ESBD_515561_1778768454948_IFB 2026-B07 Nutty Brown Road - Remove and Replace Hot Mix.pdf

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 1 of 42

SOLICITATION, OFFER

AND AWARD

Hays County Purchasing Office

1901 Dutton Dr., Suite E San Marcos, Texas 78666

Solicitation No.:

IFB 2026-B07 Nutty Brown Road – Remove and Replace

Hot Mix Date Issued: May 14, 2026

SOLICITATION

Vendors must submit proposals as listed: One (1) original and one (1) digital copy on a thumb drive at the Hays County Purchasing Office at the address shown above or Electronically through BidNet Direct and one (1) hard copy at the Hays County Purchasing Office at the address shown above until:

9:00 a.m. local time June 8, 2026.

Proposals received after the time and date set for submission will be returned unopened.

For information please email:

purchasing.bids@hayscountytx.gov

Questions concerning this IFB must be received in writing no later than 5:00 on May 28, 2026.

Phone No.: (512) 393-2267

OFFER (Must be fully completed by Respondent)

In compliance with the above, the undersigned offers and agrees to furnish all items or services awarded at the prices stipulated for each item delivered at the designated point(s) and within the time specified herein. Award shall include all solicitation documents and attachments.

MANUALLY SIGN ALL COPIES SUBMITTED. SIGNATURE IS MANDATORY.

Respondent Respondent’s Authorized Representative Entity Name:

Mailing Address:

Name:

Title:

Email Address:

Phone No.:

Signature: Date:

Name, Email Address and Phone No. of person authorized to conduct negotiations on behalf of Respondent:

NOTICE OF AWARD (To be completed by County) Funding Source: Awarded as to item(s): Contract Amount:

Vendor: Term of Contract:

This contract issued pursuant to award made by Commissioners Court on:

Date: Agenda Item:

Important: Award notice may be made on this form or by other Authorized official written notice.

Hays County Judge

Date

Hays County Clerk Date mailto:purchasing.bids@hayscountytx.gov

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 2 of 42

Table of Contents

Solicitation, Offer and Award

I. IFB Submittal Checklist

II. Summary

III. Specifications

A. Introduction

B. Scope of Work

C. Project Description

D. Qualifications

E. Attachment A: 2026-B07 Bid Form

F. Submittal Requirements

G. Award of Contract

H. Bond Requirements

I. Warranty of Performance

IV. General Terms and Conditions for Solicitations

V. Vendor Reference Form

VI. Certificate of Interested Parties

VII. Conflict of Interest Disclosure & Questionnaire

VIII. Code of Ethics

IX. HUB Practices

X. House Bill 89 Verification

XI. Comptroller Divestment Statute Certification

XII. Debarment & Licensing Certification

XIII. Vendor/Bidder’s Affirmation

XIV. Federal Affirmations and Solicitation Acceptance

XV. Related Party Disclosure Form

Attachment A: 2026-B07 Bid Form

Attachment B: 2024 TxDOT Specifications

Attachment C: Nutty Brown Road Map

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 3 of 42

I. IFB Submittal Checklist

This checklist is provided for the Vendor’s convenience and identifies the documents that MUST be submitted for the bid/proposal to be considered responsive, as well as the required forms requested by Hays County.

A COMPLETE SOLICITATION RESPONSE PACKAGE INCLUDES:

The following forms MUST be returned for the bid/proposal to be considered responsive:

____ 1. Solicitation, Offer and Award Form

____ 2. Attachment A: IFB 2026-B07 Bid Form

____ 3. Vendor Reference Form

____ 4. Conflict of Interest Disclosure & Questionnaire

____ 5. Related Party Disclosure Form

____ 6. Any addenda applicable to this solicitation

____ 7. Bid Bond: 5% of total bid amount

Required Forms by Hays County:

____ 1. Code of Ethics

____ 2. HUB Practices

____ 3. House Bill 89 Verification

____ 4. Comptroller Divestment Statute Certification:

• Iran, Sudan, and Foreign Terrorist Organization Certification (TGC 2252)

• Israel Boycott Certification (TGC 2271.002)

• Prohibition of Energy Company Boycott Certification (TGC 2274)

• Prohibition of Discrimination against Firearm Companies or Firearm Trade Org. Certification (TGC 2274.002)

____ 5. Debarment & Licensing Certification

____ 6. Vendor/Bidder’s Affirmation

____ 7. Federal Affirmations and Solicitation Acceptance

____ 8. System for Award Management (www.SAM.gov) Printout

Hays County will accept bids/proposals/SOQ, by the due date by one of the following methods:

____ 1. Electronic Submission of Bid Packet through BidNet Direct and one (1) hard copy delivered, within 24 hours of proposal due date, in a sealed envelope with the Solicitation Number and Vendor’s name on the outermost envelope addressed to: Hays County Purchasing, 1901 Dutton Dr., Suite E, San Marcos, TX 78666

OR

____ 2. One (1) original bid packet and one (1) digital copy on a thumb drive in a sealed envelope with the Solicitation

Number and Vendor’s Name on the outermost envelope, addressed to: Hays County Purchasing, 1901 Dutton Dr., Suite E, San Marcos, TX 78666 http://www.sam.gov/

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 4 of 42

II. Summary

1. Type of Solicitation: Invitation for Bid (IFB)

2. Solicitation Number: IFB 2026-B07

Nutty Brown Road – Remove and Replace Hot Mix

3. Issuing Office: Hays County Purchasing Office 1901 Dutton Dr., Suite E San Marcos, TX 78666

4. Responses to Solicitation: Sealed proposals marked with Solicitation Number and Vendor Name on the outermost envelope Manual: One (1) Original and one (1) digital copy on a thumb drive, or

Electronic: Proposals can be submitted through BidNet Direct and one (1) hard copy is required to be received within 24 hours of due date.

