereby incorporated by reference.

(Order Form Addendum to GSA 300) Page 4 of 13

1.7 Buy American Exceptions

In accordance with FAR 52.225-9, Buy American-Construction Materials, the Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of said clause. The following list of construction materials or components are hereby inserted into paragraph (b)(2) and are excepted from this requirement:

1.8 Performance and Payment Bonds and Alternative Payment Protections

(a) For contracts expected to exceed $150,000—

(1) In accordance with paragraph (c) of FAR 52.228-15, Performance and Payment

Bonds-Construction, the Contractor shall furnish all executed bonds, including necessary reinsurance agreements, to the Contracting Officer within [Contracting

Officer insert number] days, but in any event, before starting work.

(b) For contracts expected to exceed $35,000 but not expected to exceed $150,000—

(1) In accordance with paragraph (a) of FAR 52.228-13, Alternative Payment Protections, the Contractor shall submit one of the following payment protections:

[Contracting Officer insert payment protection(s)]

(2) In accordance with paragraph (c) of FAR 52.228-13, Alternative Payment Protections, the submission of the payment protection is required within [Contracting Officer insert number] days of contract award.

1.9 Rights in Data and Copyrights for Construction Contracts involving Architect-

Engineer Services

[Check one]

☐ GSAR 552.227-70, Government Rights (Unlimited) is hereby incorporated by reference, except if GSAR 552.227-71 is incorporated.

[OR]

☐ The Government requires sole property rights and exclusive control over the design and data, and GSAR 552.227-71, Drawings and Other Data to Become Property of Government is hereby incorporated by reference.

[Contracting Officer to list applicable excepted materials or indicate "none”]

(Order Form Addendum to GSA 300) Page 5 of 13

1.10 Basis of Pricing

☐ [Check if applicable] FAR 52.236-3, Site Investigations and Conditions Affecting the Work, is hereby incorporated by reference in this Contract. The Contractor shall be presumed to have established all prices with knowledge of general and local conditions that may affect the cost of

Contract performance at the site where the Work is to be performed, to the extent that such information is reasonably obtainable.

1.11 Design-Build Project Delivery Method

☐ [Check if applicable] A design-build project delivery method will be followed and the following changes to the clauses at GSAR 552.236-71, Contractor Responsibilities, and at GSAR

552.236-72, Submittals are hereby incorporated in full text:

GSAR 552.236-71 CONTRACTOR RESPONSIBILITIES (MAR 2019) ALTERNATE I (MAR 2019)

Delete paragraphs (d) – (g) of the basic clause and insert paragraphs (d) – (g) as follows:

(d) The Contractor shall be responsible for providing professional design services unless this responsibility is expressly excluded from the contract. In the performance of such work, the

Contractor shall be responsible for retaining licensed design professionals, who shall sign and seal all drawings, calculations, specifications and other submittals that the licensed professional prepares. The Contractor shall be responsible for, and GSA shall be entitled to rely upon, the adequacy and completeness of all professional design services provided under the contract.

(e) The Contractor's responsibilities include the responsibilities of the Architect-Engineer

Contractor, as specified in FAR 52.236-23.

(f) The Contractor shall include in all subcontracts that require professional design services express terms establishing GSA as a third party beneficiary. No other person shall be deemed a third party beneficiary of the contract.

(g) The Contractor shall determine whether the information contained in the contract documents complies with applicable laws, statutes, building codes and regulations. If it comes to the attention of the Contractor that any of the contract documents do not comply with such requirements, the Contractor shall promptly notify the Contracting Officer in writing. If the Contractor performs any of the work prior to notifying and receiving direction from the Contracting Officer, the Contractor shall assume full responsibility for correction of such work, and any fees or penalties that may be assessed for non-compliance.]

(End of clause)

(Order Form Addendum to GSA 300) Page 6 of 13

GSAR 552.236-72 SUBMITTALS (MAR 2019) ALTERNATE I (MAR 2019)

Add the following paragraph (g) to the basic clause:

(g) Contractor shall submit design documents for review in accordance with PBS-P100. The

Government shall review submittals for the limited purpose of verifying that the documents conform to the design criteria expressed in the contract documents.

