B.08.01 - Bowe, Senegal - Att_12 Specification Binder.pdf

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 74 01

SPECIAL CONDITIONS (NAU)

10/19

PART 1 GENERAL

1.1 PAYMENT

1.2 DEFINITIONS

1.3 ORDER OF PRECEDENCE

1.4 DOCUMENTS IN MULTIPLE LANGUAGES

1.5 COMMUNICATION IN ENGLISH

1.5.1 English Speaking Representative

1.5.2 Correspondence And Documentation

1.5.3 Translations for Disputes

1.5.4 Additional Language Requirements

1.5.5 Language Fluency

1.6 PERMITS

1.6.1 General Requirements

1.6.2 Permits and Notifications

1.6.3 Final Acceptance

1.6.4 THIRD PARTY INSPECTION REQUIREMENTS

1.7 CONTRACTOR WORKFORCE

1.7.1 Foreign Employees

1.8 CONTRACTOR OBLIGATION

1.9 SUBMITTALS

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 SITE ACCESS

3.1.1 General Access Requirements

3.1.2 Work on Military Installations (General)

3.1.3 Access to Operational Areas

3.2 IMMUNITY FROM LEGAL PROCESS

3.3 CONTRACT EXECUTION IN THE HOST NATION

3.3.1 Access to Areas Under Military Control

3.3.2 Contractor Responsibility

3.3.3 Archaeological and Historical Sites

3.4 CONTRACTOR LIAISON AND COMMUNICATION WITH HOST GOVERNMENTS

3.5 RESTRICTIONS ON PAYMENT SUBMISSIONS

-- End of Section Table of Contents --

DOCUMENT 00 74 01 Page 1

SECTION 00 74 01

SPECIAL CONDITIONS (NAU)

10/19

PART 1 GENERAL

1.1 PAYMENT

Separate payment will not be made for compliance with this or any other Division 00 or Division 01 specification. All costs associated with these specifications shall be included in the applicable unit prices or lump-sum prices contained in the Bidding Schedule.

1.2 DEFINITIONS

The following terms are used throughout the contract documents. Except where a definition is provided with the specific occurrence, the following definitions apply to these terms.

a. Betterment. Any offer by the contractor, whether submitted as part of their proposal prior to award or as part of a deliverable after award which conforms to and exceeds the provisions of the contact.

A betterment offered prior to award becomes binding upon award of the contract. After award, a betterment offered becomes a binding contract requirement upon acceptance by the Government of the document proposing the betterment, whether specifically identified as such or not. Proposed betterments submitted after award must meet or exceed any betterments offered prior to award which were accepted as part of the award.

b. Host Nation (HN). The country where the construction work is being performed.

c. Host Nation Language. The Official Language recognized by the national government of the country where the work is performed. If no Official Language has been designated, or where multiple Official Languages have been designated, it is the predominant language of the Government agency responsible for operation and maintenance of the facility or product constructed under this contract.

1.3 ORDER OF PRECEDENCE

In the event of conflict or inconsistency between any of the provisions of this contract, precedence shall be given in the following order:

(1) Clause 52.236-21 Specifications and Drawings (Alt I)

(2) Any portion of a contractor provided deliverable (including, but not limited to, plans, specifications, engineering studies and analyses, shop drawings, equipment installation drawings) that conforms to or exceeds the provisions of the contract (Betterment submitted after award).

(3) Any portions of the accepted proposal that both conform to and exceed the provisions of the solicitation (Betterment submitted prior to award).

(4) Contract Sections starting with "00", including these Special Conditions

DOCUMENT 00 74 01 Page 2

(5) Section 01 00 00, including Section 01 10 10 Statement of Work (Summary of Work or Scope of Work)

(6) All Other Specification Sections

(7) Special Requirements (SRs) or Special Technical Requirements (STRs)

(8) Referenced Technical Standards (such as NFPA, UFC, ASTM, DIN)

(9) Referenced Design Guides or other non-technical standards

(10) Drawings

(11) All other technical attachments to the contract, including Host Nation Technical Requirements, Standards, and References.

Amendments take precedence over all items listed above to the extent noted above and in the referenced clauses. For instance an amendment to a Drawing takes precedence over the original drawing but not over the Special Technical Requirements.

Design and product requirements, including criteria are minimum requisites. In case of conflicting requirements within documents of the same order of precedence, the more stringent criteria governs. A conflict does NOT exist when both requirements can be met; in these instances the contractor shall comply with both requirements.

1.4 DOCUMENTS IN MULTIPLE LANGUAGES

If this contract includes documents in English and additional languages, the English language version shall govern over all other languages. In the event contract documents contain translations into non-English languages, the translation is provided solely for convenience.

For all purposes, the English language version shall be the governing instrument and understanding of the parties. In the event of any conflict between the English language version and any translation into any other language, the English language version shall govern and control.

