INVITATION TO BID (ITB)

ITB #717-26-760

Campus-Wide Restrooms Renovations

DEADLINE FOR SUBMITTAL:

11:00 a.m. Central time, Thursday, August 13, 2026

Texas Southern University

PROCUREMENT SERVICES

Attention: Thomas Britt

3100 Cleburne Street Mack O. Hannah Hall, Suite 333

Houston, Texas 77004 -4598

(Proposals received after the date and time specified will not be accepted)

ITB Number: 717-26-760, Bathrooms Renovations

Texas Southern University Date of Issuance: Tuesday, July 16, 2026 Procurement Services – Purchasing 3100 Cleburne Street, Room HH333 Deadline: Thursday, August 13, 2026 Houston, TX 77004 11:00 a.m. Central Time

Under Section 231.006, Family Code, the Texas Vendor ID or FEI No. Vendor certifies that the individual or business entity named in this contract, offer, or application is not ineligible to receive the COMPANY NAME specified grant, loan, or payment and acknowledges that this contract may be terminated and payment may be withheld if ADDRESS this certification is inaccurate.

CITY STATE ZIP If the paragraph above is applicable, provide names and social security number of each person with at least 25% ownership. Vendors PHONE NUMBER EMAIL ADDRESS that pre-registered this information on the

Texas Procurement and Support Services Centralized Master Bidders List have satisfied

This Vendor agrees to comply with all conditions AUTHORIZED SIGNATURE DATE shown on this form.

FAILURE TO MANUALLY SIGN WILL

TYPE OR PRINT NAME OF SIGNER DISQUALIFY BID

E-MAIL ADDRESS ___________________________________

QUOTE F.O.B. DESTINATION PREPAID & ALLOWED Check below if preference is claimed under Rule 1 TAC 113.8 DELIVERY TIME DAYS [ ] Produced in Texas and/or Texas bidder [ ] Texas agricultural products TERMS OF PAYMENT: NET____DAYS [ ] USA produced supplies, materials or Equipment FREIGHT CHARGES: [ ] Historically Underutilized Business Certified If quoting other than F.O.B. Destination Prepaid and by the TX Procurement and Support Services Allowed, indicate all freight charges. [ ] Products of persons with mental or physical Disabilities [ ] Products made of recycled materials [ ] Energy efficient products

TOTAL AMOUNT OF BID:

Thomas Britt thomas.britt@tsu.edu 713-313-1963 http://www.tsu.edu/ mailto:thomas.britt@tsu.edu

Texas Southern University ("University") is soliciting sealed bids from qualified general contractors for the complete renovation of designated campus restrooms located within:

• Martin Luther King Building

• Paige Building

• School of Public Affairs

The Contractor shall furnish all labor, supervision, equipment, materials, permits, insurance, testing, and incidentals necessary to complete the work in accordance with the construction documents and specifications.

BID DELIVERY

Bid packets are commonly submitted to TSU by one of the following methods: (1) U.S. Postal Service overnight, (2) Fed Ex overnight / Express Mail, and/or (3) Hand Deliver (recommended). Regardless of how you deliver your proposals response please note:

Campus Map:

http://www.tsu.edu/about/campus/pdf/tsu-campus-map.pdf

TSU Post Office, 3100 Cleburne St, Houston, TX 77004 TSU Purchasing Dept, Hannah Hall room 333

ADDITIONAL COPIES

Texas Southern University requests that bidders submit one (1) paper original of your bid response, one (1) paper copy of bid your response, and a flash drive copy of your response

EQUAL OPPORTUNITY

Contractor represents and warrants that it shall not discriminate against any person on the basis of race, color, national origin, creed, religion, political belief, sex, sexual orientation, age, and disability in the performance of this Contract.

