DrydockingAmendment3.docx
DOCX document 22 KB Posted
- Attached to
- Drydock Maintenance and Repairs on Gatelifter and Tug Federal contract opportunity
- Solicitation number
- DTSL55-10-B-C0733
About this file
Amendment No. A003
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| DrydockingAmendment2.docx | DOCX document | |
| DrydockingAmendment1.docx | DOCX document | |
| DrydockingIFBsealedbid.docx | DOCX document |
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT
| 1. CONTRACT ID CODE |
| PAGE OF PAGES |
2. AMENDMENT/MODIFICATION NO.
Amendment No. A003
3. EFFECTIVE DATE
August 19, 2010
4. REQUISITION/PURCHASE REQ NO.
10-B-C0733
5. PROJECT NO. (if applicable)
6. ISSUED BY CODE
7. ADMINISTERED BY (if other than Item 6) CODE
U.S. Department of Transportation Saint Lawrence Seaway Development Corporation Contracting Office PO Box 520, 180 Andrews Street Massena, New York 13662
8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, state and zip code)
| (√) |
| 9A. AMENDMENT OF SOLICITATION NO. |
DTSL55-10-B-C0733
X
9B. DATED (SEE ITEM 11)
July 12, 2010
10A. MODIFICATION OF CONTRACT
10B. DATED (SEE ITEM 13)
| CODE |
| FACILITY CODE |
11. THIS ITEM APPLIES TO AMENDMENTS OF SOLICITATIONS
|X| The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers |X| is extended, |_| is not extended.
Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:
(a) By completing Items 8 and 15, and returning 1 copy of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF OUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.
12. ACCOUNTING AND APPROPRIATION DATA (If required)
13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,
IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.
| (√) |
| A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A. |
B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).
C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:
D. OTHER (Specify type of modification and authority)
E. IMPORTANT: Contractor |_| is not, |X| is required to sign this document and return 1 copy to the issuing office.
14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)
Invitation for Bid No. DTSL55-10-B-C0733, dated 8/16/10, is hereby amended to change the Bid Opening date to Thursday, September 9, 2010 at 3:00 PM and to revise No. 8 (PERFORMANCE) on page 11 of 50 as follows.
All other terms and conditions remain the same.
Continued on Page 2
Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.
| 15A. NAME AND TITLE OF SIGNER (Type or print) |
| 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print) |
Patricia L. White Contracting Officer
15B. CONTRACTOR/OFFEROR
(Signature of person authorized to sign)
| 15C. DATE SIGNED |
| 16B. UNITED STATES OF AMERICA |
BY __________________________________________
(Signature of Contracting Officer)
16C. DATE SIGNED
STANDARD FORM 30
| AMENDMENT A003 | IFB No. DTSL55-10-B-C0733 | |
| REVISED 8/19/2010 |
8. PERFORMANCE
a. Time of Performance.
| (1) The Corporation will deliver the Gatelifter and the Tug to the Contractor’s approved drydock facility at the same time in June 2011. Work must be completed within six (6) weeks of delivery of the vessels. The Corporation shall contact the Contractor to schedule the exact delivery date; | |
| (2) The Gatelifter and Tug shall be drydocked within seventy-two (72) hours following delivery; | (3) The Contractor shall provide a work schedule, which shall show the various work items, material availability, days to complete, critical quality control steps, and completion date. This schedule with copies shall be delivered to the Contracting Officer and his/her representative(s) within one (1) week after contract award and shall be kept up to date by the representative(s) within one (1) week after contract award and shall be kept up to date by the Contractor, with changes furnished weekly to the Contracting Officer while the Gatelifter and the Tug are in drydock. Acceptance of the schedule by the Contracting Officer shall not excuse the Contractor for any delay in completing the work; and, |
(4) The Contractor shall perform all work diligently and shall complete the contract within six (6) weeks from the date the Gatelifter and the Tug are delivered to the drydock. Completion shall include removal and proper disposal of all scrap, rubbish, and hazardous/non-hazardous materials resulting from the work.
File details come from the government source that posted it. Updated .