Attachment 1 - SOW.pdf

Defense Logistics Agency

DLA Installation Management Richmond

DM-FRIE

Lawn Irrigation Infrastructure Project

B46 & B47 P.2026.00622

STATEMENT OF WORK (SOW)

1. OBJECTIVES

The objective of this project is to provide a complete turnkey installation of an automatic lawn irrigation system covering an approximate area of 95,000 square feet at Buildings 46 and 47 to support proper establishment, growth, and long-term maintenance of newly installed sod and landscaped areas. The irrigation system shall provide adequate and uniform water coverage to all designated lawn areas.

2. BACKGROUND

Buildings 46 and 47 currently do not have an automated irrigation system to support landscape maintenance and sod establishment. Existing lawn areas require manual watering methods, which have proven inefficient and insufficient to maintain healthy vegetation during seasonal conditions.

The absence of a dedicated irrigation system has increased the risk of sod deterioration, uneven growth, and excessive maintenance requirements.

This project is required to improve landscape sustainability, preserve government property assets, and ensure proper irrigation coverage for all designated grass and landscaped areas surrounding Buildings 46 and 47.

3. SPECIFIC REQUIREMENTS

The Contractor shall furnish all labor, materials, equipment, supervision, transportation, permits, and incidentals necessary to provide a complete turnkey irrigation system installation.

The Contractor shall:

• Install a fully operational underground automatic irrigation system for Buildings 46 and 47.

• Provide as-built drawings identifying irrigation piping routes, valve locations, controllers, and sprinkler zones.

• Provide all Schedule 80 PVC piping, Schedule 80 PVC fittings, sprinkler heads, valves, wiring, controllers, backflow preventer (RPZ), pressure reducing valve (PRV) and associated components required for a complete and functional system.

• All PVC connections shall be joined using the appropriate, manufacturer-recommended primer and heavy-duty solvent cement (glue) specifically rated for schedule 80 PVC. All components must be weather resistant and commercial grade.

• Provide and install gear-driven rotary sprinkler heads and a zoned distribution network to ensure 100% coverage. The Contractor shall provide the PM with any tools that came with the sprinkler heads.

• The Contractor shall implement overlapping spray to the adjacent head to prevent dry spots from occurring.

• Provide and install a master control valve and all required primary zone valves as a part of the complete irrigation system.

• Provide and install a standalone programmable irrigation controller. The controller operate independently and shall not require internet, Wi-Fi, cellular, or other remote connectivity.

All programming and adjustments shall be performed locally at the controller.

• Valves shall be sized appropriately for the irrigation system and shall be compatible with the irrigation controller and system operating pressures.

• All valves shall be installed below grade within manufacturer approved, heavy-duty jumbo valve boxes designed for irrigation applications.

• Valve boxes shall be equipped with secure lockable lids and installed flush with the finished grade.

• The Contractor shall provide and securely affix permanent identification tags to all irrigation zone valves and isolation valves.

• Tags shall be constructed of heavy duty, UV resistant polyurethane. Each tag shall be secured to the valve body utilizing heavy duty cable ties and shall be marked with the controller designation and station number.

• The Contractor shall provide and install direct burial, multi conductor, 18-gauge stranded copper irrigation control wire from the irrigation controller to all field devices.

• Wire shall be continuous where practical, waterproof- spliced as required, and tested for continuity prior to system acceptance. This testing must be initiated and completed in the presence of the PM. Provide two business days’ notice.

• All splices, terminations, and connections shall be waterproof and installed per manufacture’s recommendations.

• The Contractor shall test the tracer wire system prior to any backfilling with the approval of the Project Manager. Provide two business days’ notice for this testing.

• The Contractor shall install protective sleeving for any PVC piping that penetrates building foundations. All foundation penetrations shall be properly sealed and waterproofed using industry standard, approved sealants to prevent intrusion and maintain structural integrity.

• The Contractor shall bury all main water lines and pressurized lines at a minimum depth of 18-24 inches below finished grade. All non-pressure lateral zone piping shall be buried at a minimum depth of 12 inches below finished grade.

• Any pipes running under roads and parking lots shall be routed through schedule 80 PVC sleeves and buried at a minimum of 18 to 24 inches

• The Contractor shall perform irrigation distribution uniformity testing using the catch-can method to verify proper sprinkler coverage and system performance.

• Install weather-resistant and commercial-grade irrigation components suitable for long-term outdoor use.

• The Contractor shall repair and restore all disturbed surfaces, landscaping, pavement, and turf impacted during project execution.

• The Contractor shall also ensure all grass and sod areas are fully established prior to final project completion and Government acceptance.

• The Contractor shall conduct hydrostatic pressure testing at 150 PSI or 1.5 times the systems normal operating pressure, on the mainlines for two continuous hours to verify no leaks or pressure deficiencies. This testing must be initiated and completed in the presence of the PM. Provide two business days’ notice.

• Tests must be conducted prior to backfilling so all joints can be visually inspected for leaks with the approval of the Project Manager. This testing must be initiated and completed in the presence of the PM. Provide two business days’ notice.

• All trenches shall be backfilled, tamp soil, and restore all grass.

