Texas Commission on Law Enforcement

REQUEST FOR PROPOSAL

of Audio-Visual Services

RFP 407-26-001

Release Date: 02/13/2026

NIGP CLASS/ITEM CODES:

915-09

6330 E HWY 290 STE 200 Austin, TX 78723

Table of Contents REQUEST FOR PROPOSAL of Audio-Visual Services

Table of Contents

RESPONSE SHEET / CHECKLIST

1.0 DEFINITIONS AND ACRONYMS

2.0 INTRODUCTION AND OVERVIEW

2.1 Background

3.0 SERVICES REQUIRED

3.1 Assumptions and Constraints

3.2 HUB Subcontracting Plan (HSP) Requirements

4.0 PROPOSAL AND SUBMISSION INFORMATION

4.1 Point-of-Contact for this Procurement

4.2 Calendar of Events

4.3 Submittal of Questions

4.4 Exceptions

4.5 Evaluation Process

5.0 GENERAL PROPOSAL CONDITIONS

6.0 REQUIRED CONDITIONS OF THE CONTRACT

6.1 Introduction

6.2 Failure to Comply

6.3 Taxpayer I.D. Number

6.4 Signature Authority

6.5 Prohibited Interest

7.0 RESPONDENT AFFIRMATIONS

8.0 STANDARD CONTRACTUAL TERMS AND CONDITIONS

8.1 Delivery

8.2 Payment

8.3 Warranties

8.4 General

RESPONSE SHEET / CHECKLIST

To submit a proposal, please return this signed page with your proposal.

1. Cost / Pricing (Please include any necessary attachments for cost/pricing including a price sheet if needed)

2. HUB Subcontracting Plan (if total amount $100,000 or over)

3. Contact information and affirmation

By signing below, I understand the requirements and agree with the terms and conditions of RFP 407-26-001

Email signed proposal, any attachments, and any other pertinent information to purchasing@tcole.texas.gov with RFP 407-26-001 in the subject line.

Respondent’s Business Name:

Respondent’s Business Address:

City, State, Zip:

Texas Identification #:

Respondent’s Name:

Phone Number:

Fax Number:

E-Mail Address:

Authorized Signature:

Printed Name:

Title:

Date:

mailto:purchasing@tcole.texas.gov

1.0 DEFINITIONS AND ACRONYMS

Contract The signed Purchase Order or Signature Document, the Terms and Conditions, Affirmations, along with any Attachments, Exhibits, and any Amendments, purchase orders, or Work Orders that may be issued by TCOLE, to be incorporated by reference for all purposes as a result of this RFP

Contract Term The period of time during which the Purchase Order or Contract is in effect from the start date through the end date and may include renewal or extension periods.

Contractor Vendor that signs a contract to provide goods and/or services

Debarred An exclusion from contracting or subcontracting with state agencies on the basis of cause pursuant to Title 34, Part 1, Chapter 20, Subchapter G of the Texas Administrative Code, and the Federal System for Award Management (SAM)

Deliverables The services or goods specified in this RFP and any resulting Contract that the Contractor shall perform or deliver to TCOLE

ESBD Electronic State Business Daily: The electronic online directory, administered by the Comptroller of Public Accounts, Statewide Procurement Division (SPD), for publishing procurement opportunities which exceed $25,000 in total estimated value and for providing public notice of contract awards. The ESBD may be accessed through the CPA web site at:

https://www.txsmartbuy.com/esbd

NIGP The National Institute of Governmental Purchasing Commodity Book: The Class-Item numbering and descriptions used by state agencies to properly code services or products for a procurement

Purchase Order A legally enforceable agreement issued by TCOLE indicating types, quantities, and agreed pricing for services and goods the Contractor will provide under any Contract resulting from this RFP

Response All information and materials submitted by a vendor in response to this RFP; may also be referred to as a Bid or Bid Response

Respondent Vendor that submits a proposal for this RFP

RFP Request for Proposal: A written solicitation document for purchases acquired by means of the competitive sealed proposals procurement method

Scope of Work The description of requirements, services, specifications for goods which may be required, and deliverables as provided in this RFP and any resulting Contract which the Contractor is required to provide

Subcontractor Any entity or individual that enters into a contract with the Contractor to perform part or all of the obligations of the Contractor under the Contract https://www.txsmartbuy.com/esbd

Vendor A business entity or individual that supplies services or goods and may be a potential Respondent to this RFP

VPTS Vendor Performance Tracking System: An online application, administered by SPD, that provides the state procurement community with a comprehensive online tool for evaluating vendor performance to reduce risk in the contract award process

2.0 INTRODUCTION AND OVERVIEW

The Texas Commission on Law Enforcement (TCOLE) is requesting responses from qualified respondents specializing in Audio/Video services. Services will be provided in Waco, Texas.

2.1 Background

The Texas Commission on Law Enforcement conducts a law enforcement training conference annually. The purpose of the conference is to provide quality instruction for the participants which they can take back to their departments for dissemination. Many of the conference speakers are nationally known and cover a multitude of timely and pertinent law enforcement topics. It is also a conduit for TCOLE to pass on information on legislative and commission rule changes that affect the way law enforcement training in Texas is conducted.

Conference attendance grows annually and is potentially attended by hundreds of different law enforcement agencies across the State of Texas. Additionally, there are more than 300 academies and training provider contract holders which, by contract, must send a representative to the conference.

3.0 SERVICES REQUIRED

The conference for the 2026 - 2028 TCOLE Training Conference will be in Waco, Texas at the Waco Convention Center located at 100 Washington Ave, Waco, TX 76701 during the following dates:

• August 9 – 13, 2026

• October 24 – 28, 2027

• October 22 – 26, 2028

The Successful Respondent shall perform audio/video services in eight (8) areas that meet the specifications and requirements of this solicitation, and shall include, but not be limited to, the following:

a) Setup will be between 8:00 AM to 5:00 PM on Sunday, August 9, 2026, and breakdown will be after 5:00 PM on Thursday, August 13, 2026. The Audio/Video service production dates are Monday, August 10 and Thursday, August 13, 2026;

b) There will be one room flip for McLennan Hall. It will start off as a general assembly setup on August 11, 2026 with a flip to 2 room breakout sessions to finish the conference. The rest of the setup throughout the venue will remain the same throughout the duration of the event;

c) Any requirements of the Waco Convention Center must be met in regard to these services;

d) Successful Respondent will recommend a solution for each of the eight (8) areas listed below that includes (for each area), but not limited to:

1. Microphones: 3-5 handheld microphones, 3-5 lavalier microphones

2. Displays: large displays (either monitor or large projector screens (rear projection, short throw, or otherwise)) appropriate for the space; may require scaffolding

i. Additional displays for signage around convention center

3. Audio: speaker setup appropriate for the space, with all appropriate components and accessories. Assumption should be that speakers cannot be hung from the ceiling.

4. Lighting: stage wash lighting at back of the stage, with all appropriate components and lift as needed

5. Power: assumption is that the appropriate power boxes will be provided by the venue. The Respondent will work with TCOLE to clarify this and adjust cost accordingly once contract is awarded.

6. Laptops: laptop for each area (7 total) to run speaker presentations provided either by USB drive or other electronic means

7. Confidence monitor: positioned near the stage for the speaker, including all appropriate stands and accessories

8. Digital speaker timer: one positioned at the back of the room or near the stage

9. Additional components may be recommended and negotiated.

e) The Exhibit Hall and 7 areas to be used for presentations are (see Appendix A for more detail):

Area Dimensions + Stage Seating Capacity

Seating Style Dates Room to be Used

Chisholm Hall (Exhibit Hall)

32,976 sq ft, 204 x 150 x Stage: Built in

179 Exhibitor Booths 8/10/26 – 8/12/26

McLennan Hall (207, 208, & 209)

15,000 sq ft, 179 x 84 x Stage: 12 x 16

1,200 Theater 8/11/26 – 8/11/26

McLennan Hall (207)

5,000 sq ft, 60 x 84 x Stage: 12 x 16

Theater 8/12/26 – 8/13/26

McLennan Hall (208 & 209)

10,000 sq ft, 120 x 84 x Stage: 12 x 16

Theater 8/12/26 – 8/13/26

Brazos North 7,252 sq ft, 98 x 74 x Stage: 12 X 16

500 Theater 8/12/26 – 8/13/26

Brazon South 6,566 sq ft, 98 x 67 x Stage: 12 X 16

500 Theater 8/12/26 – 8/13/26

Texas North 4,488 sq ft, 88 x 51 x 9 Stage: 12 X 16

300 Theater 8/12/26 – 8/13/26

Texas South 4,576 sq ft, 88 x 52 x 9 Stage: 12 X 16

300 Theater 8/12/26 – 8/13/26

f) The Exhibit Hall, Chisholm Hall, will require 4 large monitors, a preferred 65 inches, and 4 laptops used to display images provided by TCOLE on a USB drive.

It is acceptable not to include laptops, if the monitor is capable of displaying images from a USB drive;

g) Stages and draping are provided by the convention center;

h) TCOLE does not require any recordings or storage of event sessions. No pre-production, post-production or editing is required;

i) All audio/video, and any information contained in all electronic storage devices in relation to the contracted services shall be considered property of TCOLE;

j) Successful Respondent shall ensure that audio/video quality is high;

k) Labor: Successful Respondent shall provide a Project Manager as well as appropriate labor for setup, breakdown, and daily operation. Technicians will have the appropriate expertise levels for setup and design.

1. Successful Respondent’s employees assigned to TCOLE shall have a professional demeanor and poise suitable for working with executives and shall possess the ability to: communicate clearly and effectively with the public, exercise tact, discretion, courtesy, self-control, good judgment, maintain a neat, professional appearance, and stay alert throughout the events activities;

2. Project Manager shall arrive at least one-half hour before the start of any event for which services are required in order to set up, test, and adjust all recording equipment prior to the start of the event. As required by TCOLE, the Successful Respondent may be required to set up all recording equipment the day before an event is scheduled to begin;

Successful Respondent may provide and operate back-up audio/video equipment during events and event activity.

3.1 Assumptions and Constraints

3.1.1 Travel

a) TCOLE will not pay for any travel housing, transportation, meals or any other related costs unless approved in writing by TCOLE prior to travel;

b) Such travel cost, if any, shall be reimbursed subject to the State of Texas rules and at the rates specified for travel by TCOLE’s own classified employees. Any claim by the Successful Respondent shall be submitted in accordance with the rules prescribed by the State of Texas Travel Allowance Guide (See:

http://comptroller.texas.gov/procurement/prog/stmp). Airfare will be reimbursed at the actual cost of the airfare not to exceed the cost of the lowest priced airfare available. Under no circumstances will TCOLE reimburse the Successful Respondent for first-class airfare.

3.1.2 Parking: A contract with TCOLE does not guarantee on-site parking. Any parking arrangements will be make and paid for by Successful Respondent. The Waco Convention Center provides free parking.

3.1.3 Contract terms: The term of contract resulting from this RFP shall be for one (1) years, unless terminated or canceled, with the option to renew for two (2) additional one year terms if the 2027 and 2028 TCOLE Training Conferences are located at the same http://comptroller.texas.gov/procurement/prog/stmp venue. Successful Respondent shall hold pricing firm for the full term and optional renewal and extension terms of the contract.

3.1.4 Exceptions: Any exceptions to the specifications (other than any stated “Alternate Response”), TCOLE Standard Terms and Conditions of the Solicitation shall be explicitly set forth in the response. If there are no exceptions, Respondent shall explicitly state that Respondent takes no exception to the Solicitation’s specifications, terms, and conditions. Exceptions may result in a Contract not being awarded to Respondent.

3.2 VetHUB Subcontracting Plan (HSP) Requirements

The Comptroller of Public Accounts (CPA), Statewide Procurement Division (SPD) administers the Veteran Heroes United in Business (VetHUB) Program in accordance with Chapter 2161, Texas Government Code, and Rules §20.281 to §20.298, Title 34, Chapter 20, Subchapter D, Division 1, Texas Administrative Code. The VetHUB Program rules may be accessed at: https://comptroller.texas.gov/purchasing/vendor/hub/hub-faq.php

It is the policy of TCOLE to promote and encourage contracting and subcontracting opportunities with State of Texas-certified VetHUBs.

TCOLE has determined there are VetHUB Subcontracting opportunities associated with this RFP.

NOTE: TCOLE will not consider any changes to TCOLE or State of Texas terms and conditions of this Solicitation unless such request to amend the terms and/or conditions has been included in the response. Many terms and conditions are enumerated in law and may not be amended or waived. Any terms and conditions attached to a Response will not be considered unless specifically referred to in the Response.

4.0 PROPOSAL AND SUBMISSION INFORMATION

4.1 Point-of-Contact for this Procurement

Sarah Childress-Whitman Phone: (512) 936-7700 E-mail: sarah.childress@tcole.texas.gov

Respondents shall make no contact concerning this RFP with TCOLE personnel, except to the Point-of-Contact listed above. Any questions concerning this RFP shall be submitted in writing, via email, to the TCOLE Point-of-Contact. Failure to comply with this requirement may result in disqualification of Respondent’s Proposal.

4.2 Calendar of Events

The following table provides a timeline of events. TCOLE reserves the right to waive or modify specific terms and conditions contained in this RFP, and to waive, modify or extend deadlines specified herein.

https://comptroller.texas.gov/purchasing/vendor/hub/hub-faq.php https://comptroller.texas.gov/purchasing/vendor/hub/hub-faq.php mailto:sarah.childress@tcole.texas.gov

Date & Time (CST) Event

02/10/2026 RFP Posted to the Electronic State Business Daily (ESBD)

02/20/2026 Deadline for TCOLE Receipt of Vendor Questions

– All questions must be emailed

02/25/2026 Anticipated Date TCOLE Response to Written Questions is Posted to ESBD

03/25/2026 Deadline for TCOLE Receipt of RFP Responses

04/03/2026 Anticipated Contract Award Date; and Start of Respondent Implementation

4.3 Submittal of Questions

1. All questions shall, to the highest degree possible, cite the specific RFP section and paragraph number(s) to which the question refers. Any questions received by TCOLE prior to the date and time detailed in the Schedule of Events will be answered in a question-and-answer document issued by TCOLE. Only answers provided in writing by TCOLE will be considered official.

2. All query submissions must include the identity of the RFP#, sender, the sender’s title, Respondent’s name, mailing address, telephone number, and facsimile number or e-mail address as applicable. Submissions that do not reference the RFP# will be considered non-compliant and will not receive a response.

3. Questions must be submitted to the point-of-contact via e-mail using the point-of-contact information found in Section III.A. TCOLE is not responsible for questions received after the submittal deadlines. Email submissions must have the RFP# referenced in the email “Subject” line.

4. Answers to all questions submitted in accordance with these requirements may be made available on the Electronic State Business Daily (ESBD) website no later than the date and time indicated in the Calendar of Events in Section III.B.

5. Only information in the materials constituting this RFP, including its appendices, attachments, exhibits, forms, the question-and-answer document(s), and any RFP addenda issued shall be binding on TCOLE.

RESPONDENTS ARE SOLELY RESPONSIBLE FOR ALLOWING SUFFICIENT

TIME TO PERMIT TIMELY DELIVERY BY ANY DELIVERY SERVICE OR

AGENT TO THE TCOLE PROCUREMENT EMAIL INBOX, AND TCOLE SHALL

NOT BE RESPONSIBLE FOR THE FAILURE OF ANY DELIVERY SERVICE OR

AGENT TO TIMELY DELIVER RESPONSES. ALL RESPONSES SHALL BE

RECEIVED BY TCOLE, PRIOR TO, OR AT THE REQUIRED DEADLINE.

TCOLE’S TIME AND DATE STAMP WILL BE THE FINAL DETERMINANT OF

WHETHER A PROPOSAL HAS BEEN TIMELY RECEIVED BY TCOLE. ANY

RESPONSE RECEIVED BY TCOLE AFTER THE REQUIRED DUE DATE AND

TIME SHALL BE DEEMED TO BE A LATE RESPONSE AND SHALL NOT BE

EVALUATED.

6. All Proposals and accompanying documentation delivered to TCOLE on or before the RFP submittal deadline, become the property of TCOLE and will not be returned.

7. Required Organization, Content, and Requirements of Submitted Proposal

The Respondent’s submitted Proposal shall include all information and provide their best response to the specifications, terms and conditions contained in this RFP. Each Respondent shall be solely responsible for its thorough understanding of the RFP, including any attachments, exhibits, and/or forms. In addition, each Respondent shall be solely responsible for its Proposal and all documentation submitted. Respondents are cautioned to pay particular attention to the clarity and completeness of their Proposal. Respondents shall be as succinct as possible.

Respondents should provide detailed descriptions of how they will fulfill each requirement. The clarity and completeness of a Proposal may be considered by TCOLE evaluators. TCOLE has no responsibility to point out weaknesses in a Proposal.

4.4 Exceptions

Any exceptions to the specifications, requirements, terms and/or conditions in this RFP, shall be explicitly set forth in your Proposal. Respondent shall identify the specific RFP section and the proposed modification(s).

The quantity and substance of exceptions will be considered in evaluation of Respondent’s Proposal. At TCOLE’ sole discretion, Respondent’s exceptions may result in disqualification of Respondent’s Proposal.

4.5 Evaluation Process

4.5.1 Preliminary Review

Each Proposal will be automatically dated and time-stamped when received electronically. Proposals received after the RFP submittal deadline shall not be accepted.

1. All timely Proposals will be reviewed to determine which Proposals meet the minimum qualifications and the specified requirements.

2. TCOLE may reject any or all proposals and may, at TCOLE’ sole discretion, waive any immaterial deviation or defect in a proposal if it is in TCOLE’ best interest. A TCOLE waiver of an immaterial deviation or defect shall in no way modify the RFP documents or excuse the proposal from full compliance with the RFP requirements.

3. Proposals submitted in response to this RFP are irrevocable for 180 calendar days following the RFP submittal deadline.

4.5.2 Proposal Evaluation

Evaluation and selection of a Respondent will be based upon the responses to the requirements presented in this RFP. Special attention will be given to the knowledge and experience of the proposed personnel, the experience and capabilities of the firm, communication, account management practices, and the value of services provided by the Respondent. TCOLE is not required to select the lowest priced proposal; however, they may select the proposal that in its judgment represents the best combination of demonstrated competence, experience, knowledge, qualifications, and reasonableness of the proposed fees for the services.

TCOLE will evaluate proposals received in response to this RFP. Respondents will be evaluated based on ability to provide services with the following criteria (weight percentages listed are estimates only):

1. Capacity and Experience to provide the requested services (40%).

2. Level of needs met in the submitted proposal (40%).

3. Cost (20%).

4. In the evaluation of submitted proposals, TCOLE may take into account any and all information provided within each proposal, including, but not limited to:

• Respondent’s relevant qualifications, skills, ability, and capacity to perform the required services;

• Respondent’s understanding of the needs and operational requirements of

TCOLE;

• Quality of Respondent’s plan for providing the required services;

• Respondent’s experience providing similar services to similar organizations/agencies;

• Respondent’s personnel relevant experience, training, skills, and qualifications;

• Pricing provided by Respondent;

• Quantity and extent of exceptions to the terms of the RFP;

• Level of effort and quality of information provided in response to the TCOLE

RFP sections;

• Respondent’s ability to follow the directions provided, in submitting their

Proposal;

• Best value according to Texas Government Code, Title 10; Subtitle D, Chapter

2156.007 (d).

While TCOLE is under no obligation to do so, it may ask questions of any Respondent to seek clarification of a proposal or to ensure the Respondent understands the scope of the work or other terms of the RFP. TCOLE reserves the right to contact any Respondent, at any time, to clarify, verify, or request additional documentation or information with regard to this RFP. Requested information may vary by Respondent. TCOLE may give consideration to additional information, if TCOLE deems such information relevant.

Respondent shall provide any TCOLE requested information within five (5) working days of request. Failure to respond to TCOLE’s request may disqualify the proposal from further consideration.

4.5.3 Best and Final Offers

Upon completion of finalist interviews, a contract may be awarded, or TCOLE may request a Best and Final Offer (BAFO). TCOLE is not required to request a BAFO, and thus reserves the right to request, or not request a BAFO. Therefore, Respondents are encouraged to submit their best pricing with their initial proposal submission.

4.5.4 Award of the Contract

Award will be made to the Respondent deemed to have submitted the best value to TCOLE. TCOLE reserves the right to award a contract that will best serve the interest of TCOLE and the State of Texas. TCOLE specifically reserves the right not to award this project to any Respondent that TCOLE considers to be non-responsible and/or to make no award of this RFP at all.

The Respondent selected for award in connection with this RFP will not necessarily receive the fee stated in the proposal if a lesser fee is negotiated and determined to be appropriate by TCOLE.

Respondent will enter into a contract between Respondent and TCOLE. The Contract shall incorporate by reference this RFP, the Respondent’s Proposal, and any other information Respondent may be required to provide.

TCOLE will monitor the selected vendor’s performance and report it in the Vendor Performance Tracking System (VPTS) on a regular basis.

5.0 GENERAL PROPOSAL CONDITIONS

A. This RFP does not commit TCOLE to pay any costs incurred prior to the execution of a contract. Issuance of this RFP in no way obligates TCOLE to award a contract or to pay any costs incurred in the preparation of a proposal.

B. Any award is contingent upon a contract acceptable to TCOLE being executed.

TCOLE reserves the right to negotiate any terms and provisions of the contract after a Respondent has been selected for award.

C. By submitting a proposal, Respondent submitting the proposal agrees to waive any claim it has or may have against TCOLE and its trustees, officers, employees, agents, and attorneys, if any, and any trust fund managed by one or more of the above named entities arising out of or in connection with:

(1) the administration, evaluation, or recommendation of any proposal;

(2) the waiver of any requirement under this RFP;

(3) the acceptance or rejection of any proposal; and/or

(4) the award of a contract.

D. TCOLE may issue addenda, amendments, and clarifications regarding this RFP that TCOLE believes are necessary. All such addenda, amendments, and clarifications issued by TCOLE become part of the RFP. Addenda, amendments, and clarifications to the RFP during the initial solicitation posting period, may be issued in writing and posted to the Electronic State Business Daily. Respondent shall acknowledge all addenda by indicating receipt on FORM A – EXECUTION OF PROPOSAL. Only written addenda, amendments, and clarifications signed or sent by authorized TCOLE personnel shall be relied on.

E. TCOLE reserves the right to terminate or modify this RFP and to reject any or all proposals submitted. TCOLE reserves the right to enter into discussions and negotiations with one or more firms selected at TCOLE’s discretion, to determine the best value for TCOLE. TCOLE is not under any obligation to hold these discussions or negotiations with each firm that submits a proposal. In accordance with Chapter 1575 and Chapter 1579 of the Texas Insurance Code, the Trustee is not required to select the lowest cost proposal but may also consider other qualifications. TCOLE may take into consideration any factor it considers relevant, such as past experiences, financial stability, the ability to perform the requirements of the RFP, and other relevant criteria. TCOLE is not required to accept for consideration any proposal that fails to address or does not comply with each of the requirements set forth in this RFP.

F. It is the policy of TCOLE to promote and encourage contracting and subcontracting opportunities for State of Texas certified Historically Underutilized Businesses (HUBs) in compliance with Texas Government Code 2161.001-253 and Texas Administrative Code (TAC), Title 34, Part 1, Chapter 20, Subchapter D, Division 1, 20.285.

Respondent is encouraged to become HUB certified if applicable. More information may be found at this link: https://comptroller.texas.gov/purchasing/vendor/hub/

Definitions of State of Texas HUB certifiable businesses can be found in TAC, Title 34, Part 1, Chapter 20, Subchapter D, Division D, 20.181. Please ensure that potential HUB subcontractor’s status is “A” (Active).

The HUB Subcontracting Plan (HSP) is monitored throughout the contract. Vendors must amend their HSPs if there is any change in subcontracting during the performance of the contract from what was proposed in the HSP by submitting a written justification to the contract manager. If the contract manager approves the change, TCOLE must amend the contract and ensure that a good faith effort has been made for any subcontracting changes that the prime contractor proposes.

Vendors are required to submit Prime Contractor Progress Assessment Reports (PARs) to TCOLE with each invoice. The PAR is used to verify the vendor’s compliance with the HSP, and the contract manager must review each PAR for compliance with the HSP.

6.0 REQUIRED CONDITIONS OF THE CONTRACT

6.1 Introduction

The Contract between TCOLE and the Respondent will include the RFP as may be finally amended and/or clarified, Respondent’s Proposal as amended or clarified, if applicable, and any other information Respondent may be required to provide. The terms and conditions of any agreements, amendments, modifications, or other documents submitted by the Respondent that conflict with or in any way purport to amend or add to any of the terms and conditions of the Contract are specifically objected to by TCOLE and are of no force or effect without the express written agreement of TCOLE. The Contract may be amended within the contract period by mutual consent of the parties.

No modification or amendment to the Contract shall become valid unless in writing and signed by both parties. All correspondence regarding modifications or amendments to the Contract must be forwarded to TCOLE for prior review and approval. Unless required by law, Respondent agrees that it shall not publicize the Contract or disclose, confirm, or deny any details thereof to third parties or use any photographs or video recordings of TCOLE’s or participating entities’ employees or use the name of TCOLE name in connection with any sales promotion or publicity event without the prior express written approval of TCOLE.

https://comptroller.texas.gov/purchasing/vendor/hub/

6.2 Failure to Comply

Failure to comply with the procedures required by TCOLE or any other applicable guidelines shall be cause for the immediate imposition of liquidated damages, the assessment of performance guarantee penalties, and/or immediate cancellation of the Contract, at TCOLE’s option. Should TCOLE assess liquidated damages, liquidated damages shall continue to accrue until TCOLE is satisfied that the circumstances resulting in liquidated damages have been corrected.

6.3 Taxpayer I.D. Number

Respondent must obtain a Vendor Identification Number in order to receive payments issued through the Comptroller of Public Accounts of the State of Texas. Respondent will be required to complete a Payment Identification Form (W-9) and submit it to TCOLE to receive payment in addition to an Application for Texas Identification Number (AP-152) if needed.

6.4 Signature Authority

By submitting the Response, Respondent represents and warrants that the individual submitting this document and the documents made part of this Response is authorized to sign such documents on behalf of the Respondent and to bind the Respondent under any contract that may result from the submission of this Response.

6.5 Prohibited Interest

A Board member, officer, director or employee of TCOLE may not have a direct interest in the gains or profits from any contract executed by TCOLE pursuant to this RFP and may not receive any pay or emolument for any service performed for Respondent.

In the case where a Board member, officer, director or employee of TCOLE receives any payment from Respondent for any services performed for Respondent or for any gains or profits from any contract executed by TCOLE pursuant to this RFP, TCOLE may terminate its relationship with Respondent immediately. Under such circumstances, Respondent must complete any outstanding TCOLE transactions and provide transition data and information as required to a new Respondent within thirty (30) days. TCOLE may not consider proposals from Respondent for two (2) full years thereafter.

Respondent will be required to hold TCOLE harmless for any costs, expenses and damages associated with such termination. This provision will survive termination of the contract.

Respondent has not given, offered to give, nor intends to give at any time hereafter any economic opportunity, future employment, gift, loan, gratuity, special discount, trip, favor, or service to a public servant in connection with the submitted Response. Violation of this requirement may result in the termination of the Contract at the discretion of

TCOLE.

7.0 RESPONDENT AFFIRMATIONS

1. All statements and information prepared and submitted in the Response to this RFP are current, complete, and accurate.

2. Respondent represents and warrants that all statements and information prepared and submitted in this document are current, complete, true, and accurate.

Submitting a Response with a false statement or material misrepresentations made during the performance of a contract is a material breach of contract and may void the submitted Response and any resulting contract.

3. Respondent represents and warrants that, in accordance with Section 2155.005 of the Texas Government Code, neither Respondent nor the firm, corporation, partnership, or institution represented by Respondent, or anyone acting for such a firm, corporation or institution has (1) violated any provision of the Texas Free Enterprise and Antitrust Act of 1983, Chapter 15 of the Texas Business and Commerce Code, or the federal antitrust laws, or (2) communicated directly or indirectly the contents of this Response to any competitor or any other person engaged in the same line of business as Respondent.

4. Pursuant to Section 2155.004(a) of the Texas Government Code, Respondent certifies that neither Respondent nor any person or entity represented by Respondent has received compensation from TCOLE to participate in the preparation of the specifications or solicitation on which this Response or contract is based.

Under Section 2155.004(b) of the Texas Government Code, Respondent certifies that the individual or business entity named in this Response or contract is not ineligible to receive the specified contract and acknowledges that the contract may be terminated and payment withheld if this certification is inaccurate.

5. Pursuant to Section 2155.003 of the Texas Government Code, Respondent represents and warrants that it has not given, offered to give, not intends to give at any time hereafter any economic opportunity, future employment, gift, loan, gratuity, special discount, trip, favor, or service to a public servant in connection with the contract.

6. Respondent represents and warrants that if selected for award of a contract as a result of the Solicitation, Respondent will submit to TCOLE a Certificate of Interested Parties prior to contract execution in accordance with Section 2252.908 of the Texas Government Code.

7. Under Section 231.006 of the Texas Family Code, the vendor or applicant certifies that the individual or business entity named in this contract, bid, or application is not ineligible to receive the specified grant, load, or payment and acknowledges that this contract may be terminated and payment withheld if this certification is inaccurate in addition to other remedies set out in 231.006(f).

8. Respondent agrees that any payments due under the contract shall be applied towards any debt or delinquency that is owed to the State of Texas.

9. Under Section 669.003 of the Texas Government Code, Respondent certifies that it does not employ, or has disclosed its employment of, any former executive head of the TCOLE. Respondent must provide the following information in the Response:

Name of Former Executive:

Name of State Agency:

Date of Separation from State agency:

Position with Respondent:

Date of Employment with Respondent:

10.In accordance with Section 2252.901 of the Texas Government Code, Respondent represents and warrants that none of its employees including, but not limited to, those authorized to provide services under the contract, were former employees of the TCOLE during the twelve (12) month period immediately prior to the date of execution of the contract.

11.Pursuant to Section 572.069 of the Texas Government Code, Respondent certifies that it has not employed and will not employ a former state officer or employee who participated in procurement or contract negotiations for TCOLE involving Respondent within two (2) years after the date that the contract is signed or the procurement is terminated or withdrawn. This certification only applies to former state officers or employees whose state service or employment ceased on or after September 1, 2015.

12.For professional services procurements: In accordance with Section 2252.901 of the

Texas Government Code, Respondent represents and warrants that for professional services contracts as described by Chapter 2254 of the Texas Government Code, if a former employee of TCOLE was employed by Respondent within one year of the employee’s leaving TCOLE, then such employee will not perform services on projects with Respondent that the employee worked on while employed by TCOLE.

13.In accordance with Section 2155.4441 of the Texas Government Code, Respondent agrees that during the performance of a contract for services it shall purchase products and materials produced in Texas when they are available at a price and time comparable to products and materials produced outside Texas.

14.Respondent certifies that it is not listed in the prohibited vendors list authorized by

Executive Order No. 13224, “Blocking Property and Prohibiting Transactions with Persons Who Commit, Threaten to Commit, or Support Terrorism”, published by the United States Department of the Treasury, Office of Foreign Assets Control. Entities ineligible for federal procurement are listed at https://www.sam.gov/portal/SAM/#1

15. Respondent and warrants that TCOLE’s payments to Respondent and Respondent’s receipt of appropriated or other funds under the contract are not prohibited by Sections 556.005 or 556.0055 of the Texas Government Code.

16.Respondent represents and warrants that the provision of goods and services or other performance under the contract will not constitute an actual or potential conflict of interest or reasonably create an appearance of impropriety.

https://www.sam.gov/portal/SAM/#1

17.Respondent warrants that TCOLE will not be responsible for any costs directly or indirectly related to preparation of a response or any participation in oral presentations or negotiations.

18.Respondent warrants that Respondent will not engage in employment practices that have the effect of discrimination against employees or prospective employees because of age, religion, race, color, sex, disability, or national origin and will submit a report as TCOLE may hereafter require to assure compliance. Vendor represents and warrants that it shall not discriminate against any person on the basis of race, color, national origin, creed, religion, political belief, sex, sexual orientation, age, and disability in the performance of this contract. Respondent represents and warrants its compliance with all applicable duly enacted state and federal laws governing equal employment opportunities.

19.Respondent certifies by signature hereon that either (a) its Texas State Franchise taxes are current, or (b) it is not subject to the Texas State Franchise Tax. Making a false statement as to corporate franchise status with regard to a state contract shall be grounds for the cancellation of the contract at TCOLE’s option.

20.Respondent warrants that purchases made for State of Texas use are exempt from the State Sales Tax and Federal Excise Tax. TCOLE will furnish Tax Exemption Certificates upon request. Respondent represents and warrants that it shall pay all taxes or similar amounts resulting from the contract, including, but not limited to, any federal, State, or local income, sales or excise taxes of Respondent or its employees. TCOLE shall not be liable for any taxes resulting from the contract. Sales tax is not applicable to any parts, material, labor, or specialized service furnished hereunder on all amounts becoming payable by TCOLE to Respondent under the contract.

21.Respondent shall comply with all laws, regulations, requirements, and guidelines applicable to a vendor providing services and products required by the contract to the State of Texas, as these laws, regulations, requirements, and guidelines currently exist and as amended throughout the term of the contract. TCOLE reserves the right, in its sole discretion, to unilaterally amend the contract prior to award and throughout the term of the contract to incorporate any modifications necessary for TCOLE’s compliance, as an agency of the State of Texas, with all applicable state and federal laws, regulations, requirements, and guidelines.

22.Respondent represents and warrants that it is not aware of and has received no notice of any court or governmental agency actions, proceedings or investigations, etc., pending or threatened against Respondent or any of the individuals or entities included in the Response within the five (5) calendar years immediately preceding the submission of the Response that would or could impair Respondent’s performance under the contract, relate to the solicited or similar goods or services, or otherwise be relevant to TCOLE’s consideration of the Response. If Respondent is unable to make the preceding representation and warranty, then Respondent instead represents and warrants that it has included as a detailed attachment in its Response a complete disclosure of any such court or governmental agency actions, proceedings or investigations, etc. that would or could impair Respondent’s performance under the contract, relate to the solicited or similar goods or services, or otherwise be relevant to TCOLE’s consideration of the Response. In addition, Respondent represents and warrants that it shall notify TCOLE in writing within five

(5) business days of any changes to the representations or warranties in this clause and understands that failure to so timely update TCOLE shall constitute breach of contract and may result in immediate termination of the contract.

23.Respondent understands that TCOLE will comply with the Texas Public Information

Act (TPIA) (Chapter 552 of the Texas Government Code) as interpreted by judicial rulings and opinions of the Attorney General of the State of Texas. Information, documentation, and other material in connection with this Solicitation or any resulting contract may be subject to public disclosure pursuant to the Texas Public Information Act. In accordance with Section 2252.907 of the Texas Government Code, Respondent is required to make any information created or exchanged with the State pursuant to the contract, and not otherwise excepted from disclosure under the Texas Public Information Act, available in a format that is accessible by the public at no additional charge to the State.

24.Respondent authorizes TCOLE to submit any requested information related to

Respondent’s proposal or the procurement thereof, including information labeled by Respondent as confidential and proprietary, to the Office of the Attorney General (“Attorney General”) pursuant to Section 552.301 of the TPIA for a ruling about whether it is excepted from disclosure. In the event that Respondent’s proprietary interests are at stake in the release of the requested information, TCOLE will provide Respondent with notice pursuant to Section 552.305 of the TPIA about the existence of the request and of Respondent’s opportunity to submit arguments to the Attorney General concerning why the information should not be disclosed in response to the request. TCOLE will reasonably cooperate with Respondent in coordinating the production of requested information to the Attorney General for review. However, Respondent acknowledges that it is Respondent’s responsibility to make any legal argument to the Attorney General or the appropriate court of law regarding the applicability of any exception to disclosure based on Respondent’s proprietary interests.

25.Respondent acknowledges that TCOLE is not obligated under Respondent’s proposal to seek an Attorney General ruling where Respondent’s proprietary interests are not at stake in the release of the requested information. In that event, Respondent acknowledges that TCOLE will make the information available to the requestor, unless TCOLE reasonably believe that it is otherwise excepted from disclosure under the TPIA. Respondent waives any claim against and releases from liability TCOLE, its trustees, officers, employees, agents, and attorneys with respect to thereof that is determined by the Attorney General, a court of law, or TCOLE to be subject to disclosure under the TPIA.

26.Respondent acknowledges that it may have in its possession or custody during the term of any applicable agreement or seven-year retention period following this procurement, information that is subject to a TPIA request, subpoena, discovery request, or other legal request, order, or process requiring TCOLE to produce such information (“Request”). As required by law, Respondent shall identify, produce, and transfer such information to TCOLE within the time period requested by and at no up-front cost to TCOLE. Within the requirements of law, Respondent will be provided a reasonable amount of time to respond to TCOLE based on the scope and size of the Request.

27.Respondent shall timely prepare and provide TCOLE with ad hoc reports and other information responsive to Requests in a form that is accessible to the public, determined acceptable by TCOLE after consultation with Respondent, and consistent with Section 552.231(b) of the TPIA. Respondent acknowledges that the preparation of such reports and other information may require that Respondent program or manipulate existing TCOLE data. For avoidance of doubt, Respondent shall not otherwise be required to create new data in order for TCOLE to respond to a Request.

28.Respondent agrees to formulate and provide TCOLE with cost and employee time estimates for producing ad hoc reports or other information responsive to Requests when requested by TCOLE. Pursuant to the cost rules of the Attorney General, including Section 70.2 of title 1 of the Texas Administrative Code, the estimates shall be solely based on “actual costs” to be incurred by Respondent in preparing the information, which are the sum of all direct costs plus a proportional share of overhead or indirect costs determined in accordance with generally accepted methodologies. TCOLE agrees to reimburse Respondent for its respective share of costs incurred in preparing information responsive to Requests, up to the total amount of payment TCOLE received from a requestor for those services and in accordance with the Attorney General’s cost rules established under Section

552.262 of the TPIA.

29.If Respondent at any time during the term of the contract provides a discount on the final contract costs, Respondent will notify TCOLE in writing ten (10) calendar days prior to effective date of discount. TCOLE will generate a Purchase Order Change Notice and send a revised Purchase Order to Respondent.

30.Respondent certifies that if a Texas address is shown as the address of the

Respondent on this Response, Respondent qualifies as a Texas Bidder as defined in Section 2155.444(c) of the Texas Government Code.

31.Respondent represents and warrants its compliance with the requirements of the

Americans with Disabilities Act (ADA) and its implementing regulations, as each may be amended.

32.Respondent shall promptly notify TCOLE in the event that any representations and warranties provided herein are no longer true and correct. Respondent acknowledges that all of its representations and warranties contained in any part of the Proposal are material and have been relied upon by TCOLE in selecting a Respondent to provide the services specified herein and in entering into a contract with Respondent.

Further, Respondent warrants and represents that all of its statements and representations made to TCOLE prior to being selected to provide the services specified herein, and made herein and during the negotiation of the contract, are material, true and correct.

33.Respondent certifies that it and its principals are not suspended or debarred from doing business with the state or federal government as listed on the State of Texas Debarred Vendor List maintained by the Texas Comptroller of Public Accounts and the System for Award Management (SAM) maintained by the General Services Administration.

34.Respondent certifies that neither it, nor its holding companies or subsidiaries, is:

a) Listed in Section 889 of the 2019 National Defense Authorization Act (NDAA); or

b) Listed in Section 1260H of the 2021 NDAA; or

c) Owned by the government of a country on the U.S. Department of Commerce’s foreign adversaries list under 15 C.F.R Section 791.4; or

d) Controlled by any governing or regulatory body located in a country on the U.S.

Department of Commerce’s foreign adversaries list under 15 C.F.R. Section 791.4

35.Vendor will comply with security provisions at all times, including the prohibition on bringing firearms or other weapons on state grounds or in state buildings. 37 TEX.

ADMIN. CODE § 3.146. Persons, equipment, and vehicles may be subject to search to ensure public safety. Vendors will cooperate with officers carrying out their official duties.

36.The contract shall be binding upon and shall inure to the benefit of TCOLE and Respondent and to their representatives, successors, and assigns.

8.0 STANDARD CONTRACTUAL TERMS AND CONDITIONS

All goods/services must be listed on a Purchase Order (PO) form. If any changes to the scope of work are made, the Vendor must obtain a new or revised PO (Purchaser Order Change Notice (POCN) from the Texas Commission on Law Enforcement of Texas (TCOLE). TCOLE is only obligated to pay for the goods/services listed on the PO. By accepting the PO and providing goods and/or services to TCOLE, the Vendor agrees to comply with the Standard Purchase Order Terms and Conditions (POTCs). In the event of any conflict or inconsistency between these POTCs and any other part of the PO, the terms of the POTCs shall prevail. TCOLE disclaims any terms and conditions provided by the Vendor, unless agreed upon in writing by both parties. In the event of any conflict between these POTCs and any terms and conditions provided by Vendor, the terms and conditions provided herein shall prevail.

8.1 Delivery

1. INSPECTION AND TESTS: TCOLE has the right of inspection and approval and may reject and return goods or require re-performance of services at Vendor’s expense if defective or not in compliance with TCOLE’s specifications. Defects will not be deemed waived by TCOLE’s failure to notify Vendor upon receipt of goods or completion of services or by payment of invoice. Tests may be performed on samples submitted with the bid or quote, if requested, or on samples taken from regular shipment. All costs shall be borne by the Vendor in the event goods fail to meet or exceed all conditions and requirements. Goods delivered and rejected in whole or in part may, at TCOLE's option, be returned to the Vendor or held for disposition at Vendor's expense. Latent defects may result in revocation of acceptance.

2. LATE DELIVERY: If delay is foreseen, Vendor shall give written notice to TCOLE.

Vendor must keep TCOLE advised at all times of status of order. Default on promised delivery (without accepted reasons) or failure to meet…