ESBD_504442_1775579076374_802-26-73518_IFB 25ft Mono-Hull Boat Package.pdf

IFB No. 802-26-73518 Page 1 of 34

INVITATION FOR BID

SEND INVOICE TO: RETURN BIDS TO: BIDDER MUST SIGN BELOW:

Texas Parks and Wildlife Department ATTN: Accounts Payable 4200 Smith School Road

Austin, Texas 78744

Purchasing.bidbox@tpwd.texas.gov Or

TPWD – Purchasing and Contracting 4200 Smith School Road

Austin, TX 78744

Bid Due Deadline:

2:00 pm CST; April 22, 2026

AUTHORIZED SIGNATURE DATE

FAILURE TO SIGN WILL DISQUALIFY BID

DESTINATION IF DIFFERENT THAN ABOVE: QUESTIONS – SEND EMAIL TO: REQUISITION / IFB NUMBER

See specifications referenced in Section 7, Subsection 7.4. Purchasing.bidbox@tpwd.texas.gov

802-26-73518

By signing this bid, bidder certifies that if a Texas address is shown as the address of the bidder, bidder qualifies as a Texas bidder as defined in Title 34 TAC Rule 20.32(68). FAILURE TO SIGN THE BID ABOVE WILL DISQUALIFY BID. Bidder agrees to comply with all conditions of this bid. Show bid due date and Requisition number on sealed bid envelop and show return address of firm.

BID F.O.B. AGENCY RECEIVING ADDRESS UNLESS OTHERWISE SPECIFIED BELOW.

By signing this bid, bidder certifies that if a Texas Address is shown as the address of the bidder, bidder qualifies as a Texas bidder as defined in Title 34 TAC Rule 20.32(68). Bidder agrees to comply with all conditions of this bid. Show bid due date and Requisition number on sealed bid envelop and show return address of firm.

Pursuant to Executive Order GA-48 of the Governor of Texas: Respondent certifies that neither it, nor its holding companies or subsidiaries is: (a) Listed in Section 889 of the 2019 National Defense Authorization Act; (b) Listed in Section 1260H of the 2021 National Defense Authorization Act; or (c) Owned by the government of a country on the U.S. Department of Commerce’s foreign adversaries list under 15 C.F.R. Section 791.4; or (d) Controlled by any governing or regulatory body located in a country on the U.S. Department of Commerce’s foreign adversaries list under 15 C.F.R. Section 791.4.

Bidder must fill in: (See instructions for Texas ID Number in General Terms & Conditions, Paragraph 1.10

TEXAS ID NUMBER: _________________________________________________

Printed Name/Title: _________________________________________________ Name of Firm: _________________________________________________ Street Address: _________________________________________________ City-State-Zip: _________________________________________________ Telephone No: _________________________________________________ Email Address: _________________________________________________

AWARD NOTICE: The State reserves the right to make an award on the basis of low line-item bid, low total of line items, or in any other combination that will serve the best interest of the State and to reject any and all bid items in the sole discretion of the State.

Texas Parks and Wildlife Department (TPWD) is seeking to purchase two (2) 25 ft. Fiberglass Boats, two (2) 300hp Outboard Motors, and two (2) Boat Trailers for the Law Enforcement Division as per the attached specifications dated April 2026.

TPWD will only award a Contract to an actively licensed Marine Dealer, Manufacturer or Manufacturer’s Authorized Distributor. If Respondent is a Manufacturer’s Authorized Distributor, documentation of such is required to be furnished with bid submission.

NOTE: Two (2) boat, motor, and trailer packages (with requested accessories) shall be delivered fully assembled as a single unit. However, for property reporting purposes, TPWD requires line-item cost for each item.

mailto:Purchasing.bidbox@tpwd.texas.gov mailto:Purchasing.bidbox@tpwd.texas.gov

IFB No. 802-26-73518 Page 2 of 34

Item Description Class/Item 120-23, 120-63, 120-90 Quantity Unit of Measure Unit Price Extension

1.

25ft Fiberglass Boat

Example: Majek Xtreme, Haynie 25 McClain, Transport XLR8 2480, Dargel 250 Kuda, or TPWD approved equivalent

Specify Make/Model ____________________________________

Specify Warranty ______________________________________

Specify Estimated Delivery _______________________________

Each

2.

300hp Outboard Motor for Fiberglass Boat described in Line item 1.

Example: Mercury Sea Pro 300 Commercial DTS, Suzuki DF 300 AP, or TPWD approved equivalent.

Specify Make/Model ____________________________________

Specify Warranty ______________________________________

Specify Estimated Delivery ______________________________

3.

Boat Trailer for Fiberglass Boat with mounted outboard motor as described in lines 1 and 2 above.

Example: McClain Aluminum Model Extreme, Coastline, or TPWD approved equivalent.

Specify Make/Model __________________________________

Specify Warranty ____________________________________

Specify Estimated Delivery _____________________________

DELIVERY: TPWD would like the option to pick up boat/motor/trailer package as determined to be best value to the State to save freight charges if Respondent is in close proximity to delivery location. TPWD will determine best value at time of award.

4.

Delivery fee for ONE (1) complete and assembled Boat Package (boat, outboard motor, and trailer) to TPWD LE Region 4 Office – College Station, TX 77845

Delivery in ________ calendar days after receipt of order.

LOT

5.

Delivery fee for ONE (1) complete and assembled Boat Package (boat, outboard motor, and trailer) to TPWD LE Region 6 Office – Lubbock, TX 79415

Delivery in ________ calendar days after receipt of order.

LOT

IFB No. 802-26-73518 Page 3 of 34

OPTIONAL ACCESSORIES: Accessory items as described in Section 4, Subsection 4.5, may be awarded in part, in whole, or none, based on the availability of funds. Cost of each item shall include installation. Determination will be made at the time of award. Accessory items will not be included in the evaluation process for price but may be considered when determining best value.

6. Cup Holders (specify make) ______________________________ 2 Each $ $

7. T-Top (specify make) ___________________________________ 1 Each $ $

8. Dome Lights (specify make) ______________________________ 1 Each $ $

9. Flood Lights (specify make) ______________________________ 3 Each $ $

10. Spotlight (specify make) _________________________________ 1 Each $ $

11. Controller (specify make) ________________________________ 1 Each $ $

12. Siren (specify make) ____________________________________ 1 Each $ $

13. Speaker (specify make) _________________________________ 1 Each $ $

14. Signal (specify make) ___________________________________ 1 Each $ $

15. Electronics Package (specify make) _______________________ 1 Each $ $

16. Wireless Engine Cutoff Switch System (specify make) ________________________________________ 1 Each $ $

17. VHF Radio (specify make) _______________________________ 1 Each $ $

18. Large Helm Station Pad (specify make) ________________________________________ 1 Each $ $

19. Power Pole Blade (specify make) _________________________ 1 Each $ $

20.

Respondents are highly encouraged to submit a detailed price list for additional related accessories and attachments.

Cost of each item shall include installation. TPWD reserves the right to award one, none, or any combination of options depending on the availability of funds and as determined to be best value.

Determination will be made at the time of award. Optional items will not be included in the evaluation process.

ATTACH PRICE LIST

Offered by a Veteran Heroes United in Business (VetHUB) certified by CPA.

IFB No. 802-26-73518 Page 4 of 34

PREFERENCES

See Appendix 22 of the State of Texas Procurement and Contract Management Guide regarding preferences.

Check below to claim a preference under Title 34 TAC Rule 20.38

□ Goods produced or offered by a Texas bidder that is owned by a Texas resident service-disabled veteran

□ Goods produced in Texas or offered by a Texas bidder that is not owned by a Texas resident service-disabled veteran

□ Agricultural products grown in Texas

□ Agricultural products offered by a Texas bidder

□ Services offered by a Texas bidder that is owned by a Texas resident service-disabled veteran

□ Services offered by a Texas bidder that is not owned by a Texas resident service-disabled veteran

□ Texas Vegetation Native to the Region

□ USA produced supplies, materials, or equipment

□ Products of persons with mental or physical disabilities

□ Products made of recycled, remanufactured, or environmentally sensitive materials including recycled steel

□ Energy Efficient Products

□ Rubberized asphalt paving material

□ Recycled motor oil and lubricants

□ Products produced at facilities located on formerly contaminated property

□ Products and services from economically depressed or blighted areas

□ Vendors that meet or exceed air quality standards

□ Recycled or Reused Computer Equipment of Other Manufacturers

□ Foods of Higher Nutritional Value

FOR FURTHER INFORMATION CONTACT PURCHASER:

ALLYE POTTER, CPPB, CTCD – Telephone – 512-718-3703 Email: purchasing.bidbox@tpwd.texas.gov

IFB No. 802-26-73518 Page 5 of 34

Solicitation 802-26-73518 Specifications for 25ft Fiberglass Boat, Outboard Motor, and Trailer Package

1. INTRODUCTION: Texas Parks and Wildlife Department (TPWD) is seeking bids to purchase two (2) 25ft

Fiberglass Boats, two (2) 300hp Outboard Motors, and two (2) Boat Trailers for the Law Enforcement Division as per the attached specifications dated April 2026.

2. TERM OF CONTRACT: Contract shall commence upon the issuance of a contract by TPWD and automatically expires upon the delivery date agreed upon and final acceptance by TPWD.

3. SPECIFICATIONS AND EXCEPTIONS TO SPECIFICATIONS PROCESS:

3.1. The equipment provided shall be in accordance with the purchase specifications herein. TPWD will decide answers to all questions that may arise as to the interpretation of the specifications and the quality or acceptability of goods/services provided.

3.2. Catalogs, brand names, or manufacturer’s references are descriptive only, and indicate type and quality desired. Bids on brands of like nature and quality will be considered unless advertised under Texas Gov’t Code §2155.067. If the Respondent is offering brands other than the references, response should show manufacturer, brand or trade name, and other description of product offered.

3.3. If Respondent is offering brand(s) other than brand(s) specified, illustrations and complete description of product offered are requested to be made part of the bid. Failure to take exception to specifications or reference data will require the bid to be disqualified as non-responsive and failing to meet minimum specifications.

4. SPECIFICATIONS SHALL MEET OR EXCEED THE FOLLOWING:

4.1. Line 1 – 25ft Fiberglass Boat:

4.1.1. Examples: Majek Xtreme, Haynie 25 Magnum, Transport XLR8 2480, Skeeter SX2550, or

TPWD approved equivalent.

4.1.2. Quantity: Two (2)

4.1.3. Requirement: Boat must conform to 33CFR, Code of Federal Regulations (Part #183)

4.1.4. Length: Approximately twenty-five feet (25-ft).

4.1.5. Beam: Approximately ninety-nine to one hundred four inches (99-inches to 104-inches)

4.1.6. Weight: Approximately one thousand six hundred pounds to three thousand seven hundred pounds (1600 lb. to 3700 lb.)

4.1.7. Draft: Maximum fourteen inches (14-inches)

4.1.8. Chine Length: To run full length of the hull for stability and control.

4.1.9. Color: Grey color with black trim or TPWD approved equivalent, no decals

4.1.10. Fuel Type, Tank and Storage:

a. Fuel Type: Gasoline

b. Tank Capacity: Minimum sixty gallons (60 gallons)

c. Fuel cell shall be American Boat and Yacht Council (ABYC) approved polyurethane with an external fuel sending device with a single drain line to the bilge area of the boat.

IFB No. 802-26-73518 Page 6 of 34

4.1.11. Batteries: Two (2) marine batteries, wired through a switch with the following settings: Off, Battery 1, Battery 2, and Both / All.

a. Main grounding lug wired in battery compartment for grounding all necessary electronics.

b. Main power plug wired in battery compartment for powering all necessary electronics.

