B2 Repair Building Envelope (Facade) DPW SOW.pdf

DEPARTMENT OF THE ARMY

US ARMY INSTALLATION MANAGEMENT COMMAND

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

10 GENERAL GREENE AVENUE

NATICK MA 01760

STATEMENT OF WORK (SOW)

Directorate of Public Works (DPW) Building 2 REPAIR BUILDING ENVELOPE (Façade) Design - Build (D-B) Date: July 2025

1. General:

1.1. All work is to be performed for Building 2 Repair exterior envelope (façade), located at the US Army Natick Soldier Systems Center (NSSC), General Greene Avenue, Natick, MA, 01760.

1.2. The Contractor shall provide all labor, materials and equipment necessary to perform all work, purchase and installation of outlined in this SOW and accompanying documents.

1.3. The Contractor shall be responsible for performing all work as outlined in this Statement of Work (SOW) and all associated contract documents including Project drawings/specifications, June 2020 and accompanying documents, for the bid price submitted. The Contractor is responsible for reading entire SOW and accompanying documents included in this contract for a thorough understanding and comprehension of all content and requirements. The Contractor shall carefully review the field conditions prior to bidding and performing any work. Project is designed to build (D-B). Contractors will provide all specified design for construction.

2. Project Descriptions:

2.1. Project consists of all work required for design, repairs of exterior façade.

2.2. Project is a design/build. The Contractor shall submit design documents at 35%, 65% and 100% phases for review by Government.

2.3. Refer to US Army Corps of Engineers “Repair Exteriors, Building 2, Design-Build Solicitation, July 2020 for project scope.

2.4. Involves removing rust, striping and repainting the wind tunnels exterior. This work includes constructing temporary enclosures, brush‐off blasting and solvent cleaning the exterior surfaces, then it was assumed we are applying a primer and two coats of Sherwin Williams Corothane 1 with Micaceous Aluminum, the same paint we use on our bridge structures.

2.5. Involves replacing the main entrance doors & storefront, exterior doors, roof access stairs, exterior lights, new pipe bollards, concrete stairs & ramps to side entrances, and replacing the entire existing EFIS system with a 2” insulated metal panel system.

2.6. NOTE: DISREGARD ALL REFERENCES TO ANY AND ALL ROOF WORK IN “Repair Exteriors, Building 2, Design-Build Solicitation, July 2020. THE REPAIR OF ROOF WORK IS NOT PART OF THIS

PROJECT AND IS CURRENTLY BEING EXECUTED.

3. Period of Performance:

3.1. The period of performance for all work shall be 270 (two-hundred and seventy) days from the date the Notice to Proceed (NTP) is issued.

3.2. Failure to complete the project by the stated completion date, when delay is not attributable to the Government will lead to a negative performance evaluation.

4. Hours of Operation (for all work performed on the installation):

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

4.1. The site for all work is on a military installation known as the US Army Soldier Systems Center, in Natick, Massachusetts, hereinafter called NSSC. All rules and regulations issued by the Commanding Officer covering general safety, security, sanitary requirements, pollution control and traffic regulations shall be observed by the Contractor.

Information regarding these requirements may be obtained by contacting the Contracting Officer (KO), who will provide such information or assist in obtaining same from appropriate authorities.

4.2. The Contractor may submit a written request for Government approval to work on weekends and holidays.

The request shall be submitted a minimum of ten (10) days in advance, and if approved, it shall be authorized in writing. The Government reserves the right to deny such requests. It is anticipated that work on weekday and weekends during the off hours will be required to complete work within the Period of Performance. The following legal holidays are observed:

January 1st Third Monday in January Third Monday in February Last Monday of May July 4th 1st Monday of September 2nd Monday of October 11th of November Fourth Thursday of November 25th of December

When one of the above designated legal holidays falls on a Sunday, the following Monday will be observed as a legal holiday. When a legal holiday falls on a Saturday, the preceding Friday is observed as a holiday.

4.3. All work shall be performed during normal business hours, Monday through Friday, from 7:00 am to 5:00 pm unless otherwise authorized and coordinated in advance by the Contracting Officer Representative (COR). The COR shall be notified of a minimum of five (5) working days in advance of all work requested to be performed outside of normal business hours.

4.4. Interior Work - After business hours are as follows: 5:00 pm to 7:00 am on weekdays (Monday-Friday) and 7:00 am to 6:00 pm on weekends (Saturday & Sunday).

4.5. Exterior Work - After business hours are as follows: 5:00 pm to 7:00 pm on weekdays (Monday–Friday) and 7:00 am to 7:00 pm on weekends (Saturday & Sunday).

5. Antiterrorism/Operations Security Requirements:

5.1. AT Level 1 Training (OPSEC Cover Sheet, Part 1): All Contractor employees, to include subcontractor employees, requiring access Army installations, facilities and controlled access areas shall complete AT Level I awareness training within thirty (30) calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. The Contractor shall submit certificates of completion for each affected Contractor employee and Subcontractor employee, to the COR or to the contracting officer, if a COR is not assigned, within five (5) calendar days after completion of training by all employees and subcontractor personnel. AT level I awareness training is available at the following website: http://jko.jten.mil.

