Construction Clauses.doc

CONTRACT CLAUSES

FAR 52.204-19, Incorporation by Reference of Representations and Certifications (Dec 2014)

The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of clause) FAR 52.211-10, Commencement, Prosecution, and Completion of Work (Apr 1984) Alt 1 (Apr 1984) The Contractor shall be required to

(a) commence work under this contract within five (5) calendar days after the date the Contractor receives the notice of award, see the statement of work for timeline of specific submittal requirements.

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 40 Days after notice to proceed. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice of award by June 15, 2020. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice of award, except to the extent that the delay in completion results from the failure of the Contractor to execute the contract, provide submittals timely for approval, and give the required irrevocable letter of credit/payment bonds within the time specified in the offer.

(End of Clause) FAR 52.213-4, Terms and Conditions -- Simplified Acquisitions (Other Than Commercial Items) (JAN 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Aug 2019) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O.11246).

(vii) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(viii) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C.3553).

(ix) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Pub.L.108-77, 108-78 (19 U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (Apr 1984).

(ii) 52.232-8, Discounts for Prompt Payment (Feb 2002).

(iii) 52.232-11, Extras (Apr 1984).

(iv) 52.232-25, Prompt Payment (Jan 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (Jun 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)

(vii) 52.233-1, Disputes (May 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (Aug 2019).

(ix) 52.253-1, Computer Generated Forms (Jan 1991).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018)(Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2020) (E.O.13126) (Applies to contracts for supplies exceeding the micro-purchase threshold.)

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (May 2014) (41 U.S.C.chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C.4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (Jul 2014) (29 U.S.C.793) (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States.) (For purposes of this clause, “United States” includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.)

(vi) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C.4212) (Applies to contracts of $150,000 or more).

(vii) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C.chapter 67) (Applies to service contracts over $2,500 that are subject to the Service Contract Labor Standards statute and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer Continental Shelf).

(viii)

(A) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C. chapter78 and E.O 13627) (Applies to all solicitations and contracts).

(B) Alternate I (Mar 2015) (Applies if the Contracting Officer has filled in the following information with regard to applicable directives or notices: Document title(s), source for obtaining document(s), and contract performance location outside the United States to which the document applies).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(x) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia.))

(xi) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities).

(xii) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693)(applies to contracts for products as prescribed at FAR 23.804(a)(1)).

(xiii) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693) (Applies to maintenance, service, repair, or disposal of refrigeration equipment and air conditioners).

(xiv) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR® Program or Federal Energy Management Program (FEMP)) will be-

(A) Delivered;

(B) Acquired by the Contractor for use in performing services at a Federally-controlled facility;

(C) Furnished by the Contractor for use by the Government; or

(D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance).

(xv) 52.223-20, Aerosols (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons as a propellant or as a solvent; or contracts for maintenance or repair of electronic or mechanical devices).

(xvi) 52.223-21, Foams (Jun 2016) (E.O. 13693) (Applies to contracts for products that may contain high global warming potential hydrofluorocarbons or refrigerant blends containing hydrofluorocarbons as a foam blowing agent; or contracts for construction of buildings or facilities.

(xvii) 52.225-1, Buy American-Supplies (May 2014) (41 U.S.C.chapter 67) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition-

(A) Is set aside for small business concerns; or

(B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000).

(xviii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States).

(xix) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct 2013)(Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the System for Award Management (SAM) as its source of EFT information).

(xx) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (Applies when the payment will be made by EFT and the payment office does not use the SAM database as its source of EFT information).

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.App.1241) (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d)).

(2) Listed below are additional clauses that may apply:

(i) 52.204-21, Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) (Applies to contracts when the contractor or a subcontractor at any tier may have Federal contract information residing in or transiting through its information system.

(ii) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (Applies to contracts over $35,000).

(iii) 52.211-17, Delivery of Excess Quantities (Sept 1989) (Applies to fixed-price supplies).

(iv) 52.247-29, F.o.b. Origin (Feb 2006) (Applies to supplies if delivery is f.o.b. origin).

(v) 52.247-34, F.o.b. Destination (Nov 1991) (Applies to supplies if delivery is f.o.b. destination).

(c) FAR 52.252-2, Clauses Incorporated by Reference (Feb 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.Acquisition.gov

(d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights-

(1) Within a reasonable period of time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided.

(g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(End of clause)

FAR 52.225-9, Buy American–Construction Materials (May 2014)

(a) Definitions. As used in this clause-

“Commercially available off-the-shelf (COTS) item”-

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: ______ [Contracting Officer to list applicable excepted materials or indicate “none”]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

**Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

(End of Clause)

FAR 52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JUL 2000)

1. (a) The Contractor shall submit one of the following payment protections:

Irrevocable Letter of Credit or Payment Bond

2. (b) The amount of the payment protection shall be 100 percent of the contract price.

3. (c) The submission of the payment protection is required within Five days of contract award.

4. (d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

5. (e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

6. (f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

(End of clause)

FAR 52.252-2 CLAUSES INCORPORATD BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given full text. Upon request, the Contracting Officer will make their full text available. Also the full test of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov ; and http://farsite.hill.af.mil/ FAR 52.203-5, Covenant Against Contingent Fees (May 2014) FAR 52.203-7, Anti-Kickback Procedures (May 2014) FAR 52.203-17, Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (Apr 2014) FAR 52.204-9, Personal Identity Verification of Contractor Personnel (Jan 2011) FAR 52.204-13, System for Award Management Maintenance (Oct 2018) FAR 52.204-18, Commercial and Government Entity Code Maintenance (Jul 2016) FAR 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) FAR 52.219-6, Notice of Total Small Business Set-Aside FAR 52.219-28, Post-Award Small Business Program Rerepresentation (Mar 2020)

FAR 52.222-6 Construction Wage Rate Requirements (Aug 2018) FAR 52.222-7, Withholding of Funds (May 2014) FAR 52.222-8, Payrolls and Basic Records (Aug 2018) FAR 52.222-9, Apprentices and Trainees (Jul 2005)

FAR 52.222-10,

Compliance with Copeland Act Requirements (Feb 1988)

FAR 52.222-11, Subcontracts (Labor Standards) (May 2014)

FAR 52.222-12,

Contract Termination -- Debarment (May 2014)

FAR 52.222-13,

Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014)

FAR 52.222-14,

Disputes Concerning Labor Standards (Feb 1988)

FAR 52.222-15,

Certification of Eligibility (May 2014) FAR 52.222-26 Equal Opportunity (Sep 2016) Alt 1 (Feb 1999)

FAR 52.222-27, Affirmative Action Compliance Requirements for Construction (Apr 2015) FAR 52.222-34, Project Labor Agreement (May 2010) FAR 52.223-6, Drug-Free Workplace (May 2001) FAR 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) FAR 52.227-4, Patent Indemnity -- Construction Contracts (Dec 2007)

FAR 52.228-14 Irrevocable Letter of Credit (Nov 2014) FAR 52.232-5, Payments under Fixed-Price Construction Contracts (May 2014) FAR 52.232-23, Assignment of Claims (May 2014) FAR 52.232-27, Prompt Payment for Construction Contracts (Jan 2017) FAR 52.236-2, Differing Site Conditions (Apr 1984) FAR 52.236-3, Site Investigation and Conditions Affecting the Work (Apr 1984) FAR 52.236-5, Material and Workmanship (Apr 1984) FAR 52.236-7, Permits and Responsibilities (Nov 1991) FAR 52.236-8, Other Contracts -- (Apr 1984) FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (Apr 1984) FAR 52.236-12, Cleaning Up (Apr 1984) FAR 52.236-13, Accident Prevention (Nov 1991) FAR 52.242-14, Suspension of Work (Apr 1984) FAR 52.243-5, Changes and Changed Conditions (Apr 1984) FAR 52.245-1, Government Property (Jan 2017)