1.12 Contracts Solely for Dismantling, Demolition, or Removal of Improvements

[Check one if the contract is solely for dismantling, demolition, or removal of improvements.]

☐ The contract is solely for dismantling, demolition, or removal of improvements and the

Government shall make payment to the contractor in addition to any title to property that the contractor shall make payment to the contractor in addition to any title to property that the contractor may receive under the contract. FAR 52.237-4, Payment by Government to

Contractor, is hereby incorporated by reference. Additionally, the following fill-ins shall be inserted in paragraph (a) therein:

(a) In partial consideration of the performance of the work called for in the Schedule, the

Government will pay to the Contractor [fill in amount].

[OR]

☐ The contract is solely for dismantling, demolition, or removal of improvements and all material resulting from the dismantling or demolition work is to be retained by the Government;

FAR 52.237-4, Payment by Government, with its Alternate I is hereby incorporated by reference: delete paragraph (d) from the basic clause and renumber the remaining paragraphs.

Additionally, the following fill-ins shall be inserted in paragraph (a) therein:

(a) In full consideration of the performance of the work called for in the Schedule, the

Government will pay to the Contractor [fill in amount].

1.13 Statement of Work, Specifications, Drawings, Exhibits, and Other Attachments

The following documents are incorporated by reference into this Contract.

(a) Exhibit B of Blanket Purchase Agreement No. , Contract Terms and Conditions

(b) Statement of Work for GSA Contract No. , Dated

(c) Specifications for GSA Contract No. , Dated

(d) Construction Drawings for GSA Contract No. , Dated

(e) Site Conditions Report by , Dated

(f) Wage Determination , Dated

(Order Form Addendum to GSA 300) Page 7 of 13

[Contracting Officer to insert project specific list of documents, including, as applicable, those listed in the sample. Modify the list to reflect project specific documents (e.g., NEPA, mitigation and historic preservation documents as appropriate).]

1.14 Administrative Matters

(a) In accordance with Exhibit B of the Blanket Purchase Agreement, Section 1.10(b)(3), Administrative Matters — Payments, the Contractor shall submit the following “Additional documentation” with each invoice:

[Contracting Officer to insert project specific documentation required. If none, add "NA."]

(b) In accordance with Exhibit B of the Blanket Purchase Agreement, Section 1.10(f)(8), Administrative Matters — Safeguarding and Dissemination of Sensitive But Unclassified

(SBU) Building Information, the Contractor shall immediately report all improper disclosures of SBU building information to the Authorized Individual identified in Section 1.5(a) above.

1.15 Additional Terms and Conditions

[Contracting Officer to add project specific terms and conditions here. Delete if not used]

2. Clauses Incorporated in the Blanket Purchase Agreement

All clauses incorporated either by reference or in full text in the Blanket Purchase Agreement are incorporated in this contract, with the same force and effect as if they were given in full text.

3. Clauses Incorporated by Reference

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The full text of a clause may also be accessed electronically at this address:

FAR: https://www.acquisition.gov/browse/index/far

GSAR: https://www.acquisition.gov/browse/index/gsam

3.1 The following clause(s) are incorporated by reference if checked:

[Check all that apply]

