CDRL A002 Contract Schedule_Service-OWTS Tank Repair_Pre-Delv.pdf
PDF 180 KB Posted
- Attached to
- Service-Oily Water Treatment System (OWTS) Federal contract opportunity
- Solicitation number
- N4523A21Q5731
About this file
This Contract Data Requirements List outlines certification documentation requirements for an Oily Water Treatment System repair contract. The Navy requires the contractor to provide a Gantt chart schedule communicating milestones and critical path items. Certification documentation must include material traceability markings and be submitted via the Wide Area Workflow system, with email notifications sent to the listed Navy office. Distribution of the certification data is restricted to the DoD and contractors for administrative and operational use only.
The related federal contract opportunity is a combined synopsis and solicitation from the Navy seeking services for an Oily Water Treatment System. The solicitation number, agency details, and a brief description are provided, but no further contract details are included in the document.
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| DIST A_EXAMPLE ONLY_Photos Exhibit-Tanks 6_OWTS Tank damage_RELEASED.pdf | ||
| Solicitation_N4523A21Q5731_Service-OWTS Tank Repairs_FINAL.pdf | ||
| Memo and Exhibit A_FAR 52.204-24_N4523A21Q5731_BLANK.pdf | ||
| CDRL A003 STI Insp Report_Service-OWTS Tank Repair.pdf | ||
| Exhibit C_Corporate Experience Data Sheet_N4523A21Q5731_BLANK.pdf | ||
| ATTACHMENT 1_PSNS IMF BREMERTON SITE SPECIFIC REQUIREMENTS_N4523A21Q5731.pdf | ||
| CDRL A004 Final Insp Report_Service-OWTS Tank Repair.pdf | ||
| CDRL A001 QCP_Service-OWTS Tank Repair.pdf | ||
| ATTACHMENT 2_2020 Contrator Guide_N4523A21Q5731_37 pgs.pdf |
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
CONTRACT DATA REQUIREMENTS LIST Form Approved
(1 Data Item) OMB No. 0704-0188
Public reporting burden for this collection of information is estimated to average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding thus burden estimate or any other aspect of this collection o f information, including suggestions for reducing this burden, to Department of Defense, Washington Headquarters Services, Directorate for Information Operations and Reports, 1215 Jefferson Davis Highway, Suite 1204, Arlington, VA 22202-4302, and to the Office of Management and Budget.
Paperwork Reduction Project (0704-0188), Washington, DC 20503. Please DO NOT RETURN your form to either of these addresses.
Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
A. CONTRACT LINE ITEM NO. B. EXHIBIT C. CATEGORY:
TBD A TDP TM OTHER
MISC
D. SYSTEM|ITEM E. CONTRACT/PR NO. F. CONTRACTOR
OWTS # 4 1203-3052 TBD
1. DATA ITEM NO. 2. TITLE OF DATA ITEM 3. SUBTITLE 17. PRICE
GROUP
A002 CERTIFICATION/DATA REPORT
CONTRACT SCHEDULE
4. AUTHORITY (Data Acquisition Document No.) 5. CONTRACT REFERENCE 6. REQUIRING OFFICE 18. ESTIMATED
TOTAL PRICE
DI-MISC-80678 PER CONTRACT PURCHASING ACTIVITY
7. DD 250 REQ 9. DIST STATEMENT
REQUIRED
10. FREQUENCY 12. DATE OF FIRST SUBMISSION 14. DISTRIBUTION
DD ONE/R 10DAC b. COPIES
8. APP CODE D 11. AS OF DATE 13. DATE OF SUBSEQUENT
SUBMISSION
a. ADDRESSEE DRAFT FINAL
N/A N/A ASREQ Reg Repr o
16. REMARKS N4523A 0 4 0
Block 3: The contractor shall provide a Gantt Chart. The Gantt Chart shall communicate all major milestones and critical path items against a realistic schedule.
Block 4: Tailored to allow the vendor to only provide: 10.1, 10.3, 10.3.1-Provide actual values IAW procurement specification. Ensure certs provided are traceable to material/contract via unique markings, 10.4, 10.5.
Block 9: Distribution Statement D. Distribution authorized to DoD and DoD contractors only.
Administration and operations only, effective 8/10/2021. Other U.S. requests shall be referred to COMNAVSEASYSCOM.
Block 12 - Certification/Data Report documentation shall be attached in the Wide Area Workflow (WAWF) e-Business Suite. Upon submission in WAWF send email notifications to:
ddpw_wawf_group.fct@navy.mil.
Document No.: 1203-3052
15. Total 0
G. PREPARED BY H. DATE I. APPROVED BY J. DATE
/s/ Chris Cooper 8/10/2021 /s/ Mike Baker 8/10/2021
DD FORM 1423-1, JUN 90 (EG)
Page 1 of 1 Pages mailto:ddpw_wawf_group.fct@navy.mil
| 10DAC |
| N4523A |
File details come from the government source that posted it. Updated .