DTFAAC-17-R-00130 (1).1

Section B - Supplies or Services/Prices

Section B - Schedule

See attached Schedule B identified in SECTION J

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications

Scope of Work

The Contractor shall provide the services identified in SECTION B, SUPPLIES OR SERVICES AND PRICES/COST, in accordance with the Statement of Work shown as Attachment 1 in Part III-SECTION J, LIST OF ATTACHMENTS, and with all other terms, conditions, and provision set forth herein.

Clause List

AC4548 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE (JUL

2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel not being subject to the direction and control of Government personnel when performing non-personal contract services in FAA facilities.

(b) All contractor personnel at a FAA work site or facility during an actual emergency shall conform to the procedures posted or directed by FAA officials responsible for emergency response at that site or facility. Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, etc.

(c) Contractor personnel shall participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions and based on advance arrangements that are then announced at the time of an exercise, contractor personnel will be excused from evacuations.

(d) Contractor management/supervisors shall ensure that each contractor employee assigned work in FAA facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Information on emergency procedures may be requested from the Contracting Officer’s Representative (COR) or a designated FAA contact point at the work site.

Section D - Packaging and Marking

Clause List

Section E - Inspection and Acceptance

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.4-4 INSPECTION OF SERVICES - BOTH FIXED-PRICE & COST REIMBURSEMENT (APR 1996)

3.10.4-15 CERTIFICATE OF CONFORMANCE (APR 1996)

3.10.4-16 RESPONSIBILITY FOR SUPPLIES (APR 1996)

AC1908 INSPECTION AND ACCEPTANCE AT DESTINATION (JUN 2015)

(a) Final inspection and acceptance shall be at destination.

(b) Although source inspection by the Government is not anticipated under this contract, the provisions of this clause shall in no way be construed to limit the rights of the Government under the clause entitled 3.10.4-4 - Inspection of Services - Both Fixed-Price & Indefinite Delivery Requirement (Apr 1996).

Section F - Deliveries or Performance

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.1-9 STOP-WORK ORDER (OCT 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

3.11-34 F.O.B. DESTINATION (APR 1999)

AC1604 CONTRACT PERIOD (JUN 2015)

The effective period of this contract is 1 year from date of award, plus four, 1-year options if exercised.

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government. The COR must approve any expedited delivery or performance.

Section G - Contract Administration Data

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.1-22 CONTRACTING OFFICER'S REPRESENTATIVE (APR 2012)

AC0116 OPTION TO EXTEND SERVICES (JUN 2015)

The Government may unilaterally exercise its option to extend the term of the contract for performance of specified services pursuant to Section I, AMS Clause 3.2.4-34, Option to Extend Services , by written notice to the contractor not later than the expiration date of the current contract period.

AC0135 INVOICING PROCEDURES - GENERAL (JAN 2017)

(a) In addition to the requirements set forth at AMS Clause 3.3.1-17, Prompt Payment, for the submission of a proper invoice, the contractor shall submit a separate invoice for (1) each month of performance of services, or (2) those items of supplies furnished, as follows:

(1) The original to: 9-AMC-AMZ-FAA-APInvoices@faa.gov (Preferred) or mail to:

DOT/FAA AMK-311/314

P.O. Box 25710

Oklahoma City, OK 73169-0710

(2) One Copy to stacey.stanley@faa.gov or:

FAA, Mike Monroney Aeronautical Center

Office of Acquisition Services (AAQ-(insert routing symbol))

P.O. Box 25082

Oklahoma City, OK 73l25

(3) One Copy to candace.dodd@faa.gov or:

FAA, Mike Monroney Aeronautical Center

Candace Dodd AJW

P.O. Box 25082

Oklahoma City, OK 73l25

(b) Each invoice shall highlight the following information:

(1) Contract number and applicable Delivery Order number.

(2) Noun description of services and/or supplies, including applicable line item number(s) and quantity(s) that were provided.

(3) Extended totals for invoiced quantities.

(c) All contractors invoicing services to the FAA in labor hours shall maintain on file, and submit when required for verification or audit, certified time logs showing a daily start and ending work times, the daily total of productive hours charged to the contract, a daily entry for any non-productive work-hours and cumulative totals for each pay period.

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL 2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements

Clause List

H.1 SECURITY REQUIREMENTS - The contractor will be escorted at any FAA facility for meetings or visits.

See Section I Clauses

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2013)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

Contractors may use the following means of electronic signature technology digital signatures..

(End of Clause)

3.13-15 CONFIDENTIALITY OF DATA AND INFORMATION (OCT 2011)

(a) The contractor and any of its subcontractors, in performance of this contract, may need access to and use of various types of data and information in the possession of the Government, which the Government obtained under conditions which restrict its right to use and disclose data and information or which may be of a nature that its dissemination or use, other than in the performance of this contract, would be adverse to the interests of the Government or other parties. Therefore, the contractor and its subcontractors agree to abide by any restrictive use conditions on such data and not to: (1) knowingly disclose such data and information to others without written authorization from the Contracting Officer, unless the Government has made data and information available to the public; and (2) use for any purpose other than the performance of this contract any data which bears a restrictive marking or legend. For the sole purpose of this clause, "information" means any communication or representation of knowledge such as facts, data, or opinions in any medium or form, including textual, numerical, graphic, cartographic, narrative or visual form. Data processed in such a way that it can increase the knowledge of the person who receives it. Information is the output, or finished goods, of information systems.

(b) In the event the work required to be performed under this contract requires access to proprietary data and information of other companies, the contractor must obtain agreement from such other companies for such use unless such data are provided or made available to the contractor by the Government. Two copies of such company-to-company agreements must be furnished promptly to the Contracting Officer for information only. These agreements must prescribe the scope of authorized use of disclosure and other terms and conditions to be agreed upon between the parties thereto. It is agreed by the contractor that any such data, whether obtained by the contractor pursuant to the aforesaid agreement or from the Government, must be protected from unauthorized use or disclosure to any individual, corporation, or organization so long as it remains proprietary.

(c) The contractor agrees to conduct formal training to make employees aware of the requirement to maintain confidentiality of data and information, as required above, to the end that they will be disciplined if the necessity to refrain from divulging either the proprietary data of other companies or data that are obtained from the Government to anyone except as authorized. The contractor must obtain from each employee engaged in any effort connected with this contract an agreement, in writing, which must in substance provide that such employee will not, during his/her employment by the contractor or anytime thereafter, disclose to others or use for his/her own benefit or the future benefit of any individual any trade secrets, confidential information, or proprietary/restricted data (to include Government "For Official Use Only") received in connection with the work under this contract.

(d) The contractor agrees to hold the Government harmless and indemnify the Government as to any cost/loss resulting from the unauthorized use or disclosure of third party data or software by the contractor, its employees, subcontractors, or agents.

(e) The contractor agrees to include the substance of this clause in all subcontracts awarded under this contract. The Contracting Officer will consider case-by-case exceptions to this requirement for individual subcontracts in the event that: (1) the contractor considers the application of the prohibition of this clause to be inappropriate and unnecessary in the case of a particular subcontract; (2) the contractor provides a written statement affirming absolute unwillingness of a subcontractor to perform, absent some relief from the substance of this prohibition; (3) use of an alternate subcontract source would unreasonably detract from the quality of effort; and (4) the contractor provides the Contracting Officer timely written advance notice of these and any other extenuating circumstances.

(f) Except as the Contracting Officer specifically authorizes in writing, upon completion of all work under this contract, the contractor must return all such data and information obtained from the Government, including all copies, modifications, adaptations, or combinations thereof, to the Contracting Officer. Data obtained from another company must be disposed of in accordance with the contractor's agreement with that company, or if the agreement makes no provision for disposition, must be returned to that company. The contractor must further certify in writing to the CO that all copies, modifications, adaptations, or combinations of such data or information which cannot reasonably be returned to the Contracting Officer (or to the appropriate company), have been deleted from the contractor's (and any subcontractor's) records and destroyed.

(g) These restrictions do not limit the contractor's (or subcontractor's) right to use and disclose any data and information obtained from another source without restriction.

(End of clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.¿

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC¿s environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC4540 AGREEMENT TO PARTICIPATE IN ALTERNATIVE DISPUTE RESOLUTION (JUN 2015)

(a) The Federal Aviation Administration encourages direct communications and negotiations between the contractor and the contracting officer in an attempt to resolve contract disputes. In those situations where the parties are not able to achieve resolution at the contracting officer level, the agency favors the use of alternative dispute resolution (ADR) techniques to resolve disputes.

(b) The parties hereby agree that, prior to referring a contract dispute to the Office of Disputes Resolution as described in contract clause 3.9.1-1 ‘Contract Disputes’, the parties will discuss whether they are willing to utilize ADR techniques such as mediation or nonbinding evaluation of the dispute by a neutral party. Upon receipt of a contract dispute from the contractor, the contracting officer will explore with the contractor whether the use of ADR techniques would be appropriate to resolve the dispute. Both parties must agree that the use of such techniques is appropriate, and agree to fairly share the associated expenses. If the parties do not mutually agree to utilize ADR to resolve the dispute, the dispute will be processed in accordance with the procedures set forth in clause 3.9.1-1.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses

Clause List

DUE TO SYSTEM CONSTRAINTS THE FOLLOWING CLAUSE COULD NOT BE DELETED AND IS NOT

APPLICABLE.

3.10.1-26

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (AUG 1997)

3.2.2.3-29 INTEGRITY OF UNIT PRICES (JUL 2004)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.2.8-1 MATERIAL REQUIREMENT (APR 2009)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 1996)

3.2.5-3 GRATUITIES OR GIFTS (JAN 1999)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2010)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-1 PAYMENTS (APR 1996)

3.3.1-6 DISCOUNTS FOR PROMPT PAYMENT (MAY 1997)

3.3.1-8 EXTRAS (MAY 1997)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

3.3.1-15 ASSIGNMENT OF CLAIMS (APR 1996)

3.3.1-17 PROMPT PAYMENT (APR 2012)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(AUG 2012)

3.3.2-1 FAA COST PRINCIPLES (JAN 2016)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JUL 1996)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT 1996)

3.4.2-7 FEDERAL, STATE, AND LOCAL TAXES - FIXED-PRICE, NONCOMPETITIVE CONTRACT

(APR 1996)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JAN

2009)

3.5-3 PATENT INDEMNITY (JAN 2009)

3.5-13 RIGHTS IN DATA - GENERAL (OCT 2014)

3.5-13 RIGHTS IN DATA - GENERAL (OCT 2014) - ALTERNATE I (JAN 2009)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2016)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-9 EQUAL OPPORTUNITY (AUG 1998)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (JAN 2011)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2010)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (AUG 1998)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2015)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2012)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (OCT 2016)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (OCT 2016)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.8.2-9 SITE VISIT (APR 1996)

3.8.2-10 PROTECTION OF GOVERNMENT BUILDINGS, EQUIPMENT, AND VEGETATION (APR

1996)

3.9.1-1 CONTRACT DISPUTES (OCT 2011)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-12 CHANGES - FIXED-PRICE (APR 1996) - ALTERNATE I (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.2-1 SUBCONTRACTS (FIXED-PRICE CONTRACTS) (APR 1996)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-4 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-11 PLAIN LANGUAGE (JUL 2006)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(OCT 2012)

3.14-3 FOREIGN NATIONALS AS CONTRACTOR EMPLOYEES (APR 2014)

PART 3.1 CLAUSES AND PROVISIONS

3.2.2.3-37 NOTIFICATION OF OWNERSHIP CHANGES (JUL 2004)

(a) The Contractor (you) must notify FAA in writing within 30 days when you become aware that a change in ownership has occurred or will occur and that the change could affect the value of your capitalized assets in the accounting records, asset valuations, or cause any other cost changes.

(b) You must:

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the Contracting Officer (CO) access to the records on request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of your ownership changes; and

(4) Retain and maintain depreciation and amortization schedules based on the asset records maintained before each ownership change.

(c) You must include the substance of this clause in all subcontracts under this contract with a value exceeding $1,000,000 and that require cost and price data.

(End of clause)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

(a) Definitions. As used in this clause-

"Inverted domestic corporation" means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

"Subsidiary" means an entity in which more than 50 percent of the entity is owned-

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

(b) If the contractor reorganizes as an inverted domestic corporation or becomes a subsidiary of an inverted domestic corporation at any time during the period of performance of this contract, the FAA may be prohibited from paying for Contractor activities performed after the date when it becomes an inverted domestic corporation or subsidiary.

The FAA may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of FAA action under this clause.

(c) In the event that the contractor becomes either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation during contract performance, the contractor must give written notice to the Contracting Officer within five business days from the inversion event.

(End of clause)

3.2.4-34 OPTION TO EXTEND SERVICES (OCT 2014)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within the period specified in the Schedule.

(End of clause)

3.2.4-35 OPTION TO EXTEND THE TERM OF THE CONTRACT (APR 1996)

(a) The Government may extend the term of this contract by written notice to the Contractor within the current period of performance of the contract; provided, that the Government shall give the Contractor a preliminary written notice of its intent to extend at least 60 days before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option provision.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 60 (months) 5 (years).

(End of clause)

3.3.1-11 AVAILABILITY OF FUNDS FOR THE NEXT FISCAL YEAR (APR 1996)

Funds are not presently available for performance under this contract beyond 30 September 2017. The FAA's obligation for performance of this contract beyond that date is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the FAA for any payment may arise for performance under this contract beyond period of performance, until funds are made available to the Contracting Officer for performance and until the Contractor receives notice of availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://www.vip.vetbiz.gov.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) change the name in the SAM database;

(B) comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.3.1-36 AVAILABILITY OF FUNDS - OPTION PERIODS UNDER A CONTINUING RESOLUTION

(APR 2008)

Due to the possibility of the enactment of a continuing resolution in lieu of an annual appropriation, full fiscal year funding may not be available for an entire contract option period. In the event of a continuing resolution, FAA will only be liable for an amount based on the time period specified by the continuing resolution. The amount of funds made available by the continuing resolution will be specified by subsequent modification. If the contractor provides services in excess of the funded amount or beyond the covered period, the contractor does so at its own risk.

(End of Clause)

3.5-1 AUTHORIZATION AND CONSENT (JAN 2009)

(a) The Government authorizes and consents to all use and manufacture, in performing this contract or any subcontract at any tier, of any invention described in and covered by a United States patent -

(1) Embodied in the structure or composition of any article the delivery of which is accepted by the Government under this contract; or,

(2) Used in machinery, tools, or methods whose use necessarily results from compliance by the Contractor or a subcontractor with

(i) Specifications or written provisions forming a part of this contract or

(ii) Specific written instructions given by the Contracting Officer directing the manner of performance.

The entire liability to the Government for infringement of a United States patent must be determined solely by the provisions of the Indemnity clause, if any, included in this contract or any subcontract hereunder (including any lower-tier subcontract), and the Government assumes liability for all other infringement to the extent of the authorization and consent hereinabove granted.

(b) The Contractor must include the substance of this clause, including this paragraph (b), in all subcontracts that are expected to exceed $100,000.00. However, omission of this clause, including those from any subcontract, including those at or below $100,000.00, does not affect this authorization and consent.

(End of clause)

3.6.2-14 EMPLOYMENT REPORTS ON VETERANS (JAN 2011)

(a) Unless the contractor is a State or local government agency, the contractor must report at least annually, as required by the Secretary of Labor, on:

(1) The total number of employees in the contractor's workforce, by job category and hiring location, who are disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans,

(2) The total number of new employees hired during the period covered by the report, and of the total, the number of disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans;

and

(3) The maximum number and minimum number of employees of the Contractor or subcontractor at each hiring location during the period covered by the report.

(b) The above items must be reported by completing the form titled 'Federal Contractor Veterans' Employment Report VETS-100A.'

(c) Reports shall be submitted no later than September 30 of each year.

(d) The employment activity report required by paragraph (a)(2) of this clause must reflect total hires during the most recent 12-month period as of the ending date selected for the employment profile report required by paragraph (a)(1) of this clause. Contractors may select an ending date: (1) As of the end of any pay period during the period January through March 1st of the year the report is due, or (2) as of December 31, if the contractor has previous written approval from the Equal Employment Opportunity Commission to do so for purposes of submitting the Employer Information Report EEO-1 (Standard Form 100).

(e) The count of veterans reported according to paragraph (a) of this clause must be based on data known to the contractor when completing the VETS-100A. .The Contractor's knowledge of veterans status may be obtained in a variety of ways, including an invitation to applicants to self-identify (in accordance with 41 CFR 60-300.42), voluntary self-disclosure by employees, or actual knowledge of…