ASHE_13-1061_Technical_Specification_June_2017_(Rev_3.1).pdf

Project ASHE 13-1061 Technical Specifications (REV 3.1)

DATE: JUNE 2017

31CES/CENM 1

DATE: JUNE 2017 (REV. 3.1)

U.S. AIR FORCE

31ST FIGHTER WING

31ST CES/CENM

AVIANO AIR BASE, ITALY

TECHNICAL SPECIFICATIONS FOR

ASHE 13-1061 REPLACE AIRFIELD LIGHTS WITH LEDS AREA F

AVIANO AB, ITALY

31CES/CENM 2

1. SCOPE OF WORK: Scope of this work to replace existing airfield taxiway LED elevated fixtures

(295) with flush mounted LED fixtures, the relocation of improperly sited fixtures (9) with flush mounted LED fixtures, and the installation of the missing flush mounted fixtures (29). Work will also include the disposal of old fixtures, lamps and accessories according to environmental law and regulations. The airfield taxiway (TWY) lights are operational twenty-four hours per day, seven days a week, three hundred sixty five days per year to meet mission requirements. In addition to the replacement of the existing 295 fixtures, this project will result in correcting improperly sited or missing lights. TWY Mike requires TWY edge lighting, the North Ramp requires TWY edge lights on the west entrance, TWY Zulu requires TWY edge lights on the west entrance, NATO 14-16 Pads require TWY edge lighting, TWYs A4 and B4 require re-siting in order to have a consistently straight line of lights, and TWY A1 requires re-siting of the lights that are improperly sited. The installed fixtures are to be compliant with the below specifications as well as in accordance with references outlined in paragraph six.

2. WORKS LOCATION: ALPHA Taxiway and BRAVO Taxiway, MIKE Taxiway in front T-bird row, North Ramp apron on the West side entrance, ZULU Taxiway on the West side entrance and NATO 14-16 apron, AREA F, Aviano Air Base.

3. WORK SITE CONDITIONS:

a. The Contractor is permitted to use reasonable quantities of available electricity and water at the work site. The Contractor shall alter characteristics and shall observe conservation practices at all times. All connections shall be the responsibility of the Contractor including restorations to initial conditions.

b. Authorized work hours and days. Performance of work hereunder shall be from Monday through Friday excluding holidays from 08.00 to 17.00 hours. Work during week-ends or holidays may be requested by the Contractor with a minimum of 10 days advance notice, however the Contracting Officer has the right to deny such request if reasons requiring week-end and holiday work are not valid or for security or other necessities. Additionally, requirements to phase in work for this project within the designated period of performance may be required pending mission requirements and airfield scheduling. The schedule shall be approved by the Contracting Officer with the coordination of the 31 CES and 31 OSS prior to starting work.

Contractor may be required to work on Saturdays, Sundays and all Holidays IAW coordinated and approved work schedule. Contractor will be performing the project works IAW coordinated and approved work schedule, Contractor may be required to perform works in one or multiple areas/taxiways simultaneously.

c. Toilet facilities in the vicinity of the work site shall not be available for Contractor use. The Contractor shall provide toilet facilities for use on the site

d. The Contractor shall not use base refuse containers to discard debris. All construction debris shall be discarded by the Contractor off base at authorized sites according to category of debris/refuse in strict observance of all host country laws, decrees and local regulations in force.

e. The Contractor shall be responsible for ensuring all personnel engaged in the performance of this contract observe all host country laws concerning safety and in particular Italian laws D.M.

81/08.

f. At least 5 days prior to the pre-final inspection, the Contractor shall furnish to the Contracting Officer all installed equipment operation and maintenance documentation, certificates

31CES/CENM 3

concerning installed systems as required by host country laws, test reports and results and as built drawings where required by host nation laws.

g. Before works start, contractor will submit a detail works schedule to C.O. for coordination and approval.

h. The entire performance of this project will be in restricted areas requiring controlled entry/exit and escort at all times and this shall be considered during development of the work schedule.

The government will not be held liable for unproductive time and other related costs due to delays in access/exit to/from the restricted areas or unannounced and immediate suspension of work due to military operations and/or exercises or safety reasons.

The government will only negotiate an equitable extension of the performance period based on documented delays and unannounced suspensions of work.

i. The light base and light fixtures to be installed shall be certified in accordance with (IAW) FAA regulations and guidance (Ref: FAA Advisory Circular and FAA Type Certificate Data Sheets (TCDS) database).

31CES/CENM 4

4. WORK DESCRIPTION

EACH ITEM OF THE SCHEDULE IS INCLUSIVE OF FURNISHING AND INSTALLATION OF

MATERIALS AND EQUIPMENT, SCAFFOLDING, TRANSPORTATION TO DUMP OR

STORAGE OF DEMOLISHED AND/OR REMOVED MATERIALS, IN ACCORDANCE WITH

CONTRACTING OFFICER'S INSTRUCTIONS AND ALL FINISHING WORK REQUIRED TO

MAKE EACH ITEM COMPLETE IN A WORKMANLIKE MANNER.

ALL THE QUANTITIES THAT ARE INDICATED OR SUCCESSIVELY ADDED ARE

ESTIMATES. THEREFORE THE GOVERNMENT SHALL BE NOT HELD RESPONSIBLE FOR

THE ACCURACY OF THE ESTIMATED QUANTITIES. THE CONTRACT REQUIRES A

COMPLETED PROJECT ON A LUMP SUM BASIS. IT IS THEREFORE THE RESPONSIBILITY

OF THE CONTRACTOR TO CALCULATE, FORESEE AND PERFORM ALL QUANTITIES AND

WORK NECESSARY EVEN IF NOT MENTIONED IN THE SPECIFICATIONS BUT INCLUDED

IN THE DRAWINGS OR MANIFESTLY NECESSARY TO DELIVER A COMPLETE PROJECT

BASED ON ITS OVERALL SCOPE.

4.1 INSTALL/RELOCATE FLUSH MOUNTED LED LIGHTS AT ALPHA AND BRAVO

TAXYWAYS

4.1.a Remove existing elevated airfield taxiway fixtures in accordance with current law in matter.

Item shall also include:

• Removal existing MV (6kV) connectors;

• Removal of the existing MV (6kV) electrical lines and temporary reconnection from the closer hand holes of the existing primary circuit cable;

• Disconnection and removal of to the transformer;

• Transportation and storage of materials to be reused to storage area or disposed IAW

Italian Law, as directed by the Contracting Officer’s Technical Representative;

• Manpower, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 295

4.1.b Furnishing and installation galvanized 12” light bases, 24” depth, recessed type, complete with gasket FAA approved, certified for application subjected to aircraft and other heavy vehicular loads certified IAW FAA L868, type ADB 868B24 xH1PA or equal approved included mounting accessories. Light bases shall be installed in order to have the fixture at road level, Pic.1 shows a picture of a properly in-set flush mounted fixture.

Item shall also include:

• Compliance to L-867 & L-868 AC 150/5345-42 (Current Edition);

• The removal and disposal IAW the Italian codes of the existing light base to be relocated, the filling in layers of the holes and the compaction to the maximum density and the leveling and repair of the surfaces. Only when unused bases are necessary to be re-used to allow change path of the conduit, they shall be simply closed with solid removable cover and that neither removal/disposal nor returning the site to the condition that existed prior to the installation of the old fixture/base will be necessary;

• New 2 Way cable duct for the HV cables from the closer hand holes of the existing primary circuit cable, approx. 2m. The cable duct shall be realized with a heavy rigid

31CES/CENM 5

63 mm diameter PVC pipes, thickness of the pipe walls 4.5 mm, covered with C20/25 Class concrete;

• Supply and install approx. 50 m of 6kV cables 1x6 sqmm, single conductor, XLPE insulated, non-shielded, according to the FAA AC 150/5345-7E (L-824 Type C) Specification, ETL and CE certified. The 6kV cables will run in the new 2 Way cable duct.

Connection distance shall consider a solid cable from the previous fixture to the following one. Any unnecessary connection/junction in the electrical circuit shall be avoided;

• Coring;

• The equipotential connections of the metallic masses, including the cover and the reinforcement bars, with N07V-K cable, section 16 mm2, complete of terminals, anchoring for the drawing of the cables, cable racks and necessary accessories for the proper installation and service.

• Cut and removal of pavements and sidewalks.

• The excavation of soil of any kind and consistence, including rock, with mechanical means, 70 cm width trench and various depths for the installation of the cable duct in compatible manner with the existing utilities. The average depth of the trench shall be 90 cm;

• The leveling and the compaction of the bottom of the trench and the addition of necessary excavation for the construction of the manholes;

• The installation of warning red PVC tape with the writing “HV CABLES”;

• The filling in layers of the trenches and the compaction to the maximum density;

• The leveling and repair of the surfaces;

• The transportation to the authorized public dump of the surplus excavated material, including the dump fees;

• Manpower, tools accessories and every other necessary item to provide a job in a

EA 70

4.1.c Furnish and install primary MV series circuit n.1 receptacle connector and n. 1 plug connector kit for unshielded cable type ADB PRKU1A/ PRKU1B, or equal approved, depending on the section of the primary conductor (to be determined before installation by the contractor).

Item shall also include:

• Compliance to ICAO Aerodrome Design Manual Part 5 and FAA L-823 AC 150/5345-

26 (L-823) current edition;

• Heat Shrink Kit type ADB 71A00088-U or equal approved;

• 30VA insulating transformer;

• Manpower, cleaning of contacts, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 295

4.1.d Furnish and install flush mounted LED Taxiway Light Fixtures, Aviation Blue, 12” diameter, 50Hz, provided with built in defrost system, Type ADB ITEL C121 or equal approved, included mounting accessories and neoprene grommet.

31CES/CENM 6

• Compliance to FAA L-852T(L) AC 150/5345-46 (Current Edition) , FAA Engineering Brief No. 67, ETL, ICAO Annex 14, Vol. I, Ed. 6, para. 5.3.18, CE marking IAW EMC Directive 2004/108/EC;

• 100% checking of the pressurization of each single fixture in accordance with manufacturer specs;

• Connection of electrical lines, cleaning of contacts, manpower, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 295

31CES/CENM 7

Pic. 1: Replacing of Elevated light with flush-mounted LED lights at Alpha and Bravo Taxiway

31CES/CENM 8

4.2 LIGHTS 3FT MOVING AT ALPHA 1: A1-4, A1-5, A1-7 / BRAVO 4: B4-2, B4-4, B4-6,

B4-6

4.2.a Remove existing elevated airfield taxiway fixtures in accordance with current law in matter.

Item shall also include:

• Removal existing MV (6kV) connectors;

• Removal of the existing MV (6kV) electrical lines and temporary reconnection from the closer hand holes of the existing primary circuit cable;

• Disconnection and removal of to the transformer;

• Transportation and storage of materials to be reused to storage area or disposed IAW

Italian Law, as directed by the Contracting Officer’s Technical Representative;

• Manpower, tools accessories and every other necessary item to provide a job in a

EA 7

4.2.b Furnishing and installation galvanized 12” light bases, 24” depth, recessed type, complete with loads certified IAW FAA L868, type ADB 868B24 xH1PA or equal approved included mounting accessories. Light bases shall be installed in order to have the fixture at road level, Pic.1 shows a picture of a properly in-set flush mounted fixture.

Item shall also include:

• Compliance to L-867 & L-868 AC 150/5345-42 (Current Edition);

• The removal and disposal IAW the Italian codes of the existing light base to be relocated, the filling in layers of the holes and the compaction to the maximum density and the leveling and repair of the surfaces. Only when unused bases are necessary to be re-used to allow change path of the conduit, they shall be simply closed with solid removable cover and that neither removal/disposal nor returning the site to the condition that existed prior to the installation of the old fixture/base will be necessary;

• New 2 Way cable duct for the HV cables from the closer hand holes of the existing primary circuit cable, approx. 2m. The cable duct shall be realized with a heavy rigid 63 mm diameter PVC pipes, thickness of the pipe walls 4.5 mm, covered with C20/25 Class concrete;

• Supply and install approx. 60 m of 6kV cables 1x6 sqmm, single conductor, XLPE insulated, non-shielded, according to the FAA AC 150/5345-7E (L-824 Type C) Specification, ETL and CE certified. The 6kV cables will run in the new 2 Way cable duct.

Connection distance shall consider a solid cable from the previous fixture to the following one. Any unnecessary connection/junction in the electrical circuit shall be avoided;

• Coring;

• The equipotential connections of the metallic masses, including the cover and the reinforcement bars, with N07V-K cable, section 16 mm2, complete of terminals, anchoring for the drawing of the cables, cable racks and necessary accessories for the proper installation and service.

• Cut and removal of pavements and sidewalks.

31CES/CENM 9

• The excavation of soil of any kind and consistence, including rock, with mechanical means, 70 cm width trench and various depths for the installation of the cable duct in compatible manner with the existing utilities. The average depth of the trench shall be 90 cm;

• The leveling and the compaction of the bottom of the trench and the addition of necessary excavation for the construction of the manholes;

• The installation of warning red PVC tape with the writing “HV CABLES”;

• The filling in layers of the trenches and the compaction to the maximum density;

• The leveling and repair of the surfaces;

• The transportation to the authorized public dump of the surplus excavated material, including the dump fees;

• Manpower, tools accessories and every other necessary item to provide a job in a

EA 7

4.2.c Furnish and install primary MV series circuit n.1 receptacle connector and n. 1 plug connector kit for unshielded cable type ADB PRKU1A/ PRKU1B, or equal approved, depending on the section of the primary conductor (to be determined before installation by the contractor).

Item shall also include:

• Compliance to ICAO Aerodrome Design Manual Part 5 and FAA L-823 AC 150/5345- 26 (L-823) current edition;

• Heat Shrink Kit type ADB 71A00088-U or equal approved;

• 30VA insulating transformer;

• Manpower, cleaning of contacts, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 7

4.2.d Furnish and install flush mounted LED Taxiway Light Fixtures, Aviation Blue, 12” diameter, 50Hz, provided with built in defrost system, Type ADB ITEL C121 or equal approved, included mounting accessories and neoprene grommet.

Item shall also include:

• Compliance to FAA L-852T(L) AC 150/5345-46 (Current Edition) , FAA Engineering Brief No. 67, ETL, ICAO Annex 14, Vol. I, Ed. 6, para. 5.3.18, CE marking IAW EMC Directive 2004/108/EC.

• 100% checking of the pressurization of each single fixture in accordance with manufacturer specs.

• Connection of electrical lines, cleaning of contacts, manpower, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 7

4.3 LIGHTS MOVING [Zulu North-East Inactive PAD x2]

4.3.a Remove existing elevated airfield taxiway fixtures in accordance with current law in matter.

• Removal existing MV (6kV) connectors;

31CES/CENM 10

• Removal of the existing MV (6kV) electrical lines and temporary reconnection from the closer hand holes of the existing primary circuit cable;

• Disconnection and removal of to the transformer;

• Transportation and storage of materials to be reused to storage area or disposed IAW

Italian Law, as directed by the Contracting Officer’s Technical Representative;

• Manpower, tools accessories and every other necessary item to provide a job in a

EA 2

4.3.b Furnishing and installation galvanized 12” light bases, 24” depth, recessed type, complete with loads certified IAW FAA L868, type ADB 868B24 xH1PA or equal approved included mounting accessories. Light bases shall be installed in order to have the fixture at road level, Pic.1 shows a picture of a properly in-set flush mounted fixture.

Item shall also include:

• Compliance to L-867 & L-868 AC 150/5345-42 (Current Edition);

• The removal and disposal IAW the Italian codes of the existing light base to be relocated, the filling in layers of the holes and the compaction to the maximum density and the leveling and repair of the surfaces. Only when unused bases are necessary to be re-used to allow change path of the conduit, they shall be simply closed with solid removable cover and that neither removal/disposal nor returning the site to the condition that existed prior to the installation of the old fixture/base will be necessary;

• New 2 Way cable duct for the HV cables from the closer hand holes of the existing primary circuit cable, approx. 2m. The cable duct shall be realized with a heavy rigid 63 mm diameter PVC pipes, thickness of the pipe walls 4.5 mm, covered with C20/25 Class concrete;

• Supply and install approx. 60 m of 6kV cables 1x6 sqmm, single conductor, XLPE insulated, non-shielded, according to the FAA AC 150/5345-7E (L-824 Type C) Specification, ETL and CE certified. The 6kV cables will run in the new 2 Way cable duct.

Connection distance shall consider a solid cable from the previous fixture to the following one. Any unnecessary connection/junction in the electrical circuit shall be avoided;

• Coring;

• The equipotential connections of the metallic masses, including the cover and the reinforcement bars, with N07V-K cable, section 16 mm2, complete of terminals, anchoring for the drawing of the cables, cable racks and necessary accessories for the proper installation and service.

• Cut and removal of pavements and sidewalks.

• The excavation of soil of any kind and consistence, including rock, with mechanical means, 70 cm width trench and various depths for the installation of the cable duct in compatible manner with the existing utilities. The average depth of the trench shall be 90 cm;

• The leveling and the compaction of the bottom of the trench and the addition of necessary excavation for the construction of the manholes;

• The installation of warning red PVC tape with the writing “HV CABLES”;

31CES/CENM 11

• The filling in layers of the trenches and the compaction to the maximum density;

• The leveling and repair of the surfaces;

• The transportation to the authorized public dump of the surplus excavated material, including the dump fees;

• Manpower, tools accessories and every other necessary item to provide a job in a

4.3.c Furnish and install primary MV series circuit n.1 receptacle connector and n. 1 plug connector kit of the primary conductor (to be determined before installation by the contractor).

Item shall also include:

• Compliance to ICAO Aerodrome Design Manual Part 5 and FAA L-823 AC 150/5345- 26 (L-823) current edition;

• Heat Shrink Kit type ADB 71A00088-U or equal approved;

• 30VA insulating transformer;

• Manpower, cleaning of contacts, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 2

4.3.d Furnish and install flush mounted LED Taxiway Light Fixtures, Aviation Blue, 12” diameter, 50Hz, provided with built in defrost system, Type ADB ITEL C121 or equal approved, included mounting accessories and neoprene grommet.

Item shall also include:

• Compliance to FAA L-852T(L) AC 150/5345-46 (Current Edition) , FAA Engineering Brief No. 67, ETL, ICAO Annex 14, Vol. I, Ed. 6, para. 5.3.18, CE marking IAW EMC Directive 2004/108/EC.

• 100% checking of the pressurization of each single fixture in accordance with manufacturer specs.

• Connection of electrical lines, cleaning of contacts, manpower, tools accessories and

4.4 NEW LIGHTS INSTALL [Mike x5, North Ramp x5, NATO Pads x19 Lights]

4.4.a Furnishing and installation galvanized 12” light bases, 24” depth, recessed type, complete with gasket FAA approved, certified for application subjected to aircraft and other heavy vehicular loads certified IAW FAA L868, type ADB 868B24 xH1PA or equal approved included mounting accessories. Light bases shall be installed in order to have the fixture at road level, Pic.1 shows a picture of a properly in-set flush mounted fixture.

Item shall also include:

• Compliance to L-867 & L-868 AC 150/5345-42 (Current Edition);

• The removal and disposal IAW the Italian codes of the existing light base to be relocated, the filling in layers of the holes and the compaction to the maximum density and the leveling and repair of the surfaces. Only when unused bases are necessary to be

31CES/CENM 12

re-used to allow change path of the conduit, they shall be simply closed with solid removable cover and that neither removal/disposal nor returning the site to the condition that existed prior to the installation of the old fixture/base will be necessary;

• New 2 Way cable duct for the HV cables from the closer hand holes of the existing primary circuit cable, approx. 2m. The cable duct shall be realized with a heavy rigid 63 mm diameter PVC pipes, thickness of the pipe walls 4.5 mm, covered with C20/25 Class concrete;

• Supply and install approx. 60 m of 6kV cables 1x6 sqmm, single conductor, XLPE insulated, non-shielded, according to the FAA AC 150/5345-7E (L-824 Type C) Specification, ETL and CE certified. The 6kV cables will run in the new 2 Way cable duct.

Connection distance shall consider a solid cable from the previous fixture to the following one. Any unnecessary connection/junction in the electrical circuit shall be avoided;

• Coring;

• The equipotential connections of the metallic masses, including the cover and the reinforcement bars, with N07V-K cable, section 16 mm2, complete of terminals, anchoring for the drawing of the cables, cable racks and necessary accessories for the proper installation and service.

• Cut and removal of pavements and sidewalks.

• The excavation of soil of any kind and consistence, including rock, with mechanical means, 70 cm width trench and various depths for the installation of the cable duct in compatible manner with the existing utilities. The average depth of the trench shall be 90 cm;

• The leveling and the compaction of the bottom of the trench and the addition of necessary excavation for the construction of the manholes;

• The installation of warning red PVC tape with the writing “HV CABLES”;

• The filling in layers of the trenches and the compaction to the maximum density;

• The leveling and repair of the surfaces;

• The transportation to the authorized public dump of the surplus excavated material, including the dump fees;

• Manpower, tools accessories and every other necessary item to provide a job in a

EA 29

4.4.b Furnish and install primary MV series circuit n.1 receptacle connector and n. 1 plug connector kit of the primary conductor (to be determined before installation by the contractor).

Item shall also include:

• Compliance to ICAO Aerodrome Design Manual Part 5 and FAA L-823 AC 150/5345- 26 (L-823) current edition;

• Heat Shrink Kit type ADB 71A00088-U or equal approved;

• Supply and install approx. 52 m of 6kV cables 1x6 sqmm, single conductor, XLPE insulated, non-shielded, according to the FAA AC 150/5345-7E (L-824 Type C) Specification, ETL and CE certified. The 6kV cables will run in the new 2 Way cable duct;

31CES/CENM 13

• 30VA insulating transformer;

• Manpower, cleaning of contacts, tools accessories and every other necessary item to provide a job in a workmanlike manner.

EA 29

4.4.c Furnish and install flush mounted LED Taxiway Light Fixtures, Aviation Blue, 12” diameter, 50Hz, provided with built in defrost system, Type ADB ITEL C121 or equal approved, included mounting accessories and neoprene grommet.

Item shall also include:

• Compliance to FAA L-852T(L) AC 150/5345-46 (Current Edition) , FAA Engineering Brief No. 67, ETL, ICAO Annex 14, Vol. I, Ed. 6, para. 5.3.18, CE marking IAW EMC Directive 2004/108/EC.

• 100% checking of the pressurization of each single fixture in accordance with manufacturer specs.

• Connection of electrical lines, cleaning of contacts, manpower, tools accessories and

EA 29

31CES/CENM 14

Pic. 2: New installation flush-mounted light at Taxiway Mike T-Bird Row, relocation of not aligned lights at Taxiway Alpha 4 and Taxiway Bravo 4

31CES/CENM 15

Pic. 3: New installation flush-mounted light at North Ramp apron and NATO 14-16 apron

31CES/CENM 16

Pic. 4: New installation flush-mounted light at Taxiway Zulu,

5. MATERIAL SUBMITTALS

Materials and other items shall be submitted for the approval by the Contracting Officer (see attached Schedule of Material Approval Submittals). The Government will review, approve and/or disapprove material submittals within 10 working days.

6. FINAL ACCEPTANCE TEST , CERTIFICATIONS & OTHER REQUIREMENTS:

31CES/CENM 17

All machines, equipment and electric and mechanical components shall conform with "CE" Mark to D.P.R. No. 459 dated 24 July 1996 and subsequent modifications.

Furthermore the electric equipment shall be in compliance with the Legislative Decree No.81/08 and subsequent modifications.

All installed items will have to comply with latest ETL 9-11: Civil Engineering Industrial Control System Information Assurance Compliance, ICAO Annex 14 Vol. l para 5.3.6, 5.3.16, 5.3.22, NATO Stanag 3316 and FAA Engineering Brief N. 67.

At the end of the work, the Contractor to provide three copies set of AS BUILT drawings signed and stamped by qualified engineer and CD with AutoCAD and pdf electronic version of same drawings (AUTOCAD Release 2007 for drawings) at least for the following documents IAW UFGS 26 56 20.00 10:

-As built of the lighting fixtures layout complete of identification items & geospatially referenced using real world coordinates WGS-1984 UTM 33N;

-As built of the electrical lines path layout complete of identification items section views & geospatially referenced using real world coordinates WGS-1984 UTM 33N;

-as built of single line diagram, functional diagram, complete material list (multiline diagram, terminal strips if needed) if any.

-As built layout of grounding system;

-As built of Table of cable with the following minimum information:

- Cable item number (the same item number to be used at each cable ends permanent labels/tag to be applied);

- From switchboard/feeder,

- To switchboard/feeder,

- Type of cable;

- Cable formation/section;

- Cable length and Cableways path;

-Site acceptance test in accordance to the standards required (in particular insulation test on cables/devices and earthing measures/continuity tests shall be performed);

- Certificate of Compliance;

-Datasheets of all installed equipment;

-O&M manuals of all installed equipment;

-Warranty certifications and Warranty plan if available.

Once issued NTP, Contractor is required to contact CEIAP (Ms. Cristina Rossetto/ Mr. Franco Decovich

0434-305691) and schedule a meeting to fill Form DD1354 with appropriate project data for real property capitalization. Contractor is required to provide final Form DD1354 for 31CES/CD signature before contract close out.

7. ATTACHMENTS:

1. Schedule of Material Submittals

DATE: JUNE 2017 (REV. 3.1)