A21 - RTA-SPECS1-W912PM22B0016-CFLD3.pdf

William O. Huske Lock and Dam Esplanade Repair In Bladen County, North Carolina

RTA Specifications

Solicitation No. W912PM22B0016 Contract No. W912PM22XXXXX

MAY 2022

William O. Huske Lock & Dam, Esplanade Repair, Fayetteville, NC CFLD3

RTA

PROJECT TABLE OF CONTENTS

DI VI SI ON 00 - PROCUREMENT AND CONTRACTI NG REQUI REMENTS

00 01 15 02/11, CHG 1: 08/14 LIST OF DRAWINGS

DI VI SI ON 01 - GENERAL REQUI REMENTS

01 10 00.10 38 01/13 SUPPLEMENTARY SPECIAL CONTRACT

REQUIREMENTS

01 11 00 08/15, CHG 2: 08/21 SUMMARY OF WORK

01 20 00 11/20, CHG 2: 08/21 PRICE AND PAYMENT PROCEDURES

01 32 01.00 10 02/15 PROJECT PROGRESS SCHEDULE

01 33 00 08/18, CHG 4: 02/21 SUBMITTAL PROCEDURES

01 35 26 11/20, CHG 1: 08/21 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 02/19 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 11/16, CHG 1: 02/20 QUALITY CONTROL

01 45 00.15 10 11/16, CHG 2: 08/19 RESIDENT MANAGEMENT SYSTEM CONTRACTOR

MODE (RMS CM)

01 57 19 11/15, CHG 5: 08/21 TEMPORARY ENVIRONMENTAL CONTROLS

DI VI SI ON 02 - EXI STI NG CONDI TI ONS

02 41 00 05/10, CHG 2: 02/19 DEMOLITION

DI VI SI ON 03 - CONCRETE

03 30 00 02/19, CHG 2: 05/21 CAST-IN-PLACE CONCRETE

DI VI SI ON 31 - EARTHWORK

31 00 00 08/08, CHG 2: 02/21 EARTHWORK

DI VI SI ON 33 - UTI LI TI ES

33 01 98 05/13 GROUTING OF EXISTING PIPING

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

DOCUMENT 00 01 15

LIST OF DRAWINGS

02/ 11, CHG 1: 08/ 14

PART 1 GENERAL

1.1 SUMMARY

1.2 CONTRACT DRAWINGS

1.3 SUPPLEMENTARY DRAWINGS

1.3.1 Boring Logs & Hydrographic Data

ATTACHMENTS:

Attachment 1 - Index of Drawings

Appendix B - Hydrographic Data

-- End of Section Table of Contents --

DOCUMENT 00 01 15 Page 1

DOCUMENT 00 01 15

LIST OF DRAWINGS

02/ 11, CHG 1: 08/ 14

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings, Maps and Specifications."

1.2 CONTRACT DRAWINGS

The list of Contract drawings can be found in Attachment 1 - Index of Drawings at the end of the section.

1.3 SUPPLEMENTARY DRAWINGS

These supplementary drawings may not be a part of the contract but are included as an appendix at the end of the specifications.

1.3.1 Boring Logs & Hydrographic Data

The Government does not guarantee that borings or hydrographic data indicate actual conditions, except for the exact locations and the time that they were made. The boring logs can be found in Appendix A - Boring Logs. Hydrographic data can be found in Appendix B - Hydrographic Data.

-- End of Document --

DOCUMENT 00 01 15 Page 2

Attachment #1

Index of Drawings

G-000 COVER SHEET

G-001 DRAWING INDEX

V-101 EXISTING CONDITIONS

C-001 DEMOLITION PLAN

C-101 FINAL SITE PLAN

C-301 TYPICAL DETAILS

CE501 EROSION & SEDIMENT CONTROL DETAILS

CE502 TEMPORARY STOCKPILE DETAIL

R-001 REFERENCE – LOCK AND ESPLANADE PLAN

R-002 REFERENCE – LOCK AND ESPLANADE CROSS SECTION

R-003 REFERENCE – LOCK AND ESPLANADE ADDITONAL

MEASUREMENTS

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 10 00.10 38

SUPPLEMENTARY SPECIAL CONTRACT REQUIREMENTS

01/13

PART 1 GENERAL

1.1 REFERENCES

1.2 DEPARTMENT OF ARMY MANDATED SECURITY REQUIREMENTS

1.3 SUBMITTALS

1.4 PERFORMANCE AND PAYMENT BONDS

1.5 WATER CONSERVATION

1.6 BULLETIN BOARD

1.7 RETAINAGE FOR UNTIMELY SUBMISSION OF SUBCONTRACTING REPORTS

1.8 SHOP DRAWINGS AND MATERIALS SUBMITTAL

1.9 SAMPLING, CERTIFICATES, AND TESTING

1.10 CERTIFICATES OF COMPLIANCE

1.11 REQUIRED CONSTRUCTION MEETINGS

1.12 SURVEY DATA

1.13 SURVEYS AND SURVEY PERSONNEL REQUIREMENTS

1.14 SYSTEM AS-BUILT DRAWINGS

1.15 WORK IN QUARANTINED AREA

1.16 NCDOT SPECIFICATIONS

1.17 DEFINITIONS FOR NCDOT SPECIFICATIONS

1.18 PUBLIC CONVENIENCE AND SAFETY

1.18.1 Roads To Be Closed

1.18.2 Storage of Materials

1.19 MAINTENANCE DURING CONSTRUCTION

1.19.1 Maintenance When Work is Suspended

1.19.2 Spilled Materials

1.20 INSPECTION

1.21 PARTNERING

1.22 LOAD RESTRICTIONS

1.23 BARRICADES, DANGER, WARNING, AND DETOUR SIGNS

1.23.1 Removal of Barricades And Warning Signs

1.23.2 Replacement of Signs

1.23.3 Cost of Protective Devices

1.24 PROTECTION OF EXISTING FACILITIES

1.25 CONTRACT AREA AND TRESPASSING

1.26 COORDINATION WITH OTHER CONTRACTORS

1.27 CONTRACT DRAWINGS AND SPECIFICATIONS

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 10 00.10 38 Page 1

SECTION 01 10 00.10 38

SUPPLEMENTARY SPECIAL CONTRACT REQUIREMENTS

01/13

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NORTH CAROLINA DEPARTMENT OF TRANSPORTATION (NCDOT)

NCDOT Standard Specifications For Roads And Structures

U.S. ARMY CORPS OF ENGINEERS (USACE)

ER 1110-1-5 Plant Pest Quarantined Area and Foreign Soil Samples

1.2 DEPARTMENT OF ARMY MANDATED SECURITY REQUIREMENTS

The Contractor shall be required to comply with the following security requirements mandated by the Department of the Army:

Short-term employees (working on site less than or equal to 6 months): If a criminal history is found, the employee MAY not be allowed to work at the project site at the sole discretion of the Government.

Long-term employees (working on site more than 6 months):

ALL of the following is required WHEN REPORTING FOR WORK -

a) A completed OMB Form No. 3206-0182 (also designated as Optional Form 306).

b) A completed OMB Form No. 3206-0191 (also designated as Standard Form 85P).

c) A resume.

The Government will use all provided information to perform a National Agency Check and Inquiries (NACI) check and will pay the required fee.

The Contractor shall be responsible for furnishing to each employee and for requiring each employee engaged on the work to display such identification as may be approved and directed by the Contracting Officer or his/her designated representative. All prescribed identification shall immediately be delivered to the Contracting Officer or his/her designated representative for cancellation upon the release of any employee.

(End of Clause)

SECTION 01 10 00.10 38 Page 2

1.3 SUBMITTALS

Government approval is required for submittals with a "G, A" designation;

submittals not having a "G, A" designation are for information only. When used, a designation following the "G, A" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Subcontractors

Quality Control Plan; G, A

Certificate of Insurance

Within 24 hours of conclusion of physical tests, 5 copies of test results including calibration curves and results of calibration tests.

SD-07 Certificates

Completion of Corps CQC Course

Letter Appointing Superintendent

Qualifications of the commercial testing laboratory or Contractor's testing laboratory/facilities G, A

SD-11 Closeout Submittals

SYSTEM AS-BUILT DRAWINGS; G, A

1.4 PERFORMANCE AND PAYMENT BONDS

Each bidder shall include his premiums for performance and payment bonds under the appropriate, "Performance and Payment Bonds" contract line item of the Bidding Schedule. Payment to the Contractor therefore, shall not exceed the bid price and shall be made in accordance with the Contract Clause entitled "PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS." Any additional amount bid in excess of the actual bond premium will be included in the final pay estimate for this contract.

(End of Clause)

1.5 WATER CONSERVATION

Water is one of our valuable natural resources. Accordingly, the Contractor shall be judicious in its use in the performance of the work as specified. Water needed for compaction of roadway and/or foundation materials, and dust control shall be obtained from uncontrolled stream flow instead of potable supply sources to the extent available and suitable as determined by the Contracting Officer or his/her designated representative.

SECTION 01 10 00.10 38 Page 3

1.6 BULLETIN BOARD

Within one (1) calendar day after commencement of work under this contract, the Contractor shall provide at the job site a weatherproof, glass-covered bulletin board for displaying the Fair Employment poster, wage rates, posters and safety bulletins as noted in Section 01 35 26, paragraph DISPLAY OF SAFETY INFORMATION. The bulletin board shall be located in a conspicuous place, easily accessible to all employees, and legible copies of the aforementioned data shall be displayed until work under the contract is complete. No direct payment will be made for the bulletin board.

(End of Clause)

1.7 RETAINAGE FOR UNTIMELY SUBMISSION OF SUBCONTRACTING REPORTS

(a) In accordance with Contract Clause 52.219-9, Small Business Subcontracting Plan, and 52.219-16, Liquidated Damages - Subcontracting Plan, retainage will be withheld from progress payments in an amount sufficient to protect the Government's ability to assess liquidated damages in accordance with Clause 52.219-16 for the contractor's failure to timely submit Standard Form 294, Subcontracting Report for Individual Contracts, and Standard Form 295, Summary Subcontract Report, reports.

(b) The retainage will be determined in accordance with the following formula:

Total dollar amount for subcontracting to small business multiplied by percentage of actual progress on the contract shall be withheld from the next progress payment due after the Contractor fails to submit a required report. If one or more reports have been submitted before such failure, formula for determining the amount of retainage will be adjusted by deducting any amounts reported as subcontracted to small business from the total dollar amount proposed to be subcontracted and the difference multiplied by the percentage of actual progress.

