Amendment_0006_Solicit_Revision_0003.pdf

(x)

AG-2B46-S-17-0024

x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

NRCS-PR-12F352

HATO REY PR 00918

Suite 604

654 MUNOZ RIVERA AVENUE

USDA-NRCS CARIBBEAN AREA OFFICE

WASHINGTON DC 20250

NRCS-HQ-122B46

ROOM 6801-S

1400 INDEPENDENCE AVENUE, SW

USDA-NRCS CONTRACTING TEAM 2

NRCS-HQ-122B46

05/05/2017000006

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

03/29/2017

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

This amendment is issued to make the following changes to the solicitation document.

1. Correct bid line 8 of the Bid Schedule, Section B, Supplies or Services and Prices to read as follows:

Seeding - Spoil Berms All Except Below (B1 ad D1)

2. Add to the details in Section L - INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS, Additional Bid Instructions, Electronic or faxed bid offers will not be accepted.

3. Remove page 4 and 35 of the solicitation documents and replace with the attached.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

ORIEL VELEZ

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

5/5/2017

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

AG-2B46-S-17-0024/000006

4. There are no additional changes to the solicitation. All other terms and conditions remain unchanged.

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

SOLICITATION NUMBER AG-2B46-S-17-0024-0003

MoDNR EWPP-FPE

Linn County, Missouri

B - SUPPLIES OR SERVICES AND PRICES

This solicitation requires bidding on all line items, failure to do so will disqualify the bid.

ONE AWARD FOR THE AGGREGATE OF ALL ITMES WILL BE MADE AS A RESULT OF

THIS SOLICITATION.

52.211-18 Variation in Estimated Quantity. (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of clause)

Quantities marked with an * above are estimated quantities.

Line

Item

Description

Spec

No

Quantity

Unit

Unit Price

Extended Amount

Mobilization and Demobilization

LS

Pollution and Erosion Control

Construction surveys

Earthfill – Spoil Berms

81,870**

CY

Earthfill – Dikes & Floodways

3,085**

CY

Grading & Shaping - Dike

6.6**

AC

007 Seeding & Mulching – Dikes and

Floodways

11.5**

Seeding – Spoil Berms All Except

Below (B1 and D1)

19.4**

Seeding & Mulching – Spoil Berms B1 and D1 (See Plans)

1.3**

TOTAL BID

SOLICITATION NUMBER AG-2B46-S-17-0024-0003

MoDNR EWPP-FPE

Linn County, Missouri

NRCS 4I-52.233-70 Protests to the Agency. (Mar 2016)

(a) An agency protest filed with the contracting officer shall be sent to the contracting officer’s mailing address or email address listed in the solicitation. The contractor should contact the contracting officer to verify the mailing or email address prior to delivering a protest.

(b) The independent review of a contracting officer’s decision regarding a protest described at FAR

33.103(d)(4) is not available as an alternative to consideration of the protest by the contracting officer.

An independent review is available only as an appeal of the contracting officer’s decision on a protest.

An appeal must be filed within 10 calendar days of the protestor’s receipt of the contracting officer’s decision, otherwise the appeal will be deemed untimely and not considered. The appeal must be directed to the Contracting Services Branch Chief, but sent to the contracting officer.

(c) The protest must contain all of the elements required by FAR 33.103(d)(2). Failure to substantially comply with any of the requirements of FAR 33.103(d)(2) may be grounds for dismissal of the protest.

(End of provision)

Additional Bid Submission Instructions

THIS SOLICITATION IS BEING HANDLED ON BEHALF OF THE USDA NRCS MISSOURI

STATE OFFICE. BID OFFERS WILL NEED TO BE SUBMITTED TO THE USDA NRCS

CARIBBEAN AREA OFFICE WITH SUFFICIENT TIME AS TO REACH ON OR BEFORE

THE DEADLINE.

The deadline to receive Bids for solicitation AG-2B46-S-17-0024 has been extended to Thursday

May 11, 2017 by 3:30pm ET (2:30pm CT). Electronic or faxed bid offers will not be accepted.

1. Mailed and or hand delivered bids shall be addressed as shown below and be submitted to the following address. Ensure the envelope is addressed correctly:

USDA NRCS CONTRACTING SERVICES BRANCH

TEAM 2, ATTN: ORIEL VELEZ, CO

RE: Sealed Bid for AG-2B46-S-17-0024

654 MUÑOZ RIVERA AVE. SUITE 604

HATO REY PR 00918

2. Timely received bids submitted in response to this IFB/Solicitation shall be publicly opened at the

USDA NRCS Caribbean Area office. Interested parties in participating from this opening are invited to meet at the USDA NRCS Missouri State Office 601 Business Loop 70 West, Parkade

Center, Columbia MO. Bid opening will be offered via video teleconference. Interested parties shall meet at the Columbia MO office no later than 2:30pm CT.

Bidders should review all solicitation provisions and in particular 52.214-5, -7, and -18 when preparing their bid. As a reminder, in addition to any other requirements in this solicitation, contractors are reminded to submit the below documents in their response. Any Bidder who fails to send the bid in time as to reach the Caribbean Area Office in time before bid opening and/or fails to provide any of the below documents will be considered non responsive and the bid will be rejected.

1. Complete the bid schedule at Section B by entering a price for all line items. Ensure that unit price and extended price reflects the correct bid price.

2. Submit the required bid guarantee on an SF 24, Bid Bond (see provision 52.228-1). – provide original document with original signature as copies of documents will not be considered and will be rejected.

3. Signed and dated bid (SF 1442, Block 20a, b and c).

4. Acknowledge amendments issued (if any) (SF 1442, Block 18).