5. Deadline for Responses: In issuing office no later than:

June 8, 2026; 9:00 a.m. Central Time (CT)

6. Pre-Bid Meeting: Wednesday, May 27, 2026 @ 9:00 AM (CT) Hays County Transportation Department

2171 Yarrington Road, Kyle, TX 78640

7. Initial Contract Term: Award July 2026, must be completed by September 25, 2026

8. Bonding Requirements Bid bond: 5% of total bid amount, due at bid submittal Performance Bond: 100% of Contract Price, due 10 days within contract execution Payment Bond: 100% of Contract Price, due 10 days within contract execution

9. Designated Contact: Hays County Purchasing

Email: purchasing.bids@hayscountytx.gov

10. Questions & Answers: Questions regarding this solicitation must be made in writing and submitted to the designated contact above no later than May 28, 2026;

5:00 p.m. CT. Telephone inquiries will not be accepted. Questions may be submitted by email to the address above. Answers to questions will be provided in the form of an addendum posted after the question deadline on the CivicPlus, BidNet Direct, and ESBD websites for the benefit of all potential respondents.

The County reserves the right to contact the person submitting a question to clarify the question received, if necessary. Each clarification, supplement, or addenda to this solicitation, if any, will be posted on the CivicPlus, BidNet Direct and ESBD websites. All potential or actual respondents are responsible for monitoring the websites for such mailto:purchasing.bids@hayscountytx.gov

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 5 of 42 materials. Respondents are deemed to have notice of, and are required to comply with, any such material posted in accordance with this paragraph. Respondents should not rely upon any other sources of written or oral responses to inquiries.

have notice of, and are required to comply with, any such material posted in accordance with this paragraph. Respondents should not rely upon any other sources of written or oral responses to inquiries.

11. Addenda Any interpretations, corrections or changes to this solicitation and specifications will be made by addenda. Sole issuing authority of addenda shall be vested in the Hays County Purchasing Office. It is the Vendor’s responsibility to acknowledge receipt of all addenda with proposal submission.

12. Contact with County Staff: Upon issuance of this solicitation, employees and representatives of

Hays County, other than the Purchasing Office staff identified as the Designated Contact above, will not discuss the contents of this solicitation with any Vendor or its representatives. Failure of a Vendor or any of its representatives to observe this restriction may result in disqualification of any related offer. This restriction does not preclude discussions between affected parties for the purpose of conducting business unrelated to this procurement.

13. Websites: Plans, Specifications, and Bidding documents for pre-qualified bidders and interested non-bidders may be secured from the following websites:

www.bidnetdirect.com/hayscounty, http://www.txsmartbuy.com/sp, https://www.sanmarcostx.gov/Bids.aspx

Anticipated Schedule of Events May 12, 2026 Court Approval May 14, 2026 Issuance of IFB May 27, 2026 Pre-Bid Meeting (9:00 AM CT) May 28, 2026 Deadline for Submission of Questions (5:00 PM CT) June 8, 2026 Deadline for Submission of Proposals (9:00 AM CT)

Late bids will not be accepted.

July 2026 Anticipated contract award date https://www.sanmarcostx.gov/Bids.aspx

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 6 of 42

III. Specifications A. Introduction

Hays County issues this Invitation for Bid (IFB) to solicit bids to remove existing 5” and replace with 5” of Type B Hot Mix and 2” Superpave Type D Hot Mix Overlay on Nutty Brown Road.

B. Scope of Work Special Specification:

• Specification most current Item 341, 344, 351, and SS 3084 of the Texas Department of Transportation’s Standard Specifications for Construction and Maintenance of Highways, Streets and Bridges shall govern this project. A TRAIL tack coat placed prior to paving with Superpave Type D mix is specified. Contractor shall provide QA/QC with the required bulk samples and cores per specification for each day’s work for conformance with density and specification requirements.

Milling/ B mix Paving:

• In locations determined by the Hays County Representative pavement will be milled to 5” of depth from existing paving. Tie-ins at intersecting roadways, concrete driveways, bridge decks shall be milled to a 2” depth for a smooth transition. The Contractor will be responsible for repairs/damage to utilities while removing around water valve/manhole castings to a depth of 5”.

The Contractor will provide the trucking and dumpsite for haul off materials. After milling the location will be free of loose material and a tack coat applied to the water valve/manholes prior to paving. The Contractor will be responsible to provide safe access for resident’s driveways. B mix shall not be placed until underlying base is approved by Hays County. Proof rolling of the prepared base may be required, rutting or pumping will require rework. 5” of TXDOT Item 341 Type B shall be placed and compacted per specifications.

