B08_Attachment_1_Specifications_Package_A.pdf

ACADIA NATIONAL PARK

Hancock County, Maine

PAVEMENT IMPROVEMENTS

PACKAGE A

ACAD PMIS NO. 221640, 192321, 222085, 310998

PROJECT SPECIFICATIONS

NATIONAL PARK SERVICE

ACADIA NATIONAL PARK

August 13, 2021

ACAD – 221640, 192321, 222085, 310998 TOC-1

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 26 01 Contract Modification Procedures 01 27 00 Definition of Contract Line Items 01 31 00 Project Management & Coordination 01 32 16 Construction Schedule 01 33 23 Submittal Procedures 01 35 23 Safety Requirements 01 40 00 Quality Requirements 01 42 00 References 01 57 23 Temporary Storm Water Pollution Prevention 01 67 00 Product Requirements 01 73 40 Execution 01 74 19 Construction Waste Management and Disposal 01 77 00 Closeout Procedures 01 90 00 Acceptance of Work

DIVISION 02 – SITE WORK

02 41 20 Structure Excavation and Backfill 02 72 20 Culvert and Storm Drains

DIVISION 04 – MASONRY

04 40 30 Dry-Laid Stone Masonry 04 90 00 Mortared Stone Masonry

DIVISION 10 – SPECIALTIES

10 14 53 Traffic Signage

DIVISION 31 – EARTHWORK

31 00 00 Earthwork 31 00 99 Ditch Cleaning 31 25 00 Erosion and Sedimentation Control 31 37 00 Riprap

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 01 11.53 Removal of Existing Pavement Markings 32 01 16.71 Cold Milling Asphalt Paving 32 01 17.61 Sealing Cracks in Asphalt Paving

ACAD – 221640, 192321, 222085, 310998 TOC-2

32 01 29.63 Partial Depth Patch Repair 32 01 29.64 Full Depth Patch Repair 32 11 23 Aggregate Base Course 32 12 13.13 Asphalt Tack Coat 32 12 16.03 Asphalt Pavement 32 16 13.13 Curb Replacement 32 17 23 Pavement Markings 32 17 23.13 Temporary Pavement Markings and Markers 32 91 19.14 Aggregate Topsoil Course 32 92 20 Seeding

DIVISION 34 – TRANSPORTATION

34 01 00 Maintenance of Traffic 34 41 00 Traffic Loops

DIVISION 01 - GENERAL

REQUIREMENTS

ACAD - 221640, 192321, 222085, 310998 01 11 00 - 1

SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Contractor use of premises.

3. Public use of site.

4. Work Restrictions.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: The following roads and locations within Acadia National Park on Mount Desert

Island in Hancock County, Maine:

1. Otter Cliff Road

2. Cadillac Mountain Road

3. Blue Hill Overlook Parking Lot

4. Blackwoods Campground Entrance Road

5. Blackwoods Campground Entrance Road Dump Station

B. The Work of this contract consists of the following:

1. Pavement improvements and other site improvements at select roads and parking areas within Acadia National Park.

2. The major elements of work include:

a. Mobilization and demobilization.

b. Installation, maintenance and removal of maintenance of traffic and erosion control measures.

c. Parking lot, road and sidewalk pavement improvements including pavement crack sealing, transition milling, partial and full depth pavement patch repairs, full depth sidewalk pavement removal and replacement, and hot mix asphalt (HMA) pavement overlay; removal, replacement and/or resetting of granite curb; ditch cleaning; placement of aggregate topsoil to regrade shoulders and back up pavement edges; and new striping and pavement markings.

d. Rehabilitation and cleaning of selected culverts of various types at several locations, including regrading near inlets and/or outlets.

e. Replacement of several culverts on Cadillac Mountain Road.

C. Project will be constructed under a single prime contract.

ACAD - 221640, 192321, 222085, 310998 01 11 00 - 2

1.3 CONTRACTOR USE OF SITE

A. General: Contractor’s use of the site for construction operations during the construction period will be limited by parking restrictions noted herein. Contractor's use of the site is also limited by the

Government's right to perform work or to retain other contractors on portions of Project. The

Contractor shall coordinate his/her work with other contractors working within the project area.

The Contractor shall allow other contractors hired by the Government access and use of the project area insofar as this access does not directly impede the Contractor’s immediate plan of operations.

B. Storage of Materials: Confine storage of materials to staging area locations mutually acceptable to the Contractor and the Contracting Officer. Contractor shall not store any equipment or materials within 15 ft of the edge of any active travel lane, unless it is behind temporary concrete barrier that was installed as part of the approved maintenance of traffic plan.

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Driveways and Entrances: Keep driveways and entrances serving premises clear and available to

Government, Government's employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.4 PUBLIC USE OF SITE

A. Contractor shall at all times conduct his operations to ensure the least inconvenience to the public.

The Contractor’s Traffic Control Plans shall discuss/address ways to minimize impacts to the traveling public and Park visitors.

ACAD - 221640, 192321, 222085, 310998 01 11 00 - 3

1.5 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 72 hours in advance of the work to the

Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.6 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of

7 a.m. to 6 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend and NPS Holiday Hours: No work shall be performed on the weekends and

NPS holidays without prior approval.

2. Early Morning Hours: No work shall be performed before 7 a.m. unless approved by the

Contracting Officer.

3. Contractor shall conduct paving and striping operations at night (6 p.m. to 7 a.m.) at the

Blue Hill Overlook parking area unless otherwise approved by the Contracting Officer.

Night work for paving and striping operations at other locations will be allowed if approved by the Contracting Officer.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than 48 hours in advance of any proposed utility interruptions.

2. Do not proceed with any utility interruptions without Contracting Officer’s written permission.

3. Disruptions to facilities outside the project limits shall be prevented by investigation of existing utilities and protection during construction. Contractor shall be responsible for all costs associated with remedy of accidental disruptions to facilities outside the project limits.

ACAD - 221640, 192321, 222085, 310998 01 11 00 - 4

1.7 SPECIAL CONSTRUCTION REQUIREMENTS

A. Construction Camp: Establishment of a camp within the Park will not be permitted.

B. All construction signing, fencing, erosion control measures, and traffic control measures shall be in place before starting construction.

C. Unless specifically designated in the plans and drawings or approved by the Contracting Officer, a minimum of one lane of two-way alternating traffic shall be maintained at all times during construction.

D. Temporary lane widths shall not be less than 11.0 feet unless otherwise noted in this specification or in the Contract Plans.

E. No work shall be performed on the Cadillac Mountain Road or the Blue Hill Overlook Parking Lot between the Thursday prior to Memorial Day until the Tuesday following Labor Day. Winter weather conditions will limit access to the Cadillac Mountain Road prior to the middle of April.

F. All work of this contract shall be completed by June 30, 2023.

G. A 48 hour notice is required for any changes in the approved work schedule.

H. Do not pave or stripe when and if conditions are not suitable for paving and striping work.

I. A 48 hour notice is required for all paving and milling operations.

J. Equipment when not in use shall be shut off to minimize noise and air-pollution.

K. Areas of the Park damaged by the movement of the Contractor's vehicles and equipment, or other construction operations, shall be restored as approved by the Contracting Officer, at no additional expense to the Government.

L. As noted in the list of required submittals in Section 013323 of these specifications, maintenance of traffic plans for the work at each parking lot and road in this project shall be submitted to the

Contracting Officer for review and approval prior to the start of construction. The maintenance of traffic plans shall meet the requirements of Section 340100 of these specifications. Because the

Blackwoods Campground Entrance Road is adjacent to State Route 3, the maintenance of traffic plans for those roads shall also be submitted to MaineDOT for MaineDOT review and approval in addition to submitting the plans to the Contracting Officer.

M. The following areas may be completely closed once for a maximum of 72 consecutive hours during construction operations. All closures shall be coordinated with and approved by the Park at least two weeks prior to the closure:

1. Blackwoods Campground (prior to May 1 or after Columbus Day)

N. Some roads and parking areas have intersecting trails and walks that require passage of pedestrians.

The Contractor’s maintenance of traffic plans shall address controls to detour, and reroute pedestrian traffic through the work site safely to include a protected walking surface from hot asphalt if necessary.

ACAD - 221640, 192321, 222085, 310998 01 11 00 - 5

1.8 SOILS INVESTIGATION REPORT

A. No soils investigation reports are available for this project.

1.9 SALVAGE OF NATIVE STONE AND EXCAVATED MATERIAL

A. All blasted ledge, native stones and all other excavated material suitable for reuse shall remain property of the Park. Separate stones from other excavated material. Transport all salvage materials to Park storage area at Liscomb Pit, Fire Road 200 off Route 233 near Eagle Lake. Place in storage piles as directed by Contracting Officer.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

ACAD - 221640, 192321, 222085, 310998 01 26 01 - 1

CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

ACAD - 221640, 192321, 222085, 310998 01 26 01 - 2

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

ACAD - 221640, 192321, 222085, 310998 01 26 01 - 3

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement. Contractor may utilize the government provided Contractor Estimate

ACAD - 221640, 192321, 222085, 310998 01 26 01 - 4

Form, or their own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS.

All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work.

Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region)

ACAD - 221640, 192321, 222085, 310998 01 26 01 - 5

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals. Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the US Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………10% Profit…………………4.75%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par 1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

ACAD - 221640, 192321, 222085, 310998 01 26 01 - 6

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

ACAD - 221640, 192321, 222085, 310998 01 27 00 - 1

DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

C. Any estimated quantities of major elements of the work shown in the Contract Plans are approximate. It is the Contractor’s responsibility to visit the project site prior to bid to identify existing conditions that will affect the work and determine the quantities of all materials required to complete the work at each location.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 1 – Base Proposal: Fixed price, lump sum, that includes all the work of this project. The Base Proposal includes all work shown in the Contract Drawings and called for in the Specifications, including, but not limited to, the following major items:

1. Mobilization and demobilization.

2. Installation, maintenance and removal of maintenance of traffic and erosion control measures.

3. Parking lot and road pavement improvements including pavement crack sealing, transition milling, partial and full depth pavement patch repairs, full depth sidewalk pavement removal and replacement, and hot mix asphalt (HMA) pavement overlay.

4. New striping and pavement markings.

5. Removal, resetting and/or replacement of granite curb.

6. Ditch cleaning and/or regrading.

7. Placement of aggregate topsoil or gravel to regrade shoulders and/or back up pavement edges.

8. Rehabilitation or replacement of selected culverts at several locations, and regrading near inlets and/or outlets.

9. Regrouting the inlet ends of several culverts along Otter Cliff Road.

10. Replacement of several culverts on Cadillac Mountain Road.

END OF SECTION 01 27 00

ACAD-221640, 192321, 222085, 310998 01 31 00 - 1

PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Requests for Information (RFIs).

5. NPS/DSC SharePoint Project Website.

6. Project meetings.

7. Environmental Coordination.

8. Permits

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Agency with Jurisdiction B. Construction Permits – Contractor Provided C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

ACAD-221640, 192321, 222085, 310998 01 31 00 - 2

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Pre-installation conferences.

8. Commissioning activities.

1.4 SUBMITTALS

A. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the

Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. Temporary Storm Water Pollution Prevention Plan (SWPP or UPPP).

11. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The Agency(ies) with Jurisdiction issuing the permit.

c. Information required from the Government to complete the permit application.

ACAD-221640, 192321, 222085, 310998 01 31 00 - 3

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI utilizing the form created on the NPS/DSC SharePoint Project website.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Utilize the RFI form that can be downloaded from the Workflows website at http://www.nps.gov/dscw/con_rfi217.htm or Software-generated form with substantially the same content as indicated above, approved by the CO.

1. Attachments shall be electronic files in Adobe Acrobat PDF format.

2. Enter the general information at the top of the form.

3. Under the “Action” section at the bottom of the form, select “Question” then select “CMR” in the drop-down of the “Send to” box.

4. Enter the details of the question and attach related documents.

5. Select “Submit Form” at the bottom of the page.

D. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond.

CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

ACAD-221640, 192321, 222085, 310998 01 31 00 - 4

f. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.6 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. NPS/DSC SharePoint Project website.

17. Acceptance/rejection of work.

18. Progress meetings.

19. Submittal procedures.

20. NPS Final Accessibility Inspection.

21. Environmental requirements.

22. Permit requirements.

23. As-constructed drawings

24. Saturday, Sunday, holiday and night work.

25. Reference materials.

26. Value engineering.

B. Progress Meetings: The Contractor shall schedule weekly meetings with the Contracting Officer and be responsible for the following:

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

ACAD-221640, 192321, 222085, 310998 01 31 00 - 5

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Requests for information (RFI) and other issues.

d. Modifications.

e. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

f. Inspections of work in progress and projected (Special inspections,

g. Construction Schedule update (provide updated CPM).

h. Status of Project Record Drawings

i. Other business relating to work.

j. Permit requirements.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

1.7 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; must be familiar with environmental regulations applicable to construction operations.

B. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on the project site. Training shall include the following:

1. Overview of environmental issues related to the Project.

2. Review of site specific procedures and management plans:

a. Construction Waste Management.

b. Temporary Storm Water Pollution Prevention.

3. Pollution Prevention (P2) practices.

4. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR employee training records upon request of Contracting Officer.

C. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, and Storm Water Pollution Prevention Plan.

ACAD-221640, 192321, 222085, 310998 01 31 00 - 6

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 31 00

ACAD - 221640, 192321, 222085, 310998 01 32 16 - 1

CONSTRUCTION SCHEDULE

SECTION 01 32 16 – CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the Contractor but is jointly owned.

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

ACAD - 221640, 192321, 222085, 310998 01 32 16 - 2

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be posted on the NPS DSC SharePoint project website, provided in the native electronic file format. It is the intent of the Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit two paper copies of baseline schedule, large enough to show entire schedule for entire construction period.

D. Construction Schedule Updates: On or before the 7th day preceding the progress payment request date, submit estimates of the percent completion of each schedule activity and necessary supporting data. Provide two paper copies.

1.4 QUALITY ASSURANCE

A. The Contractor shall meet with the Contracting Officer on the day of the preconstruction conference to go over the following:

1. Review software limitations, content and format for reports.

2. Verify availability of qualified personnel needed to develop and update schedule.

3. Discuss constraints, including phasing, work stages, area separations, interim milestones, and partial Government occupancy.

4. Review delivery dates for Government-furnished products.

5. Review schedule for work of separate Government contracts.

6. Review time required for review of submittals and re-submittals.

7. Review requirements for tests and inspections by independent testing and inspecting agencies.

8. Review time required for completion and startup procedures.

9. Review time required for obtaining and activating permits.

10. Review and finalize list of construction activities to be included in schedule.

11. Review baseline schedule comments, resolve issues and progress on incorporating them

12. Review procedures for updating schedule.

13. Discuss reporting requirements and establish a protocol for naming and transmitting electronic schedules.

ACAD - 221640, 192321, 222085, 310998 01 32 16 - 3

B. Contractor's Schedule Representative: Before or at the preconstruction conference, designate an authorized representative to be responsible for the preparation and maintenance of the Construction Schedule. A resume outlining the qualifications of the Scheduler shall be submitted to the Contracting Officer for acceptance. The Scheduler shall have prepared and maintained at least 5 previous schedules of similar size and complexity similar to this Contract, demonstrating proficiency in the use of scheduling software. The authorized representative will be responsible for preparing the Baseline Schedule, all required updates, revisions, Time Impact Analyses, and preparation of reports.

1.5 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate Contractors.

B. Coordinate Construction Baseline Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. In developing the Construction Baseline Schedule, ensure that the Subcontractor’s work at all tiers, as well as the prime Contractor’s work, is included and coordinated.

2. Secure time commitments for performing critical elements of the Work from parties involved.

3. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

PART 2 - PRODUCTS

2.1 SCHEDULE OF VALUES

A. Breakdown each lump-sum item into component work activities used in the schedule, for which progress payments may be requested. The work activities broken out within the schedule of values shall be integrated into and made a logical part of the construction baseline schedule submitted under this specification. The total costs for the component work activities shall equal the contract price for that lump-sum item. The Contracting Officer may request data to verify accuracy of dollar values. Include mobilization, general condition costs, overhead and profit in the total dollar value of unit price items and in the component work activities for each lump-sum item. Do not include mobilization, general condition costs, overhead or profit as a separate item.

B. Do not break down unit price items. Use only the contract price for unit price items.

C. The total cost of all items shall equal the contract price. The Schedule of Values will form the basis for progress payments.

D. An acceptable Schedule of Values shall be agreed upon by the Contractor and Contracting Officer before the first progress payment is processed.

ACAD - 221640, 192321, 222085, 310998 01 32 16 - 4

2.2 CONSTRUCTION SCHEDULE REQUIREMENTS

A. Construction Baseline Schedule: Prepare Construction Baseline Schedule using a computerized, resource-loaded, time-scaled CPM network analysis diagram for the Work.

1. Develop and finalize Construction Baseline Schedule so it can be accepted for use no later than 30 days after date established for the Notice of Award.

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Governments acceptance of the schedule.

2. Establish procedures for monitoring and updating Construction Baseline Schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

B. Construction Baseline Schedule Preparation: Prepare a list of all activities required to complete the Work. Using the preliminary CPM network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate the estimated duration, sequence requirements, and relationship of each activity in relation to other activities.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

3. Processing: Process data to produce output data on a computer-drawn, time-scaled network. Revise data, reorganize activity sequences, and reproduce as often as necessary to produce the CPM schedule within the limitations of the Contract Time.

4. The Construction Baseline Schedule as developed shall show the sequence and interdependence of activities required for complete performance of the work. Ensure all work sequences are logical and the Construction Baseline Schedule shows a coordinated plan of the work.

5. Resource loading of each activity shall include all personnel by labor category and equipment type and capacity proposed to complete the activity in the duration shown.

6. Consider seasonal weather conditions in planning and scheduling all work influenced by high and low ambient temperatures, wind, or precipitation to ensure completion of all work within the contract time.

7. Time Frame: Proposed duration assigned to each activity shall be the Contractor's best estimate of time required to complete the activity considering the scope and resources planned for the activity.

a. An early finish date may be shown but the late finish date must be the same date as the last day of the contract period. An early completion schedule must contain the following:

1) Insert an activity titled “Project Float” as a successor to the last activity in the early project completion schedule network.

2) Add a milestone titled “Contract End Date” as a successor to the activity “Project Float”.

3) Add duration to the activity “Project Float” as required so the milestone “Contract End Date” equals the last day of the Contract Period.

ACAD - 221640, 192321, 222085, 310998 01 32 16 - 5

b. Contract completion date shall not be changed by submission of a schedule that shows an early completion date.

c. The Contractor shall limit use of lead or lag duration’s between schedule activities.

d. Project Calendars: Develop and incorporate the following calendars:

1) Administrative Calendar: Include a calendar that is based on a 7 day week to be used on any activities that are based on calendar days. Apply this calendar to administrative tasks or any other tasks that are not affected by non-working days (Federal Holidays, weather, etc.).

2) Project Calendar: Include a calendar that is based on the planned work week for the project. Include Federal Holidays, weekends, and any other non-work days indicated in the contract documents. Apply this calendar to activities which are not anticipated to be affected by weather.

3) Weather Calendar: Utilize the Project Calendar and show anticipated normal downtime related to weather as non-working time.