1.5 COMMUNICATION IN ENGLISH

1.5.1 English Speaking Representative

All personnel required to communicate with the government on a recurring basis, including but not limited to Project Managers, Site Safety and Health Officers (SSHO), Superintendents, and Quality Control personnel shall be capable of explaining the work operations and receiving instructions in the English language. This includes the ability to speak, read, write, and understand the directions of the Contracting Officer or their designated representatives when conducted in English.

If other sections of the contract allow work to be performed without these personnel being on site, the Contractor shall have a representative, designated in writing, who is capable of explaining the work operations and receiving instruction in the English language.

1.5.2 Correspondence And Documentation

In addition to clause 252.225-7041, it shall be the responsibility of the Contractor to prepare all documents related to this contract, to include, change proposals, shop drawings, submittals, quality control reports, computations, and all correspondence, in the English language or with a translation of the original document into English.

DOCUMENT 00 74 01 Page 3

1.5.3 Translations for Disputes

All documents originally produced in a language other than English submitted either as (a) part of a Request for Equitable Adjustment (REA), (b) part of a claim under the Disputes clause or (c) as part of litigation, including actions at the ASBCA or actions in U.S. courts, shall be translated into English by a person who is recognized in accordance with the appropriate authorities to produce official/certified translations, and said translations shall be so certified.

This requirement applies to any document that would normally be considered to be within the scope of discovery in an ASBCA or court proceeding concerning the dispute. The term 'documents' includes electronic documents including but not limited to e-mail and includes documents generated by subcontractors or suppliers. In the event a dispute results in litigation, including actions at the ASBCA or actions in U.S. courts, the contractor will be responsible for providing translations of any documents that are within the scope of a discovery request filed by the U.S. Government and for providing certified translations upon request by the U.S. Government.

The contractor shall bear sole responsibility for any costs associated with translation, as well as with any errors, omissions, or discrepancies between the original and English version of a document.

In the event of any difference between the English version and any other version in any language, the English version shall govern.

1.5.4 Additional Language Requirements

When any worker on site at any level (contractor, subcontractor, supplier, etc.) cannot communicate in English or a language spoken by the Contractor's key personnel, the contractor shall ensure that, at all times that person is on site, at least one person is present who can communicate to that worker in their native language. Failure to comply with this requirement will be considered a life-safety issue.

1.5.5 Language Fluency

Personnel required to communicate with the Government must be competent in the English language at a minimum level B2 of the Common European Framework of Reference for Languages: Learning, Teaching, Assessment.

The Contracting Officer shall have the right to determine without appeal of such decision, whether the proposed representative has sufficient technical and lingual capabilities and the Contractor shall immediately replace any individual not acceptable to the Contracting Officer.

1.6 PERMITS

1.6.1 General Requirements

All documents required to be prepared in accordance with this paragraph (and sub-paragraphs) shall be prepared by the Contractor in the language(s) required by the HN. An English language translation prepared by a person with the appropriate qualifications shall be provided to the Contracting Officer concurrently. Submission of documentation shall be in accordance with HN requirements; either directly to the appropriate HN authority or through the Contracting Officer when the contractor is not permitted to provide the documents directly.

When U. S. Government signature is required, the Contractor shall obtain

DOCUMENT 00 74 01 Page 4 approval and signatures as needed for HN permitting and notification process from the COR. The contractor shall provide the required documentation sufficiently in advance of the date any approval or permit is required. The contractor is solely responsible for determining the amount of time the HN authorities will require to review and process the documentation. No additional time will be granted for delayed approval or rejection of contractor prepared documents.

A copy of all Approved Permits shall be furnished to the COR prior to the start of construction work.

1.6.2 Permits and Notifications

The contractor shall obtain all permits not required to be requested or obtained by the U.S. Government in accordance with FAR 52.236-7, Permits and Responsibilities. As incorporated herein, the requirements of FAR clause 52.236-7 extend to licenses, permits, and compliance with applicable Host Nation (HN) and local laws, codes, and regulations in connection with the prosecution of the work. The contractor is responsible for identifying and providing a comprehensive List of Required HN Permits.

Where the U.S. Government is required to obtain permits in accordance with Host Nation (HN) agreements, the Government will notify the contractor and the contractor shall prepare all necessary documentation. This includes providing documentation to show compliance with permit requirements.

1.6.3 Final Acceptance

Where final acceptance by the HN is required, the Contractor will coordinate with the HN Government, in conjunction with the U.S.

Government, to determine the requirements for proper final inspection by the HN and provide any information required for proper final acceptance.

The contractor shall incorporate the requirements for final acceptance into the design and construction of the project.

1.6.4 THIRD PARTY INSPECTION REQUIREMENTS

If, as a condition of any permit or to comply with HN laws, codes, and regulations, inspections by third parties are required, the contractor shall be responsible for ensuring those inspections are conducted and documented. The contractor shall be solely responsible for any and all costs associated with these inspections, including the actual inspection and any additional work or rework identified as part of the inspection process, to include the replacement of any materials or equipment determined to be not in compliance by the inspector.