5.2. Access and general protection/security policy and procedure (OPSEC Cover Sheet, Part 2): The Contractor and all associated Subcontractors’ employees shall provide all information required for background checks to meet installation access requirement to be accomplished by installation Director of Operations, Protection or Security Manager. The Contractor workforce shall comply with all personal identity verification requirements as directed by http://jko.jten.mil/

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

Department of Defense (DOD), Head Quarters Department of the Army (HQDA) and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in Contractor security matters or processes.

NOTE:

“In accordance with ANNEX M (MISSION ESSENTIAL FUNCTIONS (MEF)) to USAG-Natick CONTINUITY OF OPERATION PLAN (COOP), this project IS NOT designated a MEF.”

5.2a. For contractors requiring Common Access Card (CAC). Before CAC issuance, the contractor employee requires, at a minimum, a favorably adjudicated National Agency Check with Inquiries (NACI) or an equivalent or higher investigation in accordance with Army Directive 2014-05. The contractor employee will be issued a CAC only if duties involve one of the following: (1) Both physical access to a DOD facility and access, via logon, to DOD networks on-site or remotely; (2) Remote access, via logon, to a DOD network using DOD-approved remote access procedures; or (3) Physical access to multiple DOD facilities or multiple non-DOD federally controlled facilities on behalf of the DOD on a recurring basis for a period of 6 months or more. At the discretion of the sponsoring activity, an initial CAC may be issued based on a favorable review of the FBI fingerprint check and a successfully scheduled NACI at the Office of Personnel Management.

5.2b. For contractors that do not require CAC but require access to a DOD facility or installation. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

5.3. Awareness Training for Contractor Personnel Traveling Overseas. Does not apply to USAG-Natick contracts.

5.4. iWATCH Training. This standard language is for contractor employees with an area of performance within an Army controlled installation, facility or area. The contractor and all associated sub-contractors shall brief all employees on the local iWATCH program (training standards provided by the requiring activity ATO). This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. This training shall be completed within 30 calendar days of contract award and within 05 calendar days of new employees commencing performance with the results reported to the COR NLT 30 calendar days after contract award.

5.5. Army Training Certification Tracking System (ATCTS) registration for contractor employees who require access to government information systems. All contractor employees with access to a government information system must be registered in the ATCTS (Army Training Certification Tracking System) at commencement of services and must successfully complete the DOD Information Assurance Awareness prior to access to the IS and then annually thereafter.

5.6. For contracts that require a formal OPSEC program. The contractor shall develop an OPSEC Standing Operating Procedure (SOP)/Plan within 90 calendar days of contract award, to be reviewed and approved by the Government OPSEC officer responsible. This plan will include a process to identify critical information, where it is located, who is responsible for it, how to protect it and why it needs to be protected. The contractor shall implement OPSEC measures as ordered by the commander. In addition, the contractor shall have an identified certified Level II OPSEC coordinator per AR 530-1.

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

5.7. For contracts that require OPSEC Training. Per AR 530-1 Operations Security, the contractor employees must complete Level I OPSEC Awareness training. New employees must be trained within 30 calendar days of their reporting for duty and annually thereafter. OPSEC Awareness for Military Members, DOD Employees and Contractors is available at the following website: http://cdsetrain.dtic.mil/opsec/index.htm

5.8. For Cyber Awareness (Information assurance (IA)/information technology (IT)) training. All contractor employees and associated sub-contractor employees must complete the DOD Cyber awareness training before issuance of network access and annually thereafter. All contractor employees working IA/IT functions must comply with DOD and Army training requirements in DODD 8570.01, DOD 8570.01-M and AR 25-2 within six months of appointment to IA/IT functions. DOD Cyber Awareness Challenge Training is available at the following website:

https://ia.signal.army.mil/DODIAA/

5.9. For Cyber (Information assurance (IA)/information technology (IT)) certification. Per DOD 8570.01-M , DFARS 252.239.7001 and AR 25-2, the contractor employees supporting Cyber (IA/IT) functions shall be appropriately certified upon contract award. The baseline certification as stipulated in DOD 8570.01-M must be completed upon contract award.

5.10. For contractors authorized to accompany the force. Does not apply to contracts at USAG-Natick.

5.11. For Contract Requiring Performance or Delivery in a Foreign Country, DFARS Clause 252.225-7043, Antiterrorism/Force Protection for Defense Contractors Outside the US. Does not apply to contracts at USAG- Natick.

5.12. For contracts that require handling or access to classified information. The contractor shall comply with FAR 52.204-2, Security Requirements. This clause involves access to information classified “Confidential,” “Secret,” or “Top Secret” and requires contractors to comply with— (1) The Security Agreement (DD Form 441), including the National Industrial Security Program Operating Manual (DOD 5220.22-M); (2) any revisions to DOD 5220.22-M, notice of which has been furnished to the contractor.

5.13. Threat Awareness Reporting Program. For all contractors with security clearances. Per AR 381-12 Threat Awareness and Reporting Program (TARP), contractor employees must receive annual TARP training by a CI agent or other trainer as specified in 2-4b of AR 381-12.

5.14. For contracts that require delivery of food and water. This standard language is for contractor employees with an area of performance delivering food and water within an Army-controlled installation, facility or area. The supplies delivered under this contract shall be transported in delivery conveyances maintained to prevent tampering with and / or adulteration or contamination of the supplies, and if applicable, equipped to maintain a prescribed temperature.

All delivery vehicles will also be subject to inspection at all times and all places by the Contracting Officers Representative, Post Veterinarian, and / or Law enforcement Officials. When the sanitary conditions of the delivery conveyance have led, or may lead to product contamination, adulteration, constitute a health hazard, the delivery conveyance is not equipped to maintain prescribed temperatures or the transport results in product "unfit for intended purpose", supplies tendered for acceptance may be rejected without further inspection. As the holder of a contact with the Department of Defense, it is incumbent upon the awardee to insure that all products and/or packaging have not been tampered or contaminated. Delivery conveyances will be locked or sealed at all times, except when actively loading or unloading. Unsecured vehicles will not be left unattended. All incoming truck drivers will provide adequate identification upon request. In the event of an identified threat to an installation, or a heightened force protection/Homeland Security threat Level, the contractor may be required to adjust delivery routes to minimize vulnerability risks and enable direct delivery to DOD facilities.

http://cdsetrain.dtic.mil/opsec/index.htm https://ia.signal.army.mil/DoDIAA/

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

6. Protection Division, Directorate of Operations:

6.1. The Contractor shall submit employee’s names and information on NSSC Contractor Access Request Form (See Attachment #2) for background investigation for all employees and subcontractors that will be entering Army-controlled installations or facilities, a minimum of seven (7) business days prior to arrival via email to COR and Protection Division.

The company shall ensure that its employees entering Army-controlled installations or facilities have obtained access badges and passes in accordance with facility regulations and that these badges and passes are obtained in advance so as not to delay the accomplishment of contracted services. It is also required that the contracting company owner, project manager, site supervisor and safety officer also acquire a personal badge for installation entry as they are expected to be on site managing the work on a frequent, if not continuous, basis throughout the performance period of the project. All Contractor personnel that have a Permanent Resident Card or Alien Registration Receipt Card (Form I-551) a.k.a. “Green Card”, shall possess them when entering the installation.

Immediately report instances of lost or stolen badges to the Contracting Officer. Badges shall be worn and be visible at all times while on the Installation. The Contractor shall be responsible for returning all Identification Badges to the Contracting Officer after completion of the project. Final payment will not be made until all badges are returned and have been accounted for.

6.2. During Force Protection Conditions (FPCONs) CHARLIE and DELTA, contracted services may be limited or discontinued. Contracted services will resume when the FPCON level is reduced to level BRAVO or lower.

6.3. The Contractor shall be responsible for maintaining a secure construction site and ensure NSSC installation perimeter confined to the area of the scope of this contract is always secure during and after work hours. Areas of staging, material storage and equipment shall be reviewed with the KO for approval at the pre-construction meeting. Fencing may be provided or required for these areas and to secure the construction site.

6.4. At the close of each workday, Government facilities, equipment, and materials shall be secured.

6.5. The Contractor shall be responsible for all arrangements for the receipt of materials and supplies at the job site.

Government personnel are not permitted to receive or sign for items delivered to the site. All Contractor deliveries shall be coordinated by the Contractor to arrive directly to the job site. The delivery driver shall be provided with address and exact location on post to deliver to, name of the Contractor’s supervisor and/or the name of the Contractor employee who will receive and sign for the delivery item(s). Off-loading and labor and equipment for such is the responsibility of the Contractor. All deliveries shall be coordinated in advance with NSSC Police.

6.6. The Contractor and all associated Sub-contractors’ employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). Increased Security upon Entry into NSSC: Since the events of 11 September 2001, security at the U.S.

Army Natick Soldier Systems Center has increased making entry into the installation more time consuming at certain times and under certain circumstances. The Contractor is responsible for familiarizing himself/herself with the entry procedures at designated Contractor entry gate and expected delays, and for including all costs for same in their base contract bid price. No future request for adjustment in neither price nor time will be allowed due to Contractor entry conditions and circumstances.

7. Contractor Personnel Conduct:

7.1. The Contractor personnel’s conduct shall not reflect discredit upon the Government. Contractors shall ensure that personnel present a professional appearance. The Contractor’s employees shall observe and comply with all local policies and procedures concerning fire, safety, environmental protection, sanitation, security, and possession of firearms or other lethal or illegal weapons or substance. The Contractor is responsible for ensuring that any Contractor employees providing services under this contract conduct themselves and perform services in a professional, safe, and responsible

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

manner. The Contractor shall remove from the job site any employee for reasons of misconduct or security. The Contractor shall ensure no Contractor’s employees conduct political related activities or events at NSSC.

7.2. Smoking is prohibited within and outside of all buildings on installations under the ownership of NSSC except in designated smoking areas. This includes, but is not limited to, existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

8. Submittals:

8.1. In accordance with the submittal checklist as listed in this SOW and accompanying documents, the Contractor shall submit for approval to the Contracting Officer Representative (COR), a minimum of ten (10) calendar days prior to purchasing and installing submittal items, all material samples/swatches and/or manufacturer specifications/cut sheets to include but not limited to: Walk-in cooler, fire protection systems for smoke heat and fire alarms and complete building sprinkler system designs; storm water report; millwork, related hardware, bar appliance/equipment, sink and faucet;

interior railing at ramp; controls and fixtures for all systems (fire protection, electrical, HVAC; windows, doors, frames and related hardware and exterior concrete lintel; finishes for paint colors, carpet, continuous roll vinyl base; ceiling tile and grid, hardware, etc., proposed electrical conduits, raceways, wiring, circuit breakers, light fixtures and emergency lights. All material finishes / colors for above as applicable shall be submitted. If the Option to Base bid is awarded, the Contractor shall also include deck (non-structural materials), decking, top and bottom rails and balusters.

8.2. All required submittals, cut sheets, construction details, etc. shall be submitted to the COR. Each submittal shall be complete and in sufficient detail to allow ready determination of compliance with contract requirements. Prior to submittal, all items shall be checked and approved by the Contractor and each item shall be stamped, signed, and dated by the Contractor indicating action taken. Proposed deviations from the contract requirements shall be clearly identified.

8.3. The Contractor shall submit to the COR a list of all hazardous materials and their associated Safety Data Sheet (SDS) sheets and statement of plans for storage and use. No hazardous materials shall be stored or used at NSSC prior to submission of the material’s SDS and approval by NSSC Environmental office of the Contractor’s plans for storage and use of the hazardous materials. The COR shall submit this information to the Environmental office and notify the Contractor of the resulting approval or rejection within ten (10) business days.

8.4. Submittals for any required information shall require up to ten (10) business days for review.

8.5. The COR’s approval of submittals shall not be construed as a complete check but will indicate only that the general method of construction, materials, detailing and other information are satisfactory. Approval will not relieve the Contractor of the responsibility for any error which may exist.

8.6. The Contractor shall make all corrections required by the COR and promptly furnish a corrected submittal. If the Contractor considers any correction indicated on the submittals to constitute a change to the contract, a notice in accordance with the Contract FAR Clause 52.243-4 “Changes” shall be given promptly to the COR.

8.7. The Government has the right to reject any submittals not meeting the requirements and standards set forth in the SOW and accompanying contract documents. All rejected submittals shall require a re-submittal prior to the performance of any associated work commencing, to include but not limited to demolition and construction phases of work.

8.8. Within ten (10) calendar days of the preconstruction meeting the Contractor shall submit a construction schedule in Gantt Chart form to the COR, outlining the duration, start and completion dates for all major disciplines and milestones for both demolition and construction phases.

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

8.9. Scheduling of work is of critical importance for impacts to the building occupants due to noise and building access. The schedule shall be updated weekly as required to reflect actual progress. Due to the nature of the work, it is understood that weather can impact progress and schedule updates help plan and modify closure activity and notification to the staff. Schedule updates may be modified by written approval by the Contracting Officer (KO) and COR.

8.10. The Contractor shall keep a daily log of all major on-site construction activity and provide to the COR at close of each business day.

8.11. The Contractor shall schedule a meeting and meet with the COR on a weekly basis throughout the performance period to review and report current status and schedule of the job’s progress as well as coordinate between various tasks of the project and the impacts upon NSSC such as physical security, other occupants on post, etc.

9. Inspections and Testing:

9.1. The KO, COR and NSSC Department of Public works (DPW) designated personnel shall be provided the opportunity to inspect all aspects of the work during the entire course of the performance period. Scheduled inspections shall take place at intervals as agreed upon in the preconstruction meeting and throughout period of performance and as noted in List of Required DPW Inspections, if provided, and entered into the Gantt Chart construction schedule. The Contractor shall coordinate Government inspections, to occur during normal business hours, with the COR five (5) business days in advance. The Contractor shall remove material as required to complete inspections if proper notification for scheduled inspection is not given. The COR will determine if the specifications and requirements of the contract documents have been met. The Contractor shall perform all necessary work to correct any deficiencies identified by the COR to ensure compliance with all contract documents during the performance period.

9.2. When all work has been completed by the Contractor and checked by the COR, the Contractor shall provide the COR with the opportunity to witness the final, actual operation and testing of systems and equipment. Before final acceptance, any deficiencies discovered during testing shall be promptly corrected by the Contractor and readjusted until the systems are functioning properly.

10. Health and Safety Plan:

10.1. The Contractor shall submit to the COR a minimum of fourteen (14) calendar days prior to any on-site work being performed, a health and safety plan for Contractor personnel, including at a minimum, personal protective clothing and equipment such as but not limited to, safety goggles, dust masks, hard hats, protective barriers, signage, caution tapes, dust barriers, etc. The Health and Safety plan submittals shall be approved before any affected-on site work can be performed.

10.2. The Contractor shall ensure that all activity hazards are identified in the health and safety plan for every applicable and unique demolition and construction activity, including but not limited to the following examples:

connecting/ disconnecting power supply; welding and torch cutting (Hot Work); drilling into concrete, etc.

10.3. The Contractor shall take all necessary precautions in observing safety regulations in accordance with Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS which can be found at:

https://www.wbdg.org/ffc/dod/unified-facilities-guide-specifications-ufgs and EM 385-1-1 and shall assume the responsibility to guard against fires and/or explosions and to protect Government property. The Contractor shall perform the work in a manner consistent with security requirements and fire safety regulations especially with regard to exits and exit way access during construction. Temporary closures shall not compromise life safety, security or fire safety. For a copy of EM 385-1-1, visit the following website: https://www.usace.army.mil/.

https://www.usace.army.mil/

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

10.4. Workers in elevated work areas in excess of six (6) feet above an adjoining surface require special safety attention. In addition to the provisions of EM 385-1-1, the following safety measures are required to be submitted to the Contracting Officer. Prior to commencement of work in elevated work areas, the Contractor shall submit drawings depicting all provisions of his positive protection system including, but not limited to, all details of guard rails.

10.5. Positive protection for workmen engaged in work that is at a height of six (6) feet or greater shall be provided by safety nets, tie-offs, hydraulic man lifts, scaffolds, or other required means. Decking crews shall be tied off or work over nets or platforms not over six (6) feet below the work area. Walking on beams and/or girders and the climbing of columns is prohibited without positive protection.

10.6. Perimeter guard rails shall be installed at floor, roof, or wall openings more than six (6) feet above an adjoining surface and on roof perimeters. Rails shall be designed to protect all phases of elevated work. Rails shall be designed by a licensed engineer to provide adequate stability under any anticipated impact loading. As a minimum, the rails shall consist of a top rail at a height of forty-two (42) inches, a mid-rail and a toe board. Use of tie-offs, hydraulic man lifts, scaffolds, or other means of roof edge protection methods may be utilized on small structures such as family housing, prefabricated metal buildings, etc.

10.7. The Contractor shall develop and implement an activity/site-specific Confined Space (CS) Program as necessary when the work to be performed requires compliance with the elements of 29 CFR 1910.146 and/or the recommendations of installation Safety and Health professionals. It is the responsibility of the site supervisor or project manager to ensure all entries into a CS are completed in a safe and protective manner. The procedures shall be documented in a CS program which is part of the Project Safety and Health Plan.

10.8. The Contractor is alerted to the requirements of Contract FAR Clause 52.236-12 "CLEANING UP" and to the requirements of UFC 3-600-01, EM 385-1-1, and NFPA 241 for fire protection during building construction and demolition operations. This item shall be covered in the submittal required under Contract FAR Clause 52.236-13 Atl I "ACCIDENT PREVENTION". Provide and maintain extinguishers in construction areas and temporary storage areas in accordance with EM 385-1-1 and NFPA 10. This standard is available from www.NFPA.org.

10.9. Store, dispense and use liquids in accordance with EM 385-1-1.

10.10. Means of egress: Maintain free and unobstructed access to facility emergency services and for fire, police and other emergency response forces to the site and building. Do not block exits for occupied buildings, including paths from exits to roads. Minimize disruptions and coordinate with the Contracting Officer. Inspect access points daily. Report the findings of obstructions and corrective actions weekly to the Contracting Officer.

10.11. Construction Fire and Safety: The Contractor shall follow NFPA 241, Safeguarding Construction, Alteration, and Demolition Operations, during the course of the work. Trash chutes shall follow these requirements for proximity to the building as noted. The Contractor shall also comply with NFPA 1 (2015), section 19.2.1.4 which states that dumpsters over one and a half (1.5) cubic yards shall not be placed within ten (10) feet of combustible walls, openings, or combustible roof eave lines. Comments provided by the Fire Inspector during laydown submission by the Contractor shall also be followed. The Contractor shall leave fire alarm pull stations in place whenever possible to alert the fire and law enforcement personnel to a fire while the building is occupied during construction. Efforts should be made to protect all fire alarm devices from physical damage and accidental activation whenever possible. Temporary heat detectors may be used to provide detection nights and weekends when the building is unoccupied by Contractors.

10.12. All construction sites are subject to fire and safety inspections without notice. Any violation of fire and safety standards may result in a work stoppage at the expense of the Contractor.

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

10.13. Throughout the course of this project, caution tape and safety warning signs shall clearly mark all construction areas where the potential exists for personnel not involved with the construction to enter or pass. When it is necessary for non-construction personnel to pass through a construction area, flag persons shall be posted at all key points to ensure the safety of the non-construction personnel, particularly during construction operations that pose a potential threat to safety.

10.14. The Contractor shall maintain a safe, orderly and reasonably clean work environment throughout the performance period and is subject to unannounced OSHA and NSSC inspections.

10.15. The Contractor shall be responsible for contacting and coordinating with DIGSAFE (call 811 or 888-DIG-SAFE) prior to any excavation work according to regulations: “220 CMR 99.00: Massachusetts Department of Public Works” and “The Dig Safe Law in Massachusetts G.L. C. 82, & 40, 40A through 40E.” Also, the Contractor shall use Ground Penetrating Radar (GPR) to confirm locations of all underground utilities prior to any excavation. The Contractor shall perform hand digging when the exact location of underground utilities is not known.

10.16. Use of Trench Boxes and/or sheeting and/or ground sloping in excavation pits shall be in accordance with OSHA.

Safety Office to approve prior to excavation.

10.17. Fire protection systems (Sprinklers, Alarms, Controls, etc.) should be maintained in service unless coordinated and approved by the COR and Installation Fire Protection Inspector and identified in the Health and Safety Plan if service is to be temporarily interrupted.

10.17.1. The Contractor shall notify Director of Emergency Services, Fire Protection Section, current contact - James Santoro (508) 206-4031 (office), email – james.g.santoro.civ@army.mil 48 hours prior to any Fire Protection Systems work. No work shall begin until the Fire Protection Inspector’s approval.

10.17.2. All work associated with the Fire Alarms and Fire Protection shall be a part of the work. Work required by Simplex for fire alarm controls shall be engaged and paid for by the Contractor.

10.17.3. The fire alarm/mass notification system throughout the installation consists of addressable and interconnected Johnson Controls Simplex panels.

10.17.4. Only qualified personnel, as defined in NFPA 72, may perform work on the fire alarm/mass warning notification systems and its components.

10.17.5. Whenever work is to be conducted in a building that affects any fire alarm system and/or its components, such as disconnecting, moving, relocating, adding or subtracting devices, and/or rewiring of any fire alarm system devices, the contractor responsible for the project must contract, at the contractor’s expense, with Johnson Controls too:

(1) Examine said panels for any existing trouble or faults prior to the start of any work affecting the fire alarm control panel(s). Disable all devices and/or zones which will be affected by the work

(2) Verify all wiring and devices are properly connected to the fire alarm panel(s) and conduct panel programming to all panels affected by the project once entire project is completed.

(3) Conduct final acceptance testing of the systems per NFPA 72 requirements once the project is completed and provide written documentation of the testing to the COR and fire protection inspector.

(4) Reprogram three fire alarm system monitoring panels including two head-end panels located in Building 1 Department of Emergency Services control room, and one located in Building 39.

The Fire Protection Inspector must be notified prior to all examinations and work on fire alarm control panels.

10.18. Hot Work:

mailto:james.g.santoro.civ@army.mil

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

10.18.1. It is the responsibility of the Contractor, without exception, to obtain a permit for all “Hot Work”, which includes but is not limited to, torch cutting, welding, laser cutting, metal grinding, soldering, etc.

10.18.2. Those performing the hot work shall have completed the NFPA, “Hot Works Safety Certificate 1-Day Program” or “Gould Construction Institute Hot Works Training”. Permits shall be obtained prior to any “Hot Work” being performed.

10.18.3. Permits can easily be obtained by contacting the Directorate of Operations Fire Protection Inspector, John Mauro

(508) 233-4325, email: john.d.mauro.civ@mail.mil.

11. Environmental Considerations

11.1. Waste Reduction: Contractor shall abide by NSSC’s commitment to reduce natural resource consumption and solid waste generation through resource recovery, re-use, and recycling. Integrate source reduction into all activities, to include minimizing all packing and packaging materials for items being shipped to NSSC.

11.2. Collection and Disposal of Construction and Demolition (C&D) Waste Streams:

11.2.1. C & D waste consists of all non-hazardous waste streams generated during construction, renovation, maintenance, repairs, and demolition projects. Waste streams include but are not limited to the following materials:

lumber, reinforcing steel and other metals, piping and wiring, concrete, brick, plaster, wall board, roofing material, insulation, plumbing fixtures, doors, windows, and asphalt. Of these materials, asphalt pavement, brick, concrete, wood, metal, glass, and clean gypsum wallboard are subject to the Massachusetts waste ban (310 CMR 19.017) and shall be segregated for recycling, reuse, or disposal in accordance with 310 CMR 19.017, no exceptions.

11.2.2. Unless otherwise specified herein, the Contractor shall provide a C&D Waste Management Plan when a roll-off or dumpster is brought onto NSSC. The waste management plan shall include a characterization of waste to be generated (types and quantities and plans for maximizing the diversion of waste through recycling and re-use).

11.2.3. The Contractor shall achieve a minimum performance requirement of sixty (60) percent diversion for all C&D waste, by weight, from landfill disposal. It is the Contractor’s responsibility to arrange collection and delivery of all C&D waste materials to the appropriate recycling center or transfer station that accepts C&D waste for the purpose of recycling.

11.2.4. A LEED Report and weight tickets for all materials salvaged, recycled, or disposed during the performance of the contact shall be provided to the COR and USAG Natick DPW-Environmental Office (Richard Valcourt, richard.a.valcourt2.civ@mail.mil, 508-233-5582).

11.2.5. NSSC security office has ultimate jurisdiction on all dumpsters (to include roll-off containers). The location and removal timeframe of all dumpsters requires approval from the government and shall be coordinated with the COR at the pre-construction meeting or a minimum of five (5) business days in advance of use of any dumpster. Dumpster locations shall also be coordinated with NSSC Department of Public Works (DPW), Roads and Grounds division, for protection of the landscape and sprinklers and to negate any impact to snow plowing. Dumpsters shall be a minimum of eighty (80’- 0”) from all occupied buildings. The COR shall be responsible for coordinating dumpster locations with DPW, Command Group and Security Police.

11.2.6. The Government reserves the right to retain possession of any items designated to be removed and disposed of by the Contractor.

mailto:richard.a.valcourt2.civ@mail.mil

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

11.2.7. All waste streams generated from any work related to this project shall be the responsibility of the Contractor to separate on site and properly dispose in accordance with the NSSC “Integrated Solid Waste Management Plan” (See Attachment 4).

11.2.8. The Contractor dumpster shall be emptied the same day it is filled to the top. The Contractor dumpster shall not have any loose debris that can be blown out by windy conditions or being moved.

11.2.9. Dumpsters shall be clearly marked with a sign showing the name of Contractor, project building and room number(s) and state "FOR CONTRACTOR USE ONLY".

11.2.10. Under no circumstances shall government dumpsters be used for disposal of any solid waste or construction and demolition waste during the contract performance period.

11.2.11. The Contractor shall actively control use of their dumpsters and shall insure that only materials from this contract get placed into the dumpsters assigned to this project.

11.3. Collection and Disposal of Scrap Metals:

11.3.1. Unless otherwise specified herein, the Contractor shall segregate, collect, and transport all ferrous and non-ferrous metals generated in the performance of work to the designated NSSC metal collection container (e.g., 30/40 yd3 open top roll-off container) located behind Building #20.

11.3.2. The Contractor shall not at any time overload the scrap metal roll-off container or place objects into the container that protrude above container walls. If the scrap metal roll-off container is at or near capacity the Contractor shall immediately contact the COR and the Logistics Readiness Center (LRC) Container Control Officer for an alternate disposal location.

11.4. Collection and Disposal of Organic/Compostable Materials:

11.4.1. The term organic/compostable material includes tree stumps, tree branches, grass clippings, leaves, and other vegetative matter resulting from land clearing or landscaping activities.

11.4.2. All Contractors shall achieve a performance requirement of one hundred (100) percent diversion for all organic/compostable material from landfill disposal. It is the Contractor’s responsibility to arrange collection and delivery of all materials to the appropriate recycling center or transfer station that accepts organic/compostable materials for the re-purposing or reuse.

11.4.3. Contractors shall provide weight tickets (from a certified truck scale or the NSSC truck scale, located adjacent to Building 20 (west side) for all materials generated during the performance of the contact to the COR and the USAG Natick DPW-Environmental Health Office (Richard Valcourt, richard.a.valcourt2.civ@mail.mil, 508-233-5582).

11.5. Storage of Hazardous Materials

11.5.1. The storage of hazardous materials shall conform to applicable fire and safety regulations and is subject to inspection of Government personnel. Storage procedures at the work site shall meet all applicable environmental regulations and standards.

11.5.2. The Contractor shall maintain current Safety Data Sheets (SDS) for any of the following materials used in the performance of his work. Hazardous materials shall not be stored on the ground or open floor drain without adequate secondary containment and shall be stored according to their compatibility.

mailto:richard.a.valcourt2.civ@mail.mil

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

11.5.3. All flammable material shall be stored in only approved flammable storage containers. Storage containers shall be provided at the expense of the Contractor.

11.5.4. Hazardous materials shall be limited in storage to the amount necessary to complete the contract requirements.

11.6. Environmental Contaminate Discoveries

11.6.1. The Contractor is responsible for contacting the COR and Contracting Officer whenever any questions arise concerning materials that may be contaminated (i.e. soils, metals, insulation, building materials etc.). Work shall be stopped until an agent from the NSSC - Environmental Health Office (EHO) is notified. The EHO will be responsible for performing all testing, storage and handling of suspected or confirmed contaminated material. The Contractor shall be responsible for all costs associated to contamination clean up.

11.7. Hazardous Material Spills or Releases

11.7.1. Oil and or Hazardous Material Release Response: In case of any release of oil and/or hazardous materials (OHM) (including leaks from hydraulic hoses or equipment) at NSSC Contractor shall immediately report the release to the NSSC Directorate of Operations (DO) at (508)-233-5911 and to the NSSC Environmental Health Office (EHO) at (508)-233- 5393. Reporting a release to DO or to EHO shall not relieve the Contractor of any other applicable reporting requirements including State and Federal laws governing reporting to USEPA or Massachusetts DEP).

11.7.2. The Contractor should be aware that there are monitoring wells for a Superfund site in various locations on NSSC. The Contractor shall not disturb these wells and shall take extra precautions when working in the vicinity of these wells.

11.7.3. Any release to the environment of Oil and Hazardous Materials (including leaks from hydraulic hoses or equipment) as a result of Contractors work shall be the sole financial liability of the Contractor and shall be cleaned up by the Contractor at no additional cost to the Army. Should a cleanup be required, the Contractor shall conduct the cleanup in accordance with all applicable state and/or federal regulations, including but not necessarily limited to the Massachusetts Contingency Plan (310 CMR40.0000) and/or the National Oil and Hazardous Substances Pollution Contingency Plan (40 CFR 300) or other applicable regulations. Any cleanup of oil and/or hazardous materials conducted on the installation shall be supervised by the Contractor as well as by staff of the EHO. It shall be the responsibility of the EHO to determine whether spill reporting requirements have been met and when spill cleanup is being conducted in accordance with applicable regulations, and to report this to the KO.

11.7.4. EHO staff may determine that a release of OHM has triggered a reporting threshold and may elect to report the release on behalf of the Contractor to the applicable regulatory agency in order to meet mandatory reporting time requirements. Should the EHO determine that reporting by the Army on behalf of the Contractor is required, the fact that the Army has reported the release shall not in any way relieve the Contractor of their financial liability to complete the cleanup at no additional expense to the Army. The Contractor’s financial liability for completing a cleanup shall include retaining cleanup subcontractors with appropriate professional licenses and preparation and submittal of all required reports to complete waste site cleanup closure as specified in applicable regulations.

11.7.5. The Contractor shall immediately contact the EHO, when required by law, to contact the Federal, Local Environmental Agency or Occupational, Safety and Health agencies for any reason related to compliance requirements arising out of performance of this contract. In the event of any agency contacts the Contractor for any reason relating to compliance requirements arising out of this contract, the Contractor shall immediately contact the EHO and the Contracting Officer no later than the close of business on the day the contract is made. If such communication is made after regular business hours, notification shall be made immediately on the next day of business. The Contractor shall

DoD Admin Spell out

US ARMY GARRISON DPW

NATICK SOLDIERS SYSTEMS CENTER

also provide the name, telephone number of the agency, name of the person making the contact and the substance of any verbal or written communication from such agency.

11.8. Fluorescent Lamps and Ballast

11.8.1. All fluorescent lamps and ballast shall be recycled under the streamlined provisions of the Universal Waste Rule.

Before shipping, lamps and ballasts shall be placed in protective packaging and a reputable transporter or carrier shall be contracted to transport lamps components to a receiving facility. NSSC Environmental Health Office shall sign manifest or bill of laden before waste leaves the installation.

11.8.2. All electronic ballast can be recycled as scrap metal, non-PCB oil filled ballast shall be managed and disposed of following the provisions of Universal Waste Rule, and PCB oil filled ballasts shall be managed and disposed of as a Hazardous Waste in accordance with 40 CFR 761.62 (a).

11.9. Asbestos Abatement:

11.9.1. All asbestos abatement shall be performed by an asbestos abatement Contractor licensed by the Commonwealth of Massachusetts in strict accordance with all EPA, OSHA, Local, State and Federal regulations.

11.9.2. The Contractor shall notify all necessary Local, State and Federal agencies before start of work.

11.9.3. A detailed asbestos abatement plan of work procedures for the demolition and removal of all materials containing asbestos shall be submitted before work can begin. The plan shall be prepared and signed, including certification number and date, by a certified industrial hygienist. This plan shall be approved by the COR or assigned representative appointed by the COR, prior to the start of any work. The approved plan shall be strictly followed.

11.9.4. Air monitoring is required before, during and after abatement. A monitoring and air clearance plan shall be prepared and signed by a certified industrial hygienist. This clearance plan shall include a certification number and date.

This plan shall be approved by the COR or assigned representative appointed by the COR, prior to the start of any work.

11.9.5. Decontamination of the space and monitoring for final air clearance is required before the space can be occupied by anyone other than licensed asbestos abatement Contractors.

11.9.6. The area shall be sealed tight in accordance with the requirements and all penetrations shall be filled with fire stopping or other appropriate material in advance of the work to prevent migration to adjacent floors.

11.9.7. Upon completion of work specified, pertinent documentation shall be forwarded to COR. This documentation includes: a Disposal Manifest, asbestos abatement notification and analytical results of air samples conducted during and following abatement.

11.10. Green Procurement:

11.10.1. All supplies and materials shall be of a type and quality that conform to applicable Federal specifications and standards and, to the extent feasible and reasonable, include the use of green products.