Overlay Paving Operations:

• A TRAIL tack coat to be applied throughout roadway followed by a 2” overlay of TXDOT Item 344 Superpave D mix. Paving be placed and compacted per TxDOT specifications along with sampling and testing requirements.

Post-Paving Cleanup:

• All post-paving clean-up will be the responsibility of the Contractor.

Traffic Control/Safety Operations:

• Safety warning signage, flagger operations, pilot cars, reflective tabs, and traffic control shall be the responsibility of the Contractor and shall meet TxDOT standards.

Scheduling:

• All paving operations shall be scheduled through the Hays County Transportation Department.

All named roadways shall be completed no later than:

• September 25, 2026

Notification:

• One week prior to paving the Contractor shall notify all residents of upcoming operations with message boards at each end of project along with fliers/doorhangers, giving instructions regarding the paving operations.

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 7 of 42

Hays County reserves the right to refuse or reject any materials that do not meet the requirements of the specifications. Any materials refused or rejected based on non-conformance with the specifications shall be removed at no cost to the County.

C. Project Description Paving Worksites: Bid according to bid sheet instructions:

1. Nutty Brown Road

a. Mill 5” depth

b. Replace 5” (B mix) 15,000 SYD

2. Nutty Brown Road 2” Overlay

a. 2” D mix overlay 10000 tons

b. Trail tack to be applied prior to overlay

3. Contractor is responsible for removing, by milling to a depth of 5”.

a. Milling Operations: Contractor is responsible for milling, rolling, and otherwise preparing the underlying base to accept the new hot mix surface. Edges will be tacked.

b. Contractor will be responsible for utility locates and any damages/repairs to utilities.

c. The Contractor will provide trucking and haul off site for materials.

d. Reference Attachment B: Nutty Brown Road Map (locations are estimated/actual locations will be determined by a Hays County Representative)

e. B mix shall not be placed until underlying prepared base is approved by Hays County. Proof rolling of the prepared base may be required, rutting or pumping will require rework.

D. Qualifications RESPONSIBILTY: A prospective bidder must affirmatively demonstrate bidder’s responsibility. A prospective bidder must meet the following requirements:

• Have adequate financial resources, or the ability to obtain such resources as required

• Be able to comply with required or proposed delivery schedule

• Have a satisfactory record of performance

• Be otherwise qualified and eligible to receive an award

• Have the proper equipment to fulfill the terms and conditions of this contract such as proper equipment for weighing materials, loading materials, delivering materials, etc.

• Does not owe any back taxes within Hays County

• Is normally engaged in this type of business

• Is familiar with and will abide by all laws, regulations, and customs applicable to this type of service.

• All licenses or permits required by a State, County, or other governmental authority shall be secured by Contractor at its sole cost and expense.

REFERENCES: Hays County requires respondent to supply with the proposal, a list of at least three (3) references where like services have been supplied by their company for a county or company of similar size within the last five (5) years. Include name of company, address, telephone number and name of representative.

TIME OF PERFORMANCE: It is imperative that the prospective respondent respond to County requests in a timely manner and comply with required or proposed delivery schedules. Please describe how you intend to respond to and track County requests.

SYSTEM FOR AWARD MANAGEMENT: Respondent and its Principals may not be debarred or suspended nor otherwise have an exclusion record created in the System for Award Management (SAM) website.

Include verification that the company as well as the company's principals are not listed (are not debarred)

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 8 of 42 through the System for Award Management (www.SAM.gov). Enclose a printout of the Entity Registration page that shows your firm is in active status and is not expired.

COMPLIANCE WITH LAWS: The successful bidder shall comply with all applicable federal, state and local laws and regulations pertaining to the practice of the profession and the execution of the duties under the bid.

INSURANCE: The successful bidder will be required to furnish proof of insurance for Workers’ Compensation, Auto Liability and General Liability before any work may begin.

It is the practice of Hays County to encourage local participation and to promote and encourage contracting and subcontracting opportunities for locally owned businesses and labor in all contracts.

The County of Hays does not discriminate on the basis of race, color, national origin, sex, religion, age and disability in employment or the provision of services.

E. Attachment A: IFB 2026-B07 Bid Form Respondent must provide its total bid amount by completing the mandatory bid form included as Attachment A: IFB 2026-B07 Bid Form.

Per Square Yard and Ton Bid for project:

• Pricing per square yard and ton should include a turn-key install and include all costs of the project.

• Submit bid pricing as cost per square yard and ton of all locations combined.

• Award will be based on qualifications and total square yard and ton bid for all projects combined based on estimated square yardage and tonnage. Contract payment will be made by square yards and tons completed. Price per square yard and ton to be used if square yardage and tonnage is increased due to miscalculations or if additional paving work is requested at or near each site.

Hays County is exempt from federal excise and state sales tax; therefore, tax must not be included in this bid.

ESTIMATED QUANTITIES: Award will be based on qualifications and total per square yard and tonnage on all projects combined based on estimated square yards and tonnage. Contract payment will be made by square yards and tonnage completed. Price per square yard and tons to be used if square yardage and tonnage are increased due to miscalculations or if additional work is requested at or near site.

