FA5709-14-R-0013_One_Year_Reefer_Maintenance_Service_Solicitation_Published.pdf

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE 17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NO.

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

RFQ IFB RFP

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

29. AWARD OF CONTRACT: REF.

DATED . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 3/2005)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITON IS

UNRESTRICTED OR

NAICS:

SIZE STANDARD:

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

OFFER

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

SET ASIDE: % FOR:

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS

EMERGING SMALL

BUSINESS

8(A)

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

DFAS-Limestone 27 Arkansas Road Limestone, ME 04751-6216

X

See Schedule

FA5709

SEE SCHEDULE

FA5709-14-R-0013

01-Jul-2014 Nicholas Turner 318-468-5580 nicholas.turner@trab.afcent.af.mil

405 ESPTS/ECONS

APO AE 09328-0000

Nicholas Turner

01-Jul-2014

16-Jul-2014 03:00 PM

F67100

405 ESPTS/ECONS

APO AE 09328-0000

FA5709

See Schedule

405 ESPTS/ECONS

APO AE 09328-0000

FA5709

318-468-5580

STANDARD FORM 1449 (REV. 3/2005) BACK

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

40. PAID BY

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELPHONE NUMBER OF AUTHORZED GOVERNMENT REPRESENTATIVE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

PARTIAL FINAL

37. CHECK NUMBER

38. S/R ACCOUNT NO. 39. S/R VOUCHER NUMBER

36. PAYMENT

COMPLETE PARTIAL FINAL

CONTRACT PIIN : FA5709-14-R-0013

Supplies or Services and Price/Costs

LINE ITEM QUANTITY UNIT OF ISSUE UNIT PRICE EXTENDED

PRICE

COST

CONSTRAINTS

0001 17.0000 Each - - Firm

Option:

Nomenclature: Refrigerator Unit Maintenance Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

FOB: Inspection: Destination Acceptance: Destination Description: Refrigerator Unit Maintenance 17 Units a month for 12 months

COST

CONSTRAINTS

0002 1.0000 Each - - Firm

Option:

Nomenclature: Parts for Reefers Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Parts for Reefers as needed

COST

CONSTRAINTS

0003 12.0000 Each - - Firm

Option:

Nomenclature: Service Calls Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Service Calls Refrigerated Unit Maintenance 17 units as needed

COST

CONSTRAINTS

1001 17.0000 Each - - Firm

Option: Option Nomenclature: Refrigerator Unit Maintenance Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 1 - Refrigerator Unit Maintenance 17 Units a month for 12 months

COST

CONSTRAINTS

1002 1.0000 Each - - Firm

Option: Option Nomenclature: Parts for Reefers Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 1 - Parts for Reefers as needed

COST

CONSTRAINTS

1003 12.0000 Each - - Firm

Option: Option Nomenclature: Service Calls Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 1 - Service Calls Refrigerated Unit Maintenance17 units as needed

COST

CONSTRAINTS

2001 17.0000 Each - - Firm

Option: Option Nomenclature: Refrigerator Unit Maintenance Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 2 - Refrigerator Unit Maintenance 17 Units a month for 12 months

COST

CONSTRAINTS

2002 1.0000 Each - - Firm

Option: Option Nomenclature: Parts for Reefers Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 2 - Parts for Reefers as needed

COST

CONSTRAINTS

2003 12.0000 Each - - Firm

Option: Option Nomenclature: Service Calls Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 2 - Service Calls Refrigerated Unit Maintenance17 units as needed

COST

CONSTRAINTS

3001 17.0000 Each - - Firm

Option: Option Nomenclature: Refrigerator Unit Maintenance Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 3 - Refrigerator Unit Maintenance 17 Units a month for 12 months

COST

CONSTRAINTS

3002 1.0000 Each - - Firm

Option: Option Nomenclature: Parts for Reefers Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 3 - Parts for Reefers as needed

COST

CONSTRAINTS

3003 12.0000 Each - - Firm

Option: Option Nomenclature: Service Calls Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 3 - Service Calls Refrigerated Unit Maintenance17 units as needed

COST

CONSTRAINTS

4001 17.0000 Each - - Firm

Option: Option Nomenclature: Refrigerator Unit Maintenance Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 4 - Refrigerator Unit Maintenance 17 Units a month for 12 months

COST

CONSTRAINTS

4002 1.0000 Each - - Firm

Option: Option

Nomenclature: Parts for Reefers Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

Description: Option Year 4 - Parts for Reefers as needed

COST

CONSTRAINTS

4003 12.0000 Each - - Firm

Option: Option Nomenclature: Service Calls Nsn:

Noun:

Part Number /

FSCM:

Serial Number:

Contract Type: Firm-Fixed-Price Contract ACRN: Dollars Obligated: $ PR Number: PR Line Item

Number:

CIN/SDN:

FOB: Inspection: Destination Acceptance: Destination Description: Option Year 4 - Service Calls Refrigerated Unit Maintenance17 units as needed

Inspection and Acceptance

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government 1001 Destination Government Destination Government 1002 Destination Government Destination Government 1003 Destination Government Destination Government 2001 Destination Government Destination Government 2002 Destination Government Destination Government 2003 Destination Government Destination Government 3001 Destination Government Destination Government 3002 Destination Government Destination Government 3003 Destination Government Destination Government 4001 Destination Government Destination Government 4002 Destination Government Destination Government 4003 Destination Government Destination Government

Deliveries and Performance

Period of Performance

CLIN START DATE END DATE WORK LOCATION

(DoDAAC)

WORK LOCATION (ADDRESS)

0001 1-Aug-2014 31-Jul-2015 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

0002 1-Aug-2014 31-Jul-2015 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

0003 1-Aug-2014 31-Jul-2015 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

1001 1-Aug-2015 31-Jul-2016 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

1002 1-Aug-2015 31-Jul-2016 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

1003 1-Aug-2015 31-Jul-2016 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

2001 1-Aug-2016 31-Jul-2017 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

2002 1-Aug-2016 31-Jul-2017 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

2003 1-Aug-2016 31-Jul-2017 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

3001 1-Aug-2017 31-Jul-2018 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

3002 1-Aug-2017 31-Jul-2018 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

3003 1-Aug-2017 31-Jul-2018 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

4001 1-Aug-2018 31-Jul-2019 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

4002 1-Aug-2018 31-Jul-2019 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

4003 1-Aug-2018 31-Jul-2019 FA5709

405 ESPTS/ECONS

APO AE 09328-0000

Contract Administration Data

Payment by Electronic Funds Transfer (EFT)

(a) Method of payment.

1. All payments by the US Government under this contract shall be made by electronic funds transfer (EFT).

(b) Submission of Contractor's EFT information.

1. The Contractor is required to provide the US Government with the information required to make payment by EFT. In the event the EFT information changes, the Contractor shall be responsible for providing the updated information to the paying office.

2. If the Contractor provides EFT information applicable to multiple contracts, the Contractor shall provide the contract numbers to which it applies. The contractor will inform the contracting officer of previously awarded contracts for which the contractor requests EFT payment.

Invoicing Procedures:

Upon delivery, the contractor shall provide a proper invoice. A proper invoice shall include the following information:

* Name, address of the business concern, invoice number, and the invoice date

* Contract number or other authorization for delivery of property and/or services (including order number and contract line item number)

* Description, price, and quantity of property or services actually delivered or rendered

* Shipping and payment terms

* Other substantiating documentation or information as required by the contract

* Name (where applicable) title, telephone number, and complete mailing address of the responsible official to whom payment is to be sent

* It is important that the invoice match the schedule of supplies and service of the contract to avoid delays in processing invoices submitted

* Submit invoices to the contracting office via e-mail shown in the invoicing paragraphs in this order.