(c) Subcontracting plans are not required--

(1) For contracts or contract modifications that will be performed entirely outside of any State, territory, or possession of the United States, the District of Columbia, and the Commonwealth of Puerto Rico; or

(2) For modifications to contracts that do not contain the clause 52.219-8, Utilization of Small Business Concerns (or equivalent prior DAR, FPR, or NASA clauses); e.g., contracts awarded before Pub. L.

95-507 and which are within the scope of the contract.

(End of Clause)

1.8 SHOP DRAWINGS AND MATERIALS SUBMITTAL

(a) Five (5) days prior to the preconstruction conference (see paragraph REQUIRED CONSTRUCTION MEETINGS), the Contractor shall complete and submit to the Contracting Officer or his/her designated representative, in duplicate, Submittal Register, listing all submittals and dates. In addition to those items listed on the Submittal Register, the Contractor will furnish submittals for any deviation from the plans or specifications. The scheduled need dates must be recorded on the document

SECTION 01 10 00.10 38 Page 4 for each item for control purposes. In preparing the document, adequate time (minimum of l5 days) will be allowed for review and approval and possible resubmittal. Scheduling shall be coordinated with the approved progress schedule. The Contractor's Quality Control System Manager shall review the listing at least every 30 days and take appropriate action to maintain an effective system. Copies of updated or corrected listings shall be submitted to the Contracting Officer or his/her designated representative at least every 60 days in the quantity specified. Payment will not be made for any material or equipment which does not comply with contract requirements.

(b) Contractor submittals required by the Technical Provisions are indicated in those provisions and are listed on the Submittal Register furnished in Section 01 33 00 SUBMITTAL PROCEDURES. The list does not relieve the Contractor from furnishing submittals required elsewhere in the specifications, those inadvertently omitted from the listing; or from furnishing other submittals that the Government may deem necessary as the work progresses.

(c) Normal review levels for required approvals are indicated by letter designations as follows:

Contractor Quality Control System Manager --- (CQC) Area or Resident Engineer ------------------- (R) Engineering Branch -------------------------- (E)

The Government reserves the right to vary the review levels for (R) and

(E) to its convenience.

(d) The Contractor shall use ENG Form 4025, furnished in Section 01 33 00 SUBMITTAL PROCEDURES, to transmit Shop Drawings, Equipment Data, Material Samples or Manufacturer's Certificate of Compliance to the Government.

(End of Clause)

1.9 SAMPLING, CERTIFICATES, AND TESTING

(a) General. Within 30 days after acknowledgment of Notice to Proceed, the Contractor shall submit to the Contracting Officer or his/her designated representative five (5) copies of a list of the items for which he proposes to furnish manufacturer's certificates and/or samples for inspection and testing. The list shall include, but is not limited to the following information:

(1) Name of item

(2) Specification paragraph covering this item

(3) Date sample will be furnished

(4) Delivery date of product

(5) Items for which a certificate will be furnished

(b) Submittals. Any product or item mentioned in these specifications and required to meet Federal, ASTM, AASHTO, U. S. Army or Navy, AREMA, AWWA, and UL Specifications or Codes, specified herein with certain limiting or qualifying requirements, or any product or item which

SECTION 01 10 00.10 38 Page 5 is required to be similar and equal to a specified product or item may require the submission, before delivery of the product or item to the job site, of one or more of the following:

(1) Certificate by the manufacturer that the item meets the contract requirements.

(2) Samples for inspection, comparison, and testing, including destructive tests.

(c) Sample delivery. Unless otherwise specified or authorized, all samples shall be delivered (without cost to the Government) to:

U.S. Army Engineer District, Wilmington Corps of Engineers ATTENTION: Civil Construction Section 69 Darlington Avenue Wilmington, North Carolina 28403

If required by the Contracting Officer or his/her designated representative, duplicate samples shall be shipped to the Wilmington District Office at no expense to the Government.

(d) Testing. All tests required in the Technical Provisions shall be made by and at the expense of the Contractor except those material tests specifically excluded which will be made by and at the expense of the Government. All instruments and personnel required for the required tests shall be furnished by the Contractor. The Government reserves the right to interrupt the work to make tests on all facets of concreting and other operations. These tests will be made as necessary to insure conformance to applicable specifications and drawings and will be made by and at the expense of the Government except Contractor sampling support as required by the Technical Provisions. In those instances where testing is specified to be made at the Government's expense, the cost of the initial testing will be at the Government's expense; however, any retesting due to failure of the materials to meet the requirements in the initial test shall be performed at the Contractor's expense. The retests shall be made at laboratories approved by the Contracting Officer or his/her designated representative. The costs of retests made at Government laboratories will be deducted from the total amount due the Contractor, at actual cost to the Government, unless otherwise specified.

(End of Clause)

1.10 CERTIFICATES OF COMPLIANCE

(l969 MAY OCE)

Any certificates required for demonstrating proof of compliance of materials with specification requirements shall be executed in 3 copies.

Each certificate shall be signed by an official authorized to certify in behalf of the manufacturing company and shall contain the name and address of the Contractor, the project name and location, and the quantity and date or dates of shipment or delivery to which the certificates apply.

Copies of laboratory test reports submitted with certificates shall contain the name and address of the testing laboratory and the date or dates of the tests to which the report applies. Certification shall not be construed as relieving the Contractor from furnishing satisfactory material, if, after tests are performed on selected samples, the material is found not to meet the specific requirements.

SECTION 01 10 00.10 38 Page 6

(End of Clause)

1.11 REQUIRED CONSTRUCTION MEETINGS

(a) In addition to meetings required elsewhere in the specifications, the Contractor and any Subcontractors identified by the Contracting Officer's Representative shall be required to attend a preconstruction meeting (after award of the contract but before Commencement of Work) and a post construction meeting (after final acceptance of the work but before final payment is made). The Contractor and identified Subcontractors shall meet with Corps of Engineers personnel at a time and place determined by the Contracting Officer's Representative.

(b) At the preconstruction conference, the Contractor shall be oriented with respect to Government procedures and line of authority in contractual, administrative, and construction matters. Additionally, a schedule of required submittals will be discussed.

(c) Five (5) days prior to the preconstruction conference, the Contractor shall submit the following items:

Certificate of Insurance Quality Control Plan (see Section 01 45 00.00 10 QUALITY CONTROL, for additional information) Certificate of Completion of Corps CQC Course Preliminary Submittal Register (ENG Form 4288 exclusive of Contractor submittal dates) Letter Appointing Superintendent (see Contract Clause entitled Superintendence by the Contractor, 52.236-6) List of Subcontractors

(d) The letter of record will be written documenting all items discussed at the conference and a copy will be furnished by the Contracting Officer's Representative to all in attendance.

(End of Clause)

1.12 SURVEY DATA

The Contractor shall maintain complete and accurate field notes, sketches, recordings and computations required in establishing the necessary horizontal and vertical control. All survey data shall be recorded in accordance with accepted standards and as approved by the Contracting Officer or his/her designated representative. All the above data shall be available at all times during the progress of the work for ready examination and use by the Contracting Officer or his/her designated representative. Upon request of the Contracting Officer or his/her designated representative, the Contractor shall furnish a copy of above survey data.

(End of Clause)

1.13 SURVEYS AND SURVEY PERSONNEL REQUIREMENTS

(a) Survey personnel. All quantity surveys required by the Contractor, except those for any periods for which progress payments are requested, shall be made by personnel of a professional engineering and/or surveying firm experienced in the practice of such work including Global Positioning Systems (GPS) surveys. The survey personnel shall have the

SECTION 01 10 00.10 38 Page 7 following minimum qualifications.

(1) Each party chief shall be a Professional Land Surveyor and shall be proficient in the operation of precise and semi-precise instruments. They shall be capable of running horizontal and vertical control of 2nd order accuracy. In the event it is considered advantageous to employ a party chief who is not a Professional Land Surveyor, detailed qualifications of the individual shall be submitted to the Contracting Officer for review and approval.

(2) Instrument men shall be proficient in the operation of precise and semi-precise instruments including transit, level, and alidade, and shall prepare all survey notes in a firm and legible manner.

(3) Rodman and chainman. At least one rodman and one chainman, with a minimum of six months prior experience each, shall be assigned to each survey part.

(4) Surveying technicians shall be familiar with all phases of surveys and the North Carolina State plane coordinate system. Also they shall be well versed in the computation and adjustment of horizontal and vertical control of 2nd and 3rd order survey.

1.14 SYSTEM AS-BUILT DRAWINGS

(a) The Contractor shall be responsible for maintaining in good condition one set of reproducible as-built drawings and five copy sets, including system layout drawings and field wiring diagrams. Drawings shall be "D" 34 by 22 inches, drawn to the same scale as the contract drawings, with title block similar to the contract drawings. Reproducible drawings shall be on mylar film. The Contractor shall keep a careful and neat record of all deviations, field changes and modifications from the original contract drawings which are made to each phase of construction as the work progresses. The Contractor is responsible for noting all changes and corrections on these prints promptly as in-place construction activities occur, but in no case less often than on a weekly basis. In addition to the above, the following shall be included:

(1) Actual location of all Contractor installed subsurface utility lines. Type of materials actually installed, major sizes of lines, etc. In order that the location of these lines and appurtenances may be determined in the event the surface openings or indicators become covered or obscured, the record drawings shall show, by offset dimensions to two permanently fixed surface features, both ends of each run and each change in direction. Valves, splice boxes and similar appurtenances shall be located by dimensions along the utility run from a reference point.

The average depth below the surface of each run shall also be recorded.

(2) Any shop drawings which constitute part of the design shall be included with the record drawings.

(3) The manufacturer and model number of all major items of equipment shall be shown on the record drawings.

(4) Upon completion of all construction, the Contractor will delete by notation all references to features not constructed.

(b) These annotated prints shall be certified as to their correctness by the signature of the Contractor and turned over to the

SECTION 01 10 00.10 38 Page 8

Contracting Officer or his/her designated representative not later than ten (10) days after final acceptance of the work by the Government.

Marked up prints shall be reviewed for approval by the Contracting Officer or his/her designated representative and returned for corrections as necessary.

(End of Clause)

1.15 WORK IN QUARANTINED AREA

USACE and the U.S. Department of Agriculture (USDA) have a compliance agreement requiring measures to prevent the spread of certain plant pests that may be present in the soil (USACE ER 1110-1-5 ). Major portions of all southeastern states are in a quarantine area for such pests, including the imported fire ant. In addition, adjacent states to the north have introduced infestations resulting from movement of soil from infested southeastern states. The Contractor shall thoroughly clean all construction equipment and tools at the previous job site in a manner that ensures that these implements are free from residual soil, egg deposits from plant pests, noxious weeds, and plant seeds. Equipment shall be cleaned using water under pressure, and hand tools shall be thoroughly cleaned by brushing or other means to remove all soil. In addition, all construction equipment and hand tools used for this USACE contract shall be thoroughly cleaned by the Contractor before they are removed from this job site. The Contractor shall consult with the USDA jurisdictional office for additional cleaning requirements that may be necessary.

(End of Clause)

1.16 NCDOT SPECIFICATIONS

The North Carolina Department of Transportation ( NCDOT) "Standard Specifications for Roads and Structures English," (hereinafter referred to as the Standard Specifications) applies to this work when so referenced.

(End of Clause)

1.17 DEFINITIONS FOR NCDOT SPECIFICATIONS

Wherever in the North Carolina Department of Transportation "Standard Specifications for Roads and Structures" or on the drawings the following terms are used, the intent shall be as indicated below unless otherwise modified within the specifications:

State - - - - - - - - - - - - - - - - - U. S. Government Department or Department of Transportation - - - - - - - - - - - Corps of Engineers Engineer or Chief Engineer- - - - - - - Contracting Officer, Corps of Engineers Materials and Test Unit - - - - - - - - Corps of Engineers Division of Highways- - - - - - - - - - Corps of Engineers Board or Board of Transportation- - - - Corps of Engineers

Where NCDOT materials and test unit requirements are referenced in these specifications, they shall be taken as such and not Corps of Engineers Standards unless otherwise stated.

SECTION 01 10 00.10 38 Page 9

1.18 PUBLIC CONVENIENCE AND SAFETY

1.18.1 Roads To Be Closed

No road shall be closed to the public by the Contractor until construction of the new facilities infringe upon the public safety or until construction of the new facilities obliterate the existing facilities.

The Contractor shall obtain the Contracting Officer's approval before closing any roads. Barricades, danger, warning and detour signs, as required, shall be erected before closing any roads.

1.18.2 Storage of Materials

Materials and equipment shall not be stored within roadway rights-of-way or in such a manner as to pose possible danger or obstruction to the traveling public.

(End of Clause)

1.19 MAINTENANCE DURING CONSTRUCTION

From the first day any work is done, the Contractor shall maintain in an equally satisfactory condition all of the items of work covered by the contract until they are finished, placed in service unfinished, or until all of the work is finally accepted. This maintenance shall be continuous and effective work prosecuted day by day with adequate equipment to the end of that roadway and structures are kept in satisfactory and acceptable condition. The Contractor shall be responsible for maintaining all barricades, danger, warning, and detour signs and lights as specified hereinafter. When no pay item for such maintenance is shown in the Bidding Schedule, the cost of maintenance shall be included in the price bid for other pay items, and no separate payment will be made.

1.19.1 Maintenance When Work is Suspended

If construction is suspended for any reason, the Contractor shall place the work in such condition as the Contracting Officer or his/her designated representative directs, before suspension, and shall maintain it in a condition satisfactory to the Contracting Officer or his/her designated representative throughout the period of the suspension.

1.19.2 Spilled Materials

The Contractor shall not allow spilled materials to remain on the highways. Spillage sufficient to create a traffic hazard shall be removed immediately. Other light spillage shall be removed daily.

(End of Clause)

1.20 INSPECTION

The Contractor shall furnish, on the request of the Contracting Officer or his/her designated representative or Government Inspector:

a) The Contracting Officer or his/her designated representative or Government Inspector shall have full access at all times to any and all points of construction. All Government Representatives will comply with the real-time/current time requirements of the Center for Disease Control (CDC) requirements. The Contractor shall not impose or

SECTION 01 10 00.10 38 Page 10 enforce requirements and/or restrictions on the Government representatives which are more stringent than, or exceed the CDC requirements without the prior written approval of the Contracting Officer, and any delays or other costs attributable to teh unauthorized impostion or enforcement of those requirements and/or restrictions shall be at the expense of the Contractor.

(End of Clause)

Should the Contractor refuse, neglect, or delay compliance with these requirements, the specific facilities may be furnished and maintained by the Contracting Officer or his/her designated representative and the cost thereof will be deducted from any amounts due or to become due the Contractor.

1.21 PARTNERING

In order to most effectively accomplish this contract, the Government proposes to form a cohesive partnership with the Contractor and its subcontractors. This partnership would strive to draw on the strengths of each organization in an effort to achieve a quality project done right the first time, within budget and on schedule. Integral to the partnership would be a joint Contractor/Government effort to settle any disputes that may arise without costly and time consuming litigation. To that end, a non-binding procedure such as the Alternate Dispute Resolution process could be developed and agreed upon by both parties when it is determined to be necessary. This partnership would be bilateral in make-up and participation will be totally voluntary. Any cost associated with developing this partnership will be agreed to by both parties and will be shared equally with no change in contract price.

(End of Clause)

1.22 LOAD RESTRICTIONS

The Contractor shall comply with all legal load restrictions in the hauling of materials on public roads beyond the limits of the project. A special permit will not relieve the Contractor of liability for damage which may result from such hauling. The Contractor shall not operate equipment of such weight or so loaded as to cause damage to drainage structures or the roadway, or to any other type of improvement, either completed or under construction. Hauling of materials over the existing surface shall be limited as directed, and in no case shall legal load limits be exceeded unless permitted in writing. The Contractor shall repair, at his own expense, all damage to the work caused by his equipment.

(End of Clause)

1.23 BARRICADES, DANGER, WARNING, AND DETOUR SIGNS

The Contractor shall provide, erect, and maintain all necessary traffic control devices in substantial conformance to Part VI of the 1988 "Manual on Uniform Traffic Control Devices for Streets and Highways" as published by the U.S. Department of Transportation, Federal Highway Administration, and available from AMERICAN ASSOCIATION OF STATE HIGHWAY AND

TRANSPORTATION OFFICIALS (AASHTO), U. S. DEPARTMENT OF TRANSPORTATION

(DOT). This requirement shall include flagman as shown in the manual when necessary and the use of electric flashers as conditions of construction

SECTION 01 10 00.10 38 Page 11 may require during hours of darkness. The Contractor shall take all necessary precautions for protection of the work and for the safety of the public at or near the site of construction. Signing, barricades, lights, and other devices shall be well maintained and repositioned or removed as the progress of the work requires. No substandard, poorly maintained device will be acceptable. Particular attention shall be given to the following:

1.23.1 Removal of Barricades And Warning Signs

As soon as construction advances to the extent that temporary barricades, and signs such as "Detour", "One Way Traffic," etc. are no longer needed to inform the traveling public, such signs shall be removed promptly.

1.23.2 Replacement of Signs

When new work is necessary during any period of construction or maintenance, necessary signs shall be replaced as are needed to adequately warn and protect the public in accordance with the provisions outlined above. As soon as the project has been accepted for maintenance, all temporary barricades and warning signs shall be removed promptly.

1.23.3 Cost of Protective Devices

Unless otherwise shown in the Bidding Schedule, the cost of furnishing, erecting, maintaining, and removing protective devices will not be paid for as separate bid items. Where the Contractor is required to perform any of these functions, the cost thereof shall be included in the overall bid submitted. Ownership of the temporary warning devices shall remain with the Contractor provided the devices are removed promptly after completion of the work as specified above. If such warning devices are left in place for more than 30 days after the specified time for removal, the Government shall have the right to remove such devices and to claim possession thereof.

(End of Clause)

1.24 PROTECTION OF EXISTING FACILITIES

The Contractor will not be responsible for any alterations to existing structures or utilities except those made by him for his convenience. The Contractor shall protect all existing structures, including bridges, roadway embankments, lock facilities, utilities and improvements from damage, and, in the event of damage as a result of his operations, the Contractor shall be responsible for their repair, restoration, or for all cost of damage resulting therefrom. In addition, the Contractor shall be responsible for any damage to bridge or culvert structures or railway embankments or track caused by the unauthorized excavation, unathorized fill, fill beyond the project dimensions, or excavation beyond the project dimensions shown on the plans. If the Contractor elects to have alterations made to any existing structure, utility or other improvements for his convenience, he shall make arrangements with the owner of the facility for such alterations and the agreement shall be reviewed and approved by the Contracting Officer or his/her designated representative prior to their alteration.

SECTION 01 10 00.10 38 Page 12

1.25 CONTRACT AREA AND TRESPASSING

Property owners have signed easements which will allow the Contractor to enter and perform the work required by these specifications upon all land lying within the right-of-way limits shown on the drawings. The Contractor's operation shall be confined solely to those areas for which permission has been granted by the owners to enter. The Contractor shall cut only such timber as may be necessary for the prosecution of the work.

The Contractor shall not inflict damage upon land outside the contract area by unwarranted entry upon, passage through, or disposal of material on such land. The Contractor may make a separate agreement with any other party, regarding the use of, or right to, lands or facilities outside the contract area. If such an agreement is made, it shall be in writing and a copy shall be furnished the Contracting Officer or his/her designated representative. The Contractor shall hold and save the Government, its officers, and agents free from liability of any nature or kind arising from any trespassing or damage occasioned by his operations.

(End of Clause)

1.26 COORDINATION WITH OTHER CONTRACTORS

Other Contractors may be working in the vicinity during the time period of this contract. The Contractor shall coordinate the contract operations with other Contractors performing work in the area as needed to avoid conflicts and delays. As a minimum the Contractor shall schedule weekly or as necessary coordination meetings between the Contractor, Contracting Officer or his/her designated representative, local Town officials and their Contractors that are working within the project area to discuss the progress of work and current activities.

1.27 CONTRACT DRAWINGS AND SPECIFICATIONS

(AUG 2000) DFARS 252.236-7001

(a) The Government will provide to the Contractor, without charge, 5 cds, (3) sets of full-size drawings, (2) sets of half-size drawings, and (5) sets of contract specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer or his/her designated representative.

(b) The Contractor shall—

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer or his/her designated representative of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

SECTION 01 10 00.10 38 Page 13

(1) Large-scale drawings shall govern small-scale drawings;

and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified in Section 00 01 15 LIST OF DRAWINGS.

(End of Clause)

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

-- End of Section --

SECTION 01 10 00.10 38 Page 14

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

08/ 15, CHG 2: 08/ 21

PART 1 GENERAL

1.1 SUBMITTALS

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

1.2.2 Location

1.3 OCCUPANCY OF PREMISES

1.4 EXISTING WORK

1.5 LOCATION OF UNDERGROUND UTILITIES

1.5.1 Notification Prior to Excavation

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 11 00 Page 1

SECTION 01 11 00

SUMMARY OF WORK

08/ 15, CHG 2: 08/ 21

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for information only. When used, a code following the "G" classification identifies the office that will review the submittal for the Government.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Project Description

The work includes removing and replacing concrete panel sections of the current esplanade shown in the contract drawings, replacing any unsuitable material to a depth of 5 feet, realigning portions of the existing concrete ditch, removing the existing drop inlet grating and grouting full the remaining length of pipe, and grout injecting the joint between the lock wall and lock retaining wall, and any incidental related work.

1.2.2 Location

The work is located at the William O. Huske Lock and Dam, approximately as indicated in the contract drawings. The exact location will be shown by the Contracting Officer.

1.3 OCCUPANCY OF PREMISES

Building(s) will be occupied during performance of work under this Contract.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.4 EXISTING WORK

In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.5 LOCATION OF UNDERGROUND UTILITIES

Obtain digging permits prior to start of excavation, and comply with

SECTION 01 11 00 Page 2

Installation requirements for locating and marking underground utilities.

Contact local utility locating service a minimum of 48 hours prior to excavating, to mark utilities, and within sufficient time required if work occurs on a Monday or after a Holiday. Verify existing utility locations indicated on contract drawings, within area of work.

1.5.1 Notification Prior to Excavation

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

SECTION 01 11 00 Page 3

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

11/ 20, CHG 2: 08/ 21

PART 1 GENERAL

1.1 SUBMITTALS

1.2 CONTRACT COST BREAKDOWN

1.3 SINGLE JOB PAYMENT ITEMS

1.3.1 Mobilization and Demobilization

1.3.1.1 Payment

1.3.1.2 Unit of Measure

1.3.2 Existing Conduit Demolition

1.3.2.1 Payment

1.3.2.2 Unit of Measure

1.4 UNIT PRICE PAYMENT ITEMS

1.4.1 Concrete Demolition

1.4.1.1 Payment

1.4.1.2 Measurement

1.4.1.3 Unit of Measure

1.4.2 Concrete Replacement

1.4.2.1 Payment

1.4.2.2 Measurement

1.4.2.3 Unit of Measure

1.4.3 Remove and Replace Backfill

1.4.3.1 Payment

1.4.3.2 Measurement

1.4.3.3 Unit of Measure

1.4.4 Grout Injection for Joints

1.4.4.1 Payments

1.4.4.2 Measurement

1.4.4.3 Unit of Measurement

PART 2 PRODUCTS

PART 3 EXECUTION

SECTION 01 20 00 Page 1

SECTION 01 20 00

PRICE AND PAYMENT PROCEDURES

11/ 20, CHG 2: 08/ 21

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" or "S" classification. Submittals not having a "G" or "S" classification are for information only. When used, a code following the "G" classification identifies the office that will review the submittal for the Government.

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

1.2 CONTRACT COST BREAKDOWN

The Contractor must furnish within 30 days after the date of Notice to Proceed, and prior to the submission of its first partial payment estimate, a breakdown of its single job pay item or items which will be reviewed by the Contracting Officer as to propriety of distribution of the total cost to the various accounts. Any unbalanced items as between early and late payment items or other discrepancies will be revised by the Contracting Officer to agree with a reasonable cost of the work included in the various items. This Contract cost breakdown will then be utilized as the basis for progress payments to the Contractor.

1.3 SINGLE JOB PAYMENT ITEMS

Payment items for the work of this Contract for which Contract job payments will be made are listed in the BIDDING SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular job or unit price payment item, are included in the listed job item most closely associated with the work involved. The job price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.3.1 Mobilization and Demobilization

1.3.1.1 Payment

Payment will be made for costs associated with mobilization and demobilization, as defined in Special Contract Requirement PAYMENT FOR

MOBILIZATION AND DEMOBILIZATION.

1.3.1.2 Unit of Measure

Unit of measure: job.

SECTION 01 20 00 Page 2

1.3.2 Existing Conduit Demolition

1.3.2.1 Payment

Payment will be made for costs associated with operations necessary for the demolition and abandonment of the existing conduit.

1.3.2.2 Unit of Measure

Unit of measure: job.

1.4 UNIT PRICE PAYMENT ITEMS

Payment items for the work of this Contract on which the Contract unit price payments will be made are listed in the BIDDING SCHEDULE and described below. The unit price and payment made for each item listed constitutes full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price items.

1.4.1 Concrete Demolition

1.4.1.1 Payment

Payment will be made for costs associated with demolation of the existing esplanade , which includes performing required excavation and other operations incidental thereto, Contractor-furnished disposal area(s) and disposition of excess excavated material and unsuitable and frozen materials.

1.4.1.2 Measurement

The total quantity of demolished material for which payment will be made will be the area outlined in the contract drawings. No allowance will be made for demolition or removal of any material outside the outlined area.

1.4.1.3 Unit of Measure

Unit of measure: square feet.

1.4.2 Concrete Replacement

1.4.2.1 Payment

Payment will be made for costs associated with furnishing, transporting, placing, and constructing the new concrete esplanade as specified.

1.4.2.2 Measurement

The total quantity of placed concrete for which payment will be made will be the area outlined in the contract drawings. No allowance will be made for concrete placed outside of the outlined area..

1.4.2.3 Unit of Measure

Unit of measure: square feet.

SECTION 01 20 00 Page 3

1.4.3 Remove and Replace Backfill

1.4.3.1 Payment

Payment will be made for costs associated with removing, furnishing, transporting, stockpiling (if applicable), delivering, and placing backfill. No separate payment will be made for accessories; include payment in the Contract unit price for the items of work to which the accessories are incidental.

1.4.3.2 Measurement

The total quantity of removed and replaced backfill for which payment will be made will not be greater then 1350 cubic yard.

1.4.3.3 Unit of Measure

Unit of measure: cubic yard in place.

1.4.4 Grout Injection for Joints

1.4.4.1 Payments

Payment will be made for costs associated with furnishing, transporting, delivering, accessing, drilling, and inserting grout. No separate payment will be made for accessories; include payment in the Contract unit price for the items of work to which the accessories are incidental.

1.4.4.2 Measurement

The total quantity of grout injection for which payment will be made will be per joint. No allowance will be made for grout injection done for joints not indicated on the contract drawings.

1.4.4.3 Unit of Measurement

Unit of measure: each.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 20 00 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 32 01.00 10

PROJECT PROGRESS SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 PROJECT SCHEDULER QUALIFICATIONS

PART 2 PRODUCTS

2.1 SOFTWARE

2.1.1 Government Default Software

2.1.2 Contractor Software

2.1.2.1 Primavera

2.1.2.2 Other Than Primavera

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

3.2 PROJECT SCHEDULE DETAILED REQUIREMENTS

3.2.1 Level of Detail Required

3.2.2 Activity Durations

3.2.3 Procurement Activities

3.2.4 Mandatory Tasks

3.2.5 Government Activities

3.2.6 Standard Activity Coding Dictionary

3.2.6.1 Workers Per Day (WRKP)

3.2.6.2 Area of Work Coding (AREA)

3.2.6.3 Modification Number (MODF)

3.2.6.4 Bid Item Coding (BIDI)

3.2.7 Contract Milestones and Constraints

3.2.7.1 Project Start Date Milestone and Constraint

3.2.7.2 End Project Finish Milestone and Constraint

3.2.7.3 Interim Completion Dates and Constraints

3.2.7.3.1 Start Phase

3.2.7.3.2 End Phase

3.2.8 Calendars

3.2.9 Open Ended Logic

3.2.10 Default Progress Data Disallowed

3.2.11 Out-of-Sequence Progress

3.2.12 Added and Deleted Activities

3.2.13 Original Durations

3.2.14 Leads, Lags, and Start to Finish Relationships

3.2.15 Retained Logic

3.2.16 Percent Complete

3.2.17 Remaining Duration

3.2.18 Early Completion Schedule and the Right to Finish Early

3.3 PROJECT SCHEDULE SUBMISSIONS

SECTION 01 32 01.00 10 Page 1

3.3.1 Initial Project Schedule Submission

3.3.2 Periodic Schedule Updates

3.4 SUBMISSION REQUIREMENTS

3.4.1 Data

3.4.2 Network Diagram

3.4.2.1 Continuous Flow

3.4.2.2 Project Milestone Dates

3.4.2.3 Critical Path

3.5 WEEKLY PROGRESS MEETINGS

3.6 REQUESTS FOR TIME EXTENSIONS

3.6.1 Justification of Delay

3.6.2 Time Impact Analysis (Prospective Analysis)

3.6.3 Time Extension

3.6.4 Impact to Early Completion Schedule

3.7 FAILURE TO ACHIEVE PROGRESS

3.7.1 Artificially Improving Progress

3.7.2 Failure to Perform

3.7.3 Recovery Schedule

3.8 OWNERSHIP OF FLOAT

3.9 TRANSFER OF SCHEDULE DATA INTO RMS/QCS

3.10 PRIMAVERA P6 MANDATORY REQUIREMENTS

SECTION 01 32 01.00 10 Page 2

SECTION 01 32 01.00 10

PROJECT PROGRESS SCHEDULE

02/15

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AACE INTERNATIONAL (AACE)

AACE 52R-06 (2006) Time Impact Analysis - As Applied in Construction

U.S. ARMY CORPS OF ENGINEERS (USACE)

ER 1-1-11 (1995) Administration -- Progress, Schedules, and Network Analysis Systems

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation.

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

Project Scheduler Qualifications; G

Initial Project Schedule; G

Periodic Schedule Update; G

1.3 PROJECT SCHEDULER QUALIFICATIONS

Designate an authorized representative to be responsible for the preparation of the schedule and all required updating and production of reports. The authorized representative must have a minimum of 2-years experience scheduling construction projects similar in size and nature to this project with scheduling software that meets the requirements of this specification. Representative must have a comprehensive knowledge of CPM scheduling principles and application.

PART 2 PRODUCTS

2.1 SOFTWARE

The scheduling software utilized to produce and update the schedules required herein must be capable of meeting requirements of this specification.

SECTION 01 32 01.00 10 Page 3

2.1.1 Government Default Software

The Government intends to use Primavera P6 and/or Microsoft Project Professional 2016.

2.1.2 Contractor Software

Scheduling software used by the contractor must be commercially available from the software vendor for purchase with vendor software support agreements available. The software routine used to create the required SDEF file must be created and supported by the software manufacturer.

2.1.2.1 Primavera

If Primavera P6 is selected for use, provide the "xer" export file in a version of P6 importable by the Government system.

2.1.2.2 Other Than Primavera

If the contractor chooses software other than Primavera P6 or Microsoft Project Professional 2016, that is compliant with this specification, the contractor must request permission from the Government to use the software prior to submission of associated submittals.

PART 3 EXECUTION

3.1 GENERAL REQUIREMENTS

Prepare for approval a Project Schedule, as specified…