4.1.12. Navigation Lights:

a. United States Coast Guard (USCG) approved navigation lights shall be installed in accordance with USCG requirements.

b. All around white navigation light mounted to the top rear of the T-Top

4.1.13. Bilge Pump: Minimum of five hundred gallons per hour (500 gph)

4.1.14. Boat Construction:

a. Boat hull shall be constructed of composite materials / wood (boat panel material) step type hull.

b. Wood shall be pentachlorophenol treated or TPWD approved marine grade equivalent.

c. Gunnel Construction: roll top style preferred, liner accepted.

d. Electric trim tabs with switches and components

e. Steering System and Components: See Section 4.2.14.

f. Wiring:

1. Shall be marine grade tinned wire of appropriate size.

2. Shall be installed and color coded according to ABYC standards.

3. Wiring connections shall be soldered and shrink wrapped.

g. Deck Hardware: Minimum of four (4) retractable cleats installed; two (2) starboard and two (2) port.

h. Transom Deck:

1. Raised deck across transom with hatch, sealed storage compartments with fiberglass hatch covers to mount battery, oiler, and hydraulic transom lift pump.

2. Hydraulic ten-inch (10-inch) transom lift.

3. Transom deck shall have nonskid medium gray Isophthalic Neopentyl Glycol (ISO- NPG) gelcoat.

i. Bow Deck:

1. Raised bow deck to gunwale with hatched, sealed storage compartments with fiberglass hatch covers and drains.

2. Bow deck shall have nonskid medium gray ISO-NPG gelcoat.

IFB No. 802-26-73518 Page 7 of 34

4.1.15. Center Console:

a. Console shall be fiberglass; center mounted with plexiglass windshield and anodized aluminum grab rail.

b. Console shall have two (2) sealed twelve-volt (12V) accessory plugs and should be mounted on the left side of console, and throttle control box mounted on the right side of helm.

c. Electrical switches shall be waterproof, marine panel switch type.

d. Console shall have the following: marine boat rocker electrical switch panel, six (6) gang waterproof toggle switches, digital voltage display, two (2) Universal Serial Bus (USB) and two (2) Universal Serial Bus Compact (USB-C) charging adapters, and one (1) 12-volt accessory plug.

e. Console instrumentation shall include Tachometer, Speedometer, Water pounds per square inch (PSI) and temperature, fuel gauge, and hour meter.

f. Two (2) blue light-emitting diode (LED) lights shall be mounted on the front of console.

g. Main grounding lug/bar shall be located under the console for grounding of all installed accessories.

h. Main power lug/bar shall be located under the console for powering all installed necessary electronics.

i. Seating:

1. Mounted seat behind console must accommodate at least two (2) passengers, shall be anodized aluminum frame leaning post with padded seat and back rest and include a foldable footrest.

2. Storage locker mounted under the aluminum frame leaning post with lockable door to the rear of the vessel to accommodate the storage of a minimum two (2) thirty-three-inch (33-inch) patrol rifles and gear.

3. Front console seat shall accommodate a minimum of two (2) passengers, shall be padded and part of console with sealed storage below.

4. Seat material shall be waterproof, and the color shall be gray or TPWD approved color.

4.1.16. Stainless steel steering wheel with turning knob.

4.1.17. Commercial Grade Keel Guard: Examples: Hamby’s Beach Bumper or TPWD approved equivalent.

a. Five inches (5-inches) wide or wider and a minimum of ten feet (10-ft) in length.

b. Shall be installed with epoxy resin by Respondent per the manufacturer’s requirements.

c. Color: Black, gray, or TPWD approved color.

4.1.18. Must have a USCG-approved fire extinguisher.

IFB No. 802-26-73518 Page 8 of 34

4.2. Line 2 – 300hp Outboard Motor for Fiberglass Boat (as described in Section 4.1)

4.2.1. Examples: Mercury Sea Pro 300 Commercial DTS, Suzuki DF300 AP, or TPWD approved

4.2.2. Quantity: Two (2)

4.2.3. Shall be compatible with the fiberglass boat listed above in Section 4.1.

4.2.4. Horsepower (HP): 300 HP

4.2.5. Engine Type: V6 or V8; Minimum 24 valve DOHC

4.2.6. Shaft Length: Approximately twenty to thirty inches (20-inches to 30-inches) dependent upon manufacturer’s specification. Shaft length shall be appropriate for the boat model specified in Section 4.1.

4.2.7. Displacement – Liter (L): Approximately 4L to 4.6L

4.2.8. California Air Resource Board (CARB) Rating: Minimum 3-star rating

4.2.9. Gear Shift: Forward, Neutral, Reverse or Digital DTS

4.2.10. Rotation: Standard

4.2.11. Full Throttle Range, RPM: In an approximate range 4,800 to 6,300 Revolutions per Minute

(RPM)

4.2.12. Fuel System: Electronic Fuel Injection (EFI)

4.2.13. Starting: Electric Start

4.2.14. Steering:

a. Preferred drive/fly by wire system.

b. If Respondent is bidding a power assisted hydraulic system, it must be constructed with commercial grade components and provide optimal performance for the vessel at both low and high speeds.

c. Must provide a steering system with all appropriate components for optimal performance of the vessel and outboard motor.

4.2.15. Color: Black, Gray, or TPWD approved equivalent

4.2.16. Propeller:

a. Shall have compatible propeller for fiberglass boat listed in Section 4.1.

b. Pitch: must provide a propeller with an appropriate pitch for optimal performance.

c. Material: Stainless Steel

4.2.17. Motor shall be installed on boat by Respondent and fully operational with all required controls and gauges.

IFB No. 802-26-73518 Page 9 of 34

4.3. Line 3 – Boat Trailer for Fiberglass Boat with Mounted 300hp Outboard Motor (as described in Section 4.1 and 4.2.)

4.3.1. Examples: McClain Aluminum, Coastline, or TPWD approved equivalent.

4.3.2. Quantity: Two (2)

4.3.3. Trailer Material: Aluminum

4.3.4. Capacity: Suitable to fit and transport boat and outboard motor specified above.

4.3.5. Length: Shall be approximately thirty feet (30-ft) overall to include trailer with boat and outboard motor.

4.3.6. Axle: Galvanized steel tandem axle with buddy bearing, lubricated hubs, or TPWD approved

4.3.7. Tires and Wheels:

a. Shall be new radial trailer-rated tires specifically for the load.

b. Shall include one (1) mounted spare wheel and carrier.

c. Wheel material shall be galvanized.

4.3.8. Fenders: Aluminum, stainless steel or TPWD approved equivalent

4.3.9. Mechanical Tongue-Mounted Jack: Retractable / foldable with wheel for ground contact.

4.3.10. Shall be properly sized for boat, outboard motor, and trailer.

4.3.11. Lighting: Trailer shall be equipped with fully grounded, waterproof, submergible LED lighting that meets Texas Department of Transportation (TXDOT) regulation standards, with 4-prong connector.

4.3.12. All wiring shall meet TXDOT requirements.

4.3.13. Safety chains, transom saver, and guidepost.

4.3.14. Transom tie downs to secure boat to trailer.

4.3.15. Treated wood or composite bunking.

4.3.16. Aluminum I-beams and welded bunk under structure

4.3.17. Aluminum guidepost with polyvinyl chloride (PVC) cover / rollers with stainless pins

4.3.18. Heavy duty three-piece bow stop

4.3.19. All hardware and submersible parts shall be stainless steel.

4.3.20. Mechanical winch with strap and bow hook

4.3.21. Two-inch (2-inch) ball hitch

4.3.22. Rollers shall be minimum size twelve inches (12-inches).

4.3.23. Shall include two (2) boat buckles:

IFB No. 802-26-73518 Page 10 of 34

a. Examples: G2 retractable transom tie downs, Fulton Transom tie downs, or TPWD approved equivalent

b. Shall be installed by Respondent at rear of trailer for proper transom stabilization.

4.3.24. Trailer to be equipped in accordance with federal and State of Texas laws governing 24-hour highway operation.

4.4. Lines 4 & 5 – Refer to delivery information in Section 7, Subsection 7.4. Inspection, Delivery, and Acceptance

4.5. Lines 6 to 20 – Optional Accessory Items: Accessory items may be awarded in part, in whole, or none based on funds availability. Best Value determination will be made at the time of award. Cost of each item shall include installation. Accessories to be priced as separate line items shall include the following, at a minimum:

4.5.1. Cup Holders: Two (2) placed on or in the console.

4.5.2. T-Top:

a. Heavy duty aluminum with minimum four (4) legs installed by Respondent to the center console with covered top and Stryker electronics box, CM Marine electronics box, or TPWD approved equivalent.

b. Must have radio box with latching, lockable front door.

c. Radio Box shall fit between the T-Top uprights and be of heavy-duty fiberglass construction.

d. Tab to be welded to outside edge of top at each corner with three eights inch (3/8-inch) hole in center of tab, and twelve inches by fourteen-inch (12-inches x 14-inches) aluminum plate welded across center of top and positioned approximately above top cover to facilitate emergency light mounting.

e. Cable pull wires shall be installed inside the T-Top uprights from the bottom to the top frame, suitable for pulling electronic wires through the T-Top for any future wiring of additional electronics.

4.5.3. Dome Lights:

a. Examples: i2Systems Tri-Color LED recessed light, ITC Tri-Color LED Light, or TPWD approved equivalent.

b. Color: Marine grade Tri-Color LED light with red, white, and blue selection.

Dome lights to be installed on the bottom of T-Top electronics box and wired to rocker switch panel.

4.5.4. Flood Lights:

a. Examples: Rigid Industries D-Series PRO flood diffused white LED lights, Vision X LED

Light Cannon 4.5-inch Marine Grade, or TPWD approved equivalent.

b. Color: White

c. Shall be installed by Respondent on T-Top as follows: One (1) center port side, one (1) center starboard side, and one (1) center stern side. Lights shall be wired to rocker switch panel.

IFB No. 802-26-73518 Page 11 of 34

4.5.5. Spotlight:

a. Examples: Sho-Me model# 10.5120F w/D flasher dual color, Vision X Marine Grade, Xmitter Low Pro Extreme LED bar 12.2-inch, Rigid Industries SR Series Pro 10-inch LED light, or TPWD approved equivalent.

b. Color: White

c. Shall be mounted and installed by Respondent on top of the T-Top in the center facing the bow with necessary hardware and mounting plates.

4.5.6. Controller:

a. Examples: Feniex 4200 Mini X Controller, Federal Signal Smart Controller Series B, or

TPWD approved equivalent.

b. Shall be mounted and installed by Respondent on top starboard side of center console with necessary hardware and mounting plates.

4.5.7. Siren:

a. Examples: Feniex Storm Pro 100-watt Siren, Federal Signal Smart Siren Platinum, or

TPWD approved equivalent.

b. Shall be mounted and installed by Respondent in T-Top electronics box. Accompanying microphone shall be mounted outside the T-Top electronics box on the starboard side with a properly weather sealed grommet to protect microphone cord.

4.5.8. Speaker:

a. Examples: Feniex Triton 100-watt Siren Speaker, Federal Signal BP100 Series Siren

Speaker, or TPWD approved equivalent.

b. Shall be mounted and installed by Respondent in T-Top in the front of the electronics box facing the bow.

4.5.9. Signal:

a. Examples: Feniex Fusion Mini Lightbar, all blue LED, Federal Signal 18” Navigator

Discrete all blue LED Light bar, or TPWD approved equivalent.

b. Shall be mounted, installed, and centered by Respondent on top of T-Top with adequate support plate and wired to controller.

4.5.10. Electronics Package:

a. Examples: Raymarine Axiom Pro 12 RVX with Platinum + SD 365 Est Gulf of Mexico and

RV-100 All-in-One Transom 8M with 170s Multifunction Color Display and AIS5000 Transponder Bundle and AR200 Augmented Reality; Hummingbird XPLORE 12 CMSI+ with XM 14 HW CMSI T Transducer with side scan sonar, or TPWD approved equivalent.

b. To be installed and mounted by Respondent on center console with necessary hardware and mounting plates. Transducers to be mounted in appropriate place on vessel to avoid any interference with transmitting and receiving appropriate signals.

c. Shall be separately wired with main power line coming from battery and with main power disconnect switch wired into the six (6) panel rocker installed on the console.

IFB No. 802-26-73518 Page 12 of 34

4.5.11. Wireless Engine Cutoff Switch System:

a. Examples: Fell Marine MOB+, or TPWD approved equivalent.

b. Must meet ABYC A-33 standard for Engine cutoff devices.

c. Shall be installed in addition to the manufacturer’s installed manual switch and not replace it.

d. Must include a minimum of four (4) wireless devices for the vessel’s occupants.

e. Shall be installed and mounted by Respondent per manufacturer’s instructions and fully operational upon delivery.

4.5.12. VHF Radio:

a. Examples: Standard Horizon GX 1400B VHF with Antenna, G3 Ray 53 VHF Radio with

VHF Antenna, 8-ft, 6db, or TPWD approved equivalent.

b. Shall be mounted and installed by Respondent in T-Top Electronics box. Accompanying microphone shall be mounted outside the T-Top electronics box on the starboard side with a properly weather sealed grommet to protect the microphone cord.

4.5.13. Large Helm Station Pad:

a. Examples: SeaDek, Aqua Marine Deck, or TPWD approved equivalent.

b. Size shall be approximately sixteen inches by thirty-nine inches (16-inches x 39-inches).

c. Shall be installed by Respondent per manufacturer’s instructions.

4.5.14. Power Pole Blade:

a. Examples: Minn Kota Talon or TPWD approved equivalent.

b. Quantity: One (1)

c. Length: Ten feet (10-ft)

d. Hydraulic, shallow water anchor

e. Shall be installed by Respondent per manufacturer’s instructions.

5. REFERENCED BRAND EXAMPLE: Catalogs, brand names or manufacturer's references are descriptive only, and indicate type and quality desired. Proposals on brands of like nature and quality will be considered. If proposing other than the referenced brands/model number, Respondent must show manufacturer, brand or trade name, product number and provide complete descriptive information of product offered and include with response. Failure to take exception to specifications or reference data will require Respondent to furnish specified brand names, numbers, etc.

6. REQUIREMENTS:

6.1. Condition of Product: New Equipment ONLY; NO re-manufactured or “gray market” items. All items must be covered by the manufacturer’s warranty. The unit shall be made ready for continuous operation upon delivery. Responded is cautioned that any unit delivered to the FOB point that does not meet specifications in every aspect will not be accepted.

IFB No. 802-26-73518 Page 13 of 34

6.2. All Parts: All parts not specifically mentioned which are necessary for the unit to be complete and ready for operation or which are normally furnished as standard equipment shall be furnished by the vendor. All parts shall conform in strength, quality, and workmanship to the accepted standards of the industry.

6.3. Quantities: Quantities listed are projected order quantities. TPWD reserves the right to increase or decrease quantities prior to award depending on bid results and budget constraints.

6.4. Manuals: Manuals containing illustrated parts list, operating and service instructions for the unit shall be delivered with unit. Manual shall outline all necessary service and operating instructions for the unit delivered and provide necessary warning and safety precautions.

6.5. Warranty Requirements: The unit shall be warranted against defects in material and workmanship for the Manufacturer’s Standard Warranty for government use. The warranty begins on the date the unit is determined to meet specifications and accepted by TPWD.

7. INSPECTION, DELIVERY AND ACCEPTANCE:

7.1. Freight Charges: Shipping shall be F.O.B. destination; therefore, unit prices must include all shipping, handling, fuel surcharges, delivery fees, and tariffs. TPWD would like the option to pick up the boat and trailer as specified herein to save freight charges if the vendor is in close proximity to delivery location(s). Respondent shall include delivery quote line-item option in bid response. TPWD will determine best value as it pertains to delivery at time of award.

7.2. Predelivery Inspection:

7.2.1. Vendor shall contact TPWD Boating Law Administrator and Assistant Boating Law Administrator to schedule an inspection of the final assembled boat(s), motor(s), accessories, and trailer(s) prior to scheduling of their delivery as specified in Section XX. The Inspection shall be performed at awarded Vendor’s facility for verification that final predelivery status of boat package is in compliance with all specifications herein prior to the scheduling of a delivery appointment. Contact for TPWD Predelivery Inspection shall be provided upon award.

7.2.2. TPWD will pay for TPWD staff travel expenses for initial predelivery inspection. If specification compliance issues are identified at initial predelivery inspection, Vendor shall be responsible for TPWD personnel travel expense for any additional on-site inspections required to ensure specification compliance issues have been resolved.

7.2.3. Final acceptance shall not occur until completion of delivery, inspection, and acceptance at location specified in Section 7.4.

7.3. Delivery Schedule and Requirements:

7.3.1. Vendor must contact TPWD point of contact as shown on any resulting contract award or purchase order to schedule delivery date and time. Vendor shall provide one (1) week notice prior to delivery to contact designated on purchase order.

7.3.2. Respondent shall provide delivery terms with bid response. Delivery may be a factor in determining best value award.

IFB No. 802-26-73518 Page 14 of 34

7.3.3. TPWD does not have a loading dock to unload fully assembled boat/motor/trailer packages upon delivery. Trailers shall be delivered by means and method that does not require TPWD to unload at no additional cost to TPWD.

7.4. Delivery Address:

7.4.1. Quantity one (1) shall be delivered to:

TPWD Law Enforcement Region 4 College Station Office 12815 FM 2154, Suite 160 College Station, TX 77845

7.4.2. Quantity one (1) shall be delivered to:

TPWD Law Enforcement Region 6 Lubbock 1702 Landmark Ln, Unit 1 Lubbock, TX 79415

7.5. Registration and Titling: Respondents shall title and register as EXEMPT registration, all equipment requiring titling and registration to the address listed below once received by TPWD. The original Manufacturer’s Statement of Origin (MSO) as well as the most current version of TxDMV form 130U or Application for Texas Title, with signature shall be submitted to:

Texas Parks and Wildlife Department Attn: Fleet Manager 4200 Smith School Road Austin, TX 78744

7.6. Delivery Delays: If delay is foreseen, Contractor shall give written notice to TPWD and must keep TPWD advised at all times of status of order. Default in promised Delivery Days After Receipt of Order (ARO) without accepted reasons or failure to meet specifications authorizes TPWD to purchase goods and services of this contract elsewhere and charge any increased costs for the goods and services, including the cost of re-soliciting, to the Contractor.

7.7. Compliant Products: Delivery does not occur until the Contractor delivers products, materials, or services in full compliance with the specifications to Customer’s F.O.B. destination, unless delivery is specifically accepted, in whole or in part, by the Customer. Providing products, materials or services which do not meet all specification requirements does not constitute delivery. Customer reserves the right to require new delivery or a refund in the event that materials or products that do not meet specifications are discovered after payment has been made.

7.8. Acceptance: All equipment ordered will be subject to acceptance inspection and performance testing upon receipt. Acceptance inspection and performance testing will not take more than five (5) working days, weather permitting. Vendor will be notified within this time frame of any units not delivered in full compliance with the purchase order specifications.

IFB No. 802-26-73518 Page 15 of 34

8. INQUIRIES:

8.1. Contact: All requests, questions, or other communications about this Solicitation shall be made in writing to TPWD’s Purchasing Department, addressed to the following person:

Allye Potter, CPPB, CTCD Phone 512-718-3703 Purchaser VI purchasing.bidbox@tpwd.texas.gov Texas Parks & Wildlife Department 4200 Smith School Road, Austin, Texas 78744

8.2. Clarifications: TPWD will allow written requests for clarification of this Solicitation. Questions may be e-mailed to the point-of-contact listed above. Questions should be submitted in the following format:

a) Reference the Solicitation number; b) Reference the Section number, Page number, Paragraph number, and Text of passage being questioned; and c) Question.

8.3. PROHIBITED COMMUNICATIONS: Upon issuance of this solicitation, TPWD, its representative(s), or partners will not answer questions or otherwise discuss the contents of this Solicitation with any potential Respondent or their representative(s), except for the written inquires described in (Section 8.1) above. Attempts to ask questions by phone or in person will not be allowed or recognized as valid. Failure to observe this restriction may disqualify respondent. Respondent shall rely only on written statements issued through or by TPWD’s purchasing staff. This restriction does not preclude discussions between affected parties for the purposes of conducting business unrelated to this solicitation.

9. BID RESPONSE INSTRUCTIONS:

9.1. Bid Submission:

9.1.1. Submission Deadline: All bids shall be received, and time stamped at TPWD prior to 2:00

PM Central Time on the “Bid Opening” date specified on the IFB Cover Page (page 1).

Late bids will not be considered under any circumstance and will be returned.

9.1.2. General Format: Respondent shall submit bid response, signed dated and completed.

9.1.3. Bid Delivery: Bids may be returned via email to Purchasing.BidBox@tpwd.texas.gov , mail, or hand-delivery.

9.1.4. Bids returned by mail or hand delivery should be placed in a sealed envelope and correctly identified with IFB number, submittal deadline/opening date and time. It is the Bidder’s responsibility to appropriately mark and deliver the bids to TPWD by the specified date.

9.1.5. Respondents are responsible for all costs of bid preparation.

9.2. Bid Content: Below is a summary of required and requested information. Bids submitted without this information will be evaluated accordingly. TPWD reserves the right, in its sole judgment and discretion, to waive minor technicalities and errors in the best interest of the state.

9.2.1. Bid Form: Respondent must submit the IFB form, signed, dated, and completed. Failure to submit this information will result in disqualification of bid.

9.2.2. Brand Name/Model: Respondents to specify Brand/Model of quoted product. Failure to take exception to specifications or referenced data will require Respondent to furnish specified mailto:purchasing.bidbox@tpwd.texas.gov mailto:Purchasing.BidBox@tpwd.texas.gov

IFB No. 802-26-73518 Page 16 of 34 brand name and model, etc. (Respondent may be required to submit product spec sheets and/ or other documentation prior to award.)

9.2.3. Descriptive Literature: Respondent should provide descriptive literature (product specification sheets) with response submission. Literature to address all salient characteristics and clearly document that the offered product meets salient characteristics stated in the specifications. (Note: Respondent may be required to submit product specification sheets and/ or other documentation prior to award.)

9.2.4. Delivery Time: Respondent to specify delivery time from receipt of TPWD order.

9.3. Response Period: Responses shall be binding for a period of sixty (60) business days from bid-due date. No other costs, rates, or fees shall be payable to the Successful Respondent unless expressly agreed upon in writing by TPWD.

10. EVALUATION AND AWARD:

10.1. An award will be made on an all or none basis. Only responses submitted by the bid due date, with required submittal documents and meeting qualifications will be considered. Failure to submit the required information may be cause for rejection of the bid response. TPWD reserves the right to waive informalities and minor irregularities in bids received.

10.2. TPWD reserves the right to consider respondent qualifications, equipment, facility, references;

conduct studies and other investigations as necessary to evaluate any response; request additional relevant information; disqualify bid based on unsatisfactory reference checks, reports, and records of service.

10.3. Award: TPWD will award a Contract(s) to the Respondent(s) whose quote is considered to be the

Best Value to TPWD, price and other factors considered. The following factors may be used to evaluate bids:

a) Lowest Price

b) Ability, Qualifications and Experience - Meeting or Exceeding the Requirement

c) Delivery / Service Schedule

d) Past Performance

11. INVOICING AND PAYMENT:

The following procedures apply to invoicing and payment in addition to those listed in the General Terms and Conditions, Para. 9:

11.1. Contractor to submit invoice(s) to: Accounts.Payable@tpwd.texas.gov

11.2. Invoices must show:

a) Name of contractor exactly as shown on the contract, Texas Payee Identification Number (PIN), and correct “Remit to” address.

b) Name of receiving entity mailto:Accounts.Payable@tpwd.texas.gov

IFB No. 802-26-73518 Page 17 of 34

c) Contract/purchase order number

d) Description, quantity, unit of measure, unit price, extended price of each item

e) Total Price

f) Discount, if applicable, extended and deducted to arrive at a NET TOTAL for invoice

g) Attach supporting documentation, if required.

11.3. Payment:

11.3.1. Contractor will be paid for the services as invoiced. If another payment mechanism is agreed to by the parties, then Contractor will be paid in accordance with the agreement approved by the parties.

11.3.2. Payment normally will be made to the Contractor within 30 days after receipt of a properly prepared invoice or the receipt of and the acceptance of goods/services ordered, whichever is later. State agencies are required by state law to pay properly submitted invoices within 30 days.

11.3.3. Payments for goods/services purchased with state appropriated funds will be made through state warrants issued by the Comptroller of Public Accounts. Payments by qualified ordering entities will be made through the entities’ local payment system.

Electronic payment may be available through some ordering entities. Contact Accounts Payable at 512-389-4833 for additional information.

12. BIDDER AFFIRMATION:

12.1. Bidder has not given, offered to give, nor intends to give at any time hereafter any economic opportunity, future employment, gift, loan, gratuity, special discount, trip, favor, or service to a public servant connected with the submitted bid.

12.2. Pursuant to Texas Government Code, Title 10, Subtitle D, Section 2155.004(a), the bidder has not received compensation for participation.

IFB No. 802-26-73518 Page 18 of 34

GENERAL TERMS AND CONDITIONS

OCTOBER 2025

(ITEMS BELOW APPLY TO AND BECOME A PART OF THE CONTRACT)

Any Contract awarded as a result of this solicitation will contain the General Terms and Conditions listed below in this Section. Subcontractors are also obliged to comply with these provisions.

1. DEFINITIONS: As used throughout this solicitation, the following terms have the meaning set forth below.

All other terms have the meaning set forth in Webster’s II New College Dictionary.

1.1. Bidder: An individual or entity that submits a bid. The term includes anyone acting on behalf of the individual or entity that submits a bid, such as an agent, employee and representative. See Respondent.

1.2. Contractor: The individual, corporation, company, partnership, firm, or organization that has to furnish the materials and has to perform the work as stated in the solicitation.

1.3. ESBD: The Electronic State Business Daily, which is available online at http://www.txsmartbuy.gov/esbd .

1.4. Gov’t Code: The Texas Government Code.

1.5. Owner: Texas Parks and Wildlife Department, an agency of the State of Texas.

1.6. Party/Parties: Either the TPWD and Respondent separately or collectively.

1.7. Respondent: Any person or Vendor who submits a Bid/Proposal/Offer in response to this solicitation.

1.8. Services: Includes the use of labor, materials, facilities, equipment, and any other need that is necessary or incidental to the successful completion of the Contract.

1.9. Subcontractor: Any supplier, distributor, Contractor, person, or firm furnishing to the Contractor, materials or services necessary or incidental to the performance of the Contract between TPWD and Contractor.

1.10. TAC: The Texas Administrative Code, which is the publication for administrative rules.

1.11. Texas Identification Number: A unique 11-digit number assigned by the Texas Comptroller of Public Accounts. When a Payee first contracts with a state agency, that Payee must provide either a federal Employer Identification Number (EIN) or a Social Security number (SSN). The Texas Identification Number (TIN) is based on this number. (Note: If Respondent does not have a TIN, or does not know their TIN, they may list their EIN or SSN on the “Texas Identification Number” line of the Vendor Information Block of their RFP, RFO, IFB or RFQ response.)

1.12. TPWD: Texas Parks and Wildlife Department acting on behalf of the State of Texas.

2. SPECIFICATIONS:

2.1. The goods/services provided shall be in accordance with the purchase specifications herein. TPWD will decide the answers to all questions that may arise as to the interpretation of the specifications and the quality, or acceptability of goods/services provided. TPWD will decide the rate of progress of the work and the acceptable fulfillment of the goods/service on the part of the Contractor.

2.2. Catalogs, brand names or manufacturer's references are descriptive only, and indicate type and quality desired. Bids/Proposals on brands of like nature and quality will be considered unless advertised under Texas Gov't Code §2155.067. If the Respondent is offering brands other than the references, response should show manufacturer, brand or trade name, and other description of product offered. If Respondent is offering brand(s) other than brand(s) specified, illustrations and complete description of product offered are requested to be made part of the bid. Failure to take exception to specifications or reference data will require Respondent to furnish specified brand names, numbers, etc.

2.3. Unless otherwise specified, items shall be new and unused and of current production.

http://www.txsmartbuy.gov/esbd

IFB No. 802-26-73518 Page 19 of 34

2.4. Samples, when requested, must be furnished free of expense to the State. If not destroyed in examination, they will be returned to the Respondent, on request, at Respondent's expense. Each sample should be marked with Respondent's name and address, and requisition number. Do not enclose in or attach response submission to sample.

2.5. The State will not be bound by any oral statement or representation contrary to the written specifications of this Solicitation.