NUMBER TITLE DATE

☐ FAR 52.211-18 Variation in Estimated Quantity APR 84

☐ FAR 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons

JUN 16

☐ FAR 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners

JUN 16

https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/browse/index/gsam

(Order Form Addendum to GSA 300) Page 8 of 13

☐ FAR 52.223-20 Aerosols JUN 16

☐ FAR 52.223-21 Foams JUN 16

☐ FAR 52.236-2 Differing Site Conditions APR 84

☐ FAR 52.236-3 Site Investigations and Conditions Affecting the Work APR 84

☐ FAR 52.236-16 Quantity Surveys APR 84

☐ FAR 52.236-17 Layout of Work APR 84

☐ FAR 52.236-26 Preconstruction Conference FEB 95

☐ FAR 52.246-12 Inspection of Construction AUG 96

☐ FAR 52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements

AUG 96

☐ FAR 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form) Alternate I

APR 84

☐ FAR 52.249-10 Default (Fixed-Price Construction) APR 84

☐ FAR 52.249-10 Default (Fixed-Price Construction) Alternate I APR 84

☐ FAR 52.249-10 Default (Fixed-Price Construction) Alternate II APR 84

☐ FAR 52.249-10 Default (Fixed-Price Construction) Alternate III APR 84

[The contracting officer shall insert the clause at 52.211-18, Variation in Estimated Quantity, in solicitations and contracts when a fixed-price construction contract is contemplated that authorizes a variation in the estimated quantity of unit-priced items.]

[Insert 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons, in solicitations and contracts for–

(i) Refrigeration equipment (in product or service code (PSC) 4110);

(ii) Air conditioning equipment (PSC 4120);

(iii) Clean agent fire suppression systems/equipment (e.g., installed room flooding systems, portable fire extinguishers, aircraft/tactical vehicle fire/explosion suppression systems) (in PSC 4210);

(iv) Bulk refrigerants and fire suppressants (in PSC 6830);

(v) Solvents, dusters, freezing compounds, mold release agents, and any other miscellaneous chemical specialty that may contain ozone-depleting substances or high global warming potential hydrofluorocarbons (in PSC 6850);

(vi) Corrosion prevention compounds, foam sealants, aerosol mold release agents, and any other preservative or sealing compound that may contain ozone-depleting substances or high global warming potential hydrofluorocarbons (in PSC 8030);

(vii) Fluorocarbon lubricants (primarily aerosols) (in PSC 9150); and

(viii) Any other manufactured end products that may contain or be manufactured with ozone-depleting substances.]

[Insert 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners, in solicitations and contracts that include the maintenance, service, repair, or disposal of–

(i) Refrigeration equipment, such as refrigerators, chillers, or freezers; or

(ii) Air conditioners, including air conditioning systems in motor vehicles.]

[Insert 52.223-20, Aerosols, in solicitations and contracts– https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063128 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053180 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053196 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_223_20

(Order Form Addendum to GSA 300) Page 9 of 13

(i) For products that may contain high global warming potential hydrofluorocarbons as a propellant, or as a solvent; or

(ii) That involve maintenance or repair of electronic or mechanical devices.]

[Insert 52.223-21, Foams, in solicitations and contracts for–

(i) Products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent, such as building foam insulation or appliance foam insulation; or

(ii) Construction of buildings or facilities.]

[The contracting officer may insert the clause at 52.236-2, Differing Site Conditions, in solicitations and contracts when a fixed-price construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated and the contract amount is expected to be at or below the simplified acquisition threshold.]

[The contracting officer may insert the clause at 52.236-3, Site Investigation and Conditions Affecting the Work, in solicitations and contracts when a fixed-price construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated and the contract amount is expected to be at or below the simplified acquisition threshold.]

[The contracting officer may insert the clause at 52.236-16, Quantity Surveys, in solicitations and contracts when a fixed-price construction contract providing for unit pricing of items and for payment based on quantity surveys is contemplated.]

[The contracting officer shall insert the clause at 52.236-17, Layout of Work, in solicitations and contracts when a fixed-price construction contract is contemplated and use of this clause is appropriate due to a need for accurate work layout and for siting verification during work performance.]

[If the contracting officer determines it may be desirable to hold a preconstruction conference, the contracting officer shall insert a clause substantially the same as the clause at 52.236-26, Preconstruction Conference, in solicitations and fixed price contracts for construction or for dismantling, demolition or removal of improvements.]

[The contracting officer shall insert the clause at 52.246-12, Inspection of Construction, in solicitations and contracts for construction when a fixed-price contract is contemplated and the contract amount is expected to exceed the simplified acquisition threshold. The contracting officer may insert the clause in such solicitations and contracts when the contract amount is expected to be at or below the simplified acquisition threshold, and its use is in the Government’s interest.]