• The Contractor shall install a dedicated compressed air blowout connection assembly, “quick connect air fitting and isolation valve” at the main water sources or manifolds to facilitate routine seasonal winterization and prevent freeze damage to the system.

• The Contractor shall install a Reduced Pressure Zone (RPZ) backflow preventer and a pressure-reducing valve (PRV) on the irrigation system service line. The RPZ assembly shall be sized and installed in accordance with applicable plumbing codes to protect the potable water supply from contamination.

• The pressure reducing valve shall be sized and adjusted to maintain irrigation system operating pressure within the manufacture’s recommended limits and protect all irrigation piping, valves, fittings, and sprinkler heads from excessive pressures.

• The Contractor shall ensure the RPZ is tested, certified, and documented by a licensed backflow tester. This testing must be initiated and completed in the presence of the PM.

Provide two business days’ notice.

• Provide on-site training for government personnel regarding system operation and basic maintenance procedures. Training shall be initiated and completed in the presence of the PM.

Provide two business days’ notice.

• Remove and properly dispose of all debris generated during project execution.

• Ensure all work complies with applicable federal, state, local, and industry standards.

2. CONTRACTOR QUALIFICATIONS

The Contractor shall possess demonstrated experience in commercial irrigation system installation projects of similar size and complexity.

The Contractor shall:

• Have a minimum of five (5) years of experience installing commercial irrigation systems.

• Employ qualified personnel and trained in irrigation system installation and troubleshooting.

• The Contractor shall possess a valid backflow certification prior to commencement of work.

• Be knowledgeable in underground utility protection and excavation safety procedures.

• Maintain adequate insurance coverage throughout the duration of the project.

• Ensure all personnel comply with installation access requirements and applicable facility safety regulations.

2. PERIOD OF PERFORMANCE

Completion date shall be no later than 90 days after notice to proceed.

3. POINTS OF CONTACT

Project Manager (PM)/Sponsor/Contracting Officer Representative (COR) Name: Orville Ray Massey Jr. (Ramey) Cell Phone: (804) 921-6694 Email: orville.massey@dla.mil DLA Installation Management Richmond 6090 Strathmore Rd.

Richmond, Virginia 23237

4. PROPOSAL EVALUATION

The proposal/quote and all documentation received by the Government from the contractor before the solicitation end date will be reviewed and evaluated based on the criteria listed below. The submission will be deemed either technically acceptable or technically unacceptable. The contractor is required to provide all documentation at the time of the submission and before the solicitation end date. Failure to provide all required documents will result in the contractor’s proposal/offer being technically unacceptable.

Technically Acceptable – meets the minimum requirement and contains no deficiencies.

Demonstrates an understanding of the services required to meet or exceed the contract requirements. An acceptable quality level of contract performance is anticipated.

Technically Unacceptable – does not meet the minimum requirement and contains one or more deficiencies and/or omissions. Failure to demonstrate an understanding of the services required to meet the contract requirements. The acceptable quality level of contract performance is not anticipated.

The following is a list of documents that shall be provided as separate PDF and/or hardcopy documents along with the proposal:

Project narrative

• A narrative outlining the way the contractor is planning to accomplish the project

• A list of definable features of work

• Projected timeline for each DFOW

Previous relevant project experience

• Provide a minimum of 5 projects completed within the last 5 years related to this SOW

• Award amounts

• Project descriptions

• POC information

• Contract number or unique identifier

5. IMPORTANT CONSIDERATIONS

Administrative

a. Technical correspondence (where technical issues relate to compliance with the requirements herein) will be addressed to the Contracting Officer with an information copy to the Contracting Officer Representative/Project Manager/Facility Operations Specialist

(COR/PM).

b. The contractor awarded this contract shall always have the Quality Control system Manager (CQC-SM) onsite when work is being performed. Onsite is defined as the actually work location where work is being performed, not in a vehicle, trailer etc. Government employees overseeing this project (PM, COR, Safety, etc.) reserve the right to order a stop work order if the contractor QC manager is not onsite while work is being performed. Provide the name(s) of the QC Manager to the PM/KO in writing (submittal required) within 10 business days of the start of work. The government will not be responsible for any additional costs incurred by the contractor if a stop work order is issued.

c. All other correspondence, including invoices (which propose or otherwise involve waivers, deviations or modifications to the requirements, terms, or conditions of this SOW) will be addressed to the COR/PM with an information copy to the Contracting Officer.

d. Upon any invoice submission into WAWF the contractor must email the PM/COR to inform them that an invoice has been submitted for approval. The government will not be responsible for any late fees if the contractor fails to follow-up.

e. All documentation, records, and schedules, as described in this SOW, are the responsibility of the Contractor and the property of the Government and shall remain so upon termination or completion of the contract. The Contractor shall keep these items current.

f. The contractor shall always keep conditions in mind throughout the life of this contract.