Estimated square yards and tonnage shown are for bid purposes only.

F. Submittal Requirements Respondent must deliver the following to the Issuing Office by the specified deadline or upload the bid packet electronically to BidNet Direct:

• Mailed or Dropped off Bid Packets: All items must be in a sealed envelope marked with the Solicitation Number and Respondent Name on the outermost envelope.

One (1) original bid with required forms manually signed by Respondent with original signatures One (1) digital copy of the full bid packet with all required forms on a thumb drive

• Electronic Bids:

Upload proposal with required forms manually signed by the respondent. (through BidNet

Direct) One (1) original proposal with required forms manually signed by the respondent, delivered to the Hays County Purchasing Office. Either the original or Electronic Proposal (through

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 9 of 42

BidNet Direct) MUST be received by the due date and time to be considered responsive.

Physical copy must be received in the Hays County Purchasing Office within 24 hours of proposal due date.

LATE SUBMITTALS WILL NOT BE ACCEPTED.

Submittals will be publicly opened at the Office of the Hays County Auditor upon the deadline for submittal. Respondents, their representatives and interested persons may be present. All unofficial bid results will be posted on the following two sites, until an award has been made in Commissioners Court:

BidNet Direct: https://www.bidnetdirect.com/texas/hayscounty

ALTERING BIDS: Any interlineations, alteration, or erasure made before receiving time must be initialed by the signer of the bid, guaranteeing authenticity.

WITHDRAWING OF BID: A bid may be withdrawn at any time prior to the official opening. After the official opening, bids may not be amended, altered or withdrawn without the recommendation of the County Purchasing Agent and the approval of Commissioners Court.

FORMS: All Bids must be submitted on the forms provided in this solicitation document. Changes to solicitation forms made by bidders shall disqualify the bid.

G. Award of Contract BASIS OF AWARD: The County reserves the right to award a contract to a bidder on the basis of unit price low bid and/or the best value for the County. The County reserves the right to accept in part or in whole any bids submitted and waive any technicalities for the best interest of the County.

The bid award shall be based on but not necessarily limited to, the following factors:

• Total price

• Special needs and requirements of Hays County

• Vendors past performance record with Hays County, if applicable

• Hays County’s evaluation of vendor’s ability to perform

• Vendor’s references

REFERENCES: Hays County requires respondent to supply with the statement of qualifications, a list of at least three (3) references where like services have been supplied by their company. Include name of company, address, telephone number and name of representative.

CONTRACT: This bid, when properly accepted by Hays County shall constitute a contract equally binding between the successful bidder and Hays County. No negotiations, decisions, or actions shall be initiated or executed by any vendor as a result of any discussions with any County employee. Only those communications that are in writing from the Purchasing Agent shall be considered as a duly authorized expression on behalf of the County. No oral agreements either expressed or implied will be considered in fulfilling this contract. No additional terms will become part of this contract with the exception of Commissioners Court approved change orders.

BIDDER AGREES, if this bid is accepted, to furnish any and all services upon which prices are offered, at the price(s) and upon the terms and conditions contained in the specifications. The period for acceptance of the bid will be ninety (90) calendar days.

The successful bidder expressly warrants that all services specified in the IFB will be performed with care and diligence and in accordance with all specifications of the IFB. The successful bidder agrees to correct https://www.bidnetdirect.com/texas/hayscounty

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 10 of 42 any deficiencies in its performance of services upon notification by the County and without additional expense to the County.

The County reserves the right to accept in part or in whole any bids submitted and waive any technicalities for the best interest of the County.

If the bid is accepted and approved by Commissioners Court, this document shall be made part of the contract. No negotiations, decisions, or actions shall be initiated or executed by any vendor as a result of any discussions with any County employee. No oral agreements either expressed or implied will be considered in fulfilling this contract.

H. Bond Requirements BID BOND: A Bid Bond shall be submitted with your offer. It shall be in the amount of 5% of the total bid amount and issued by a surety company authorized to do business in Texas. Within Ten (10) days of award, it may be returned to you, if you are the unsuccessful offer. If you are the awardee, it shall be held until a Performance Bond is received as explained below.

PERFORMANCE & PAYMENT BONDS: Contractor shall furnish Performance and Payment Bonds to the County Purchasing Agent within ten (10) calendar days of notification of contract award. Each shall be in the amount at least equal to the contract price, as security for the faithful performance and payment of all of contractor’s obligations under the contract documents. Even though a contract may be awarded, no contract is deemed to exist until the proper Performance Bond has been received. The bonds are to be issued from a surety company holding a license from the State of Texas to act as a surety. These bonds shall remain in effect until final acceptance by the Engineer and until a Maintenance Bond, which will run for a period of two (2) years after the successful completion of all work under the contract and acceptance of Hays County, is obtained and provided to the county. A Maintenance Bond guarantees all work under the contract to be free from faulty materials and free from improper workmanship, and against injury from proper and usual wear, and guarantees to replace or to re-execute, without cost to Hays County, such work as may be found to be improper or imperfect, and to make good all damage caused to the other work of materials, due to such required replacement or re-execution. At your request, the Performance Bond shall be returned by the County upon completion of the contract and final acceptance of all items in the contract. Neither the final certificate, nor payment, nor any provision in the contract documents shall relieve the contractor of responsibility for neglect or faulty materials or workmanship during the period covered by the Maintenance Bond. If the awardee fails to perform any of the services required by the contract within ten (10) days of receipt of written demand for performance from County or if the awardee fails to correct or replace defective goods or products within ten (10) days from receipt of written demand, the contract is deemed BREACHED and is cause for termination of the contract. A contract terminated for cause results in retention of the Bond by County for liquidated damages.

I. Warranty of Performance The successful respondent expressly warrants that all services specified in the IFB will be performed with care and diligence and in accordance with all specifications of the IFB. The successful bidder agrees to correct any deficiencies in performance of services upon notification by the County and without additional expense to the County.

CONTINUING NON-PERFORMANCE of the bidder, in terms of specifications, shall be basis for the termination of the contract by the County. The County shall not pay for merchandise/services that are unsatisfactory. Failure to perform any provision will constitute a default of contract, in which case, corrective action shall take place within ten (10) days from the date of written notice citing the nature of breach. Failure to take corrective action or to provide a satisfactory written reply excusing such failure within the prescribed ten (10) days will authorize the County to terminate this agreement by written notice.

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 11 of 42

COMPLIANCE WITH LAWS: The successful Respondents shall comply with all applicable federal, state and local laws and regulations pertaining to the practice of the profession and the execution of the duties under the solicitation. Any contract executed as a result of this IFB shall be governed by the laws of the State of Texas.

LIQUIDATED DAMAGES FOR DELAYS: If the work is not substantially complete by September 25, 2026, the Contractor shall pay to the County as fixed, agreed, and liquidated damages (it being impossible to determine the actual damages occasioned by the delay) the amount of $500 (five hundred dollars) for each calendar day of delay, until the work is completed. The Contractor and Contractor’s sureties shall be liable to the County for the amount thereof.

EXCUSABLE DELAYS: The right of the Contractor to proceed shall not be terminated nor shall the Contractor be charged with liquidated damages for any delays in the completion of the work due to:

1. Any acts of the Government, including controls or restrictions upon or requisitioning of materials, equipment, tools, or labor by reason of war, national defense, or any other national emergency;

2. Any acts of the County;

3. Causes not reasonably foreseeable by the parties to this Contract at the time of execution which are beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God, terrorism, war, acts of another Contractor in the performance of some other contract with the County, fires, floods, epidemics, quarantine, restrictions, strikes, freight embargoes, and weather of unusual severity such as hurricanes, tornadoes, cyclones and other extreme weather conditions;

Provided, however, that the Contractor promptly notifies the County within ten (10) days in writing of the cause of the delay. Upon receipt of such notification, the County shall ascertain the facts and the cause and extent of delay. If, upon the basis of the facts and the terms of this contract, the delay is properly excusable, the County shall extend the time for completing the work for a period of time commensurate with the period of excusable delay.

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 12 of 42

IV. General Terms and Conditions for Solicitations Applicable To: Invitations for Bid (IFB)

1. GENERAL DEFINITIONS:

a. "Auditor" means the Hays County Auditor or his/her designee.

b. "Commissioners Court" means Hays County Commissioners Court.

c. “Contract” means the contract awarded pursuant to the IFB.

d. “Contractor” means a person or firm receiving an award of contract from Commissioners Court.

e. "County" means Hays County, Texas, a political subdivision of the State of Texas.

f. "County Building" means any County owned buildings and does not include buildings leased by County.

g. "Is doing business" and "has done business" mean:

i. Paying or receiving in any calendar year any money or other valuable thing which is worth more than $250 in the aggregate in exchange for personal services or for purchase of any property or property interest, either real or personal, either legal or equitable; or

ii. Loaning or receiving a loan of money; or goods or otherwise creating or having in existence any legal obligation or debt with a value of more than $250 in the aggregate in a calendar year;

iii. But does not include any retail transaction for goods or services sold to a Key Contracting Person at a posted, published, or marked price available to the general public.

h. "Purchasing Agent" means the Hays County Purchasing Agent.

i. “Sub-contractor” means a person or firm doing business with a Contractor.

2. FUNDING: Funds for payment on this Contract have been provided through the County budget approved by

Commissioners Court for this fiscal year only. State of Texas statutes prohibit the obligations and expenditure of public funds beyond the fiscal year for which a budget has been approved. However, the cost of items or services covered by this Contract is considered a recurring requirement and is included as a standard and routine expense of Hays County to be included in each proposed budget within the foreseeable future. County Commissioners expect this to be an integral part of future budgets to be approved during the period of this Contract except for unanticipated needs or events which may prevent such payments against this Contract. However, County cannot guarantee the availability of funds and enters into this Contract only to the extent such funds are made available.

The Fiscal Year for County extends from October 1st of each calendar year to September 30th of the next calendar year.

3. FUNDING OUT: Despite anything to the contrary in this Contract, if, during budget planning and adoption, Commissioners Court fails to provide funding for this Contract for the following fiscal year of County, County may terminate this Contract after giving Contractor thirty (30) calendar days written notice that this Contract is terminated due to the failure to fund it.

4. INVOICING/PAYMENTS:

a. Contractor shall provide County with an Internal Revenue Form W-9, Request for Taxpayer Identification

Number and Certification, that is completed in compliance with the Internal Revenue Code and its rules and regulations before any Contract funds are payable.

b. As a minimum, invoices shall include: (i) name, address, and telephone number of Contractor and similar information in the event payment is to be made to a different address; (ii) County Contract or Purchase Order number; (iii) identification of products or services as outlined in this Contract; (iv) quantity or quantities, applicable unit prices, total prices, and total amount; and (v) any additional payment information called for by this Contract. County will not pay invoices that are in excess of the amount authorized by the purchase order.

c. Payment shall be made by check or warrant by County upon satisfactory delivery and acceptance of products and services and submission of an invoice to the address below:

County Auditor 712 S Stagecoach Trail, Suite 1071 San Marcos, Texas 78666

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 13 of 42

d. Payment shall be deemed to have been made on the date of mailing of the check or warrant. For purposes of payment discounts, time will begin upon satisfactory delivery of products and services and/or submission of acceptable invoice, whichever is last. Partial payments will not be made unless specifically requested and approved by County prior to Contract award.

e. Accrual and payment of interest on overdue payments shall be governed by Tex. Gov't Code Ann., ch.

2251.

5. COUNTY TAXES: If the Contractor subsequently becomes delinquent in the payment of County taxes, it will be grounds for cancellation of the contract. Despite anything to the contrary, if the contractor is delinquent in payment of County property taxes at the time of invoicing, Contractor assigns any payments to be made for performance under this contract to the County Tax Assessor-Collector for the payment of delinquent taxes.

6. PROMPT PAYMENT ACT: TEX. GOV'T CODE ANN., ch. 2251 (Vernon Supp. 1995) requires that payments be made within 30 calendar days. If County fails to pay within 30 days, interest on overdue amounts is subject to Chapter 2251, Texas Government Code. The law does not apply if the terms of a federal grant, contract, regulation, or statute prevent local governments from making timely payments with federal funds. Contractors and subcontractors must pay their suppliers interest if the supplier is not paid within 10 calendar days after the contractor or subcontractor receives payment. Contractors must apply for interest payments within 6 months of submitting a proper invoice if they believe such interest was due but not paid. Interest begins accruing 30 days after either of the following, whichever is later; (i) satisfactory delivery or performance has been completed, or,

(ii) a correct invoice is received at the designated place.

7. FOB POINT: Delivery of all products under this contract, if any, shall be made Free on Board to final destination, at the address shown in this contract or as indicated on each Purchase Order placed against this contract. The title and risk of loss of the goods shall not pass to County until acceptance takes place at the F.O.B. point.

8. INSPECTION AND ACCEPTANCE: The County office or department receiving items pursuant to this contract shall inspect and accept only those items that are satisfactory to them and reject those items which are damaged, or which do not conform to specifications. Contractor shall be responsible for the proper labeling, packing, and delivery to final destination, including replacement of rejected deliveries.

9. VARIATION IN QUANTITY: No variation in the quantity of any item called for by this contract will be accepted unless such variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified elsewhere in this contract.

10. OFFICIALS NOT TO BENEFIT: If a member of Commissioners Court belongs to a cooperative association, the County may purchase equipment or supplies from the association only if no member of the Commissioners Court will receive a pecuniary benefit from the purchase, other than as reflected in an increase in dividends distributed generally to members of the association.

11. NONDISCRIMINATION; CIVIL RIGHTS/ADA COMPLIANCE:

a. Contractor shall not engage in employment practices that have the effect of discriminating against employees or prospective employees because of age, race, color, sex, creed, national origin or handicapped condition.

b. Contractor shall provide all services and activities required in a manner that would comply with the Civil Rights Act of 1964, as amended, the Rehabilitation Act of 1973, Public Law 93-1122, Section 504, and with the provisions of the Americans with Disabilities Act of 1990, Public Law 101-336 [S.933] if Contractor were an entity bound to comply with these laws.

12. CHANGES:

a. This Contract may be amended only by written instrument signed by both County and Contractor. It is acknowledged by Contractor that NO OFFICIAL, EMPLOYEE, AGENT OR REPRESENTATIVE OF COUNTY HAS

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 14 of 42

ANY AUTHORITY, EITHER EXPRESS OR IMPLIED, TO CHANGE THE SCOPE OF THIS CONTRACT OR OTHERWISE AMEND THIS CONTRACT, OR ANY ATTACHMENTS HERETO, UNLESS EXPRESSLY GRANTED

THAT AUTHORITY BY THE COMMISSIONERS COURT.

b. Contractor shall submit all requests for changes to this Contract or any attachment(s) to it to the Purchasing Agent. The Purchasing Agent shall present Contractor's requests to Commissioners Court for consideration.