2.6. Manufacturer's standard warranty shall apply unless otherwise stated in the solicitation.

3. AWARD OF A PURCHASE ORDER: Standard Purchase Order Terms and Conditions apply. If a conflict exists between the standard Purchase Order Terms and Conditions and specific language in this solicitation, the language in the solicitation shall prevail.

3.1. A response to a solicitation is an offer to Contract with TPWD based on the terms, conditions and specifications contained in the solicitation. Responses do not become Contracts unless and until they are accepted through an authorized TPWD designee by issuance of a Purchase Order.

3.2. This procurement will be conducted in accordance with the State Purchasing Act, Title 10, Subtitle D, Chapters 2151 through 2177, of the Texas Gov’t Code (TGC) and TPWD rules. Any Contract resulting from this procurement shall consist of one (1) document. This document will contain all of the rights and duties of the parties extracted from the relevant terms and conditions of this solicitation (including its attachments, exhibits, supplements, and addenda); the successful Contractor’s response; any TPWD request for a Best and Final Offer; and any successful Contractor’s Best and Final Offer, if applicable.

3.3. Best Value – TPWD will be the sole judge of best value. Award will be based on Best Value criteria and may include, but is not limited to:

3.3.1. Best meets the goals and objectives of the solicitation as stated above.

3.3.2. Best meets the quality and reliability of the proposed services.

3.3.3. Effect of the proposed solution on agency productivity.

3.3.4. Provides the most customer focused solution that will best meet the needs of the public.

3.3.5. Experience in successfully providing services in this solicitation.

3.3.6. Past Performance: A Respondent’s past performance will be measured based upon pass/fail criteria in compliance with applicable provisions of Gov't Code §§2155.074, 2155.075, 2156.007, 2157.003, and 2157.125. Respondents may fail this selection criterion for any of the following conditions:

• The Vendor has a score less than C or Legacy Unsatisfactory in the Vendor

Performance System,

• Currently under a Corrective Action Plan through the Texas Comptroller of Public

Accounts (CPA),

• Having repeated negative Vendor Performance Reports for the same reason,

• Having Purchase Orders that have been cancelled in the previous 12 months for non-performance (i.e., late delivery, etc.).

3.3.7. Contractor performance information is located on the CPA web site at:

www.txsmartbuy.gov/vpts. CPA may conduct reference checks with other entities regarding past performance. In addition to evaluating performance through the Vendor Performance Tracking System (as authorized by 34 Texas Administrative Code §20.115), CPA may examine other sources of vendor performance including, but not limited to, notices of termination, cure notices, assessments of liquidated damages, litigation, audit reports, and non-renewals of Contracts. Any such investigations shall be at the sole discretion of CPA, and any negative findings, as determined by CPA, may result in non-award to the Respondent.

4. UNIT PRICES: Respondents must price per unit shown. Unit prices shall govern in the event of extension errors.

http://www.txsmartbuy.gov/vpts

IFB No. 802-26-73518 Page 20 of 34

5. FREIGHT: Quote FOB destination, freight prepaid and allowed unless otherwise stated within the specifications.

6. DELIVERY:

6.1. Show number of days required to place material in receiving agency's designated location under normal conditions. Delivery days mean calendar days, unless otherwise specified. Failure to state delivery time obligates Respondent to deliver in 14 calendar days. Unrealistic delivery promises may cause solicitation to be disregarded.

6.2. If delay is foreseen, Contractor shall give written notice to the TPWD. Contractor must keep the TPWD advised at all times of status of order.

6.3. Default in promised delivery (without accepted reasons) or failure to meet specifications authorizes the TPWD to purchase supplies elsewhere and charge full increase, if any, in cost and handling to defaulting Contractor.

6.4. Substitutions: No substitutions permitted without written approval of TPWD.

6.5. Delivery shall be made during normal working hours only unless prior approval has been obtained from ordering agency. Normal working hours are 8:00 AM until 5:00 PM Monday through Friday except State and National holidays.

7. TESTING AND INSPECTION:

7.1. TPWD may test and inspect goods and services purchased under the Contract to ensure compliance with the specifications of this solicitation and the Contract. TPWD may also test and inspect goods and services before they are purchased under the Contract. Authorized TPWD personnel shall have access to the Respondent's place of business for the purpose of inspecting the goods. To the extent practical, TPWD inspections will not disrupt the Respondent's daily operations. Tests shall be performed on samples submitted with the Bid/Proposal or on samples taken from regular shipments. All costs of testing and inspection shall be borne by the Respondent.

In the event the goods tested fail to meet or exceed all conditions and requirements of the solicitation and Contract, the goods will be rejected in whole or in part, at the State's option, and returned to the Respondent or held for disposition at the Respondent's expense. Latent defects may result in cancellation of the Contract at no expense to the state.

7.2. If material fails to meet specifications, the Respondent will be notified by fax, mail, or e-mail. The Respondent will have ten (10) working days after receipt of the notification to remove the rejected material from state property. Material will be removed at the Respondent’s expense. Material not removed in the allotted time period will be disposed by TPWD. The Respondent will be charged for all disposable expenses conducted by TPWD.

8. CHANGES: TPWD may at any time, by a written order, make changes within the general scope of this Contract, in the definition of services to be performed, and the time (i.e., hours of the day, days of the week, etc.) and place of performance thereof. If any such change causes an increase or decrease in the cost of, or the time required for the performance of any part of the services under this Contract, whether changed or not changed by any such order, an equitable adjustment shall be made in the Contract price or time of performance or both and the Contract shall be modified in writing accordingly. Any claim by the Contractor for adjustment under this clause must be asserted within 30 days from the date of receipt by the Contractor of the notification of change, provided, however, that TPWD, if it decides that the facts justify such action, may receive and act upon such claims asserted at any time prior to final payment under this Contract.

Failure to agree to any adjustment shall be a dispute concerning a question of fact within the meaning of the clause of this Contract entitled "Dispute Resolution."

9. INVOICING AND PAYMENT:

9.1 Invoices: In order to receive payment under the Contract, the Contractor must…