ESBD_409021_1744209401342_010 IFB.pdf

CITY OF SAN ANTONIO

Issued By: Building and Equipment Services Department Date Issued: April 9, 2025

ID NO.: 35-00359

(010) LOW QUALIFIED FORMAL INVITATION FOR BIDS (IFB) to CONTRACT Fuel Sump Replacement – Central PD

Form 010 Invitation for Bids (IFB) Revised 10/2023

Online bidding is utilized via CivCast at https://www.civcastusa.com/bids. Online bid services will open for bidding on Wednesday, April 9, 2025 and close on Friday, May 9, 2025 at 2:00 P.M. (CT). Follow submittal instructions on https://www.civcastusa.com/. Hard Copies will not be accepted for this solicitation. Bids will be opened and the Bid Results will be posted on CivCast on the day of the bid deadline.

Bid Results will be read aloud utilizing WebEx. Access WebEx by phone at 1-415-655-0001 and/or https://www.webex.com/ with Access Code: 1770 23 1452, Password: 3HrMPWvWr58

A Non-Mandatory Pre-bid meeting will be held through WebEx on Friday, April 18, 2025, at 10:00 A.M. (CT) and a Non-Mandatory Site Visit will be held at 3:00 P.M. CT at the the Central Service Area Police Department, located at 515 South Frio Street, San Antonio, Texas 78207. Access the WebEx by phone at 1-415-655-0001 and/or https://www.webex.com/ with Access Code: 2870 927 0983, Password: tnMKPbqc744. The Deadline for questions is scheduled for April 25, 2025, at 4:00 P.M. (CT).

The estimated construction budget for this contract is $400,000.00.

Bidder acknowledges that this is a unit price or Lump Sum contract; that prices established will remain in effect and valid throughout the duration of the contract; the quantities shown are estimated quantities for budgetary purposes only; the award of this contract does not guarantee contractor the entire work shown in this FORMAL INVITATION FOR BID (IFB); the City of San Antonio (City) may order all, some, or none of the work shown in this IFB. City may elect to award this Project based solely on the base bid, based on a combination of the base bid plus any combination of selected alternates or based on a combination of the base bid plus all alternates that serve the best interest of City. All bids must include a price for all units or line items, including any alternates. Entering a price of “$0.00” shall mean the units or line items will be provided at no cost to City. A unit price left blank shall result in the bid being deemed nonresponsive and disqualified from consideration. City reserves the right to delete line items prior to award.

This invitation includes the following Contract Documents which are required downloads in CivCast:

010 Invitation for Bids ◘ VOSB Program Tracking Form 020 Contract Signature Page ◘ Wage Decision 030 Experience & Qualifications Form w/Project Sheets ◘ Insurance Requirements 040 Standard Instructions to Respondent ◘ Heat Illness Prevention Acknowledgment Form 041 Certificate of Interested Parties (TEC Form 1295) 060 Supplemental Conditions 075 Performance Bond 076 Payment Bond 081 General Conditions for Construction Contracts ◘ Local Preference Program Identification Form

The City of San Antonio point of contact for this solicitation is Procurement Specialist II, Michelle Birch, michelle.birch@sanantonio.gov. Questions are to be submitted in writing in the Questions and Answers section on CivCast. Bidder understands and agrees to the responsibility for obtaining any and all addenda and adhering to all requirements in addenda. City is not responsible for incorrect information obtained through other sources.

Bid Documents must contain “Legal Name of Company” as listed by the Texas Secretary of State Registry (http://www.sos.state.tx.us/).

The documents required in CivCast (fully completed and with digital signatures) constitute the required information to be submitted as a part of the bid proposal.

The following documents constitute the required information to be submitted as a part of the bid proposal and are required uploads in CivCast:

020 Contract Signature Page ◘ VOSB Program Tracking Form 030 Experience & Qualifications Form w/Project Sheets ◘ Heat Illness Prevention Acknowledgment Form ◘ Bid Bond ◘ TEC Form 1295 Certification Number & Date ◘ Local Preference Program Identification Form

It is understood and agreed that the work is to be substantially completed on or before 75 calendar days. This project does not include hazardous environmental work. This project requires 0 project sign(s).

Local Preference Program Ordinance – For more detailed information on the Local Preference Program Ordinance, see solicitation document “040 Standard Instructions to Respondent”, section 5.

https://www.civcastusa.com/bids https://www.civcastusa.com/ https://www.webex.com/ https://www.webex.com/ mailto:michelle.birch@sanantonio.gov http://www.sos.state.tx.us/

Form 010 Invitation for Bids (IFB)

Veteran-Owned Small Business Preference Program – For more detailed information on the Veteran-Owned Small Business Preference Program, see Ordinance No. 2013-12-05-0864 and solicitation document “040 Standard Instructions to Respondent”, section 6.

Responsible Bidder Ordinance – For more detailed information on the Responsible Bidder Ordinance, see Ordinance No. 2023-01-26- 0041 and solicitation document “040 Standard Instructions to Respondent”, section 7.

Heat Illness Ordinance – For more detailed information on the Heat Illness Ordinance, see Ordinance No. 2023-08-31-0585 and General Conditions for Construction Contract, Article X.1.5 and Art.X.2.3(a).

Bid Protest Procedures – See solicitation document “040 Standard Instructions to Respondent”, section 11.

Wage Decision – Bidder shall meet the prevailing wage rate requirements established for this contract and shall reference the wage decision posted with this solicitation on the City’s website.