Attachment A - OSP Final Philippines.pdf

OFFEROR SUBMISSION PACKAGE SOLICITATION: SPE605-21-R-0219

PURCHASE PROGRAM: 1.6P Philippines

THE ENCLOSED SOLICITATION COVERS THE PERIOD:

ORDERING PERIOD

01 JANUARY 2022 THROUGH 31 DECEMBER 2026

DELIVERY PERIOD

48 HOURS AFTER DATE OF AWARD THROUGH 31 DECEMBER 2026

TO BE TIMELY, OFFERS MUST BE RECEIVED AT THE DLA ENERGY CENTER BY:

JULY 15, 2021; 3:00 PM, EASTERN STANDARD TIME (EST) FT. BELVOIR, VA LOCAL TIME

OFFERS MUST BE ACCOMPANIED BY SPECIFICATION SHEETS FOR THE TYPES OF FUEL OFFERED

OR WILL NOT BE CONSIDERED FOR EVALUATION.

All documents to be completed and returned are contained in this Offer Submission Package: X Signed Letter on Company Letter Head stating that your company agrees to all the terms and conditions of Solicitation SPE605-21-R-0219 and that all applicable taxes are included in offer prices. An Officer of the Company must sign this letter

NOTE: Clause K33.01 AUTHORIZED NEGOTIATORS (DLA ENERGY APR 2007 only authorizes other designated employees to prepare offers and conduct negotiations with the Contracting Officer or his designated Government representative in lieu of an Officer of the Company.

X All applicable fill-in clauses. Please type in all prices.

Please be sure to proofread all offers for accuracy and legibility prior to submission and Initial all changes. ALL PAGES

MUST SHOW SOLICITATION NUMBER AND OFFEROR’S COMPANY NAME. ALL PAGES MUST BE

RETURNED.

By submission of this package, you are stating that all terms and conditions of the entire solicitation are accepted and apply to your offer unless clearly stated herein and in a formal letter accompanying this OSP on company letterhead with a full explanation of ALL exceptions be taken and what is proposed instead. The Offeror should be prepared to provide a cost savings summary to the Government for review based on any exceptions submitted.

________Initial here -OFFERORS ARE RESPONSIBLE FOR CONFIRMING THE APPLICABILITY OF TAXES AND TAX RATES WITH THE STATE OR LOCAL TAX AUTHORITIES. OFFERORS ARE ADVISED THAT OFFER

PRICES SHOULD INCLUDE ALL APPLICABLE TAXES AND FEES AND ALL OTHER COSTS ARISING

FROM CONTRACTOR'S PERFORMANCE OF THE CONTRACT, WHERE NO U.S. GOVERNMENT OR

DEPARTMENT OF DEFENSE EXEMPTION APPLIES.

COMPANY NAME: _____________________________

SPE605-21-R-0219

SOURCE SELECTION INFORMATION - SEE FAR 2.101 AND 3.104

Table of Contents

SECTION F

F3 TRANSPORT TRUCK AND/OR TRUCK AND TRAILER FREE TIME AND DETENTION RATES (PC&S)

(DLA ENERGY AUG 2005)

F3.03 NOTIFICATION OF CHANGE IN TRANSPORTATION COMPANY (PC&S) (DLA Energy APR 2005)

SECTION G

G9.06 ADDRESS TO WHICH REMITTANCE SHOULD BE MAILED (DLA ENERGY JAN 2017)

G9.07-5 ELECTRONIC TRANSFER OF FUNDS PAYMENTS – FEDERAL RESERVE WIRE TRANSFER

SYSTEM (DLA ENERGY JAN 2012)

SECTION I

DFARS 252.229-7001 Tax Relief-BASIC (APR 2020)

SECTION K

FAR 52.203-2 -- Certificate of Independent Price Determination (Apr 1985)

FAR 52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions

FAR 52.204-16 Commercial and Government Entity Code Reporting

FAR 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Oct 2020)

FAR 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Aug 2020)

FAR 52.204-26 Covered Telecommunications Equipment or Services Representation (Oct 2020)

FAR 52.209-5 Certification Regarding Responsibility Matters

FAR 52.209-7 –Information Regarding Responsibility Matters (Oct 2018)

FAR 52.212-3 -- Offeror Representations and Certifications -- Commercial Items. (Feb 2021)

FAR 52.222-18 -- Certification Regarding Knowledge of Child Labor for Listed End Products.(Feb 2001)

DFARS 252.204-7016 Covered Defense Telecommunications Equipment or Services-Representation (Dec 2019)

DFARS 252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services- Representation (May 2021)

DFARS 252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services (Jan 2021)

DFARS 252.225-7020 Trade Agreements Certificate. (NOV 2014)

DFARS 252.247-7022 Representation of Extent of Transportation by Sea. (JUN 2019)

K33.01 AUTHORIZED NEGOTIATORS (DLA ENERGY APR 2007)

K86 FOREIGN TAXES (DLA ENERGY NOV 2014)

SECTION L

L117 NOTIFICATION OF TRANSPORTATION COMPANY TO BE UTILIZED IN THE DELIVERY OF

PRODUCT (PC&S) (DLA ENERGY JAN 2012)

SECTION F

F3 TRANSPORT TRUCK AND/OR TRUCK AND TRAILER FREE TIME AND DETENTION RATES

(PC&S) (DLA ENERGY AUG 2005)

(a) Upon arrival of Contractor's transport truck or truck and trailer, the receiving activity shall promptly designate the tanks into which the load is to be discharged. Free time will commence when the discharge hose is connected to the receiving line at the delivery point and will end when discharge is completed. The Contractor shall be paid for detention beyond free time for delays caused by the Government. A minimum of one hour free time is required.

(1) Free time for unloading a transport truck or truck and trailer (includes one hour minimum plus any additional time): _______________________________________________.

(2) Rate for detention beyond free time:

The above will not be considered in the evaluation of offers for award except that a free time of less than one hour may render an offer unacceptable. Notwithstanding the above, the Government is entitled to at least as much free time as is allowed by the common carrier or that the Contractor normally allows its regular commercial customers, whichever is greater. Free time only applies to single-drop deliveries (it is not applicable to multiple-drop tank truck/truck and trailer deliveries or any tank wagon deliveries).

(b) Notwithstanding the above, the Government will not pay more in detention rates than the actual rate charged by the common carrier or the rate the Contractor normally charges its regular commercial customers, whichever is lower. Detention costs will be the sole responsibility of the activity incurring them and are only allowable on single drop deliveries (they are not allowable on multiple drop tank truck/truck and trailer deliveries or any tank wagon deliveries.

Invoices for detention costs will be submitted by the Contractor directly to the activity receiving the product. These provisions are applicable to DLA-owned/capitalized as well as non-DLA-owned/noncapitalized products.

(c) UNLESS THE OFFEROR OTHERWISE INDICATES IN PARAGRAPHS (a)(1) AND (a)(2) ABOVE, FREE TIME WILL BE CONSIDERED UNLIMITED AND DETENTION COSTS WILL NOT BE CHARGEABLE.

F3.03 NOTIFICATION OF CHANGE IN TRANSPORTATION COMPANY (PC&S) (DLA Energy APR 2005)

(a) In the performance of this contract, the Contractor agrees not to utilize transportation companies that have been debarred or suspended, are ineligible for receipt of contracts with Government agencies, are in receipt of a notice of proposed debarment or ineligibility from any Government agency, or are otherwise ineligible under Federal programs.

Substitution of a new transportation company is subject to review by the Contracting Officer for use under this contract.

(b) If the Contractor changes transporters after award, the Contractor shall provide the Contracting Officer with the following information on alternative or new transportation company(ies) being utilized in the transportation of supplies under this contract.

Name, Address, and Phone Number State(s) in which transporter of Transportation Company is authorized to operate

SECTION G

G9.06 ADDRESS TO WHICH REMITTANCE SHOULD BE MAILED (DLA ENERGY JAN 2017)

Remittances shall be mailed only at the Government’s option or where an exception to payment by Electronic Funds Transfer (EFT) applies. (See the PAYMENT BY ELECTRONIC FUNDS TRANSFER – SYSTEM FOR AWARD MANAGEMENT or the PAYMENT BY ELECTRONIC FUNDS TRANSFER - OTHER THAN SYSTEM FOR AWARD MANAGEMENT clause.)

Offeror shall indicate below the complete mailing address (including the nine-digit zip code) to which remittances should be mailed if such address is other than that shown in Block 15a (Standard Form (SF) 33) for noncommercial items or Block 17a (SF 1449) for commercial items. In addition, if offeror did not incorporate its nine-digit zip code in the address shown in Block 15a of the SF 33 or in Block 17a of the SF 1449, the offeror shall enter it below:

(a) Payee Name (Contractor): | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

(b) Check Remittance Address:

(DO NOT EXCEED 30 CHARACTERS PER LINE)

(c) Narrative Information (special instructions).

