C255105_Exhibit_F_Payment_Bond.pdf
PDF 80 KB Posted
- Solicitation number
- 255105
- Issued by
- Orange County, California
About this file
This is a Payment Bond document for Invitation for Bid (IFB) 255105 issued by the Orange County Transportation Authority (OCTA) in California for Roads, Parking Lots, and Signage Improvements at the Naval Weapons Station Seal Beach. The payment bond serves as a financial guarantee that the awarded contractor will pay all workers, subcontractors, and suppliers for labor and materials performed under the contract. The bond is required as a condition of the construction contract and must be executed by both the contractor and a surety company prior to commencement of work. The document references scope of work including slurry seal applications, pavement markings, and roadside sign installations at the specified Naval Weapons Station location.
The payment bond is structured to protect all persons entitled to payment under California Civil Code Section 9100, including laborers, materialmen, and subcontractors. The bond amount is to be specified by the contractor based on the contract value and is subject to California's Public Works Payment Bond requirements outlined in Civil Code Sections 8150-8154 and 9550-9566. The surety assumes liability for unpaid wages, Unemployment Insurance Code obligations, and Employment Development Department withholdings up to the bond amount specified. The bond remains in effect regardless of contract modifications, time extensions, or changes to the work scope, and provides a basis for legal action by claimants to recover unpaid amounts, including reasonable attorney's fees as determined by the court.
View the file
Other files
Show all 11
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
IFB 255105
EXHIBIT F
PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS:
That we, _____________________________________________________________ hereinafter referred to as "Contractor", as principal, and _________________________ as surety, are held and firmly bound unto the Orange County Transportation Authority, State of California, in the sum _____________________________________________ Dollars, ($_____________________), lawful money of the United States of America, for the payment of which sum, well and truly to be made, we bind ourselves, jointly and severally, firmly by these presents.
The Condition of the foregoing obligation is such that, WHEREAS, said Contractor has been awarded and is about to enter into the annexed Agreement with the ORANGE COUNTY TRANSPORTATION AUTHORITY for the IFB
255105, “ROADS, PARKING LOTS, AND SIGNS IMPROVEMENTS AT THE NAVAL
WEAPONS STATION SEAL BEACH” as specified in said Agreement, which is incorporated herein to this bond by reference, and is required under the terms of said Agreement to give this bond in connection with the execution thereof;
NOW, THEREFORE, if said Contractor or a subcontractor fails to pay any of the persons named in Section 9100 of the Civil Code of the State of California, or amounts due under the Unemployment Insurance Code with respect to work or labor performed under the contract, or for any amounts required to be deducted, withheld and paid over to the Employment Development Department from the wages of employees of said Contractor and subcontractors pursuant to Section 13020 of the Unemployment Insurance Code with respect to such work and labor, then said surety will pay for the same, in an amount not exceeding the sum specified in this bond, and also, in case suit is brought upon this bond, a reasonable attorney's fee, to be fixed by the court. This bond shall inure to the benefit of all persons named in Section 9100 of the Civil Code of the State of California so as to give a right of action to such persons or their assigns in any suit brought upon this bond. This bond shall be subject to and include all of the provisions of Title 3 of Part 64 of Division 4 of the Civil Code of California relating to Payment Bond for Public Works, including but not confined to, Civil Code Sections 8150 – 8154, inclusive and Sections 9550 - 9566, inclusive.
PROVIDED, that any changes in the work to be done or the material to be furnished, whether or not made pursuant to the terms of said contract, shall not in any way release either the Contractor or the surety thereunder, nor shall any extensions of time granted under the provisions of said contract release either the Contractor or the surety, and notice of such alterations or extensions of the contract is hereby waived by the surety.
IFB 255105
EXHIBIT F
PAYMENT BOND, PAGE 2
WITNESS our hands this ___________________ day of _______________, 202_.
(SEAL) ________________________________
(Contractor)
By _____________________________
(Title)
Approved: ________________________________ (Surety)
______________________________ By _____________________________
(SEAL)
File details come from the government source that posted it. Updated .