Whenever weather conditions indicate strong winds, tornadoes, hurricanes etc. the contractor shall take all necessary action to prevent all materials, debris etc. from becoming flying hazards. Any damage or harm caused by contractor material, debris etc. will be the sole responsibility of the contractor at no cost to the Government.

g. Weather delays for a contract extension will only be considered if the following conditions are met. The delay must be a minimum of 4 hours that impacts the critical path of the project. The delay and reason why the contractor believe they are entitled to a delay must be documented in the daily report for that day and must be submitted by 8:00am the next business day. The contractor must send a separate email to the PM and KO explaining why they believe a delay is warranted by 8:00am the next business day. Requests for weather delays received after the above timeline will be denied.

h. The Contractor should conduct a site visit to each location to verify all measurements, sizes, interferences, quantity of material etc. for this project. It’s the contractors responsibility to confirm all measurements. The contractor shall verify via email if they will be attending any scheduled site visit with the COR/PM and the contracting officer at least 2 business days ahead of the site visit.

i. The contractor shall propose a phasing work schedule for work being performed in occupied spaces for government comment, changes and approval.

j. For all meetings conducted by the contractor via internet the contractor shall use Microsoft Teams. A call-in telephone number shall be provided for those without computer access.

k. For all government inspections, meetings etc. the contractor shall send a Microsoft Outlook invite to COR/PMs within the specified timelines. Set the reminder time in Outlook to a minimum of 4 hours ahead inspections, meetings etc.

l. The contractor shall provide the minutes of all meetings the same day the meeting was held.

m. Music of any kind is not permitted. Use of any ears buds or the like is prohibited.

General & Construction

a. The contractor is required to and shall adhere to The Buy American Act.

b. The contractor is responsible for all materials, hardware, tools, labor, equipment, etc. pertaining to execution of work under this SOW unless otherwise specified.

c. All demolished and excess dirt/materials/etc. shall be removed from the premises of the installation. The areas that were disturbed shall be fixed to restore original condition.

d. All hardware and equipment shall be tested, started up and fully operational after turnover.

e. The contractor shall consider ALL electrical, mechanical, plumbing, security or any other interferences that may impede their work are considered part of the SOW and contract requirements. The contractor shall remove, disable, relocate etc. all interferences as needed ensuring all items function as they were intended to at the conclusion of the contract. All items that need to be terminated for any reason are the responsibility of the contractor.

f. Anytime any electrical work is completed the contractor shall update all affected panel schedules. The contractor shall rewrite (type written) the entire panel schedule(s) completely. Any new or replaced receptacles, switches, and any other electrical equipment shall receive a type of written tag with panel name/number and circuit number of the panel/circuit that it is fed by. The location of the tag is to be confirmed with the COR/PM.

Place the old panel schedule behind the new one.

g. Prior to submitting their proposal, the contractor shall confirm/verify any new equipment, components, plumbing, circuits, voltage, phasing, wiring, or other systems, are compatible with the existing infrastructure. This assessment must confirm that the current structural, mechanical, electrical, and plumbing systems are adequate to support the proposed additions and modifications. The Contractor shall verify that all new installations will function correctly, efficiently, and at full capacity without compromising safety, performance, or compliance with applicable codes, regulations, and manufacturer specifications. Any deficiencies or limitations identified during this assessment must be promptly reported to the Contracting Officer and Project Manager via request for information. If the contractor fails to identify any issues the contractor shall be responsible for any additions, modifications etc. to the existing infrastructure components at no cost to the government.

h. Anytime any utilities (water, heat, AC, gas, electric etc.) need to be shut down for any period of time during the duration of the contract, the contractor shall provide 14 calendar day advance notice to the COR/PM.

i. All new openings that are to receive a frame and door(s) or any door/frame that was replaced shall receive a typewritten tag indicating the door number. The contractor is to request the correct door number and installation location from COR/PM in case the tag is missing, or the opening was a new requirement.

j. If the contractor needs water to fill a tank for use on DSCR they may use the hydrant near building 80, which is already equipped with a backflow preventor.

k. If the above hydrant or backflow preventor is not available, the contractor shall provide a back flow preventer for use on any hydrant, with approval from the PM. The contractor shall provide documentation that the back flow preventer has been inspected within the previous six months prior to using the hydrant and keep this six-month inspection interval for the length of the contract. In addition to this documentation, DSCR Maintenance personnel will also inspect the backflow preventer on the hydrant the contractor plans to use. This additional testing will take approximately 15 minutes. Provide the PM 3 business days’ notice so this DSCR inspection can be scheduled. No hydrant shall be used without the proper documentation. The contractor shall provide the Government COR/PM three business day notice if they will need to access a hydrant. The contractor shall fill out and submit to the COR/PM the hydrant application 3 business days in advance. The application must be approved by the fire department and a copy provided to the contractor prior to hydrant use. At no time will the contractor use the hydrant without an approved hydrant application. The Contractor shall instruct employees in utilities conservation practices. The Contractor shall be responsible for operating under conditions that preclude the waste of utilities, which include turning off the water faucets or valves after using the required amount of water to accomplish cleaning vehicles and equipment etc.

l. Any door locks or hardware required shall accept Best cores using the Best 7-pin lock system, heavy duty series for the core and cylinder. The contractor shall provide a core for each lock provided pre-pinned to DSCR specifications. Contact the PM 60 days before the final inspection to obtain the pin schedule. The contractor shall have the pinned cores mailed directly to the FRIM shop supervisor. The mailing shall have a tracking number.

m. The Contractor shall diligently prosecute their work and must always maintain an adequate workforce for the uninterrupted performance of all tasks defined within this SOW when the Government facility is not closed for any reason.

n. The contractor is forbidden to use any government equipment or tools, i.e. ladders, lifts, etc.

unless the contractor’s use of government tools and/or equipment is expressly permitted in this SOW. If any government employee offers the contractor use of any government tools, equipment, lifts, etc. they shall not use the items and report the incident to the contracting officer and COR/PM immediately.

o. The contractor shall provide and allow the use of contractor equipment, ladders, tools, lifts (including operator and fall protection), for government use to conduct all inspections.

p. The contractor shall provide portable sanitary facilities which will be used by the contractor’s personnel and will be the responsibility of the contractor. Upon completion of the project all portable sanitary facilities shall be removed from the installation. No contractor personnel are allowed to use government restrooms unless approved by the PM.

q. Anytime there is a chance dust could be created by the contractor a MERV 8 filter shall be installed over all HVAC returns to prevent dust from entering the HVAC system. If the contractor fails to install these filters, they will need to have the HVAC system and all ducts professionally cleaned by a third party at no cost to the government.

r. Whenever carpet tile, vinyl composite tile, ceramic tile or any other tile is being installed all borders edges must be of the same dimension.

s. For concrete provided by a ready-mix truck, the contractor has 90 minutes to complete the discharge of the entire concrete load, from the time water is introduced into the mix. When the 90 minute mark has been reached no further concrete will be discharged from the truck.

6. PRE-CONSTRUCTION MEETING

After the award, and prior to the pre-construction meeting, the contractor shall provide a Site- Specific Safety Plan, their OSHA 300A Logs, Activity Hazard Analyses, and Quality Control Plan, via email in PDF format. Send the three safety documents in one email (separate pdf’s) at the same time for review and approval by the DLA Weapons Support Safety Office and DLA PM/COR.

After the award and prior to the initiation of work, a pre-construction meeting will be held in person on DSCR. At a minimum, the Contractor Quality Control System Manager (CQC-SM), who will be monitoring onsite daily progress, shall attend the onsite pre-construction meeting. Other contractor personnel are welcome to attend. The Contracting Officer, Contract Specialist/Contract Administrator, and any other individuals designated by the Government will also attend. The purpose of the Pre-Construction meeting is to discuss matters of mutual interest concerning the resulting delivery order. General conditions, work schedules, coordination, security, safety, permits, and other matters pertinent to work accomplishments shall be discussed in this meeting. This meeting shall be held in person, on DSCR, by all parties.

PRE-CONSTRUCTION DELIVERABLES

Name of Deliverable Due Date Recipient Site Specific Safety Plan Within 10 calendar days of award (PM/COR email)

OSHA 300A Log Within 10 calendar days of award (PM/COR email) Activity Hazard Analyses Within 10 calendar days of award (PM/COR email)

QC Plan Within 10 calendar days of award (PM/COR email) Payment Bond Within 5 calendar days of award (Contract specialist email)

Performance Bond Within 5 calendar days of award (Contract specialist email) Security Vetting Requests NLT 5 working days prior to start of work (PM/COR email)

The contractor shall submit a site-specific safety plan following the US Army Corps of Engineers engineering Manual EM-385-1-1 (latest edition). All safety related items must be approved by the DLA Weapons Support Safety Office before work can begin. The QC Plan shall meet all QCP standards outlined in the Submittals section of this SOW. These documents should be emailed to the Project Manager/COR and the Contract Specialist outlined in Points of Contact section of this

SOW.

Until all the required above documentation is provided, a pre-construction conference will not be held and the Notice to Proceed will not be issued. If the contractor fails to meet the above guidelines the contract may be terminated for cause at the convenience of the government.

Additionally, all subcontractors that perform work under this contract shall also submit their own Site-Specific Safety Plan, OSHA 300A Logs and Activity Hazard Analyses for approval by DLA Safety, a minimum of 10 Business days prior to the start of any work IAW the above references. No work can start until these items are approved.

For all the above submittals, the contractor shall make appropriate modifications within five (5) calendar days after receiving any comments and provide revised submittals within the same five (5) calendar days.

SUBMITTALS

The contractor shall provide submittals for Government review and/or approval for all materials, equipment, supplies and other items to be used in the completion of this project prior to completing any commitments for purchases (see information below and in Attachment 4). Submittals shall be provided in both electronic format (PDF) via email to COR/PM and hard copies. All hard copy submittals shall be single sided prints with the material/equipment being submitted clearly indicated by the contractor.

Failure to provide required submittals on time may result in a ‘stop work’ order. The government will not incur any additional costs for delays or cost overruns caused by any such issue.

The list below along with the information in Attachment 4 outlines requirements for submittals:

Quality Control Plan (QCP) The Contractor shall submit a Quality Control Plan within 10 calendar days of contract award. This plan shall describe the Contractor’s methodology for compliance with the Deliverables and Performance Requirements Summary above. The Contracting Officer, or his/her authorized representative will notify the Contractor of concurrence or required modifications to the QCP within 10 calendar days of receipt. The Contractor shall make appropriate modifications within five

(5) calendar days of the Contracting Officer, or his/her authorized representative’s notification and provide a revised QCP within five (5) calendar days.

Include, as a minimum, the following to cover all construction-operations, both onsite and offsite, including work by subcontractors, fabricators, suppliers, and purchasing agents, subcontractors’ designers of record, consultants, architect/engineers (AE), fabricators, suppliers and purchasing agents:

a. A description of the quality control organization, including a chart showing lines of authority and acknowledgment that the CQC staff will implement the three-phase control system for all aspects of the work specified. Include a CQC System Manager that reports to the project superintendent.

b. The name, qualifications (in resume format), duties, responsibilities, and authorities of each person assigned a CQC function.

c. A copy of the letter to the CQC System Manager signed by an authorized official of the firm which describes the responsibilities and delegates sufficient authorities to adequately perform the functions of the CQC System Manager, including authority to stop work which is not in compliance with the Contract. Letters of direction to all other various quality control representatives outlining duties, authorities, and responsibilities will be issued by the CQC System Manager. Furnish copies of these letters to the Contracting Officer/Gov’t rep.

d. Procedures for scheduling, reviewing, certifying, and managing submittals, including those of subcontractors, offsite fabricators, suppliers, and purchasing agents, subcontractors, designers of record, consultants, architect engineers (AE), offsite fabricators, suppliers, and purchasing agents.

These procedures must be in accordance with SOW Submittals section.

e. Control, verification, and acceptance testing procedures for each specific test to include the test name, specification paragraph requiring test, feature of work to be tested, test frequency, and person responsible for each test. Laboratory facilities accepted by the Contracting Officer are required to be used.

f. Procedures for tracking preparatory, initial, and follow-up control phases and control, verification, and acceptance tests including documentation.

g. Procedures for tracking construction deficiencies from identification through acceptable corrective action. Establish verification procedures that identified deficiencies have been corrected.

h. Reporting, scheduling, and communication procedures, including proposed reporting formats, deadlines, meeting notifications, etc. Communication with the Government shall be outlined and defined.

i. A list of the definable features of work. A definable feature of work is a task which is separate and distinct from other tasks, has separate control requirements, and is identified by different trades or disciplines, or it is work by the same trade in a different environment. Although each section of the specifications can generally be considered as a definable feature of work, there are frequently more than one definable feature under a particular section. This list will be agreed upon during the coordination meeting.

j. Completion inspections (punch-out, pre-final, final), startups, training, and turnover of all final documentation to the Government.

k. The contractor shall use the quality control report listed in Attachment 5.

Three phase Inspection The contractor is required to follow the U.S Army Corps of Engineers three-phase inspection process. If the contractor is not familiar with this process it can be found on the internet. The contractor shall take notes from all inspections, startups, training etc. Provide all notes, type written to the PM within one business day.

a. Preparatory phase inspection – The general contractor shall provide notice to the Government within 3 business days prior to calling for a preparatory meeting for each Definable Feature of Work (DFOW). No work can start on a DFOW without a preparatory meeting. The supervisor leading that DFOW MUST attend the preparatory meeting AND stay on the work site acting as a supervisor until that DFOW has been completed.

b. Initial phase inspection – The general contractor shall provide notice to the Government two business days prior to calling for an initial inspection.

c. Follow up inspections – The general contractor shall conduct follow up inspections daily, by the on-site supervisor to ensure all contract requirements are being met. The contractor shall schedule a pre-final inspection after it verifies all work conforms to the contract for either that DFOW and/or when all work is completed. The contractor shall provide notice to the Government within 3 business days of when it would like to hold pre final inspection(s).

Contractor Punch-Out Inspection Near the completion of all work or any increment thereof the Contractor Quality Control System Manager (CQC-SM) shall conduct an inspection of the work and develop a punch list of items which do not conform to the approved drawings, specifications, SOW, etc. The CQC-SM shall provide the list of items identified as deficient to the COR/PM in writing via email. The CQC-SM will make a backcheck inspection to ensure all previously identified deficiencies have been corrected. Once this is accomplished, the CQC-SM shall notify the Government COR/PM that the project is ready for the Government/Contractor Pre-Final Inspection.

Government & Contractor Pre-Final Inspection This inspection shall not be scheduled until the contractor provides the information required under the Contractor Punch-Out Inspection section above. The contractor shall give the Government 5 business days’ notice for the Government/Contractor pre-final inspection to be scheduled with the

Contractor’s CQC-SM/Superintendent to verify that all work is complete. The CQC-SM shall develop a new joint punch-out list (if applicable) from this inspection and provide it to the COR/PM in writing via email. The CQC-SM will perform a backcheck inspection to ensure all previously identified deficiencies have been corrected. Once this is accomplished, the CQC-SM shall provide the final completed punch list and notify the Government COR/PM that the project is ready for the Final Inspection.

Final inspection This inspection shall not be scheduled until the contractor provides the information required under the Government/Contractor Pre-Final Inspection section above. The contractor shall provide the Government with 10 business days’ notice when they would like to hold the final inspection. The COR/PM may have to change the final date based on other government personnel’s schedule that are required to attend. Any schedule changes will be at no cost to the government. New punch list items may be developed during the Final Inspection. The contractor CQC-SM shall develop a new joint punch-out list (if applicable) from this inspection and provide to the COR/PM in writing via email. The CQC-SM will make a backcheck inspection to ensure all previously identified deficiencies have been corrected. Once this is accomplished, the CQC-SM shall notify the Government COR/PM that the project is ready for the Final Inspection backcheck.

Startups/Training The contractor shall not hold any required training on the same day any startups of equipment are required. All inspections shall be held on different days when startups or training is scheduled (i.e., each task shall be held on a different day). The contractor shall provide manufacturer training on all equipment/systems installed. The contractor shall provide 10 business days of any training and 10 business days of any startups of equipment for the Government maintenance personnel to arrange to be present. The contractor shall provide a minimum of three different dates and times for training and startups to allow government personnel to schedule to attend.

Daily Reports Once construction has begun, the contractor shall perform daily inspections of the project, to be conducted by a qualified employee outlined in the QCP. The contractor shall provide the COR/PM with daily inspection reports detailing the work accomplished that day, weather conditions, safety related topics, etc. The contractor shall use the daily report form in Attachment 5. The contractor can propose using an alternate daily report form but must be approved by the PM. The daily report shall be typed. The daily report is due the next business day by 8:00am.

Construction schedule The contractor shall, within two weeks after receipt of the notice to proceed but at least 5 calendar days prior to beginning any construction work, provide the COR/PM with a fully detailed construction schedule in a Gannt chart format. For projects lasting longer than 90 days, an updated version of this schedule shall be provided on the first Monday of the month. Contractors shall provide a “two-week look ahead” for the work scheduled for the next two weeks not later than noon every Monday, regardless of project duration.

Equipment Data Sheet After final acceptance of the entire project the contractor shall completely fill out the equipment data sheet found in Attachment 1 for all equipment removed and/or installed. The contractor shall include the sheet(s) in the closeout documents (Section 13 of this SOW). All information provided on the equipment data sheet shall be type written. Upon request the project manager will provide the form to the contractor in Adobe PDF format.

Warranty After final acceptance of the entire project the contractor shall provide a one-year written warranty letter along with any other warranties for the project. No warranty start date for any equipment installed will start until after the final acceptance of the entire project. The warranty letter shall be included in the closeout documents (Closeout Documents Section of this SOW). At a minimum, the warranty letter shall include the following information.

a. Contractor name

b. Contract phone number

c. Project title

d. Warranty start date

e. Warranty end date

f. Name and phone number of the person to call for warranty issues

g. Contractors’ physical address

Warranty Response The contractor shall physically respond on site within 2 business days after being notified of a warranty issue to survey the issue and develop a plan to make corrections.

7. REQUESTS FOR UTILITY MARKING

The contractor shall:

1. Submit routine requests to the PM/COR at a minimum of 14 calendar days in advance.

2. Mark the area to be excavated with white marking paint prior to submitting requests to

PM/COR.

3. Provide the PM/COR with a satellite (Google maps/earth) map showing where the area marked in white paint is located to aid the marking crews.

4. Maintain all utility markings for the duration of the work once the initial markings have been completed.

The contactor shall use the following APWA Uniform Color Codes for temporary marking of underground utilities:

RED – Electric Power Lines, Cables, Conduit, and Lighting Cables YELLOW – Gas, Oil, Steam, Petroleum, or Gaseous Material ORANGE – Communication, Alarm or Signal Lines, Cables, or Conduit BLUE – Potable Water GREEN – Sewers and Drain Lines WHITE – Proposed Excavation Limits or Route PINK – Temporary Survey Markings, Unknown / Unidentified Facilities PURPLE – Reclaimed Water, Irrigation, and Slurry Lines

8. CONSTRUCTION TRAILER SIGN REQUIREMENTS

The following section is only applicable if the contractor is required to provide a construction trailer per Specific Requirements Section of this SOW, or if the contractor chooses to provide one voluntarily at no cost to the government. Contractor trailers placed at DSCR shall have a project sign posted at the trailer location within 5 days of trailer placement. Sign shall be 2’x4’ ¾” plywood painted white with black letters 3” tall, mounted of on 4x4 post, Top of the plywood sign shall be 7’ high from grade located within 10’ of the main entrance to the trailer. Coordinate with DSCR PM for sign placement.

Project sign shall include the following information.

1. Project Title

2. General Contractor

3. Contact Name and Phone Number

4. Project Completion Date

The contractor shall schedule a site visit at the trailer location with the DLA PM one day prior to trailer placement to ensure site use is correct. The contractor shall schedule a site visit the day after the trailer is removed and any equipment, debris etc. is removed. Any equipment, materials etc. left will be considered abandoned. Final payment will be withheld until all equipment, materials etc. are removed. If the contractor damages any Government provided utilities the contractor shall repair/replace at their own cost.

9. APPLICABLE DOCUMENTS

The contractor is required to reference and follow the latest editions of the following publications:

a. Unified Facilities Criteria (UFC)

b. International Building Code (IBC)

c. International Mechanical Code (IMC)

d. International Plumbing Code (IPC)

e. National Fire Protection Agency (NFPA) 72, 70, 101, 90A, 13, etc.

f. National Electric Code (NEC)

g. AHRI/ASHRAE publications

h. ASME publications

i. USACE EM 385-1-1 Safety Manual

j. Americans with Disabilities Act and Architectural Barriers Act Accessibility Guidelines

k. 29 CFR 1926 OSHA Construction Industry Regulations

l. 29 CFR 1910 OSHA General Industry Regulations

m. All manufacture recommendations

10. CLOSEOUT DOCUMENTS

Documentation, records, and schedules shall be turned over to the Government upon termination or completion of the contract. Before the conclusion of the project (end of POP) and within 5 working days of the final inspection the contractor shall provide 2 loose leaf binders, a CD containing all the information from the binders, and an electronic PDF copy (emailed to the PM/COR) with all project documentation: warranty, O&M’s, submittals, etc. The PDF submission shall be sent in one portfolio PDF file. The binders shall have a table of contents and be tabbed. If the PDF file size is larger than 10Mb the contractor shall notify the COR/PM and request a drop-off link from the COR/PM. Warranty letter shall be placed after the table of contents. At a minimum the following information shall be provided (as applicable) in the following order:

a. Table of Contents

b. Warranty Letter

c. All submittals and warranties

i. Lighting / gear

ii. Fire protection

iii. Mechanical

iv. Electrical

v. Plumbing

vi. Other divisions if applicable

d. Equipment Data Sheet(s)

e. Provide the manufacture, color codes and sheen of any paint used in the closeout documents.

f. Any other pertinent documents for the project

11. INSTALLATION SECURITY REQUIREMENTS

Work to be performed under this contract or task order may, in full or in part, be performed at the Defense Supply Center Richmond), with physical access to a federally controlled facility. Prior to beginning work on a contract, DLA and its field activity offices require all contractor personnel working on the federally controlled facility to have a minimum of a favorably adjudicated National Agency Check with Written Inquiries (NACI) or NACI equivalent.

a. The Contractor shall comply with current visitor pass requirements for access to and/or performance of work at DSCR, which can be found at https://www.dla.mil/Aviation/Installation/Visitors.aspx

Effective May 7th, 2025, DSCR will no longer accept state-issued identification that does not meet the Real ID Act of 2005 standards for identity proofing. Visitors seeking unescorted access to DSCR must present a Real ID-compliant driver’s license or identification card, or an alternative ID. Acceptable alternate IDs:

U.S. or foreign passport or passport cards Federal personal identity verification cards Non-federal PIV-interoperable cards

i. Combination of the following:

ii. Non-Real ID Driver’s license and a Transportation Worker ID Card (TWIC)

iii. Non-Real ID Driver’s license and a Veteran’s Health ID cards (VHIC)

iv. Non-Real ID Driver’s license and an original or certified copy of your Birth

Certificate and Social Security Card

ii. Enhanced Driver’s Licenses are Real ID Compliant (EDLs Michigan, Minnesota, New York, Vermont, and Washington).

b. Anytime a contractor would like to access DSCR for one or more days, they shall submit the request a minimum of 5 business days prior to the visit date.

c. No employee or representative of the Contractor will be admitted to the work site unless he/she furnishes satisfactory proof that he is a citizen of the United States or an alien who has been lawfully admitted for permanent residence, or who presents evidence from the Immigration and Naturalization Service that employment will not affect his immigration status.

d. Personnel Information: All authorized non-military personnel utilizing the base are required to always have in their possession an installation visitor pass or access control badge. This pass shall be worn on the outermost garment above the waistline. This pass is issued by the DSCR Visitor Center, located at Building 210. The Visitor Center is open Monday through Friday except federal holidays from 6:30 a.m. to 4:30 p.m.

e. Badge Requests: To obtain pass/badge for one day or more, the contractor shall complete DBIDS pre-registration online using the following link DBIDS Pre-Enrollment or at https://dbids-global-enroll.dmdc.mil/preenrollui/#/landing-page. Once pre-registration has been complete, the visitor/contractor shall record and send the QR code/alpha-numeric https://www.dla.mil/Aviation/Installation/Visitors.aspx https://dbids-global-enroll.dmdc.mil/preenrollui/#/landing-page https://dbids-global-enroll.dmdc.mil/preenrollui/#/landing-page code as a PDF/screenshot to the COR/PM via email (if multiple people are visiting or being vetted, the contractor shall compile all QR/alpha-numeric codes into a single email) at least 5 business days prior to visit/start date. The contractor shall include requested dates, times and names of personnel in the email. Failure to provide all the above information may lead to delays in requests being processed which could result in missed site visits, meetings etc. The COR/PM will notify the contractor upon their approval or denial. If approved, the contractor will have 30 days to pick up their visitor pass or project badge. When picking up the project badge the contractor is required to present their QR or alphanumeric code along with a valid form of ID. When filling out the QR code form, for the Service Site - select All. State – Virginia. Filter – Defense Logistics Agency Richmond. Note, a valid DOD ID card (Retired military, CAC etc.) is NOT permitted to be used to enter DCSR for commercial purposes.

f. Badge duration: DSCR doesn’t allow blanket access for contractors that don’t need full access routinely (with exceptions for management if applicable). The contractor shall submit personnel for access for only the amount of time needed for those individuals to complete their work.

g. The contractor shall arrive at the visitor’s center at least 1 hour prior to any scheduled site visit time, to get through the access process. It’s the contractor’s responsibility to ensure they allow ample time to receive their badging and arrive at the site visit location at the appropriate time. Sites visit will start on time.

h. Proof of Identity: Official identification consists of any current Government issued picture identification. Examples of official identification are valid state issued driver's license, military ID card, military dependent ID card, green card, etc. Expired identification is not valid.

i. Pass or Badge Management: Expired, invalid, inaccurate, inoperative, or terminated pass or Access Control Badge shall be returned to the Contracting Officer or his designee for disposition. These cards are the property of the U.S. Government and shall not be retained by the cardholder upon expiration, replacement, or when the DoW affiliation of the employee has been terminated. The Contract Officer or his designee shall deliver all returned contractor badges to the Visitor Center (Building 210) within 5 business days. If the Pass or Access Control Badge is lost or stolen, a police report will be completed, and the applicant must submit a new request through DBIDS pre-registration portal.

Compliance with this requirement is mandatory and certification thereof to the Contracting Officer is required prior to submitting final invoices. Failure to return badges will hold up Contractor's final payment.

j. Contractor Security Responsibilities: The contractor is responsible for employees and subcontractors under their employment. Contractors will ensure that employees are familiar with and obey installation traffic, safety, and security regulations. Contractor employees, including subcontractors, are required to always wear the ID card conspicuously on their outer clothing and above the waist while working on DSCR.

Personnel are subject to challenge and removal from the work area if the ID card is not worn. It is the COR/designee’s responsibility to enforce this requirement. Failure to do so is just cause for ordering that work on a contract be stopped.

k. Firearms, Weapons, Illegal Drugs (federal level), and Contraband are prohibited on DSCR property. Violators may be prosecuted. State issued/authorized concealed weapons permits are not valid on Federal (DSCR) property. See Attachment 7 for additional details.

L. Camera Security Policy: DM-FR SOP 5200.01, effective April 17, 2025 Contractors must consult with their COR/PM/Sponsor prior to any/all image capturing.

The COR/PM/Sponsor is responsible for determining if the image capturing is in support of projects or mission requirements and if it needs to be approved through the PAO or DLA Intelligence as prescribed in this SOP. If the image being captured is in a LOW- RISK AREA, the COR/PM/Sponsor may approve the image capturing. Image capturing of SENSITIVE AREAS cannot be approved by the COR/PM/Sponsor.

Image capturing and image capturing devices are not permitted in the following types of areas: Restricted, Controlled Areas or areas containing or processing classified material.

Livestreaming of any kind is strictly prohibited. In the rare event image capturing of these areas is required for official business, prior written approval by the OPSEC Program Manager is required.

The contractor shall schedule all image capturing needs in support of projects with their COR/PM/Sponsor a minimum of 3 business days in advance.

Unless otherwise specified, there is no restriction on photography at ceremonies, community events or outdoor areas such as static aircraft displays, historic buildings and the elk herd.

a. The Government is not responsible for job site security. Removal of material from jobsite and DSCR are subject to security checks. The contractor is to notify DSCR security of any special measures (watchmen, alarm, etc.), security concerns, security problems, or unusual activities within the job site.

b. Traffic laws and enforcement:

i. Motor Vehicle Operation: Ingress and egress of personnel will be subject to the

DSCR security regulations. All personnel must be made aware of the base speed limits, which are 25 mph (unless otherwise posted). Speed limits are enforced, and violators will be ticketed. DSCR traffic violations are processed through the federal court system.

ii. Seatbelts are mandatory.

iii. Use of cellphones while driving is prohibited. Exception: use of "hands free" devices for cellphone use is authorized.

iv. Parking is in designated areas only, between two white lines. No parking is permitted in fire lanes, on seeded areas, in reserved parking slots, or assigned handicapped parking. Any equipment or vehicle that does not fit within a standard parking space must contact the Contracting Officer to determine a designated area for parking such equipment or vehicle.

v. Traffic accidents should be reported immediately to the DSCR Emergency Dispatch by calling 911 or (804) 279-4888 for non-emergencies.

vi. All personnel entering DSCR are subject to random vehicle inspections/searches at any time while on the Installation. The purpose of these inspections is to detect the theft of Government and private property, or entry onto DSCR with firearms, weapons, alcoholic beverages, illegal drugs, or contraband.

c. Truck deliveries:

i. The contractor shall notify the Contracting Officer of truck deliveries and escort trucks from the truck gate to their destination.

ii. All commercial vehicles will enter DSCR through the Commercial gate adjacent to…