PPUUBBLLIICC IINNFFOORRMMAATTIIOONN

TSU considers all information, documentation and other materials requested to be submitted in response to this solicitation to be of a non-confidential and/or non-proprietary nature, and therefore shall be subject to public disclosure under the Texas Public Information Act (Texas Government Code, Chapter 552.001, et seq.) after a contract is awarded. Respondents are hereby notified that the University strictly adheres to all statutes, court decisions, and opinions of the Texas Attorney General with respect to disclosure of ITB information.

WAIVER OF INCONSISTENCIES:

The University reserves the right to waive any and all minor technical inconsistencies in evaluating the proposal responses.

INCURRED EXPENSES

Any and all expenses incurred in response to this proposal are entirely the responsibility of the contractor. Neither the University, nor the State of Texas, is liable in any manner.

http://www.tsu.edu/about/campus/pdf/tsu-campus-map.pdf

PRE-BID MEETING / WALKTHROUGH:

Pre Bid meeting and Site Walkthrough will be held on Wednesday, July 22, 2026 at 10:00 am. Please meet at the

General Services Building, located at 3443 Blodgett Street, Houston, Texas 77004, Suite 221

INQUIRIES

All inquiries regarding this Invitation to Bid must be submitted via email by Friday, July 24, 2026, by 12:00 p.m.

noon Central Time. The University will not accept questions after this date. All inquiries may result in written responses posted to the Electronic State Business Daily, available at https://www.txsmartbuy.com/esbd Questions must be emailed to Thomas Britt at thomas.britt@tsu.edu in Word format for ease of cutting and pasting.

SCHEDULE OF EVENTS

The solicitation process for this RFP will proceed according to the following schedule:

EVENT DATE

Issue ITB / ESBD Posting Date July 16, 2026

Pre-Bid/Walkthrough July 22, 2026

Deadline for Submission of Questions July 24, 2026

Response to Questions July 28, 2026

Deadline for Submission of Proposals August 13, 2026

ADDENDA, CHANGES AND MODIFICATIONS TO THIS BID

It is the bidder's responsibility to periodically check the Electronic State Business Daily Website https://www.txsmartbuy.com/esbd up until the offer opening time for any changes, modifications or addenda to this offer. Receipt of all addenda to this ITB should be acknowledged by returning a signed copy of each addendum with the submitted Bid. Failure to do so could result in an offer submission that cannot be considered

REFERENCES

Vendors responding to this bid must be prepared, if asked pre-award, to submit a list of at least three references your company has successfully provided products for projects of this type and magnitude. The list must include the client’s name, address, telephone number, a contact person, and a brief description of the project completed. The University shall not be confined to this list if it deems further reference investigation necessary.

SUBCONTRACTORS

Subcontractors providing services under a Contract shall meet the same requirements and level of experience as required of Respondent. No subcontract under the Contract shall relieve Respondent of responsibility for ensuring the requested services are provided. Respondents planning to subcontract all or a portion of the work to be performed shall identify the proposed subcontractors

AWARD

Texas Southern University intends to award in such a way as to gain the greatest benefit to the result of this project and therefore the University. Texas Southern University will be the sole judge of what constitutes the most advantageous proposition to the University. An award to multiple vendors is reserved by the university if so chosen.

https://www.txsmartbuy.com/esbd mailto:thomas.britt@tsu.edu https://www.txsmartbuy.com/esbd

CRITERIA FOR AWARD

The evaluation of the bid will include the overall response to the bid, and will include, but is not limited to the “Best Value Standard for Purchase of Goods or Services” and any other factor Texas Southern University deems relevant.

The University must be confident that their needs can be met. The University will evaluate and make the award on the offer that is determined to be the best value to the University based on the criteria listed below. All bids must be complete and convey all the information requested to be considered responsive.

Considerations for award of this contract will include the factors in accordance with Government Code 2155.074.

Best Value Standard for Purchase of Goods or Services are as follows:

(a) For a purchase of goods and services under this chapter, each state agency, including Texas Southern University and shall purchase goods and services that provide the best value for the state.

(b) In determining the best value for the state, the purchase price and whether the goods or services meet specifications are the most important considerations. However, the Texas Procurement and Support

Services or other state agency may, subject to Subsection (c) and Section 2155.075, consider other relevant factors, including:

(1) Proposed costs

(2) Stability and success of contractor’s business

(3) Quality and reliability of the goods and services

(4) Delivery terms and proposed transition plan

(5) Indicators of probable contractor performance under the contract such as past contractor performance, the contractor's financial resources and ability to perform, the contractor's experience or demonstrated capability and responsibility, and the contractor's ability to provide reliable maintenance agreements and support

(6) Other factors relevant to determining the best value for the state in the context of a particular purchase

Added by Acts 1997, 75th Leg., ch. 1206, § 6, eff. Sept. 1, 1997.

Amended by Acts 2001, 77th Leg., ch. 1422, § 14.16, eff. Sept. 1, 2001.

PUBLICITY

Contractor agrees that it shall not publicize this Contract or disclose, confirm or deny any details thereof to third parties or use any photographs or video recordings of the University's employees or use the University's name in connection with any sales promotion or publicity event without the prior express written approval of the University.

BID TABULATION

Electronic copy of the submittal tabulation sheet will be made available after the scheduled public bid opening per request through Purchasing. Only names of respondents and total bid price will be released to the public at the public bid opening. All other information will be kept confidential until after successful contract award.

SEVERABILITY

In case any provision hereof, or of any resulting agreement or purchase order, shall, for any reason, be held invalid or unenforceable in any respect, such invalidity or unenforceability shall not affect any other provision thereof, and this Contract shall be construed as if such invalid or unenforceable provision had not been included herein.

GOVERNING LAW

This Contract, including, without limitation, this ITB and any resulting agreement or purchase order, shall be construed and governed by the laws of the State of Texas.

HOUSE BILL 1295

The awarded vendor may be required to submit the State of Texas House Bill 1295, Certificate for Interested Parties, if your bid response is over $100,000; unless you are a publicly traded company. If your price is over $100,000 you must complete the 1295 form and include it in your response. Mr. Britt is the contact person. The bid number 717-26-760 is the contract number.

If not applicable, then clearly state this point as well.

FIRM PRICING

Prices contracted for are to be guaranteed firm pricing for ninety (90) days from the bid deadline.

TERMINATION FOR FAILURE TO MEET SPECIFIED DELIVERY

Should the contractor consistently fail to meet the specified delivery, Texas Southern University reserves the right to cancel upon 10 days written notice. Texas Southern University specifically reserves the right to purchase these items elsewhere when delivery cannot be met, and Texas Southern University deems it necessary to override the contractual agreement.

FIXED ESCALATION CLAUSE

Bidders must certify a fixed, maximum percentage of escalation for both the initial and any subsequent terms of the contract as specified. This percentage will be employed in the evaluation and award of any contract resultant of the bid. The maximum annual percentage of escalation is ______%. If this field is not filled in, an escalation of 0% will be assumed.

RIGHT TO TERMINATE

The University reserves the right to terminate this contract or any portion thereof on thirty (30) days written notice.

Grounds for cancellation shall include, but are not limited to the following:

1) Failure to provide timely prompt service, and

2) Failure to provide quality products.

The University shall be the sole judge of acceptable service as indicated above.

TERMINATION

For termination, which is not based upon cause, thirty (30) day written notice shall be given to the contractor.

AMENDMENTS

This Contract may be amended only upon written agreement between Texas Southern University and Contractor;

however, any amendment of this Contract that conflicts with the laws of the State of Texas shall be void.