[The contracting officer shall insert the clause at 52.246-13, Inspection-Dismantling, Demolition, or Removal of Improvements, in solicitations and contracts for dismantling, demolition, or removal of improvements.] https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#id1668D08086F https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048797 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048811 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048957 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048970 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1049062 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1047074 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1047097

(Order Form Addendum to GSA 300) Page 10 of 13

4. Contract Clauses Incorporated in Full Text

4.1 The following clause(s) are incorporated in full text if checked:

[Check all that apply]

☐ FAR 52.236-13 ACCIDENT PREVENTION (NOV 1991) ALTERNATE I (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will—

(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) Avoid interruptions of Government operations and delays in project completion dates;

and

(3) Control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall—

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR Part

1926 and 29 CFR Part 1910 ; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and

Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

[The contracting officer shall insert the clause at 52.249-1, Termination for Convenience of the Government (Fixed-Price) (Short Form), in solicitations and contracts when a fixed-price contract is contemplated and the contract amount is not expected to exceed the simplified acquisition threshold. If the contract is for dismantling, demolition, or removal of improvements, the contracting officer shall use the clause with its Alternate I.]

[The contracting officer may insert the clause at 52.249-10, Default (Fixed-Price Construction), in solicitations and contracts for construction, when a fixed-price contract is contemplated and the contract amount is at or below the simplified acquisition threshold, if appropriate (e.g., if completion dates are essential). If the contract is for dismantling, demolition, or removal of improvements, the contracting officer shall use the clause with its Alternate I. If the contract is to be awarded during a period of national emergency, the contracting officer may use the clause with its Alternate II when a fixed-price contract for construction is contemplated or with its Alternate III when a contract for dismantling, demolition, or removal of improvements is contemplated.] https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1044605 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1044997

(Order Form Addendum to GSA 300) Page 11 of 13

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the

Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor’s representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the

Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) Before commencing the work, the Contractor shall—

(1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and

(2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

5. Purchase Order Provisions Incorporated in Full Text

5.1 The following provision(s) are incorporated in full text if the clauses at FAR 52.236-

2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions

Affecting the Work, are included.

FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and

Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

[The contracting officer shall insert the clause at 52.236-13, Accident Prevention, in solicitations and contracts when a fixed-price construction or a fixed-price contract for dismantling, demolition, or removal of improvements is contemplated and the contract amount is expected to be at or below the simplified acquisition threshold. The contracting officer shall insert the clause or the clause with its Alternate I in solicitations and contracts when a contract for services to be performed at Government facilities (see 48 CFR Part 37) is contemplated, and technical representatives advise that special precautions are appropriate.] https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048797 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048811 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1048913

(Order Form Addendum to GSA 300) Page 12 of 13

(b) Site visits may be arranged during normal duty hours by contacting:

Name:

Address:

Telephone:

(End of Provision)

[OR]

FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB1995)

If an organized site visit will be conducted, substitute the following for paragraph (b) of the basic provision:

(b) An organized site visit has been scheduled for—

[Insert date and time]

(c) Participants will meet at—

[Insert location]

(End of Provision)

5.2 The following provision(s) are incorporated in full text if the amount of the contract is expected to be in excess of $10,000.

FAR 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror’s attention is called to the Equal Opportunity clause and the Affirmative Action

Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the

Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade

Goals for Female Participation for Each Trade

[Contracting Officer shall insert goals] [Contracting Officer shall insert goals]

These goals are applicable to all the Contractor’s construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in

(Order Form Addendum to GSA 300) Page 13 of 13 the Federal Register in notice form, and these notices may be obtained from any Office of

Federal Contract Compliance Programs office.

(c) The Contractor’s compliance with Executive Order11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause,

(2) specific affirmative action obligations required by the clause entitled “Affirmative Action

Compliance Requirements for Construction,” and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract, Executive Order11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for

Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the-

(1) Name, address, and telephone number of the subcontractor;

(2) Employer’s identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the “covered area” is [Contracting Officer shall insert description of the geographical areas where the contract is to be performed, giving the state, county, and city].

(End of provision)