* Name of banking institution (must be SWIFT capable) and Electronic Funds Transfer (EFT) Routing information (if applicable)

Include the following banking information:

Bank: _____________________________ Account No: ________________________ Swift Code: ________________________

Properly prepared invoices, bearing the contract number will be submitted to the Contracting Officer via email.

The contractor shall submit all invoices to the Contracting Officer shown in block nine.

Ensure contract number is included in the subject line, for example:

"FA5709-12-C-0004 Invoice"

Contract Clauses

SPECIAL CONTRACT REQUIREMENTS

H-1 GOVERNING LAW

This contract shall be construed and interpreted in accordance with the substantive laws of the United States of America. By the execution of this contract, the Contractor expressly agrees to waive any rights to invoke the jurisdiction of local national courts where this contract is performed and agrees to accept the exclusive jurisdiction of the United States Armed Services Board of Contract Appeals and the United States Court of Federal Claims for the hearing and determination of any and all disputes that may arise under the Disputes clause of this contract.

H-2 ENGLISH SPEAKING REPRESENTATIVE

At all times when any performance of the work at any site is being conducted by any employee of the Contractor or its subcontractors, the Contractor shall have a representative present at each site who has the capability of reading, writing, speaking, and receiving instructions in the English language and can explain the work operations to persons performing the work in the language that those performing the work are capable of understanding. The Contracting Officer shall have the right to determine whether the proposed representative has sufficient technical and lingual capabilities.

H-3 ENVIRONMENTAL IMPACT/COMPLIANCE WITH APPLICABLE FEDERAL,

STATE AND LOCAL REQUIREMENTS

All waste materials generated by work under a contract performed on a Government installation shall be handled, transported, stored, disposed of, and treated by the contractor and any subcontractor in accordance with all applicable federal, state, and local laws, ordinances, regulations, executive orders, agency rules or order, court orders, or any other types of rules or ruling having the effect of the law. In performing work under this contract, the contractor shall comply with all other relevant federal, state and local statutes, ordinances, regulations, executive orders, agency rules or orders, court orders or any rules ruling having the effect of law.

H-4 MUSLIM AND OMANI HOLIDAYS

The U.S. Government acknowledges the following holidays: Ramadan, Eid Al Fitr, Eid Al Adha, and accepts the notion that the contractor may decide not to work on these days, or to work reduced hours on these days. However, the contractor understands, and agrees, that the performance period for this contract includes any and all non-productive time attributable to the contractor's observance of these holidays. The contractor shall notify the Contracting Officer of the holidays it intends to observe; and whether it intends to work reduced hours or not at all.

H-5 HAZARDOUS WASTE REMOVAL

The Contractor shall dispose of all hazardous waste in accordance with all applicable laws and regulation. The Contractor shall assume the responsibility of determining what constitutes "hazardous waste" and complying with all environmental laws and regulations governing its removal.

H-6 MATERIAL SAFETY DATA SHEET

A Material Safety Data Sheet (MSDS), OSHA Form 20 or accepted equivalent, must be submitted for each hazardous or potentially hazardous, material or chemical to be utilized by the contractor. This includes solvents or treated materials, such as preservative treated wood (MSDS for preservative) or fungicide treated rubber goods (MSDS for fungicide). All, materials must be approved by the Contracting Officer or their designated representative prior to installation.

H-7 SALVAGE MATERIALS

(a) All items of Government property indicated on the drawings or in the specifications to be removed and disposed of by the contractor shall become the property of the contractor and shall be removed promptly from the installation and legally disposed of.

(b) Contractor is encouraged to recycle salvage materials when possible.

H-8 COORDINATION OF WORK WITH OTHER CONTRACTS

The Government may undertake or award other contracts for additional work at or near the site of the work under this contract. The Contractor shall fully cooperate with other contractors and with Government employees and shall carefully adapt scheduling and performing the work under this contract to accommodate the additional work, heeding any direction that may be provided by the Contracting Officer. The Contractor shall not commit or permit any act that will interfere with the performance of work by any other contractor or by Government employees.

H-9 SECURITY / PASS REQUIRMENTS

(a) The contractor shall follow existing security procedures and instructions applicable to Thumrait Air Base, Oman. Contractor personnel working on Thumrait shall hold a current Omani Pass necessary to gain access through Thumrait. Only Omani registered vehicles and personnel with Omani IDs are authorized entry onto Thumrait AB.

i. Contractor management staff shall ensure that all employees and subcontract employees visa and passport shall remain current during the life of the contract. At no time shall contractor management staff permit personnel currently issued a pass to hold visa or passports that expire during the performance period.

ii. Base Access Requests and DBIDS Paperwork shall be submitted no later than five (5) calendar days after notice of contract award. All Base Access paperwork shall be kept current for the duration of the contract's period of performance. If a base pass is going to expire before contract completion and renewal is needed: the contractor shall re-submit renewal Base Access Requests at least 21 (twenty-one) calendar days prior to expiration of the original base access pass. The contractor is responsible to ensure the resident ID cards and visas remain current throughout the duration of the contract period.

iii. The contractor is solely responsible for the submission and approval of passes and the government shall not be held liable for any delays due to obtaining base access passes.

(b) The work site is located in a restricted or controlled area. The contractor may therefore experience delays due to compliance with entrance/exit requirements of restricted/controlled areas. The maximum amount of delay shall not exceed four (4) hours per occurrence.

(c) The contractor is responsible for providing the Contracting Officer with a list of company personnel that will be used to execute the contract as well as the description of any vehicles to be used during the execution of the contract. The information required for base pass requests includes but is not limited to:

i. General Info:

-Cover Letter from Contractor to Royal Air Force of Oman requesting base access and stating the purpose of the pass (shall be in Arabic &English) -Subcontractor agreements with signature and stamp, if applicable (shall be in Arabic &English) -Copy of the contract with contractor signature and stamp

ii. Listing of personnel:

-Name -Nationality

-Clear copy of Resident ID Card (front &back) -Clear copy of Driver License, if driving (front &back)

iii. Listing of Equipment:

-Make -Model -License plate numbers -Copy of Vehicle Registration -All workers job description on the resident ID card must match the job in accordance with the contract

H-10 SECURITY/SEARCH

(a) Before entry through the Thumrait Gate, contractor personnel and vehicles shall process through the search area.

(b) Material including but not limited to concrete, asphalt emulsions, and other time critical materials will require search and surveillance by the U.S Air Force personnel from the point of origin to the search area. The contractor shall notify the designated Project Inspector four (4) days in advance of the schedule delivery. The contractor shall immediately notify the Project Inspector of changes. Changes shall require an additional four (4) days for Government personnel coordination. The U.S Air Force shall not be liable for delays resulting from the contractor's failure to follow the above notification requirements or supplier/contractor delivery changes.

(c) Tanker truck/trailer cargo compartments shall allow for a complete visual inspection. All tanks and the baffled sections shall have a minimum 3 ft /.91-meter diameter visual inspection port. Equipment not meeting the above requirements shall not be allowed entry onto Thumrait Air Base. The U.S Air Force shall not be liable for delays caused by equipment not meeting the above requirements.

(d) The contractor shall be responsible for safeguarding all government property for the contractor use. At the close of each work period, government facilities, equipment and material shall be secured.

(e) The contractor is hereby advised that these requirements are subject to change at any time during the performance of this contract. The contractor shall comply with any changes to U.S.

Government procedures at the direction of the Contracting Officer. It is the contractor's responsibility to be aware of and comply with any changes to Omani Government procedures.

H-11 ESCORTS

(a) Upon entry through the Thumrait Gate, contractor personnel are required to be in the presence of a military escort while on the Thumrait at all times. Escorts shall be provided by the U.S Air Force. The contractor shall comply with escort directions. Initially the contractor shall notify the designated Project Manager 72 hours in advance of any revised personnel/escort requirements. The contractor shall notify the designated Project Inspector 72 hours in advance of any change in time that the escorts shall meet the contractor and/or when the number of contract workers increases or decreases. The contractor will not be able to start work until escort arrangements are made. The U.S Air Force shall not be liable for delays caused by the contractor's failure to follow the above notification requirements.

(b) The contractor is hereby advised that these requirements are subject to change at any time during the performance of this contract. The contractor shall comply with any changes to U.S.

Government procedures at the direction of the Contracting Officer. It is the contractor's responsibility to be aware of and comply with any changes to Omani Government procedures.

H-12 Defense Biometric Identification System (DBIDS) Enrollment

Third County Nationals (TCNs) who access the installation are required to enroll in the Defense Biometric Identification System (DBIDS). Effective 16 Aug 2009, all workers who access the installation must be enrolled in DBIDS or access will be denied. TCNs will be issued a DBIDS pass for the duration of the contract they are working on or their work visa, whichever comes sooner. In addition, all TCNs are required to carry a copy of their Entry Authorization Application (EAA) with them at all times. Access to the installation will be denied by US and/or Omani officials if either the DBIDS pass or the EAA is not current and valid. DBIDS procedures may be changed at the discretion of the government at any time during the performance of this contract; the contractor must comply with any changes to DBIDS procedures upon direction of the contracting officer. The government will not be liable for any delays to contract performance resulting from the contractor's failure to comply with this clause.

DBIDS Access Cards (DAC) shall be displayed at all times while on the installation.

H-13 NORMAL WORK HOURS

Normal work hours at Thumrait Air Base for this project are 0700Hrs to 1800Hrs, Saturday through Thursday, excluding holidays. Access to work sites shall be restricted to these hours and days. Work that requires inspection during accomplishment or that prevents inspection of previous work after accomplishment normally will not be allowed during other than the normal work hours specified above. The Contracting Officer must approve work during other than normal hours. Requests must be submitted in writing, seven (7) days in advance and shall include proposed work hours and outline specific work to be performed.

H-14 MATERIAL &EQUIPMENT EXIT PERMIT

Prior to removing material and/or equipment from Thumrait, the contractor shall notify the designated Project Manager 48 hours in advance of any requirement to remove material and/or equipment from Thumrait AB. The U.S Air Force shall not be liable for delays resulting from the contractor's failure to follow the above notification requirements. The U.S Air Force shall not be liable for delays resulting from permit coordination/approval.

H-15 380TH AEWI 31-102 02 May 2009

TCN/CONTRACTOR RULES

I am your escort official. I am responsible for your safe and secure conduct until you leave the area. While you are in this area, you must be under escort at all times. If for any reason you are separated from your escort, you must contact the first American military member you see and have them escort you to the main entry control point of the American compound.

EXCEPTION: If you are in a designated work area, you must remain in that area and attempt to contact any American military member and have them contact Security Forces.

You will not be allowed into any areas unescorted, especially living quarters. Visitors are not allowed to bring any hand-carried items (with the exception of personal items and tools) into the area without written permission. Is there anyone who has any hand-carried items? (Verify the authorization -- search items with the assistance of Security Forces).

The following are prohibited items: wear of any type of US military uniform, cellular telephones, mobile radios, beepers, pagers, or any other type of communication device, still cameras or video recording devices, and contraband (weapons, drugs, etc.). EXCEPTION:

TCNs or contractors may carry a cellular telephone if they possess a signed letter of authorization from 405 ESPTS/SC. This letter must contain the name of the authorized individual; the name of the company represented, and has an expiration date not to exceed six months. This letter is required to be carried at all times when in possession of a cellular telephone.

You are not allowed to bring vehicles into the area unless the vehicle is mission essential and has passed through the Security Forces search pit. If you are in a convoy, follow your escort, and do not leave the convoy. Drive with your flashers on at all times while on the installation. If for any reason I stop so must you. If you get separated from the convoy, stop and wait to be contacted; do not proceed ahead. Do not leave your job site without an escort. I must remain in line of sight and within 150 feet at all times.

Do not record any information; any information written or recorded will be confiscated. Do not ask or request official or personal information from any US personnel. Do not go through any papers or trash. Your issued badge must be displayed on the upper torso after I have verified it is not expired and you are the owner of the badge. This badge must be displayed at all times while on the installation. If you need to remove the badge for safety reasons contact your escort and ask permission.

Do not attempt to take anything off the installation you did not bring on.

H-16 CONTRACTOR CHANGE OVER:

The Government reserves the right to conduct site visits in all contractor-operated facilities in conjunction with this contract. In the event that a follow on contract is awarded to other than the incumbent, the incumbent Contractor will cooperate to the extent required to permit an orderly changeover to the successor Contractor.

H-17 LIABILITY:

The Government shall not be held responsible for damages to property or for injuries or death to persons, which might occur without fault on the part of the Government as a result of, or incident to, performance of work.

H-18 PERMITS AND RESPONSIBILITIES FOR WORK:

The contractor shall, without additional expense to the Government obtain all passes, certifications, clearances, licenses and permits required for performance of work. The contractor shall be responsible for all damages to persons or property that occurs as a result of his fault or negligence in connection with the performance of work.

H-19 UTILITY SERVICES:

The Contracting Officer has determined that Government operated utilities are adequate and will be furnished to the contractor without charge where existing outlets/supplies are available.

H-20 CONTRACTOR RESPONSIBILITY

Contractors operating on base will be responsible for briefing and ensuring their employees adhere to the traffic rules, regulations and all security measures to include: not asking any security related questions, soliciting any personal information from any government employee, and transporting any items for government personnel. The foreman, job site supervisor, and other personnel providing workman leadership will, when possible, ensure the workers comply with these rules and regulations. The speed limit on base is 20 KPH unless otherwise posted.

Individuals are to obey all entry procedures. If instructions are given by Security Forces personnel, they will be complied with immediately.

H-21 COMPLIANCE WITH LOCAL LABOR LAWS

The Contractor shall be responsible for complying with any and all local laws, regulations, and labor union agreements governing hours, wages, labor regulations (including collective bargaining), workers compensation, working conditions, fringe benefits, and other matters pertaining to labor standards and contracts. The contractor hereby indemnifies and holds harmless the United States Government from any and all claims of any type arising out of or in connection with the requirements of this contract. This indemnity shall include the obligation of the Contractor to handle and settle without cost to the United States Government, any claims or litigation against the United States Government based on the allegation that the Contractor or the United States Government or both have not fully complied with local labor laws or regulations relating to performance of the work required by this contract.

(END OF SECTION)

CLAUSES AND PROVISIONS

(a) Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

(b) Clauses and provisions in this document will be numbered, but will not necessarily appear in consecutive order.

(c) Sections K, L, and M will be physically removed from any resultant award, but will be deemed to be incorporated, by reference, in that award.

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE FEB 1998

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

http://farsite.hill/af.mil/reghtml/regs/far2afmcfars/fardfars/far/far1toc.htm http://farsite.hill/af.mil/reghtm/regs/far2afmcfars/fardfars/dfars/dfar1toc.htm http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/af_afmc/affars/affar1toc.htm

(END CLAUSE)

Clauses Incorporated by Reference 52.202-1 Definitions (Jan 2012) 52.203-5 Covenant Against Contingent Fees (Apr 1984) 52.203-6 Alt I Restrictions on Subcontractor Sales to the Government (Sep 2006) 52.203-7 Anti-Kickback Procedures (Oct 2010) 52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions (Sep 2007) 52.203-12 Limitation of Payments to Influence Certain Federal Transactions (Oct 2010) 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011) 52.204-7 Central Contractor Registration (Feb 2012) 52.204-9 Personal Identity Verification of Contractor Personnel (Jan 2011) 52.209-6 Protecting the Governments Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) 52.209-7 Information Regarding Responsibility Matters (Jan 2011) 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (Jan 2012) 52.212-4 Contract Terms and Conditions Commercial Items (Feb 2012) 52.213-3 Notice to Supplier (Apr 1984) 52.214-34 Submission of Offers in the English Language (Apr 1991) 52.215-8 Order of Precedence Uniform Contract Format (Oct 1997) 52.217-5 Evaluation of Options (Jul 1990)

52.223-5 Pollution Prevention and Right-to-Know Information (May 2011) 52.223-6 Drug-Free Workplace (May 2001) 52.223-10 Waste Reduction Program (May 2011) 52.223-11 Ozone-Depleting Substances (May 2001) 52.225-19 Contractor Personnel in a Designated Operational Area or Supporting a Diplomatic or Consular Mission Outside the United States (Mar 2008) 52.228-5 Insurance Work on a Government Installation (Jan 1997) 52.232-8 Discounts for Prompt Payment (Feb 2002) 52.232-17 Interest (Oct 2010) 52.232-18 Availability of Funds (Apr 1984) 52.232-23 Assignment of Claims (Jan 1986) 52.233-1 Disputes (July 2002) 52.237-2 Protection of Government Buildings, Equipment, and Vegetation (Apr 1984) 52.237-3 Continuity of Services (Jan 1991) 52.242-13 Bankruptcy (Jul 1995) 52.245-1 Government Property (Aug 2010) 52.246-4 Inspection of Services Fixed-Price (Aug 1996) 52.249-2 Termination for Convenience of the Government (Fixed-Price) (May 2004) 52.249-8 Default (Fixed-Price Supply and Service) (Apr 1984) 52.253-1 Computer Generated Forms (Jan 1991) 252.201-7000 Contracting Officers Representative (Dec 1991) 252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies (Dec 2008) 252.204-7004 Alternate A, Central Contractor Registration (Sep 2007) 252.209-7001 Disclosure of Ownership or Control by the Government of a Terrorist County (Jan 2009) 252.209-7002 Disclosure of Ownership or Control by a Foreign Government (Jun 2010) 252.209-7004 Subcontracting with Firms That Are Owned or Controlled by the Government of a Terrorist County (Dec 2006) 252.223-7004 Drug-Free Work Force (Sep 1988) 252.225-7042 Authorization to Perform (Apr 2003) 252.243-7001 Pricing of Contract Modifications (Dec 1991) 5352.223-9001 Health and Safety on Government Installations (Jun 1997)

CLAUSES INCORPORATED BY FULL TEXT

52.209-5 Certification Regarding Responsibility Matters (Apr 2010)

(a)

(1) The Offeror certifies, to the best of its knowledge and belief, that --

(i) The Offeror and/or any of its Principals --

(A) Are [_] are not [_] presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have [_] have not [_], within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks have , the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are [_] are not [_] presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision; and

(D) Have [_], have not [_], within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples.

(i) The taxpayer has received a statutory notice of deficiency, under I.R.C. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has [[_] has not [_], within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer; director; owner; partner; or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offerors responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror non-responsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders Commercial Items (Feb 2012)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)).

____ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)).

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108- 78).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

_X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110- 252, Title VI, Chapter 1 (41 U.S.C. 251 note)).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

___ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Feb 2012) (Pub. L. 109-282) (31U.S.C. 6101 note).

___ (5) 52.204-11, American Recovery and Reinvestment ActReporting Requirements (Jul 2010) (Pub. L. 111-5).

_X__ (6) 52.209-6, Protecting the Government Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) (31 U.S.C. 6101 note).

___ (7) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jan 2012) (41 U.S.C. 2313).

___ (8) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (section 740 of Division C of Public Law 111-117, section 743 of Division D of Public Law 111-8, and section 745 of Division D of Public Law 110-161).

___ (9) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C.

657a).

___ (10) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

___ (11) [Reserved] ___ (12) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

___ (ii) Alternate I (Nov 2011).

___ (iii) Alternate II (Nov 2011).

___ (13) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

___ (14) 52.219-8, Utilization of Small Business Concerns (Jan 2011) (15 U.S.C. 637(d)(2) and (3)).

___ (15) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2011) (15 U.S.C. 637 (d)(4).)

___ (ii) Alternate I (Oct 2001) of 52.219-9.

___ (iii) Alternate II (Oct 2001) of 52.219-9.

___ (iv) Alternate III (July 2010) of 52.219-9.

___ (16) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

___ (17) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

___ (18) 52.219-16, Liquidated Damages Subcontracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

___ (19) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008) (10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer).

___ (ii) Alternate I (June 2003) of 52.219-23.

___ (20) 52.219-25, Small Disadvantaged Business Participation Program Disadvantaged Status and Reporting (Dec 2010) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323).

___ (21) 52.219-26, Small Disadvantaged Business Participation Program Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323).

___ (22) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f).

___ (23) 52.219-28, Post Award Small Business Program Representation (Apr 2009) (15 U.S.C.

632(a)(2)).

___ (24) 52.219-29, Notice of Set-Aside for Economically Disadvantaged Women-Owned Small Business Concerns (Nov2011).

___ (25) 52.219-30, Notice of Set-Aside for Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Nov 2011).

_X__ (26) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X__ (27) 52.222-19, Child Labor Cooperation with Authorities and Remedies (Jul 2010) (E.O.

13126).

_X__ (28) 52.222-21, Prohibition of Segregated Facilities (Feb 1999).

___ (29) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246).

___ (30) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212).

___ (31) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C.

793).

___ (32) 52.222-37, Employment Reports on Veterans (Sep 2010) (38 U.S.C. 4212).

_X_ (33) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

___ (34) 52.222-54, Employment Eligibility Verification (Jan 2009). (Executive Order 12989).

(Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in22.1803.)

___ (35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA- Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (36) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C.

8259b).

_X__ (37) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423).

___ (ii) Alternate I (Dec 2007) of 52.223-16.

_X_ (38) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011).

___ (39) 52.225-1, Buy American Act--Supplies (Feb 2009) (41 U.S.C. 10a-10d).

___ (40) (i) 52.225-3, Buy American Act--Free Trade Agreements--Israeli Trade Act (June 2009) (41 U.S.C. 10a-10d, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, Pub. L. 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, and 110-138).

___ (ii) Alternate I (Jan 2004) of 52.225-3.

___ (iii) Alternate II (Jan 2004) of 52.225-3.

___ (41) 52.225-5, Trade Agreements (Nov 2011) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

___ (42) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

___ (43) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C.

5150).

___ (44) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

___ (45) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)).

___ (46) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)).

_X__ (47) 52.232-33, Payment by Electronic Funds Transfer Central Contractor Registration (Oct. 2003) (31 U.S.C. 3332).

___ (48) 52.232-34, Payment by Electronic Funds Transfer Other Than Central Contractor Registration (May 1999) (31 U.S.C. 3332).

___ (49) 52.232-36, Payment by Third Party (Feb 2010) (31 U.S.C. 3332).

_X_ (50) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

___ (51) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

___ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

___ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.).

___ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.).

___ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.).

___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.).

___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.).

___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services?Requirements (Feb 2009) (41 U.S.C. 351, et seq.).

___ (7) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247).

___ (8) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract…