CDRLs_FA8121-23-R-0004.pdf

For the best experience, open this PDF portfolio in

Acrobat X or Adobe Reader X, or later.

Get Adobe Reader Now!

http://www.adobe.com/go/reader

CONTRACT DATA REQUIREMENTS LIST Form Approved OMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 222202-2302, and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract. PR No. listed in Block E.

A. Contract Line Item No. B. Exhibit A C. Category

Other __X___ D. System/Item.

F100-PW-229 Divergent Nozzle Segment Assembly E. Contract/PR NO.

FD2030-21-31328

F. Contractor

1. Data Item No.

A003

2. Title of Data Item:

Teardown Deficiency Report

3. Subtitle:

4. Authority (Data Acquisition Document No.)

DI-PSSS-81534A

5. Contract Reference

PWS 1.1.1.3

6. Requiring Office

AFLCMC/LPSIB

7. DD 250 Req N/A

1. Dist Statement Required

10. Frequency As Required

12. Date of First Submission See Block 16

14. Distribution

8. APP Code

11. As of Date

13. Date of Subsequent Submission

a. Addressee b. Copies D r a f t

Final

Reg Re pr o b.

16. REMARKS

Changes to the office symbols shall be made by letter thought the PCO/ACO without revision to this CDRL.

Blocks 10, 11, 12 and 13: CAT I and II Material Deficiency Report (MDR) Teardown Deficiency Report (TDR) will be requested by the cognizant program office using Specific Statement of Work (SSOW) through PCO/ACO. CAT I and CAT II MDRs will be inducted for TDR upon receipt of exhibit and approved funding. Using TO 00-35D-54 as a reference, final CAT I MDRs will be submitted to the PCO/ACO NLT 45 days after exhibit induction. Final CAT II MDR TDRs will be submitted to the PCO/ACO NLT 90 days after exhibit induction. TDR may be written in contractor format.

FOR E-MAIL ADDRESS & ADDITIONAL PHONE NUMBERS CONTACT THE FOLLOWING

GUY BIERWIRTH 405-736-5970 OR EMAIL AT GUY.BIERWIRTH@US.AF.MIL

SCOTT ROBINSON 405-739-2312 OR EMAIL AT SCOTT.ROBINSON.15@US.AF.MIL

DAMON HUBBS 405-831-2800 OR EMAIL AT DAMON.HUBBS@US.AF.MIL

AFLCMC/LPSIB 1

PCO 1

DCMA/ACO 1

15. TOTAL 3

G. PREPARED BY H. DATE I. APPROVED BY J. DATE

DD Form 1423-1, JUN 90 Previous editions are obsolete Page 1 of 1 Pages

1383133072C

Cross-Out

CONTRACT DATA REQUIREMENTS LIST

CONTRACT DATA REQUIREMENTS LIST:

Form Approved CMB No 07040188:

A Contract Line Item No:

B Exhibit A:

C Category:

F Contractor: Paradigm Manchester Inc.

1 Data Item No A0002:

2 Title of Data Item Deficiency Report DR:

3 Subtitle None:

4 Authority Data Acquisition Document No DIALSS81535:

5 Contract Reference PWS 1111:

8 APP Code NA:

1 Dist Statement Required NA:

12 Date of First Submission See Block 16:

14 Distribution:

11 As of Date NA:

b Copies:

a Addressee13 Date of Subsequent Submission See Block 16:

Final:

a Addressee13 Date of Subsequent Submission See Block 16_2:

D r a f13 Date of Subsequent Submission See Block 16:

Reg:

D r a fAFLCMCLPSIB:

Re pr o1:

D r a fPCO:

Re pr o1_2:

D r a fDCMAACO:

Re pr o1_3:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_2:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_2:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_2:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_2:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_3:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_3:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_3:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_3:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_4:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_4:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_4:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_4:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_5:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_5:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_5:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_5:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_6:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_6:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_6:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_6:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_7:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_7:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_7:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_7:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_8:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_8:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_8:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_8:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_9:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_9:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_9:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_9:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_10:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_10:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_10:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_10:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_11:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_11:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_11:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_11:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_12:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_12:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_12:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_12:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_13:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_13:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_13:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_13:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_14:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_14:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_14:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_14:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_15:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_15:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_15:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_15:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_16:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_16:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_16:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_16:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_17:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_17:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_17:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_17:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_18:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_18:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_18:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_18:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_19:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_19:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_19:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_19:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_20:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_20:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_20:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_20:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_21:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_21:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_21:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_21:

DCMAACO16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_22:

D r a f16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_22:

116 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_22:

Re pr o16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_22:

16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract:

16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_2:

16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contract_3:

16 REMARKS As defined by TO 0035D54 submit a report whenever a material or a quality deficiency occurs utilizing SF Form 368 Ref Block 14a Complete address for distribution AFLCMCLPSIB 3001 Staff Dr Ste 2AE1107B Tinker AFB OK 731453031 DCMAACO See the face contractRow1:

15 TOTAL:

3:

2022-02-10T14:03:51-0600

WILSON.ATUEAYU.DEJUAN.1459161135

2022-01-20T14:57:51-0600

ROBINSON.SCOTT.B.II.1386987927

Date4_af_date: 2/9/22

Date5_af_date: 2/10/22

CONTRACT DATA REQUIREMENTS LIST Form Approved CMB No. 0704-0188

Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 222202-2302, and to the Office of Management and Budget, Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses. Send completed form to the Government Issuing Contracting Officer for the Contract. PR No. listed in Block E.

A. Contract Line Item No. B. Exhibit A C. Category

D. System/Item.

F100-PW-220/229 Divergent Segment Assembly E. Contract/PR NO.

FD2030-21-31328

F. Contractor

1. Data Item No.

A001

2. Title of Data Item:

Production Report for Contractor Receipt/Shipment of FMS R/R

3. Subtitle:

4. Authority (Data Acquisition Document No.)

DI-MGMT-80368A

5. Contract Reference

PWS 1.1.2.1

6. Requiring Office

AFLCMC/LPSIB

7. DD 250 Req

1. Dist Statement Required

10. Frequency Monthly

12. Date of First Submission

14. Distribution

8. APP Code

11. As of Date

13. Date of Subsequent Submission

a. Addressee b. Copies D r a f t

Final

Reg Repro

16. REMARKS

BLOCK 4: DID IS TAILORED AS FOLLOWS:

THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE

STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT. THE

REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH

AND FORWARDED BY E-MAIL NO LATER THAN THE 5TH WORKING DAY OF THE

FOLLOWING MONTH. THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH

DURING WHICH THE CONTRACT ASSETS ARE RECEIVED. REPORTS WILL CONTINUE

TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED. THE LAST REPORT

WILL BE ANNOTATED “FINAL REPORT”. NEGATIVE REPORTS ARE REQUIRED.

THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY, CASE/LINE NUMBER,

DOCUMENT CONTROL NUMBER, PART NUMBER, NATIONAL STOCK NUMBER,

NOMENCLATURE, SERIAL NUMBER, DELIVERY ORDER NUMBER, CLIN, ASSET

RECEIVED DATE, QUANITY PLACED ON ORDER, CONTRACTUAL START DATE,

INDUCTION DATE, CONTRACT COMPLETION DATE, FORECAST COMPLETION DATE,

ACCEPTANCE DATE, TURNAROUND TIME, SHIPMENT TRACKING NUMBER, AND

COMMENTS FOR PRODUCTION STATUS. THE REPORT SHOULD BE FURNISHED IN

DELIVERY ORDER SEQUENCE.

ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE

COMMUNICATED TO LPSIB VIA DETAILED E-MAIL OR PHONE CONVERSATION.

DETAILED INFORMATION SHALL INCLUDE, BUT NOT BE LIMITED TO, CAUSE FOR

DELAY/SLIPPAGE (I.E., PARTS CONSTRAINTS, TEST-STAND ISSUES, PERSONNEL

SHORTAGE, ETC.,).

FOR E-MAIL ADDRESS & ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865-

742-3274 OR EMAIL AT SCOTT.ROBINSON.15@US.AF.MIL

AFLCMC/LPSIB 1

DCMA/ACO 1

PCO 1

15. TOTAL 3

G. PREPARED BY H. DATE I. APPROVED BY J. DATE

DD Form 1423-1, JUN 90 Previous editions are obsolete Page 1 of 1 Pages mailto:SCOTT.ROBINSON.15@US.AF.MIL

CONTRACT DATA REQUIREMENTS LIST

CONTRACT DATA REQUIREMENTS LIST:

Form Approved CMB No 07040188:

A Contract Line Item No:

B Exhibit A:

C Category:

F Contractor:

1 Data Item No A001:

3 Subtitle:

4 Authority Data Acquisition Document No DIMGMT80368A:

5 Contract Reference PWS 1121:

8 APP Code NA:

1 Dist Statement Required NA:

10 Frequency Monthly:

12 Date of First Submission See Block 16:

14 Distribution:

11 As of Date See Block 16:

13 Date of Subsequent Submission See Block 16:

b Copies:

Final:

a Addressee16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL:

D r a f16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL:

Reg16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL:

Repro16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL:

D r a fAFLCMCLPSIB:

Repro1:

D r a fDCMAACO:

Repro1_2:

D r a fPCO:

Repro1_3:

PCO16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL:

D r a f16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL_2:

116 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL:

Repro16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL_2:

PCO16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL_2:

D r a f16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL_3:

116 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL_2:

Repro16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST REPORT WILL BE ANNOTATED FINAL REPORT NEGATIVE REPORTS ARE REQUIRED THIS REPORT SHOULD REFLECT THE APPLICABLE COUNTRY CASELINE NUMBER DOCUMENT CONTROL NUMBER PART NUMBER NATIONAL STOCK NUMBER NOMENCLATURE SERIAL NUMBER DELIVERY ORDER NUMBER CLIN ASSET RECEIVED DATE QUANITY PLACED ON ORDER CONTRACTUAL START DATE INDUCTION DATE CONTRACT COMPLETION DATE FORECAST COMPLETION DATE ACCEPTANCE DATE TURNAROUND TIME SHIPMENT TRACKING NUMBER AND COMMENTS FOR PRODUCTION STATUS THE REPORT SHOULD BE FURNISHED IN DELIVERY ORDER SEQUENCE ANY DELAYS OR SLIPPAGE TO FORECAST COMPLETION DATE SHALL BE COMMUNICATED TO LPSIB VIA DETAILED EMAIL OR PHONE CONVERSATION DETAILED INFORMATION SHALL INCLUDE BUT NOT BE LIMITED TO CAUSE FOR DELAYSLIPPAGE IE PARTS CONSTRAINTS TESTSTAND ISSUES PERSONNEL SHORTAGE ETC FOR EMAIL ADDRESS ADDITIONAL PHONE NUMBERS CALL Scott Robinson AT 865 7423274 OR EMAIL AT SCOTTROBINSON15USAFMIL_3:

PCO16 REMARKS BLOCK 4 DID IS TAILORED AS FOLLOWS THE CONTRACTOR SHALL PREPARE AND FURNISH A MONTHLY CUMULATIVE STATUS REPORT FOR ALL ITEMS THAT HAVE BEEN PLACED ON CONTRACT THE REPORT SHALL BE PREPARED AS OF THE LAST WORKING DAY OF EACH MONTH AND FORWARDED BY EMAIL NO LATER THAN THE 5TH WORKING DAY OF THE FOLLOWING MONTH THE INITIAL REPORT WILL BE PREPARED FOR THE MONTH DURING WHICH THE CONTRACT ASSETS ARE RECEIVED REPORTS WILL CONTINUE TO BE FORWARDED UNTIL ALL END ITEMS ARE REPARIED THE LAST…