13. REPRESENTATIONS:

a. Contractor represents that he has thoroughly examined the drawings, specifications, schedule, instructions and all other contract documents. Contractor has made all investigations necessary to be thoroughly informed regarding plant and facilities for delivery of material, equipment and/or services as required by the proposal conditions.

b. The Contractor's delivery time includes weekends and holidays.

c. Contractor certifies that he is a qualified, bondable business entity that he is not in receivership or contemplates it, and has not filed for bankruptcy. He further certifies that the Company, Corporation, Partnership, or Sole Proprietorship is not delinquent with respect to payment of County property taxes.

d. Contractor warrants that all applicable patents and copyrights which may exist on items that will be supplied under the contract have been adhered to and further warrants that County shall not be liable for any infringement of those rights. Warranties granted County shall apply for the duration of this contract or for the life of equipment or supplies purchased, whichever is longer. County must not extend use of the granted exclusive rights to any other than County employees or those with whom County has established a relationship aimed at furthering the public interest, and then only for official public uses.

County will not knowingly or intentionally violate any applicable patent, license, or copyright. Contractor must indemnify County, its officers, agents, and employees against all claims, suits, and liability of every kind, including all expenses of litigation, court costs, and attorney's fees arising in connection with any alleged or actual infringement of existing patents, licenses or copyrights applicable to items sold.

e. The Contractor warrants that upon execution of a contract with the County, he will not engage in employment practices which have the effect of discriminating against employees or prospective employees because of age, religion, race, color, sex, creed, handicap, or national origin and will submit reports as the County may require to assure compliance.

f. Contractor warrants to County that all items delivered and all services rendered will conform to the specifications, drawings, or other descriptions furnished or incorporated by reference, and will be of merchantable quality, good workmanship, and free from defects. Contractor further agrees to provide copies of applicable warranties or guarantees to the Purchasing Agent. Copies will be provided within 10 days after the Notice of Award is issued. Return of merchandise under warranty shall be at Contractor's expense.

14. SUBCONTRACTS:

a. Contractor shall not enter into any subcontracts for any service or activity relating to the performance of this Contract without the prior written approval or the prior written waiver of this right of approval from County. IT IS ACKNOWLEDGED BY CONTRACTOR THAT NO OFFICER, AGENT, EMPLOYEE OR REPRESENTATIVE OF COUNTY HAS THE AUTHORITY TO GRANT SUCH APPROVAL OR WAIVER UNLESS

EXPRESSLY GRANTED THAT SPECIFIC AUTHORITY BY THE COMMISSIONERS COURT.

b. If a subcontract is approved, Contractor must make a "good faith" effort to take all necessary and reasonable steps to insure HUBs maximum opportunity to be subcontractors under this Contract.

Contractor must obtain County approval of all proposed HUB subcontractors through the Purchasing Agent. Failure by Contractor to make a good faith effort to employ HUBs as subcontractors constitutes a breach of this Contract and may result in termination of this Contract.

15. ASSIGNMENT:

a. The parties to this Contract shall not assign any of the rights or obligation hereunder without the prior written consent of the other party. No official, employee, representative or agent of County has the

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 15 of 42 authority to approve any assignment under this Contract unless that specific authority is expressly granted by Commissioners Court.

b. The terms, provisions, covenants, obligations and conditions of this Contract are binding upon and inure to the benefit of the successors in interest and the assigns of the parties to this Contract if the assignment or transfer is made in compliance with the provisions of this Contract.

c. Contractor remains responsible for the performance of this Contract when there is a change of name or change of ownership. If a change of name is required, the Purchasing Agent shall be notified immediately.

No change in the obligation of or to Contractor will be recognized until it is approved by Commissioners Court.

16. DISPUTES AND APPEALS: The Purchasing Agent acts as the County representative in the issuance and administration of this contract in relation to disputes. Any document, notice, or correspondence not issued by or to the Purchasing Agent or other authorized County person, in relation to disputes is void unless otherwise stated in this contract. If the Contractor does not agree with any document, notice, or correspondence issued by the Purchasing Agent, or other authorized County person, the Contractor must submit a written notice to the Purchasing Agent within ten (10) calendar days after receipt of the document, notice, or correspondence, outlining the exact point of disagreement in detail. If the matter is not resolved to the Contractor’s satisfaction, Contractor may submit a written Notice of Appeal to the Commissioners Court, through the Purchasing Agent, if the Notice is submitted within ten (10) calendar days after receipt of the unsatisfactory reply. Contractor then has the right to be heard by Commissioners Court.

17. MEDIATION: When mediation is acceptable to both parties in resolving a dispute arising under this Agreement, the parties agree to use a mutually agreed upon mediator, or a person appointed by a court of competent jurisdiction, for mediation as described in Section 154.023 of the Texas Civil Practice and Remedies Code. Unless both parties are satisfied with the result of the mediation, the mediation will not constitute a final and binding resolution of the dispute. All communications within the scope of the mediation shall remain confidential as described in §154.073 of the Texas Civil Practice and Remedies Code, unless both parties agree, in writing, to waive the confidentiality.

18. FORCE MAJEURE: If the performance by either party of any of its obligations under this Contract is interrupted or delayed due to an act of God or the common enemy or as the result of war, riot, civil commotion, sovereign conduct, or the act or conduct of any person or persons not a party to this Contract, then it shall be excused from performance for such period of time as is reasonably necessary to remedy the effects thereof.

19. NON-WAIVER OF DEFAULT:

a. No payment, act or omission by County may constitute or be construed as a waiver of any breach or default of Contractor which then exists or may subsequently exist. No official, agent, employee or representative of County may waive any breach of any term or condition of this Contract unless expressly granted that specific authority by the Commissioners Court.

b. All rights of County under this Contract are specifically reserved and any payment, act or omission shall not impair or prejudice any remedy or fight to County under it. Any right or remedy in this Contract shall not preclude the exercise of any other right or remedy under this Contract or under any law, nor shall any action taken in the exercise of any right or remedy be deemed a waiver of any other rights or remedies.

20. TERMINATION FOR DEFAULT: Failure by either County or Contractor to perform any provisions of this Contract shall constitute a breach of contract. Either party may require corrective action within ten (10) calendar days after date of receipt of written notice citing the exact nature of the other's breach. Failure to take corrective action or failure to provide a satisfactory written reply excusing such failure within the ten (10) calendar days shall constitute a default. The defaulting party shall be given a twenty (20) calendar day period within which to show cause why this Contract shall not be terminated for default. All notices for corrective action, breach, default or show cause on behalf of County shall be issued by the Purchasing Agent or County legal representative only, and all replies to the same shall be made in writing to the County Purchasing Agent or County legal representative at

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 16 of 42 the address provided herein. Notices issued by or to anyone other than the Purchasing Agent or County legal representative shall be null and void, and shall be considered as not having been issued or received. County reserves the right to enforce the performance of this Contract in any manner prescribed by law in case of default and may contract with another party with or without competition or further notification to the contractor. At a minimum, Contractor shall be required to pay any difference in the cost of securing the services covered by this Contract, or compensate for any loss or damage to the County derived hereunder if it becomes necessary to contract with another source because of a default, plus reasonable administrative costs and attorney's fees. In the event of termination for default, County, its agents or representatives, shall not be liable for loss of any profits anticipated under this Contract.

21. TERMINATION FOR CONVENIENCE: County reserves the right to terminate this Contract upon thirty (30) days written notice for any reason deemed by the Commissioners Court to serve the public interest, or resulting from any governmental law, ordinance, regulation, or court order. Termination for convenience shall not be exercised with the sole intention of awarding the same or similar contract requirements to another source. In the event of such termination, County shall pay Contractor those costs directly attributable to work done in preparation for compliance with this Contract prior to termination; provided, however, that no costs shall be paid which are recoverable in the normal course of the business in which Contractor is engaged, nor shall County pay any costs which can be mitigated through the sale of supplies or inventories. If County pays for the cost of supplies or materials obtained for use under this Contract those supplies or materials shall become the property of County and shall be delivered to the FOB point shown in this Contract, or as designated by the Purchasing Agent. County shall not be liable for loss of any profits anticipated under this Contract.

22. GRATUITIES: Contractor shall not provide any gratuity in any form, including entertainment, gifts, or otherwise, to any employee, buyer, agent, or representative of County with a view to securing a contract, or securing favorable treatment with respect to the award or amendment, or the making of any determination with respect to the performance of this Contract. County may terminate this Contract if it is found that gratuities of any kind including entertainment, or gifts were offered or given by the Contractor or any agent or representative of the Contractor, to any County Official or employee with a view toward securing favorable treatment with respect of this contract. If this Contract is terminated by the County pursuant to this provision, County shall be entitled, in addition to any other rights and remedies, to recover from the Contractor at least three times the cost incurred by Contractor in providing the gratuities.

23. COVENANT AGAINST CONTINGENT FEES: Contractor represents and warrants that no persons or selling agency has been retained to solicit this Contract upon an understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial selling agencies maintained by the Contractor to secure business. For breach or violation of this warranty, County shall have the right to terminate this Contract without liability, or in its discretion to, as applicable, add to or deduct from the Contract price for consideration, or otherwise recover, the full amount of such commission, percentage, brokerage, or contingent fee.

24. COUNTY ACCESS: Contractor shall maintain and make available for inspection, audit or reproduction by any authorized representative of County all books, documents, and other evidence pertinent to the costs and expenses of this Contract, including but not limited to both direct and indirect costs, cost of labor, material, equipment, supplies, and services, and all other costs and expenses of whatever nature for which reimbursement is claimed under this Contract. All required records shall be maintained until an audit is completed and all required questions arising therefrom are resolved, or three (3) years after completion of the contract term, whichever occurs first; provided, however, the records will be retained beyond the third year if an audit is in progress or the finding of a completed audit have not been resolved satisfactorily.

25. FORFEITURE OF CONTRACT:

IFB 2026-B07 Nutty Brown Road – Remove and Replace Hot Mix Page 17 of 42

a. The selected Offeror must forfeit all benefits of the contract and County must retain all performance by the selected Offeror Contractor and recover all consideration or the value of all consideration paid to the selected Offeror pursuant to the contract if:

b. The selected Offeror was doing business at the time of submitting its proposal offer or had done business during the 365- day period immediately prior to the date on which its proposal offer…