FAR 52.245-9, Use and Charges (Apr 2012) FAR 52.249-10, Default (Fixed-Price Construction) (Apr 1984) Alt 1 (Apr 1984) CAR 1352.201-70, Contracting Officer's Authority (APR 2010)

CAR 1352.209-73, Compliance with the Laws (APR 2010)

CAR 1352.209-74, Organizational Conflict of Interest (APR 2010)

(End of Clause)

FAR 52.252-6, AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Commerce Acquisition Regulation (48 CFR 13) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

(End of Clause)

CAR 1352.246-70, PLACE OF ACCEPTANCE (APR 2010)

(a) The Contracting Officer or the duly authorized representative will accept supplies and services to be provided under this contract.

(b) The place of work will be:

NOAA/National Marine Fisheries Service Northeast Fisheries Science Center 212 Rogers Avenue Milford, CT 06460 (End of Clause) NAM 1330-52.222-70 NOAA SEXUAL ASSAULT AND SEXUAL HARASSMENT PREVENTION AND RESPONSE POLICY (MAY 2018)

In accordance with NOAA Administrative Order (NAO) 202-1106, NOAA Sexual Assault and Sexual Harassment Prevention and Response Policy, it is the policy of NOAA to maintain a work environment free from sexual assault and sexual harassment. NOAA prohibits sexual assault and sexual harassment by or of any employee, supervisor, manager, contractor, vendor, affiliate, or other individual with whom NOAA employees come into contact by the virtue of their work for NOAA.

(a) Definitions.

Contractor Employees - The term “contractor employees,” as used in this solicitation and contract language, refers to employees of the prime contractor or its subcontractors, affiliates, consultants, or team members.

Sexual Assault - The term sexual assault, as used in this solicitation and contract language, means any conduct proscribed by state or federal sexual abuse laws, including, but not limited to, those defined in chapter 109A of title 18 of the U.S. Code (sexual abuse), and assaults committed both by offenders who are strangers to the victim and by offenders who are known or related by blood or marriage to the victim.

Sexual Harassment - As defined by the Equal Employment Opportunity Commission, sexual harassment is a form of sex discrimination that violates Title VII of the Civil Rights Act of 1964. It includes unwelcome sexual advances, requests for sexual favors, and other verbal, non-verbal, or physical conduct of a sexual nature when any of the following are true:

• Submission to such conduct is made either explicitly or implicitly as a term or condition of an individual's employment;

• Submission to or rejection of such conduct by an individual is used as the basis for employment decisions affecting such individual;

• The conduct unreasonably interferes with an individual's work performance or creates an intimidating, hostile, or offensive working environment.

The main characteristics of sexual harassment are that the harasser's conduct is targeted against the recipient’s sex, gender identity, or sexual orientation, and is unwelcome to the recipient. It may include, but is not limited to: offensive jokes, slurs, epithets or name calling, undue attention, physical assaults or threats, unwelcome touching or contact, intimidation, ridicule or mockery, insults or put-downs, constant or unwelcome questions about an individual's identity, and offensive objects or pictures.

(b) Requirements.

1. It is the responsibility of the contractor to ensure that contractor employees maintain the highest degree of conduct and standards in performance of the contract. In support of this, NOAA urges its contractors to develop and enforce comprehensive company policy addressing sexual assault and sexual harassment. 2. The contractor shall include wording substantially the same as this solicitation and contract language in every subcontract so that it is binding upon each subcontractor. 3. If a contractor employee observes or is the object of sexual assault or sexual harassment, he or she is highly encouraged to report the matter, as soon as possible, to their immediate supervisor, the Contracting Officer’s Representative (COR), subset of the COR (e.g. Task Manager or Assistant COR), or contracting officer (CO) if a COR is not assigned to the contract. The contract employee may also contact the NOAA Civil Rights Office to obtain guidance on reporting instances of sexual assault or sexual harassment. If deemed necessary, the contractor employee may also report such instances to local law enforcement. In the case where the incident occurs while performing at a remote location, such as at sea or in the field (at a field camp or other isolated location) where the above referenced individuals are unavailable, the contractor employee should follow the reporting procedure set forth in NAO 202-1106, Section 6, .07, Reporting from Remote Locations. i. Swift reporting allows NOAA and the contractor to take the appropriate measures to ensure that offensive behavior stops and the complainants’ needs are addressed. ii. The COR (if assigned), CO, and contractor, where applicable, will work together to ensure appropriate action is taken in accordance with applicable laws and regulations, contract terms and conditions, and the contractor’s written policy (where applicable).

4. The contractor shall provide all contractor employees assigned to perform under this contract with mandatory sexual assault and sexual harassment prevention and response training in compliance with the requirements of NAO 202-1106, Section 5, Prevention Training and Awareness, as part of their initial in-processing and on an annual basis thereafter. The initial training shall be completed within ____ business days [30 unless a different number is inserted] of contract award or the date a contractor employee is assigned to perform under the contract, as applicable. Evidence of initial training by name and date completed for each contractor employee, shall be submitted to the COR or contracting officer (if no COR assigned) within 10 business days of completion. Evidence of annual training by name and date completed for each contractor employee shall be submitted to the COR or contracting officer (if no COR assigned) no later than March 1st of each calendar year of contract performance.

i. The mandatory sexual assault and sexual harassment training provided by the contractor shall include the required elements set forth by NOAA’s Workplace

Violence Program Manager. A link to the website including the required elements of the training is provided at: http://www.ago.noaa.gov/quicklinks/harassment_training.html. The website will also provide training materials and resources to assist the contractor in conducting the training. The contractor may provide training that solely addresses the NOAA required elements or may supplement existing company sexual assault and sexual harassment training in a manner that ensures all of the elements are adequately addressed.

ii. The required elements of the training and resources available to the contractor for the training may be updated by NOAA periodically. The contractor is responsible for monitoring the website and incorporating any changes to the NOAA required elements into the contractor provided training. iii. NOAA’s Workplace Violence Program Manager, COR, or CO may periodically review the contractor’s training outline to ensure all required elements are included and, if necessary, any appropriate adjustments are made to the training by the contractor. iv. Contractor employees performing on assignments in a remote location, such as at a field camp or other isolated locations, are subject to receiving the same briefing on the parameters of the order provided to NOAA employees as set forth in Section 6 of NAO 202-1106.

5. The contractor shall provide a copy of this solicitation and contract language and NAO 202-1106 to contractor employees. (c) Sexual Assault/Sexual Harassment (SASH) Helpline.

For NOAA employees, affiliates, and contractors who have experienced sexual assault or sexual harassment, NOAA has established the NOAA Sexual Assault/Sexual Harassment (SASH) helpline. This helpline is designed to provide crisis intervention, referrals, and emotional support to those who are victims and/or survivors of sexual harassment or sexual assault within the workplace. Contractor employees may use the helpline to receive live, confidential, one-on-one support in an occurrence of sexual harassment or assault by a Federal Government employee. All services are anonymous, secure, and available worldwide, 24 hours a day, seven days a week. The NOAA SASH helpline is accessible through a variety of channels, including:

● Phone: 1-866-288-6558 ● Website & Online Chat:

http://NOAASASHHelpline.org

● Mobile App: NOAA SASH Helpline (available via iOS and Android App Stores) ● Text: (202) 335-0265

(d) Confidentiality.

Any party receiving information from the filing of a complaint alleging sexual assault or sexual harassment, or while performing an investigation into such a complaint, shall keep the information confidential. “Confidentiality” means that the information shall only be shared with others who have a need to know the information to conduct their official duties. 3

(e) Remedies.

In addition to other remedies available to the Government, contractor employee violations of Federal requirements (e.g., law, statutes, executive orders, code, rules, regulations) applicable to sexual assault and sexual harassment and/or failure to complete the mandatory training set forth in this solicitation and contract language, may result in:

1. Requiring the Contractor to remove a contractor employee or employees from the performance of the contract; 2. Requiring the Contractor to terminate a subcontract; 3. Suspension of contract payments until the Contractor has taken appropriate remedial action; 4. Termination of the contract for default or cause, in accordance with the termination clause of this contract; 5. Suspension or debarment; or 6. Other appropriate action.

(End of Clause)

NAM 133052.23770, CONTRACTOR COMMUNICATIONS

(a) A contractor employee shall be identified both by the individual’s name and the contractor’s name when:

(1) Included in NOAA’s locator, and

(2) When submitting any type of electronic correspondence to any NOAA employee or stakeholder.

(b) Any written correspondence from a contractor or any contractor employee shall be printed on company/organization letterhead or otherwise clearly identify the sender as an employee of the company or organization and shall identify the contract number.

(c) Contractors and/or contractor employees shall clearly identify themselves as such in any verbal communications, whether in informal discussion or a formal meeting.

(End of clause) NAM 1330-52.237-71 NOAA GOVERNMENT – CONTRACTOR RELATIONS – NON-PERSONAL SERVICES (SEP 2017)

(a) The Government and the contractor understand and agree that the services to be delivered under this contract by the contractor to the Government are non-personal services as defined in FAR Part 37, Service Contracting, and the parties recognize and agree that no employer-employee relationship exists or will exist under the contract between the Government and the contractor’s personnel. It is, therefore, in the best interest of the Government to afford both parties an understanding of their respective obligations.

(b) Contractor personnel under this contract shall not:

1. Be placed in a position where they are under relatively continuous supervision and control of a Government employee.

2. Be placed in a position of command, supervision, administration, or control over Government personnel or over personnel of other contractors performing under other NOAA contracts.

(c) The services to be performed under this contract do not require the contractor or the contractor’s personnel to exercise personal judgement and discretion on behalf of the Government. Rather, the contractor’s personnel will act and exercise personal judgement and discretion on behalf of the contractor.

(d) Rules, regulations, directives, and requirements that are issued by the Department of Commerce and NOAA under its responsibility for good order, administration, and security are applicable to all personnel who enter the Government installation and facilities, who are provided access to Government systems, or who travel on Government transportation. This is not to be construed or interpreted to establish any degree of Government control that is inconsistent with a non-personal services contract.

(e) Both parties are responsible for monitoring contract activities for indications of improper employee-employer relationships during performance. In the event a situation or occurrence takes place inconsistent with this contract language, the following applies:

1. The contractor shall notify the contracting officer in writing within 5 business days from the date of any situation or occurrence where the contractor considers specific contract activity to be inconsistent with the intent of this contract language. The notice must include the date, nature and circumstance of the situation or occurrence, the name, function and activity of each Government employee or contractor employee involved or knowledgeable about the situation or occurrence, provide any documents or the substance of any oral communications related to the activity, and an estimated date by which the Government is recommended to respond to the notice in order to minimize cost, delay, or disruption of performance.

2. The contracting officer will review the information provided by the contractor, obtain additional information (if needed), and respond in writing as soon as practicable after receipt of the notification from the contractor. The contracting officer’s response will provide a decision on whether the contracting officer determines the situation or occurrence to be inconsistent with the intent of this contract language and, if deemed necessary, will specify any corrective action(s) to be taken in order to resolve the issue.

(End of Clause)

NAM 1330-52.237-72 CONTRACTOR ACCESS TO NOAA FACILITIES (SEPT 2017)

(a) The performance of this contract requires employees of the prime contractor or its subcontractors, affiliates, consultants, or team members (“contractor employees”) to have access to and to the extent authorized, mobility within, a NOAA facility.

1. NOAA may close and or otherwise deny contractor employees access to a NOAA facility for a portion of a business day or longer for various reasons including, but not limited, to the following events:

i. Federal public holidays for Federal employees in accordance with 5 U.S.C. 6103;

ii. Fires, floods, earthquakes, and unusually severe weather, including but not limited to snow storms, tornadoes, and hurricanes;

iii. Occupational safety or health hazards;

iv. Lapse in Appropriations; or

v. Federal Statute, Executive Order, Presidential Proclamation, or any other unforeseen reason.

2. In such events, the contractor employees may be denied access to a NOAA facility that is ordinarily available for the contractor to perform work or make delivery, as required by the contract.

(b) In all instances where contractors are denied access or required to vacate a NOAA facility, in part or in whole, the contractor shall be responsible to ensure contractor personnel working under the contract comply. If the circumstances permit, the contracting officer will provide direction to the contractor, either directly or through the Contracting Officer’s Representative (COR), which could include continuing on-site performance during the NOAA facility closure period; however, if Government oversight is required and is not available, on-site performance shall not be allowed. In the absence of such direction, the contractor shall exercise sound judgment to minimize unnecessary contract costs and performance impacts, for example, performing required work off- site if possible or reassigning personnel to other activities if appropriate.

(c) The contractor shall be responsible for monitoring the Office of Personnel Management at opm.gov, the local radio, television stations, NOAA web sites, and other communication channels. Once the facility is accessible, the contractor shall resume contract performance as required by the contract.

(d) For the period that NOAA facilities were not accessible to contractors who required access in order to perform the services, the contracting officer may—

1. Adjust the contract performance or delivery schedule for a period equivalent to the period the NOAA facility was not accessible;

2. Forego the work; or

3. Reschedule the work by mutual agreement of the parties.

(e) Notification procedures of a NOAA facility closure, including contractor denial of access, are as follows:

1. The contractor shall be responsible for notification of its employees of the NOAA facility closure to include denial of access to the NOAA facility. The dismissal of NOAA employees in accordance with statute and regulations providing for such dismissals shall not, in itself, equate to a NOAA facility closure in which contractors are denied access. Moreover, the leave status of NOAA employees shall not be conveyed or imputed to contractor personnel. Accordingly, unless a NOAA facility is closed and the contractor is denied access to the facility, the contractor shall continue performance in accordance with the contract.

2. Access to Government facilities and resources, including equipment and systems, will be limited and personnel necessary to administer contract performance may not be available. Generally, supply and service contracts that are funded beyond the date of the lapse in appropriation and do not require access to Government facilities, active administration by Government personnel or the use of Government resources in a manner that would cause the Government to incur additional obligations during the lapse in appropriation may continue. If a delivery date for a contract falls during the period of a lapse in appropriations, Government personnel may not be available to receive delivery. Contractors are directed to consult with a contracting officer before attempting to make a delivery. Contracting officers will be available throughout the lapse in appropriation period to provide guidance.

Once OMB guidance is given, CORs, in consultation with the contracting officer, will notify those contractors that are deemed by the Program Office to be performing excepted work and identify the contractor personnel requiring access to NOAA facilities. CORs will also coordinate with directly with facility management or physical security personnel at respective locations to ensure that the names of contractor personnel requiring access to Government facilities during the lapse in appropriations are provided to physical security personnel.

Contractors who are not designated as performing excepted work are not allowed access to Government facilities or to utilize Government resources in a manner that would incur any additional obligation of funding on behalf of the Government during the lapse in appropriation.

1. Unless otherwise specified within the contract award, contractors requiring access to NOAA facilities outside normal business hours or outside the normal workweek shall submit a written request in writing through the COR to the contracting officer. The written request shall provide justification supporting the required access and be submitted 72 hours before access to the NOAA facility is needed. (End of Clause)

NAM 1330-52.242-70 SUBMITTAL OF INVOICES (FEB 2011)

The contractor shall prepare and submit an invoice to the Government POC for approval [with a copy to the contracting officer for information]. All invoices shall be submitted by the 10th day of the subsequent month.

To constitute a proper invoice, the contractor’s invoice shall be prepared in accordance with, and contain all elements specified in, the paragraph titled, “Contractor’s Invoice,” of the applicable prompt payment provision of the contract (e.g., FAR 52.232-25, Prompt Payment; FAR 52.232-26, Prompt Payment for Fixed-Price Architect Engineer Contracts; or FAR 52.232-27, Prompt Payment for Construction Contracts). For contracts and orders for commercial items and services, paragraph (g) of FAR 52.212-4, titled, “Invoices,” applies.

If the invoice does not comply with the applicable prompt payment provision of the contract, the COR will return it to the contractor within seven days after the date the designated office received the invoice along with a statement as to the reasons why it is not a proper invoice.

NAM 1330-52.243-70 REQUESTS FOR EQUITABLE ADJUSTMENT (OCT 2017)

(a) The amount of any request for equitable adjustment to contract terms shall accurately reflect the contract adjustment for which the contractor believes the Government is liable. The request shall include only costs for performing the change. All indirect costs included in the request shall be properly allocable to the change in accordance with applicable acquisition regulations.

(b) Any request for equitable adjustment to contract terms that exceeds the simplified acquisition threshold shall bear, at the time of submission, the following certificate executed by an individual authorized to certify the request on behalf of the Contractor:

I certify that the request is made in good faith, and that the supporting data are accurate and complete to the best of my knowledge and belief.

(Official’s Name) (Title)

(c) The certification in paragraph (b) of this clause requires full disclosure of all relevant facts, including:

1. Certified cost or pricing data, if required, in accordance with subsection 15.403-4 of the Federal Acquisition Regulation (FAR); and

2. Data other than certified cost or pricing data, in accordance with subsection 15.403-3 of the FAR, including actual cost data and data to support any estimated costs, even if certified cost or pricing data are not required.

(d) The certification requirement in paragraph (b) of this clause does not apply to:

1. Requests for routine contract payments; for example, requests for payment for accepted supplies and services, routine vouchers under a cost-reimbursement type contract, or progress payment invoices; or

2. Final adjustments under an incentive provision of the contract.

(End of Clause)

NAM 1330-52.270-304, NOAA ACQUISITION AND GRANTS OFFICE OMBUDSMAN (OCT 2016)

(a) The NOAA Acquisition and Grants Office (AGO) Ombudsman is available to organizations to promote responsible and meaningful exchanges of information. Generally, the purpose of these exchanges will be to:

(1) Allow contractors to better prepare for and propose on business opportunities.

(2) Advise as to technologies and solutions within the marketplace that the Government may not be aware of, or is not fully benefiting from.

(3) Identify constraints in transparency and process.

(b) The AGO Ombudsman will objectively, reasonably, and responsibly collaborate with parties and recommend fair, impartial, and constructive solutions to the matters presented to him/her. Further, the AGO Ombudsman will maintain the reasonable and responsible confidentiality of the source of a concern, when such a request has been formally made by an authorized officer of an organization seeking to do business with, or already doing business with NOAA.

(c) Before consulting with the AGO Ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations with the respective contracting officer for resolution. However, direct access to the AGO Ombudsman may be sought when an interested party questions the objectivity or equity of a contracting officer’s decision, or when there is a bona fide reason to believe that reasonable, responsible, and objective consideration will not be received from an assigned contracting officer.

(d) There are several constraints to the scope of the AGO Ombudsman’s authority, for instance:

(1) Consulting with the AGO Ombudsman does not alter or postpone the timelines of any formal process (e.g., protests, claims, debriefings, employee employer actions, activities involving A76 competition performance decisions, judicial or congressional hearings, or proposal, amendment, modification or deliverable due dates, etc.).

(2) The AGO Ombudsman cannot participate in the evaluation of proposals, source selection processes, or the adjudication of protests or…