No adjustment in the contract price or duration will be made based on events arising from these inspections, unless a delay occurs which is completely beyond the control and without the fault of the contractor, in which case an adjustment in the contract duration may be made under the DEFAULTS clause of the contract. No adjustment in price will be made should this occur. The contractor is solely responsible for identifying the period(s) of delay and substantiating an impact to the completion date.

These requirements are in addition to and separate from any requirements for Third Party Inspection Services identified in Section 01 10 00 Statement of Work.

DOCUMENT 00 74 01 Page 5

1.7 CONTRACTOR WORKFORCE

1.7.1 Foreign Employees

The contractor may arrange, through the appropriate Host Nation Government (HN) offices, to bring into the country nationals of third countries (TCN) having diplomatic relations with the host nation for purposes of employment in carrying out this contract work.

Contractors shall be responsible for timely and complete submittal of the necessary information and forms directly to the appropriate HN agency for the required customs clearances, passports, visas, licenses, or permits.

The contractor shall be responsible for the sponsorship of its employees and their dependents and shall process said permits directly with the appropriate HN agency. Offerors are advised that the HN reserves the right to limit access to designated security areas and refuse entry or employment of specified individuals, or to require their departure from the country, in accordance with national or local law and practice.

The U.S. Government does not have influence over the TCN issue and does not warrant the availability of TCN labor. The Contractor is cautioned to review any additional information specified elsewhere in this contract for more stringent requirements or specific restrictions or limitations on the use of foreign workers.

1.8 CONTRACTOR OBLIGATION

Contractors shall be responsible for timely and complete submittal of the necessary information and forms directly to the appropriate HN agencies for any and all required customs clearances, passports, visas, licenses, or permits.

1.9 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Required HN Permits Permits And Notifications Approved Permits

SD-11 Closeout Submittals

Final Acceptance

PART 2 PRODUCTS

Not Used.

PART 3 EXECUTION

3.1 SITE ACCESS

3.1.1 General Access Requirements

The Contractor shall be responsible for obtaining access and adhering to

DOCUMENT 00 74 01 Page 6 all guidelines established by the local authorities for access to the work site and will be responsible for the daily access of their personnel and subcontractor workers.

The Contractor is cautioned to review any additional security guidelines specified elsewhere in this contract for more stringent requirements or specific access conditions.

3.1.2 Work on Military Installations (General)

When work is performed on a military installation, every employee of the prime contractor, all subcontractor employees, and all material suppliers' employees, who require access to the installation for any reason and for any length of time will be required to obtain an installation/base access.

All personnel, vehicles, and equipment are subject to search when entering or leaving the installation and at any time while on the installation. The contractor shall be responsible for notifying their personnel, to include subcontractors and suppliers of this. Entry of any individual onto the installation constitutes consent to being searched.

Individuals who will be performing work onsite for five or more days in total - even if non-consecutively - shall apply for installation/base pass and may not be "signed in" or otherwise presented as a "visitor".

Failure to comply with this requirement may result in the loss of sign-in privileges and/or loss of installation access.

All personnel in possession of an installation/base pass issued for work under this contract shall return them to the issuing office upon completion of the contract work or upon termination of employment.

3.1.3 Access to Operational Areas

Contractor personnel are expressly prohibited and shall be restricted from entering operational buildings or areas without the specific authorization of the Contracting Officer. To perform work, where "security escorts" are required for access to a facility, the Contractor shall coordinate with the Contracting Officer for access to such facilities.

3.2 IMMUNITY FROM LEGAL PROCESS

The Contractor agrees to indemnify and save harmless the United States Government against all claims and suits of whatsoever nature arising under or incidental to performance of this contract by any subcontractor against the United States Government.

The Contractor further agrees to waive his rights to bring suit or other legal action against the United States Government, except as provided in the "Disputes" clause of this contract and in the United States Federal Statutes.

3.3 CONTRACT EXECUTION IN THE HOST NATION

3.3.1 Access to Areas Under Military Control

The laws of the Host Nation (HN) may prohibit access to certain areas of the country which are under military control. Clearances to access these areas must be obtained from the HN. It is understood that areas to which rights of entry are provided by the HN are to be used only for work carried out under the contract and no destruction or damages shall be caused, except through normal usage, without concurrence of the HN.

DOCUMENT 00 74 01 Page 7

3.3.2 Contractor Responsibility

The Contractor shall be responsible for providing the necessary information (such as but not limited to, names of personnel, type, and amounts of equipment, dates and length of time required at the site, and purpose of entering the HN) to the appropriate HN representatives, both civilian and military.

The following items are the sole responsibility of the Contractor to investigate, estimate as to cost, and assume the risk, as normally encountered by Contractors. The Contractor shall be responsible for determining the effect of the following on his own cost of performance of the contract and for including sufficient amount in the contract price:

a. Official language and type of accounts required to satisfy the officials of the Local Government.

b. Entry and exit visas, residence permits, and residence laws applicable to aliens. This includes any special requirements of the Host Government, including those required by local Labor Offices, which the Contractor may have to fulfill before an application for visas will be accepted.

c. Passports, health and immunization certificates, and quarantine clearance.

d. Compliance with local labor and insurance laws, including payment of employer's share of contribution, collecting balance from employee and paying into insurance funds.

e. Strikes, demonstrations and work stoppage.

f. Collection through withholding and payment to local Government, of any HN income tax on employees subject to tax.

g. Arranging to perform work in the HN, to import personnel, to employ non-indigenous labor, to receive payments and to remove such funds from the country.

h. Operating under local laws, practices, customs and controls, and with local unions, in connection with hiring and firing, mandatory wage scales, vacation pay, severance pay, overtime, holiday pay, days of rest or other non-work days, legal notice or pay in lieu thereof for dismissal of employees, slowdown and curtailed schedules during religious holidays, and ratio of local labor employed in comparison to others.

i. Possibility of claims in local bureaus, litigation in local courts, or attachment of local bank accounts.

j. Compliance with workmen's compensation laws and contributions into funds. Provisions of necessary medical service for Contractor employees.

k. Special license required by the local Government for setting up and operating any manufacturing plant in the HN, e.g. concrete batching, precast concrete, concrete blocks, etc.

l. Sales within the HN of Contractor-owned materials, and equipment.

m. Special licenses for physicians, mechanics, tradesmen, drivers, etc.

DOCUMENT 00 74 01 Page 8

n. Identification and/or registration with local police of imported personnel.

o. Stamp tax on documents, payments and payrolls.

p. Base passes for permanent staff, day laborers, motor vehicles, etc.

q. Compliance with all customs and import rules, regulations and restrictions, including, but not limited to, local purchase requirements.

3.3.3 Archaeological and Historical Sites

The contractor shall be aware of all archeological laws and work accordingly including stopping work in the vicinity and reporting should archeological items be uncovered during the course of this contract.

3.4 CONTRACTOR LIAISON AND COMMUNICATION WITH HOST GOVERNMENTS

All communication by the Contractor with all officials, representatives and/or offices of the Host Government (at any level) in all matters pertaining to the design or construction of this contract, shall be through and in full liaison with the Contracting Officer. This does not relinquish Contractor responsibility for obtaining routine items to conduct day-to-day business, such as visas, permits, and custom clearances.

The contractor is further reminded that only the Contracting Officer or their authorized representative may give the contractor direction in regards to contract interpretation. Only a Contracting Officer or Administrative Contracting Officer may modify the contract terms or conditions: directions received from Host Nation Government officials do not constitute direction to proceed in accordance with the Change clause and will not be considered a change to the contract without prior specific direction from the Contracting Officer.

3.5 RESTRICTIONS ON PAYMENT SUBMISSIONS

Reference is made to clause 52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS. Due to financial cutoff periods, the Government will not accept any progress payments submitted between the last 5 work days of a given month and the first 3 work days of the following calendar month (second month). Invoices submitted during this time will not be considered "received" as described in the reference clause until the 4th working day of the second month.

-- End of Section --

DOCUMENT 00 74 01 Page 9

SECTION 00 74 02

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (NAU)

10/19

PART 1 GENERAL

1.1 DETERMINATION OF UNUSUALLY SEVERE WEATHER

1.2 MINIMIZING WEATHER IMPACTS

1.3 INCORPORATION IN PROJECT SCHEDULE

1.4 WEATHER CONDITIONS AT THE PROJECT SITE(S)

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 REPORTING

3.2 OCCURRENCE OF ACTUAL DELAY

3.3 CALCULATION OF DELAY AND CONVERSION TO CALENDAR DAYS

3.4 ISSUANCE OF MODIFICATION

3.5 DELAYS OUTSIDE STANDARD WORK DAYS

DOCUMENT 00 74 02 Page 1

SECTION 00 74 02

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (NAU)

10/19

PART 1 GENERAL

1.1 DETERMINATION OF UNUSUALLY SEVERE WEATHER

This specification prescribes the procedures to be used on this contract for determination of time extensions for "unusually severe weather" in accordance with the contract clause 52.249-10 "Default: (Fixed Price Construction)".

In order for the Contracting Officer to award a time extension for "unusually severe weather" under this clause, all of the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must exceed the weather which could reasonably be anticipated based on a minimum of 25 years of historical weather data.

b. The weather must actually cause a delay to the completion of the project or any specified contractual milestone beyond that which would reasonably be anticipated based on the contractors means and methods. The delay must result from events which are beyond the control and without the fault or negligence of the Contractor.

c. The delay must occur during the contractual performance period.

