Updated_Bid_Schedule8-23-17_Solicitation0071.pdf

Jerry Jones WRP Restoration Solicitation # AG-2B46-S-17-0071

Updated thru FAC 2005-94 and 2005-95 eff 1/19/2017

B - SUPPLIES OR SERVICES AND PRICES/COSTS

This solicitation requires a price be submitted for all line items, failure to do so will disqualify the quote.

Line Item

Description Spec.

No.

Quantity Unit Unit Price Extended Amount

001 Silt Fence for Pollution Control

5 1,985 LF

002 Seeding and Straw Mulching

6 4.1 Acre

003 Seeding and Erosion Control Blanket

6 3,836 SY

004 Mobilization & Demobilization

8 1 JOB

$ XXXX $

005 Removal of Water 11 1 JOB

$ XXXX $

006 Pumping to Dewater 21 300 1000

GAL $ $

007 Excavation, common 25 11,611 CY

008 Plastic Pipe, 12 inch 45 160 LF

009 Placed Rock 61 213 TON

TOTAL QUOTE $

SUBMITTED BY:_____________________________________DUNS#_____________________

52.211-18 Variation in Estimated Quantity. (Apr 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of clause)

Quantities marked with an * above are estimated quantities and the clause FAR 52.211-18, Variation in Estimated Quantity, applies.

Jerry Jones WRP Restoration Solicitation # AG-2B46-S-17-0071

Updated thru FAC 2005-94 and 2005-95 eff 1/19/2017

ONE AWARD FOR THE AGGREGATE OF ALL ITEMS WILL BE MADE AS A RESULT OF THIS

SOLICITATION