SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

COLUMBIA Class Submarine Propulsor Tailcone

FPIF

Procure material, manufacture and deliver one COLUMBIA Class Submarine Propulsor Tailcone FOB: Origin (Shipping Point) PN/CN: Tailcone PSC CD:

TARGET COST:

TARGET PROFIT: ______________________

TOTAL TARGET PRICE:

CEILING PRICE:

SHARE RATIO ABOVE TARGET:

SHARE RATIO BELOW TARGET:

0002 COLUMBIA Class Submarine Propulsor Tailcone

OPTION

Procure material, manufacture and deliver one COLUMBIA Class Submarine Propulsor Tailcone FOB:

Origin (Shipping Point) PN/CN: Tailcone

PSC CD:

TARGET COST:

TARGET PROFIT: ______________________

TOTAL TARGET PRICE:

0003 Engineering Services Year 1 1,200 Hours

CPFF

Provide engineering support services in support of CLINs 0001-0002 – NTE 1,200 hours. FOB:

Destination PN/CN: EngSvcs PSC CD:

ESTIMATED COST: $0.00

FIXED FEE: $0.00

TOTAL EST COST + FEE: $0.00

0004 NRE & Manufacturing Strategy

Perform all requisite NRE, procure all related material and develop a COLUMBIA Class Tailcone Manufacturing Strategy.

FOB: Destination PN/CN: MftStgy PSC CD:

0005 Other Direct Costs (ODC)

Cost

ODC’s in support of all CLINs of this contract FOB: Destination PN/CN: Travel PSC CD:

Data Data for all CLINs as specified in CDRLS, DD Form 1423, Exhibit A.

NSP

NET AMT NSP

0101 COLUMBIA Class Submarine Propulsor Tailcone

Procure material, manufacture and deliver one COLUMBIA Class Submarine Propulsor Tailcone FOB: Origin (Shipping Point) PN/CN: Tailcone PSC CD:

TOTAL TARGET PRICE:

CEILING PRICE:

0102 Engineering Services Year 2 1,200 Hours

Provide engineering support services in support of CLINs 0101 – NTE 1,200 hours. FOB:

0201 COLUMBIA Class Submarine Propulsor Tailcone

FOB: Origin (Shipping Point) PN/CN: Tailcone PSC CD:

TARGET COST:

TARGET PROFIT: ______________________

TOTAL TARGET PRICE:

0202 COLUMBIA Class Submarine Propulsor Tailcone

FOB: Origin (Shipping Point) PN/CN: Tailcone PSC CD:

TARGET COST:

TARGET PROFIT: ______________________

TOTAL TARGET PRICE:

0203 Engineering Services Year 3 1,200 Hours

Provide engineering support services in support of CLINs 0201-0202 – NTE 1,200 hours. FOB:

0301 COLUMBIA Class Submarine Propulsor Tailcone

FOB: Origin (Shipping Point) PN/CN: Tailcone PSC CD:

TOTAL TARGET PRICE:

SHARE RATIO ABOVE TARGET:

SHARE RATIO BELOW TARGET:

0302 Engineering Services Year 4 1,200 Hours

Provide engineering support services in support of CLINs 0301 – NTE 1,200 hours. FOB:

0401 COLUMBIA Class Submarine Propulsor Tailcone

Procure material, manufacture and deliver one COLUMBIA Class Submarine Propulsor Tailcone FOB: Origin (Shipping Point) PN/CN: Tailcone

PSC CD:

TARGET COST:

TARGET PROFIT: ______________________

TOTAL TARGET PRICE:

0402 COLUMBIA Class Submarine Propulsor Tailcone

FOB: Origin (Shipping Point) PN/CN: Tailcone PSC CD:

TARGET COST:

TARGET PROFIT: ______________________

TOTAL TARGET PRICE:

0403 Engineering Services Year 5 1,200 Hours

Provide engineering support services in support of CLINs 0401-0402 – NTE 1,200 hours. FOB:

CLAUSES INCORPORATED BY FULL TEXT

CONTRACT SUMMARY FOR PAYMENT OFFICE (COST/FIXED PRICE) (FEB 1997)

This contract includes the following line items:

Item Type

CLIN 0001 FPIF

CLIN 0002 FPIF

CLIN 0003 CPFF

CLIN 0004 CPFF CLIN 0005 COST CLIN 0006 NSP

CLIN 0101 FPIF

CLIN 0102 CPFF

CLIN 0201 FPIF

CLIN 0202 FPIF

CLIN 0203 CPFF

CLIN 0301 FPIF

CLIN 0302 CPFF

CLIN 0401 FPIF

CLIN 0402 FPIF

CLIN 0403 CPFF

SECTION C - DESCRIPTION/SPECIFICATION

C.1. Background

The Advanced Propulsor Management Office (Code 808) in the Naval Architecture and Engineering Department (Department 80) of the Naval Surface Warfare Center, Carderock Division (NSWCCD) is responsible for Engineering and Manufacturing of US Navy COLUMBIA (CLB) Class submarine propulsors. The CLB Class tailcone is a key component of the propulsor.

C.2. Scope

The objective of this procurement is to manufacture maximum of eight (8) COLUMBIA Class submarine Tailcone Kits. The Government will require a minimum of one (1) Tailcone Kit in year one, with options for an additional seven (7) Tailcone Kits throughout the contract’s period of performance.

C.3 References

Applicable references include NAVY drawings and industry specifications.

References Title DWG No.

(a) DP2.3.3 / DP2.3.4 TAILCONE KIT 324561000, Rev (A)

C.4 CLIN 0001 and if Options are exercised, CLINS 0002, 0101, 0201, 0202, 0301, 0401 and 0402

The contractor shall manufacture, paint and deliver 1 (one) DP2.3.3 / DP2.3.4 Tailcone Kit, Item 324561000 of reference (a). The contractor shall meet all requirements specified in reference (a), as modified by Attachment 1, and the items referenced therein. The Tailcone kit shall include the items and quantities specified in reference (a).

The contractor shall provide a final certification package (CDRL A001) in accordance with reference (a).

The contractor shall allow seven (7) business days after completion of the last coat of paint applied in accordance with reference (a) before on-site government inspection occurs.

C.5 If Options are exercised, CLINs 0003, 0102, 0203, 0302 and 0403

Upon receipt of a written request from the Contracting Officer, the contractor may perform engineering services in support of COLUMBIA Class Propulsor related design review, design change or other engineering related tasking.

C.6 If Option is exercised, CLIN 0004

The contractor shall develop a manufacturing plan to outline the processes, facilities, personnel, and qualifications necessary to manufacture and deliver a COLUMBIA Class Tailcone. The manufacturing plan shall also include, in detail, the internal (prime vendor) and external (sub-vendor/supplier) process required to complete the delivery of all CLINS identified in this contract (CDRL A002). The contractor shall perform all requisite engineering and procure all hardware, material and equipment necessary to manufacture and deliver COLUMBIA Class propulsor tailcones in accordance with reference (a), as modified by Attachment 1.

C.7 If Option is exercised, CLIN 0005

Other Direct Costs (ODCs) may be required in support of the engineering services provided under this contract.

Specific ODC requirements shall be identified during performance via Technical Instructions (TIs). All ODCs shall receive Government approval via contract modification and a signed TI prior to funds being expended.

C.7.1 Travel

Upon receipt of a written request from the Contracting Officer, the Contractor shall conduct official travel within the Continental United States (CONUS) as necessary to monitor subcontractors and report status to the Government.

Any travel performed under CLIN 0053 shall be reported in CDRL A007 (Travel & Trip Report).

C.8 CLIN 0006 Data Requirements

The data to be furnished hereunder shall be prepared in accordance with the Contract Data Requirements List, DD Form 1423, Exhibit A attached hereto.

C.9 General Requirements (ALL CLINS)

C.9.1Project Planning Chart

The contractor shall design and develop a project planning chart (CDRL A003) that graphically depicts a composite schedule of all planned technical activities and milestones. This data item shall be submitted as an appendix to the Monthly Status Report (CDRL A004).

C.9.1.1 The contractor shall design the logical sequence of activities to correlate with the Manufacturing Plan (CDRL A002). The sequence of activities shall include designation of all Production Milestone Tasks which are critical production tasks which are production tasks that capture critical path production processes, top level production processes, and/or sub-contracted production processes that have the potential to impact end item delivery dates if they are delayed.

C.9.1.2 Gantt chart essential elements shall include discrete tasks and activities consistent with authorized work and relationships for contract completion by identifying items from Contract Award through completion of each Contract Line Item (CLIN). Further, identify the critical path, all major events, and program milestones. The contractor shall define baseline Planned Start Dates for each Production Milestone Task. The contractor shall also define the Latest Start Dates for each Production Milestone Task which are the latest that a production task can begin that does not affect the end item delivery date. The contractor shall inform the government in writing of any changes to the baseline Production Milestone Task Planned or Latest Start dates at least 30 days prior to changing the baseline.

C.9.1.3 Activities shall have a valid total slack or float identified for critical path analysis and impact analysis from delays.

C.9.1.4 Subordinate level elements (3rd thru 5th level or greater activities) shall not exceed thirty (30) work days in duration. The contractor shall propose any exceptions to this parameter to the Contracting Officer’s Representative (COR) for approval in writing. The Contractor may implement any exceptions only upon approval in writing by the Procurement Contracting Officer (PCO) or COR.

C.9.2 Monthly Status Reports

The contractor shall submit monthly status reports in accordance with CDRL A004. The report shall clearly demonstrate progress against key milestone dates in the Project Planning Chart (CDRL A003). The report shall include the progress/status of all work, including that of subcontractors, inventory of all parts in production and in stock, action items, discussion topics and rationale for schedule delays and improvements. The contractor shall also provide machine status, action item tracking and risk identification and management strategies. The monthly report shall include a separate attachment containing key milestones through completion of each awarded CLIN and shall include schedule impacts to each key milestone if schedule delays or accelerations are achieved by the contractor.

C.9.3 Biannual Progress Reviews and Kickoff Meeting

The contractor shall host a kick-off meeting no later than 30 days after contract award. Thereafter, the contractor shall be responsible for planning, scheduling, and conducting biannual progress reviews with Government representatives. These reviews shall be held at the contractor’s facility, or a subcontractor’s facility, as agreed to by the Government. Each review shall include, at a minimum:

• Facility Tour of the work in progress;

• Status Briefing

• Manufacturing status;

• Configuration control/quality assurance;

• Contractor-requested requests for variance;

• Adherence to contract delivery schedule;

• Any outstanding action items; and,

• Any other information which may impact contract performance or delivery.

The contractor shall prepare and provide a Conference Agenda in accordance with CDRL A005 and Conference Minutes in accordance with CDRL A006 for each meeting held with the Government.

C.9.4 Requests for Variance Requests for Variances shall be submitted via form DD1694, “Request for Variance” throughout performance of this contract.

C.9.5 Security Requirements The contractor shall comply with all security requirements as specified in the DD Form 254 (Attachment 2).

C.9.10 Cost Reports

The contractor shall submit monthly Cost Status Reports with CDRL A008 for Cost Type Contract Line Item Numbers (CLINs) only.

C.9.11 COLUMBIA Class SharePoint

The contractor shall request and maintain access to the Government-maintained COLUMBIA Class Propulsor SharePoint site.

SECTION D – PACKAGING AND MARKING

D.1 CLIN 0001 and if Options are exercised, CLINS 0002, 0101, 0201, 0202, 0301, 0401 and 0402

Contractor shall package delivered components in accordance with reference (a), as modified by Attachment 1.

Prior to crating, the Tailcone assembly shall be affixed with the Propulsor Certification Data Report, NAVSEA Form 9245/1, which shall be provided with the final certification package (CDRL A001).

D.2 If Options are exercised, CLINs 0003, 0004, 0102, 0203, 0302 and 0403

Unclassified data shall be marked in accordance with DFARS 254.204-7012. Classified data shall be marked in accordance with the Department of Defense Industrial Security Manual for Safeguarding Classified Information, DOD 5220.22M, dated 28 February 2006.

D.3 CLIN 0006

Data shall be furnished in accordance with CDRLS, DD Forms 1423, Exhibit A.

SECTION E – INSPECTION AND ACCEPTANCE

Prior to acceptance of any CLIN, all applicable CDRLs and waivers/deviations must be provided and approved by the government in accordance with CDRLs as required and identified under each CLIN in Section C.

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Origin Government Origin Government 0003 Origin Government Origin Government 0004 Destination Government Destination Government 0005 Destination Government Destination Government 0006 N/A N/A N/A N/A 0101 Origin Government Origin Government 0102 Destination Government Destination Government 0201 Origin Government Origin Government 0202 Origin Government Origin Government 0203 Destination Government Destination Government 0301 Origin Government Origin Government 0302 Destination Government Destination Government 0401 Origin Government Origin Government 0402 Origin Government Origin Government 0403 Destination Government Destination Government

SECTION F – DELIVERIES OR PERFORMANCE

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC / CAGE

0001 TBD 1 TBD TBD

0002 TBD 1 TBD TBD

0003 TBD N/A TBD TBD

0004 TBD 1 TBD TBD

0005 TBD 1 TBD TBD

0006 N/A N/A N/A N/A

0101 TBD 1 TBD TBD

0102 TBD 1 TBD TBD

0201 TBD 1 TBD TBD

0202 TBD 1 TBD TBD

0203 TBD N/A TBD TBD

0301 TBD 1 TBD TBD

0302 TBD 1 TBD TBD

0401 TBD 1 TBD TBD

0402 TBD 1 TBD TBD

0403 TBD 1 TBD TBD

Early delivery is acceptable provided the COR has granted prior written approval.

SECTION J – LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

The following documents, exhibit, and other attachments form a part of this solicitation:

Exhibit “A”, Contract Data Requirements list (CDRL), DD Form 1423 Attachment 1, Applicable PERs, 1 page.

Attachment 2, DD Form 254

Attachment 1: Applicable PERs – 6 January 2026

PER #

Applicable

Dwg Description

CLIN Applicability 0001 0002 0101 0201 0202 0301 0401 0402

0242 324561000 Tailcone Kit;

Update CAGE Code and Markings

X X X X X X X X

1038 324561000 Tailcone Kit Crating and

Marking Updates X X X X X X X X

0713 324561002 Edge Chamfer & Matl Spec Update X X X X X X X X

1178 324561005 Update Specs For

Peek Thread-Saver Material &

Reference Typo X X X X X X X X

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS