FA812121R0002_Amendment0004_13MAY2021.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE Page 1

2. AMENDMENT/MODIFICATION NO.

FA8121-21-R-0002-0004

3. EFFECTIVE DATE

13 MAY 2021

4. REQUISITION/PURCHASE REQ. NO.

FD20301800713

5. PROJECT NO (If applicable)

6. ISSUED BY CODE

DEPARTMENT OF THE AIR FORCE, AFSC PZAAA

3001 STAFF DR STE 1AF1 98C

TINKER AFB OK 73145-3303

BUYER: Shannon Gumto/AFSC/PZAAA shannon.gumto@us.af.mil Phone: (405) 739- 7770

7. ADMINISTERED BY (If other than item 6) CODEFA8121

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

CODE

X

9A. AMENDMENT OF SOLICITATION NO.

FA812121R0002

9B. DATED (SEE ITEM 11)

19-MAR-2021

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended. Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods. ( a ) By completing Items 8 and 15, and returning copies of the amendment; ( b ) By acknowledging receipt of this amendment on each copy of the offer submitted; or ( c ) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified. 21-MAY-2021 3:00 AM

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return 1 copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

FMS REQUIREMENT

Routine

15A. NAME AND TITLE OF SIGNER (Type or print)

15B. CONTRACTOR/OFFEROR

BY ________________________________________________________

(Signature of person authorized to sign)

15C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16B. UNITED STATES OF AMERICA

BY ____________________________________________________

(Signature of Contracting Officer)

16C. DATE SIGNED

FACILITY CODE

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

30-105 STANDARD FORM 30 (REV. 10-83)

PRESCRIBED BY GSA

FAR (48 CFR) 53.243

X

X X

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

FA8121-21-R-0002-0004

Continuation of block 14. DESCRIPTION OF AMENDMENT/MODIFICATION

The purpose of this amendment is to extend the proposal due date from 17 May 2021 to 21 May 2021, provide an updated pricing matrix and to incorporate answers to offeror questions.

Contractor Questions w/ Government Responses-Final Round

Subject: FA8121-21-F-0002, 229 Combustion Chamber Date: 13 May 2021

Question: If the Government maintains the current posture - - no pricing for Option Years 3 and 4, will a new price matrix be provided? Current ITO mandates all years must be input on the price matrix.

Answer: An updated pricing matrix is added to beta.sam to account for Option Years 3 and 4 being TBN.

Question: With the knowledge of known distributor parts shortages, how does the Government expect a responsible contractor to meet the delivery requirements in the solicitation/contract?

Answer: If the offeror identifies that the delivery schedule in the solicitation cannot be met, the offeror may take an exception to the delivery schedule in accordance with paragraph 1.1 in Section M. “Offerors must clearly identify any exception to the solicitation terms and conditions and must provide complete supporting rationale.”

Quotes for parts may serve as supporting rationale.

Question: With the knowledge of known distributor parts shortages, how should a responsible contractor respond to the solicitation delivery requirements?

Answer: See above answer.

Question: With the knowledge of known distributor parts shortages, will the contractor be held liable for not meeting delivery schedules when the Government is aware necessary repair detail components are-not and will-not be available?

Answer: If the Government determines the delay to be beyond the Contractor’s control, the Contractor will not be held liable for the delay. Each delay will be reviewed on a case by case basis and the circumstances surrounding the delay. Any potential delays discovered during solicitation posting shall be identified in the offeror’s proposal and will be resolved prior to contract award.

Please note: All offerors are advised that no additional questions will be accepted by the Government for this solicitation posting. Should the offerors encounter difficulties obtaining quotes for parts they are instructed to contact the contracting office for resolution immediately.

FA8121-21-R-0002-0004

PART III - LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J

LIST OF ATTACHMENTS

Form Number Description/File Name Date Number of Pages F100_229_RemanPricingMatrix_13MAY2021.xlsx 13MAY2021 3