(DO NOT EXCEED 153 CHARACTERS)

G9.07-5 ELECTRONIC TRANSFER OF FUNDS PAYMENTS – FEDERAL RESERVE WIRE TRANSFER

SYSTEM (DLA ENERGY JAN 2012)

(a) The Contractor shall supply the following information to the Contracting Officer no later than 5 days after contract award and before submission of the first request for payment. The bank designated as the receiving bank must be capable of receiving Federal wire transactions via either a SWIFT Code or an IBAN.

(b) Any change by the Contractor in the designation of the bank account to receive electronic transfer of funds in accordance with this contract text must be received by the Contracting Officer no later than 30 days prior to the date the change is to become effective.

(c) The electronic transfer of funds does not constitute an assignment of such funds in any form or fashion.

COMPLETE THE FOLLOWING INFORMATION (TYPE WRITTEN OR CLEAR PRINTING)

RECIPIENT’S NAME: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

ORIGINATOR ABA: ____044036205____ (DLA ENERGY fill-in)

CONTRACT NUMBER: ______________________________________________ (DLA ENERGY fill-in)

RECIPIENT’S CAGE CODE: __________________

[ ] CHECKING TYPE 22

[ ] SAVINGS TYPE 32

RECIPIENT’S DUNS NUMBER: ______________________________________

BENEFICIARY’S BANK NAME: | | | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 29 CHARACTERS)

BENEFICIARY’S BANK ADDRESS: | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

(DO NOT EXCEED 25 CHARACTERS)

BENEFICIARY’S BANK ACCOUNT NUMBER: ______________________________________

BENEFICIARY’S BANK SWIFT NUMBER: | | | | | | | | | | | |

(EITHER 8 OR 11 CHARACTERS ONLY)

IBAN NUMBER: ______________________________________

BENEFICIARY’S BANK SORT CODE: | | | | | | | (FOR BANKS IN THE UNITED KINGDOM

ONLY)

(6 CHARACTERS ONLY)

(d) CONTRACTOR’S DESIGNATED OFFICIAL SUBMITTING ELECTRONIC FUNDS TRANSFER

INFORMATION.

NAME | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

TITLE | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

TELEPHONE NUMBER | | | | | | | | | | | | | | | | | | | | | | | | | |

(DO NOT EXCEED 25 CHARACTERS)

SIGNATURE ___________________________________________________________

(e) Notwithstanding any other provision of the contract, the requirements of this contract text shall control.

INTENTIONALLY LEFT BLANK

SECTION I

DFARS 252.229-7001 TAX RELIEF—BASIC (APR 2020)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor’s government.

The following taxes or duties have been excluded from the contract price:

NAME OF TAX: (Offeror insert) RATE (PERCENTAGE): (Offeror insert)

(b) Invoices submitted in accordance with the terms and conditions of this contract shall be exclusive of all taxes or duties for which relief is available. The Contractor’s invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government’s exemption from these taxes. The Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

(End of clause)

SECTION K

FAR 52.203-2 -- Certificate of Independent Price Determination (Apr 1985)

(a) The offeror certifies that --

(1) The prices in this offer have been arrived at independently, without, for the purpose of restricting competition, any consultation, communication, or agreement with any other offeror or competitor relating to --

(i) Those prices;

(ii) The intention to submit an offer; or

(iii) The methods or factors used to calculate the prices offered.

(2) The prices in this offer have not been and will not be knowingly disclosed by the offeror, directly or indirectly, to any other offeror or competitor before bid opening (in the case of a sealed bid solicitation) or contract award (in the case of a negotiated solicitation) unless otherwise required by law; and

(3) No attempt has been made or will be made by the offeror to induce any other concern to submit or not to submit an offer for the purpose of restricting competition.

(b) Each signature on the offer is considered to be a certification by the signatory that the signatory --

(1) Is the person in the offeror’s organization responsible for determining the prices being offered in this bid or proposal, and that the signatory has not participated and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision; or

(2)

(i) Has been authorized, in writing, to act as agent for the following principals in certifying that those principals have not participated, and will not participate in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision ____________________ [insert full name of person(s) in the offeror’s organization responsible for determining the prices offered in this bid or proposal, and the title of his or her position in the offeror’s organization];

(ii) As an authorized agent, does certify that the principals named in subdivision (b)(2)(i) of this provision have not participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision; and

(iii) As an agent, has not personally participated, and will not participate, in any action contrary to subparagraphs (a)(1) through (a)(3) of this provision.

(c) If the offeror deletes or modifies subparagraph (a)(2) of this provision, the offeror must furnish with its offer a signed statement setting forth in detail the circumstances of the disclosure.

FAR 52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.

(Sept 2007)

(a) Definitions. As used in this provision-“Lobbying contact” has the meaning provided at 2 U.S.C. 1602(8). The terms “agency,” “influencing or attempting to influence,” “officer or employee of an agency,” “person,” “reasonable compensation,” and “regularly employed” are defined in the FAR clause of this solicitation entitled “Limitation on Payments to Influence Certain Federal Transactions” (52.203-12).

(b) Prohibition. The prohibition and exceptions contained in the FAR clause of this solicitation entitled “Limitation on Payments to Influence Certain Federal Transactions” (52.203-12) are hereby incorporated by reference in this provision.

(c) Certification. The offeror, by signing its offer, hereby certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on its behalf in connection with the awarding of this contract.

(d) Disclosure. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/content/52203-12-limitation-payments-influence-certain-federal-transactions#i1063429 https://www.acquisition.gov/content/52203-12-limitation-payments-influence-certain-federal-transactions#i1063429

(e) Penalty. Submission of this certification and disclosure is a prerequisite for making or entering into this contract imposed by 31 U.S.C. 1352.Any person who makes an expenditure prohibited under this provision or who fails to file or amend the disclosure required to be filed or amended by this provision, shall be subject to a civil penalty of not less than $10,000, and not more than $100,000, for each such failure.

FAR 52.204-16 Commercial and Government Entity Code Reporting (Aug 2020)

(a) Definition. As used in this provision –

Commercial and Government Entity (CAGE) code means–

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its proposal. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via–

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process.

SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Contractor and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the Offeror does not otherwise register in SAM, an Offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity’s country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE code is required for the immediate owner and/or the highest-level owner by Federal Acquisition Regulation (FAR) 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE code from that entity to supply the CAGE code to the Government.

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.sam.gov/ https://cage.dla.mil/ https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx http://www.nato.int/structur/AC/135/main/links/contacts.htm https://cage.dla.mil/ https://www.acquisition.gov/far/52.204-17#FAR_52_204_17 https://www.acquisition.gov/far/52.212-3#FAR_52_212_3

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(g) If the solicitation includes FAR clause 52.204-2, Security Requirements, a subcontractor requiring access to classified information under a contract shall be identified with a CAGE code on the DD Form 254. The Contractor shall require a subcontractor requiring access to classified information to provide its CAGE code with its name and location address or otherwise include it prominently in the proposal. Each location of subcontractor performance listed on the DD Form 254 is required to reflect a corresponding unique CAGE code for each listed location unless the work is being performed at a Government facility, in which case the agency location code shall be used. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

(End of provision)

FAR 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Oct 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to— https://www.acquisition.gov/far/52.204-2#FAR_52_204_2

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(d) Representation. The Offeror represents that—

(1) It □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It □ does, □ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

FAR 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Aug 2020)

(a) Definitions. As used in this clause—

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People’s Republic of China.

Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement. (1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting

Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

FAR 52.204-26 Covered Telecommunications Equipment or Services-Representation (Oct 2020)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c) (1) Representation. The Offeror represents that it □ does, □ does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it □ does, □ does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

FAR 52.209-5 Certification Regarding Responsibility Matters (Aug 2020)

(a)

(1) The Offeror certifies, to the best of its knowledge and belief, that—

(i) The Offeror and/or any of its Principals–

(A) Are □ are not □ presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have □ have not □, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks "have", the offeror shall also see 52.209-7, if included in this solicitation);

(C) Are □ are not □ presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision;

(D) Have □, have not □, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds the threshold at 9.104-5(a)(2) for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples.

(i) The taxpayer has received a statutory notice of deficiency, under I.R.C. § 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. § 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. § 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has □ has not □, within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

https://www.acquisition.gov/far/52.209-7#FAR_52_209_7 https://www.acquisition.gov/far/9.104-5#FAR_9_104_5

(2) "Principal," for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror’s responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

FAR 52.209-7 –Information Regarding Responsibility Matters (Oct 2018)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management which can be accessed via https://www.sam.gov (see 52.204-7).

FAR 52.212-3 Offeror Representations and Certifications-Commercial Items (Feb 2021)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (v)) of this provision.

(a) Definitions. As used in this provision—

Covered telecommunications equipment or services has the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

https://www.sam.gov/

Forced or indentured child labor means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror.