Hilo_-_SECTION_F_Plumbing.docx

SECTION F – DELIVERIES OR PERFORMANCE

CLAUSES INCORPORATED BY REFERENCE ((FAR 52.252-2)(FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov/far/

FEDERAL ACQUISITION REGULATION 948 CFR CHAPTER 1) CLAUSES

FAR 52.242-14 Suspension of Work (APR 1984) FAR 52.242-15 Stop Work Order (AUG 1989)

SUPERINTENDENCE BY THE CONTRACTOR (FAR 52.236-6)(APR 1984)

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

PERIOD OF PERFORMANCE (AGAR 452.211-74)(FEB 1988)

The period of performance of this contract is from September 9, 2013 through January 6, 2014.

Work Timing Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time.