PROTECTION OF PROPERTY

Vendors shall always guard against damage or loss to the University property or of other vendors, suppliers or contractors, and shall be responsible for replacing or repairing, or for the cost of repairs or replacement of any such loss or damage. The University may require payment or require such additions and/or adjustments to the Vendor’s assessment to ensure reimbursement or replacement for such loss or damage to property incurred by the Vendor or its agents

INDEMNIFICATION

CONTRACTOR SHALL DEFEND, INDEMNIFY, AND HOLD HARMLESS THE STATE OF TEXAS, ITS OFFICERS, AND EMPLOYEES, AND TEXAS SOUTHERN UNIVERSITY ITS OFFICERS, AND EMPLOYEES AND

CONTRACTORS, FROM AND AGAINST ALL CLAIMS, ACTIONS, SUITS, DEMANDS, PROCEEDINGS, COSTS, DAMAGES, AND LIABILITIES, INCLUDING WITHOUT LIMITATION ATTORNEYS’ FEES AND COURT COSTS, ARISING OUT OF, CONNECTED WITH, OR RESULTING FROM ANY ACTS OR OMISSIONS OF CONTRACTOR OR ANY AGENT, EMPLOYEE, SUBCONTRACTOR, OR SUPPLIER OF CONTRACTOR IN THE EXECUTION OR

PERFORMANCE OF THIS CONTRACT. CONTRACTOR SHALL COORDINATE ITS DEFENSE WITH THE

TEXAS ATTORNEY GENERAL AS REQUESTED BY TEXAS SOUTHERN UNIVERSITY.

THIS PARAGRAPH IS NOT INTENDED TO AND SHALL NOT BE CONSTRUED TO REQUIRE CONTRACTOR TO INDEMNIFY OR HOLD HARMLESS THE STATE OR TEXAS SOUTHERN UNIVERSITY FOR ANY CLAIMS OR LIABILITIES RESULTING FROM THE NEGLIGENT ACTS OR OMISSIONS OF TEXAS SOUTHERN UNIVERSITY

OR ITS EMPLOYEES.

VENDOR CERTIFICATION / ACCEPTANCE

The undersigned hereby certifies that he has read, understands, and agrees that acceptance by Texas Southern University of the bidder’s offer by issuance of a purchase order will create a binding legal contract. Further he agrees to fully comply with documentary forms herewith made a part of this specific procurement

NAME OF COMPANY:

AUTHORIZED SIGNATURE:

TYPED NAME & TITLE:

Executive Order GA-48 Compliance Statement (Higher Education)

Pursuant to Executive Order GA-48 issued by Greg Abbott, Respondent affirms its understanding of and commitment to comply with all applicable requirements related to foreign adversary restrictions as they apply to public institutions of higher education.

Respondent certifies that it is not owned by, controlled by, or affiliated with any entity identified as a foreign adversary and does not participate in prohibited foreign talent recruitment programs or restricted research collaborations. Respondent further certifies that it does not receive funding, contractual support, or other resources from prohibited foreign sources that would conflict with the requirements of this Executive Order.

In support of institutional research security and academic integrity, Respondent agrees to fully disclose any foreign affiliations, partnerships, funding sources, or collaborative arrangements that may involve foreign entities. This includes, but is not limited to, research sponsorships, joint academic programs, data-sharing agreements, and subcontracting relationships.

Respondent acknowledges that any resulting agreement may be subject to enhanced compliance measures, including review of research activities, data access limitations, export control considerations, and restrictions on the use of certain technologies, equipment, or personnel connected to foreign adversaries.

Respondent further agrees to comply with all institutional policies related to international travel, remote work conducted outside the United States, and access to university systems or sensitive data, where applicable to the services provided.

Failure to comply with the provisions of Executive Order GA-48 and applicable institutional policies may result in disqualification from the solicitation process, contract termination, and/or other remedies available under law.

Vendor Certification – Executive Order GA-48 Compliance

The Respondent must complete the following certification. Failure to complete this section may result in disqualification.

☐ Certified Compliant

Respondent affirms that it is fully compliant with the requirements of Executive Order GA-48 and has no prohibited affiliations, funding sources, or engagements.

☐ Disclosure Required

Respondent affirms compliance but has disclosed below any affiliations, funding sources, partnerships, or activities that may require review under GA-48.

☐ Non-Compliant

Respondent is unable to certify compliance with Executive Order GA-48.

If “Disclosure Required” is selected, provide details below (attach additional pages if necessary):

Authorized Representative Name: __________________________________________

Title: _________________________________________________________________

Company Name: __________________________________________________________

Signature: _______________________________________ Date: ____________

VETERAN HEROES UNITED IN BUSINESS SUBMITTAL REQUIREMENTS:

** A State of Texas VETHUB plan is required for this solicitation.

It is the policy of Texas Southern University to promote and encourage contracting and subcontracting opportunities for Veterans Heroes United in Business (VETHUB) in all contracts. Accordingly, the Owner has adopted its Policy on Utilization of Veterans Heroes United in Business (VETHUB) Businesses, a copy of which is attached hereto and will be included as an Exhibit to the Agreement. The Policy applies to all contracts with an expected value of $100,000 or more. If Owner determines those subcontracting opportunities are probable, then a VETHUB Subcontracting Plan is a required element of the Proposal. Failure to submit a required VETHUB Subcontracting Plan will result in the rejection of the Proposal.

STATEMENT OF PROBABILITY Owner has determined that subcontracting opportunities are probable in connection with this solicitation. Therefore, a VETHUB Subcontracting Plan (VHSP) is required as a part of the Respondent's Proposal. Respondent shall develop and administer a VHSP as a part of the Respondent's Proposal in accordance with the Owner’s Policy on Utilization of Veterans Heroes United in Business (VETHUB).

Respondent’s VETHUB Subcontracting Plans must be attached separately in a sealed envelope clearly labeled “VETHUB Subcontracting Plan” and must have the name of the project and the bid number clearly marked on the outside of the sealed envelope.

Refer to Policy on Utilization of Veterans Heroes United in Business (VETHUB) for a detailed list of attachments required with the VET HUB HSP available at https://comptroller.texas.gov/purchasing/vendor/hub/forms.php

VETHUB SUBCONTRACTING GOAL: The VETHUB Subcontracting Goal for this Project is for Respondents are expected to make a good faith effort to meet this goal. For more information, please review the VETHUB webpage:

https://comptroller.texas.gov/purchasing/vendor/hub/certification-process.php

ATTACHMENTS

The following attachments are to be considered as part of this bid:

TSU Terms and Conditions Form 1295, if applicable VETHUB Subcontracting Plan

PREFERENCES

See Section 2.38 of the State of Texas Procurement Manual regarding preferences. Check below to claim a preference under 34 TAC

Rule 20.38

( ) Supplies, materials or equipment produced in TX or offered by TX bidder or TX bidder that is owned by a service-disabled veteran *

( ) Agricultural products produced or grown in TX

( ) Agricultural products and services offered by TX bidders*

( ) USA produced supplies, materials or equipment

( ) Products of persons with mental or physical disabilities

( ) Products made of recycled, remanufactured, or environmentally sensitive materials including recycled steel

( ) Energy Efficient Products

( ) Rubberized asphalt paving material

( ) Recycled motor oil and lubricants

( ) Products produced at facilities located on formerly contaminated property

( ) Products and services from economically depressed or blighted areas

( ) Vendors that meet or exceed air quality standards

( ) Recycled or Reused Computer Equipment of Other Manufacturers

( ) Foods of Higher Nutritional Value https://comptroller.texas.gov/purchasing/vendor/hub/forms.php https://comptroller.texas.gov/purchasing/vendor/hub/certification-process.php

SPECIFICATIONS

1. Purpose

Texas Southern University ("University") is soliciting sealed bids from qualified general contractors for the complete renovation of designated campus restrooms located within:

• Martin Luther King Building

• Paige Building

• School of Public Affairs

The Contractor shall furnish all labor, supervision, equipment, materials, permits, insurance, testing, and incidentals necessary to complete the work in accordance with the construction documents and specifications.

2. Project Scope

The work generally includes:

• Demolition

• Architectural renovations

• Ceramic tile

• Flooring

• Drywall

• Painting

• Toilet partitions

• Toilet accessories

• Plumbing fixtures

• Domestic water modifications

• Sanitary piping

• HVAC modifications

• Electrical demolition

• LED lighting

• Power modifications

• Accessibility upgrades (ADA/TAS)

• Firestopping

• Final cleaning

• Testing and commissioning

3. Restroom Locations

Martin Luther King Building

• Men's Restroom E301A

• Women's Restroom W301A

Total: 2 Restrooms

Paige Building

• Restrooms 122 & 126

• Restrooms 250 & 252

• Restrooms 365 & 370

Total: 6 Restrooms

School of Public Affairs

• Restrooms 113 & 114

• Restrooms 212 & 219

• Restrooms 316 & 321

• Restrooms 416 & 421

Total: 8 Restrooms

4. Bid Pricing Form (Provide itemized labor and materials cost can be included on an individual sheet)

Building Restroom No./Location Lump Sum Price

Martin Luther King Building Restroom E301A $___________

Martin Luther King Building Restroom W301A $___________

Total MLK Building $___________

Paige Building Restroom 122 $___________

Paige Building Restroom 126 $___________

Paige Building Restroom 250 $___________

Paige Building Restroom 252 $___________

Paige Building Restroom 365 $___________

Paige Building Restroom 370 $___________

Total Paige Building $___________

School of Public Affairs Restroom 113 $___________

School of Public Affairs Restroom 114 $___________

School of Public Affairs Restroom 212 $___________

School of Public Affairs Restroom 219 $___________

School of Public Affairs Restroom 316 $___________

School of Public Affairs Restroom 321 $___________

School of Public Affairs Restroom 416 $___________

School of Public Affairs Restroom 421 $___________

Total SOPA $___________

Grand Total

Description Amount

Martin Luther King Building $_____________

Paige Hall $_____________

School of Public Affairs $_____________

Grand Total Bid $_____________

5. Alternate Pricing

Provide separate pricing for:

• Alternate Bid No. 1: Remove and replace existing light fixtures.

• Alternate Bid No. 2: Remove existing ceiling tile and grid system in area indicated.

• Alternate Bid No.3: Remove existing toilet partition system and urinal screens, including panels, doors, pilasters, and hardware. Prepare substrate for installation of new toilet partitions.

• Alternate Bid No.4: Remove existing door signage and prepare surface for new signage installation.

6. Project Schedule:

Respondents shall submit a detailed project schedule outlining all phases of the work, including procurement of materials, delivery dates, mobilization, labor activities, inspections, substantial completion, and final completion.

The schedule shall identify the anticipated start and completion dates for each major task and shall commence upon issuance of the Notice to Proceed (NTP), unless otherwise approved in writing by Texas Southern University. The proposed schedule shall demonstrate the Respondent's ability to complete the project within the required timeframe while minimizing disruptions to university operations. Any deviations from the proposed schedule must be approved in advance by the University.

This version is more comprehensive and establishes clear expectations for:

• Material procurement and delivery timelines

• Labor and construction activities

• Milestones and Completion Dates

• Start after Notice to Proceed (NTP)

• Requirement for University approval of schedule changes

• Minimization of campus disruption

7. Contractor Qualifications

The Contractor shall:

• Be licensed to perform work in Texas.

• Demonstrate experience with occupied building renovations.

• Maintain all required insurance and bonding.

8. Drawings and Specifications (Box Link or Zip File)

The complete set of project drawings, technical specifications, and supporting bid documents are available electronically. Bidders shall review all documents prior to submitting a bid.

Box Link: Specifications_TSU Restroom Reno - MLK, Paige, SOPA

Zip File: Specifications_TSU Restroom Reno - MLK, PAIGE, SOPA.zip

End of this solicitation

TSU%20Restrooms%20Specifications%20and%20Drawings%20MLK%20Paige%20SOPA Specifications_TSU%20Restroom%20Reno%20-%20MLK,%20PAIGE,%20SOPA.zip