1.2 MINIMIZING WEATHER IMPACTS

The contractor is responsible for identifying and implementing the means and methods to minimize the overall impact of weather during the contract period.

The means and methods and sequencing of work will impact the extent to which the work is sensitive to or may be impacted by the weather.

Separate payment will not be made for any costs associated with mitigating the impacts of weather.

1.3 INCORPORATION IN PROJECT SCHEDULE

The Contractor's progress schedule must reflect reasonably anticipatable weather in weather dependent activities. The Contractor shall be solely responsible for identifying anticipated weather days based on the activities scheduled during a given time period and the means and methods of executing the work.

Refer to Section 01 32 01 PROJECT SCHEDULE (NAU) for the procedures for incorporating these weather days into the schedule.

1.4 WEATHER CONDITIONS AT THE PROJECT SITE(S)

The Government makes no representation of the actual weather conditions to be expected at the site. No inference or conclusion shall be made regarding the actual weather conditions or the actual amount of weather delays based on any information included in the contract documents.

The Contractor shall, prior to submitting a proposal or offer, be solely responsible for determining the actual weather conditions prevalent at

DOCUMENT 00 74 02 Page 2 the project site or sites and accounting for this information in their proposal or offer.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.1 REPORTING

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract performance period, the contractor will record on the CQC report the occurrence of weather and resultant impact to normally scheduled work. Impacted activities shall be identified by name and activity id on the CQC report.

When the use of RMS-CM (Section 01 45 01 RESIDENT MANAGEMENT SYSTEM - CONTRACTOR MODE) is required by the contract, weather shall be reported on the QC Report in RMS-CM and tracked therein.

3.2 OCCURRENCE OF ACTUAL DELAY

To be considered a day of actual weather delay, progress on critical path activities must be less than 50 percent of the progress scheduled to occur on that day, and the progress must be impacted due solely to the weather.

The delay must be recorded in accordance with paragraph 3.1: failure to provide this information at the time of the preparation of the CQC report will be considered an acknowledgement that no delay existed, however reporting on the CQC report will not automatically be considered concurrence by the Government that delay occurred and it was due solely to the weather.

Failure to make adequate preparations for weather or to adequately protect the work from reasonably anticipatable weather will not be considered an impact due solely to weather.

3.3 CALCULATION OF DELAY AND CONVERSION TO CALENDAR DAYS

Any adjustment in the contract period of performance resulting from unusually severe weather will be based upon the weather over a minimum period of six months.

The contractor shall be solely responsible for providing documentation to substantiate that the actual weather was "unusually severe" based on a minimum of 25 years of historical weather data, the critical path was impacted as a result, and the actual impact to the critical path could not have been prevented through reasonably prudent measures.

As part of this documentation, the contractor must substantiate the reasonableness of anticipated weather days included in the schedule as discussed in paragraph 1.3 INCORPORATION IN PROJECT SCHEDULE. Failure to substantiate the reasonableness of the anticipated weather days may result in a determination that the contractor failed to adequately plan and execute the work in a manner consistent with the requirements of the contract, making the delay within their control.

Additionally, the contractor shall provide a detailed listing of all weather days occurring from the Notice to Proceed through the date of the request and show a cumulative net impact to the performance period exceeding that which could be anticipated based on the aforementioned 25 years of historical weather data.

DOCUMENT 00 74 02 Page 3

Any calculation performed within RMS-CM under the "Weather Delays" screens of the QA/QC Module shall not serve as the basis for determining the amount of adjustment required.

3.4 ISSUANCE OF MODIFICATION

If the contractor can substantiate an impact to the completion date of the project based on actual "unusually severe" weather as described herein, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause 52.249-10 entitled "Default (Fixed Price Construction)".

3.5 DELAYS OUTSIDE STANDARD WORK DAYS

Weather delays occurring prior to Notice to Proceed, during non-working days, and after the required completion date are not excusable under the Defaults clause.

When the contract performance period, or any extension thereof, has passed, no extensions for unusually severe weather will be granted.

This applies as well to any interim milestone or completion date.

DOCUMENT 00 74 02 Page 4

SECTION 00 74 70

ANTI-TERRRORISM/OPERATIONS SECURITY REQUIREMENTS

10/19

PART 1 GENERAL

1.1 PURPOSE

1.2 REFERENCES

1.3 ACRONYMS AND ABBREVIATIONS

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 REQUIREMENTS

DOCUMENT 00 74 70 Page 1

SECTION 00 74 70

ANTI-TERRRORISM/OPERATIONS SECURITY REQUIREMENTS

10/19

PART 1 GENERAL

1.1 PURPOSE

This section describes the minimum Anti-Terrorism and Operations Security requirements of the contract. The contractor is required to comply with the requirements identified herein as part of this contract.

These requirements are in addition to other requirements specified in other Sections regarding Installation Access and Military Installation Access Procedures.

1.2 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. DEPARTMENT OF DEFENSE (DoD)

DoD 5220.22-M (2006; Change 2 2016) National industrial Security Program Operating Manual

DoD 8570.01-M (2005; Change 4 20157) Information Assurance Workforce Improvement Program

U.S. ARMY (DA)

DA AR 25-2 (2007; RAR 2009) Information Assurance

DA AR 190-13 (2011) The Army Physical Security Program

DA AR 381-12 (2016) Threat Awareness and Reporting Program

DA AR 380-49 (2013) Industrial Security Program

DA AR 380-67 (2014; RAR 2014) Personnel Security Program

1.3 ACRONYMS AND ABBREVIATIONS

AT - AntiTerrorism

HQDA - Headquarters, U.S. Department of the Army

RA - Requiring Activity.

PART 2 PRODUCTS

Not Used

DOCUMENT 00 74 70 Page 2

PART 3 EXECUTION

3.1 REQUIREMENTS

The contractor shall comply with all items indicated as "Applicable" in Table 1 for this contract. Items marked "Not Applicable" are not included in the scope of work of this contract.

TABLE 1: REQUIREMENTS

Project

Item Appli-cable

Not Appli-cable

Requirement

1 AT Level I Training

All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities, controlled access areas, or require network access, shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable.

Upon request, the contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at the following website: http://jko.jten.mil/courses/atl1/launch.html;

or it can be provided by the RA ATO in presentation form which will be documented via memorandum.

2 Access & General Protection/Security Policy & Procedures

All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks or background investigation and to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

DOCUMENT 00 74 70 Page 3

TABLE 1: REQUIREMENTS

Project

Item Appli-cable

Not Appli-cable

Requirement

2a Contractors requiring Common Access Card (CAC)

The Contractor and all sub-contractors employees will be issued a CAC only if duties involve one of the following: (1) Both physical access to a DoD facility and access, via logon, to DoD networks on-site or remotely; (2) Remote access, via logon, to a DoD network using DoD-approved remote access procedures;

or (3) Physical access to multiple DoD facilities or multiple non-DoD federally controlled facilities on behalf of the DoD on a recurring basis for a period of 6 months or more. At the discretion of the sponsoring activity, an interim CAC may be issued based on a favorable review of the FBI fingerprint check and a successfully scheduled NACI at the Office of Personnel Management.

2b Contractors who do not require CAC, but require access to a DoD facility or installation

Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / DA AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

3 AT Awareness Training for Contractor Personnel Traveling Overseas

All US based contractor employees and associated sub-contractor employees traveling overseas will receive the government provided Area of Responsibility (AOR) specific AT awareness training. The documentation of training completion must be provided to the COR prior to departure.

DOCUMENT 00 74 70 Page 4

Item Appli-cable

Not Appli-cable

Requirement

4 Suspicious Activity Reporting Training (e.g. iWATCH, CorpsWatch, or See Something, Say Something

The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

5 Contractor Employees Who Require Access to Government Information Systems

All contractor employees with access to a government info system must be registered in the Army Training Certification Tracking System (ATCTS) at commencement of services, and must successfully complete the DOD Information Assurance Awareness prior to access to the information systems and then annually thereafter in accordance with personnel security standards listed in DA AR 25-2 (Information Assurance), an appropriate background investigation will be conducted prior to accessing the government information systems.

6 OPSEC Standing Operating Procedure (SOP)/Plan

The Contractor shall develop an OPSEC SOP/Plan within 90 days of contract award. The OPSEC SOP/Plan must be reviewed and approved by the RA OPSEC Officer. The SOP/Plan will include the government's critical information, why it needs to be protected, where it is located, who is responsible for it and how to protect

it. In addition, the contractor shall identify an individual who will be an OPSEC Coordinator.

DOCUMENT 00 74 70 Page 5

Item Appli-cable

Not Appli-cable

Requirement

7 OPSEC Level I Training

All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. OPSEC awareness training is available at the following websites: https://www.iad.gov/ioss/ or http://www.cdse.edu/catalog/operations-security.html;

or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.

8 Information assurance (IA)/information technology (IT) training

All contractor employees and associated sub-contractor employees must complete the DoD IA awareness training before issuance of network access and annually thereafter. All contractor employees working IA/IT functions must comply with DoD and Army training requirements in DoDD 8570.01, DoD 8570.01-M and DA AR 25-2 within six months of employment.

9 Information assurance (IA)/information technology (IT) certification

All contractor employees supporting IA/IT functions shall be appropriately certified upon contract IAW DoD 8570.01-M, DFARS 252.239-7001 and DA AR 25-2. The baseline certification as stipulated in DoD 8570.01-M must be completed upon contract award.

10 Contractor Personnel Authorized to Accompany U.S. Armed Forces Deployed Outside the United States

All contractor employees shall ensure the AT/OPSEC requirements are met prior to deploying personnel authorized to accompany U.S. Armed Forces outside the United States; to include compliance with laws, regulations, pre-deployment requirements, and required training in accordance with combatant command guidance.

DOCUMENT 00 74 70 Page 6

Item Appli-cable

Not Appli-cable

Requirement

11 Contracts Requiring Performance or Delivery in a Foreign Country

All non-local contracting personnel will comply with theater clearance requirements and allows the combatant commander to exercise oversight to ensure the contractor's compliance with combatant commander and subordinate task force commander policies and directives.

12 Contracts That Require Handling or Access to Classified Information.

Contractor shall comply with DA AR 380-67 (Personnel Security Program) and Homeland Security Presidential Directive 12 (Policy for a Common Identification Standard for Federal Employees and Contractors) as well as FAR 52.204-2, Security Requirements. Additionally, Contractors must comply with - (1) The Security Agreement (DD Form 441), including the National Industrial Security Program Operating Manual ( DoD 5220.22-M); any revisions to DoD 5220.22-M, notice of which has been furnished to the contractor. For classified contracts, the DD Form 254 will be attached with the contract.

13 Escorts in Areas Where Contractor may be Exposed to Classified and/or Sensitive Materials and/or Sensitive or Restricted Areas

All contractor employees, iincluding subcontractor employees, who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

DOCUMENT 00 74 70 Page 7

Item Appli-cable

Not Appli-cable

Requirement

14 Contractor Company to obtain a Facility Clearance and individual clearances at the appropriate level.

The Prime Contractor Company must have a Facility Clearance (FCL) at the appropriate level (IAW the NISPOM DOD 5220.22-M and DA AR 380-49) prior to the start of the contract awarded period of performance.

Contractor personnel performing work under this contract must have the required security clearance, per DA AR 380-67, at the appropriate level at the start of the period of performance. Security Clearances and FCL requirements are required to be maintained for the life of the contract IAW the DD Form 254 attached to the contract. If no FCL, the supporting Government Contracting Activity will sponsor the prime contract company in obtaining the FCL.

15 Pre-screen candidates using E-Verify Program

The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award. *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

16 Contract Requiring Armed Security Guards

All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility policies and procedures on storing weapons and ammunition IAW AR 190-11 (provided by government representative

DOCUMENT 00 74 70 Page 8

Item Appli-cable

Not Appli-cable

Requirement

17 Threat Awareness Reporting Program

All new contractor employees will complete annual Threat Awareness and Reporting Program (TARP) Training provided by a Counterintelligence Agent, IAW DA AR 381-12. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee(s) or a memorandum for the record, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. Authorized webbased TARP training for CAC card holders is available at the following website:

https://www.us.army.mil/suite/page/655474

DOCUMENT 00 74 70 Page 9

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 30 01

GENERAL REQUIREMENTS (NAU)

02/20

PART 1 GENERAL

1.1 PURPOSE

1.2 DESIGN AND DESIGN RELATED WORK

1.2.1 Design-Build Language

1.2.2 Design Related Activities

1.2.3 Performance Requirements

1.3 SUBMITTALS

1.4 DEFINITIONS

1.5 NO WAIVER BY GOVERNMENT

1.6 PROPRIETARY NAMES

1.7 PUBLIC RELEASE OF INFORMATION

1.7.1 Prohibition

1.7.2 Subcontracts and Purchase Orders

1.8 PERSONNEL AND SUBCONTRACTORS

1.8.1 Removal for Non-Compliance

1.8.2 Substitution and Replacement

1.8.3 Qualifications

1.8.4 Employment

1.9 REFERENCES

1.10 REFERENCED STANDARDS

1.10.1 Version and Date of Standard

1.10.2 Host Nation Standards

1.10.3 Equivalency of References

1.11 PRECONSTRUCTION CONFERENCE

1.12 PARTNERING

1.12.1 Informal Partnering

1.12.2 Formal Partnering

1.13 ELECTRONIC MAIL (E-MAIL) ADDRESS

1.14 ELECTRONIC CORRESPONDENCE

1.15 HOURS OF WORK

1.15.1 Normal Work Hours

1.15.2 Work Outside of Normal Hours

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 PHOTOGRAPHIC DOCUMENTATION

3.2 MOBILIZATION PLAN

3.3 PROJECT SIGN

3.4 TRAFFIC CONTROL

3.4.1 Haul Routes

3.4.2 Road Closures

3.5 CONTRACTOR SITE FACILITIES

3.5.1 Contractor Offices

3.5.1.1 Site Facilities - Other Than JOC Projects

3.5.1.2 Site Facilities - JOC Projects

3.5.2 Construction Fence/Screening

3.5.3 Maintenance of Construction Site

3.5.4 Storage Areas

3.5.5 Physical Security

SECTION 01 30 01 Page 1

3.5.6 Washing of Vehicles

3.6 ENVIRONMENTAL PROTECTION

3.6.1 Environmental Protection Plan

3.6.2 Protection of Personnel

3.6.3 Protection of Land Resources

3.6.4 Protection of Water Resources

3.6.5 Spillage

3.6.6 Dust Control

3.7 MATERIALS

3.7.1 Hazardous Materials

3.7.2 Recycling and Minimization of Waste

3.8 EXCLUSIONS

3.8.1 Prohibited Materials

3.8.2 Hazardous Materials

3.8.3 Explosive Materials

3.8.4 Burning

3.9 PROTECTIVE MEASURES

3.10 UTILITY OUTAGES

3.11 TEMPORARY CONSTRUCTION AND UTILITIES

3.11.1 Temporary Utilities

3.11.2 Temporary Construction

3.12 EXCAVATION

3.12.1 Permission to Excavate

3.12.2 Utility Locations

3.12.3 Utility Location Verification

3.12.4 Weather Protection

3.13 UNEXPLODED ORDNANCE

3.14 DISPOSITION OF MATERIALS

3.14.1 Turn-In Salvage Materials

3.14.2 Title to Materials

3.14.3 Waste

3.15 RESTORATION OF CONSTRUCTION SITE

SECTION 01 30 01 Page 2

SECTION 01 30 01

GENERAL REQUIREMENTS (NAU)

02/20

PART 1 GENERAL

1.1 PURPOSE

This specification provides general requirements which the contractor shall follow during the execution of the work. As they are general in nature, specific requirements identified in any other portions of the contract, including in other Division 01 specifications, shall take precedence in the event of a conflict. In this context, a conflict exists only when both requirements cannot be met; if both can be met there is no conflict and the contractor shall comply with both requirements.

1.2 DESIGN AND DESIGN RELATED WORK

1.2.1 Design-Build Language

References in the Division 00 and 01 specifications to "design-build" are not applicable to Job Order Contract (JOC) projects and task orders.

Nothing in the aforementioned specifications shall be interpreted to require design effort unless required by other contract documents.

Where contract documents refer to contractor prepared designs, "design-build" requirements identified in these specifications apply.

1.2.2 Design Related Activities

Notwithstanding the above, design related activities, including extensions of design and shop drawings, required to perform the work and comply with other technical requirements are considered part of this contract and shall be included in the contractors pricing. No separate or additional payment will be made for the performance of this effort.

1.2.3 Performance Requirements

Where this contract includes performance requirements or otherwise establishes parameters such as operating parameters, sequences of operation, or coordination of equipment or systems, that requires the contractor to identify, size, select, prepare and submit for review or approval equipment and materials, the contractor is required to perform all efforts necessary to accomplish this effort as part of the contract.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Pre-construction photos;

Mobilization Plan; G Environmental Protection Plan; G

SECTION 01 30 01 Page 3

Traffic Control Plan; G Construction Fence/Screening; G Temporary Construction Plan; G

SD-03 Product Data

Hazardous Materials; G

1.4 DEFINITIONS

The following definitions apply to terms as used in the sections identified above in paragraph 1.1. These definitions shall not change or infer a meaning in any other document made part of this contract either directly or via reference.

Fugitive Dust. Solid particles generated by the forces of wind or machinery acting upon materials exposed as a result of the contractors operations

Installation. The entity considered to be the legal owner or authorized user of the location of the construction work.

Project. A "Project" is a single task or delivery order under an Indefinite Delivery, Indefinite Quantity award, including Job Order Contracts (JOC's) and Multiple Award Task Order Contracts (MATOCs). For all other contracts, it refers to a single contract award.

Superintendent. The highest level manager responsible for the overall construction activities on a project, including quality and production. The Superintendent maintains a physical presence at the site at all times work is being performed and is responsible for all construction and related activities at the site, except as otherwise acceptable to the Contracting Officer.

Site. The location where construction work physically occurs. On a single project, when construction work occurs at more than one location, and the locations are geographically separated by more than 5 kilometers (as measured via travel distance), they are considered separate sites.

1.5 NO WAIVER BY GOVERNMENT

The failure of the Government, in any one or more instances, to insist upon the strict performance of any of the terms of this Contract or to exercise any option herein conferred shall not be construed as a waiver or relinquishment to any extent of the right to assert or rely upon such terms or option on any future occasion.

1.6 PROPRIETARY NAMES

Unless specifically identified in the contract as a Sole Source Item, manufacturer's proprietary names indicated for colors, textures and patterns of materials are for the purpose of color, texture and pattern selection only. Other materials are acceptable provided they closely approximate colors, textures and patterns indicated. Any substitutions must conform to all other requirements and must be approved by the Contracting Officer

1.7 PUBLIC RELEASE OF INFORMATION

1.7.1 Prohibition

There shall be no public release of information, documents, or

SECTION 01 30 01 Page 4 photographs concerning any aspect of the materials or services relating to this project without the prior written approval of the Contracting Officer.

1.7.2 Subcontracts and Purchase Orders

The Contractor agrees to insert…