AG-82B1-S-10-0099_amend_3.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 3

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

Three (3) 2/9/10 356500/356539

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

USDA Forest Service Intermountain EROC 740 Simms Street Golden, CO 80401

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State, and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NO.

AG-82B1-S-10-0099

9B. DATED (SEE ITEM 11)

1/12/10

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

(X) A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN

THE CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.

1. Clause F.2, Commencement, Prosecution and Completion of Work is deleted and FAR 52.211-10 Alt 1 (attached) is substituted.

2. Drawing sheet no. 13 is added to the drawing package for this solicitation.

3. The closing date/time for receipt of offers is extended to Feb 17, 2010 at 3:00 PM, Mountain Time.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Stephen M. Patton

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

F.2 FAR 52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984) Alt I (APR

1984)

The Contractor shall be required to (a) commence work under this contract 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than August 30, 2010 for Peters Creek and September 30, 2010 for

Canyon Creek Bridge. The time stated for completion shall include final cleanup of the premises.

The completion dates are based on the assumption that the successful offeror will receive the notice to proceed by March 31, 2010. The completion date will be extended by the number of calendar days after the above date(s) that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the specified time in the offer.

All in-stream work shall be completed beyween July 15, 2010 and August 31, 2010.

CANYON CREEK NFSR 38 MP 26.339

BRIDGE REPLACEMENT

SUPERSTRUCTURE PLAN

REGION ONE

A

F

C a n y o n \d w g

\C a n y o n B ri d g e

.d w g

S u p e r P la n /1

/2

:1 :1

P

M c u rt is