7007873 SpecsAsOne.pdf

Building 488 & Building 427 Replace Roof 7007873

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 15 LIST OF DRAWINGS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 20 00.00 20 PRICE AND PAYMENT PROCEDURES

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 16.00 20 SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.10 20 QUALITY CONTROL FOR MINOR CONSTRUCTION

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 80 00 REPORTS

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 82 00 ASBESTOS REMEDIATION

02 83 00 LEAD REMEDIATION

DIVISION 05 - METALS

05 51 33 METAL LADDERS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 22 00 ROOF AND DECK INSULATION

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 92 00 JOINT SEALANTS

DIVISION 09 - FINISHES

09 90 00 PAINTS AND COATINGS

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

THIS PAGE INTENTIONALLY LEFT BLANK

PROJECT TABLE OF CONTENTS Page 2

DOCUMENT 00 01 15

LIST OF DRAWINGS

02/11

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings, Maps and Specifications."

1.2 CONTRACT DRAWINGS

Contract drawings are as follows:

DRAWING NO. NAVFAC DWG NO. TITLE

G-001 12767174 COVER SHEET

AD101 12767175 ROOF PLAN - DEMOLITION

AD501 12767176 DETAILS - DEMOLITION

AD502 12767177 DETAILS - DEMOLITION

A-101 12767178 ROOF PLAN - CONSTRUCTION

A-201 12767179 EXTERIOR ELEVATIONS

A-202 12767180 EXTERIOR ELEVATIONS

A-501 12767181 DETAILS - CONSTRUCTION

A-502 12767182 DETAILS - CONSTRUCTION

A-503 12767183 DETAILS - CONSTRUCTION

A-101(427) 12767184 ROOF PLAN AND DETAILS - DEMOLITION

AND CONSTRUCTION

-- End of Document --

DOCUMENT 00 01 15 Page 1

DOCUMENT 00 01 15 Page 2

SECTION 01 11 00

SUMMARY OF WORK

08/15

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes demolition of an existing roof and construction of new roof on Buildings 488 and 427 and incidental related work.

1.1.2 Location

The work is located at the MCAS Cherry Point, approximately as indicated.

The exact location will be shown by the Contracting Officer.

1.2 OCCUPANCY OF PREMISES

Building will be occupied during performance of work under this Contract.

Occupancy notifications will be posted in a prominent location in the work area.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.4 LOCATION OF UNDERGROUND UTILITIES

It shall be the responsibility of the contractor to locate all existing underground utilities that are within the limits of work, prior to any excavation activities. These include but are not limited to the following buried utilities: water lines, sanitary and storm sewers, steam condensate, fuel lines, gas lines, electrical ducts and direct buried conductors, commercial telephone, Base telephone, commercial cable TV, Base instructional cable TV, EMCS, and fire alarm. The contractor shall employ the services of a qualified Utility locating company to locate, identify, and mark all underground utilities. The entire construction limits shall be thoroughly scanned and researched to determine existing utility locations. Any existing utilities that are indicated on the project drawings shall be considered for reference use by the locating company and shall be verified. All underground utilities shall be clearly marked with

SECTION 01 11 00 Page 1 flags, paint or stakes prior to any digging operation except that required to determine exact utility location and depth. CAUTION shall be used when trenching or excavating around or near buried utilities. The contractor shall be responsible for the timely repair and/or replacement of direct and collateral damage on any and all underground utilities that are severed, crushed, broken, displaced or otherwise disturbed by the construction operation. The Government shall not incur any additional cost for such repair or replacement. The contractor shall notify the FEAD a minimum of three working days prior to utility location. Do not continue with excavation or installation of new work without resolving elevation discrepancies and conflicts.

1.4.1 Notification Prior to Excavation

Notify the Contracting Officer at least 15 days prior to starting excavation work.

1.5 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged remain the property of the Government.

FOR FRC EAST JOBS: All equipment, machinery, metallic piping, wire, and other scrap metal shall remain the Government's property. Recycle these items as part of demolition and deconstruction operations. Provide separate containers to collect these items and transport to the FRC East recycling facility in Building 4785.

Provide a salvage plan, listing material and equipment to be salvaged, and their storage location. Maintain property control records for material or equipment designated as salvage. Use a system of property control that is approved by the Contracting Officer. Store and protect salvaged materials and equipment until disposition by the Contracting Officer.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 11 00 Page 2

SECTION 01 14 00

WORK RESTRICTIONS

11/11

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for all submittals. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

List of Contact Personnel

1.2 SPECIAL SCHEDULING REQUIREMENTS

a. Have materials, equipment, and personnel required to perform the work at the site prior to the commencement of the work.

b. The building will remain in operation during the entire construction period. The Contractor must conduct his operations so as to cause the least possible interference with normal operations of the activity.

c. Permission to interrupt any Activity roads, railroads, or utility service must be requested in writing a minimum of 15 calendar days prior to the desired date of interruption.

1.3 CONTRACTOR ACCESS AND USE OF PREMISES

DBIDS has gone live at MCAS Cherry Point. In order to reduce wait time when exchanging your RapidGate credential, it is highly recommended each applicant pre-register at https://dbids-global.dmdc.mil/enroll#!/

Non-DoD cardholding visitors to Marine Corps Installations with a driver's license or ID issued by a state that is not compliant with the Real ID Act of 2005 will now need to provide an alternate form of acceptable identification to gain entry, or be escorted by an authorized patron of the air station.

North Carolina now issues REAL ID compliant drivers licenses, but many drivers have yet to be issued the new license. Drivers may get a North Carolina REAL ID driver's license at any NCDMV driver's license office.

The Act established minimum security standards for license issuance and production and prohibits Federal agencies from accepting driver's licenses and identification cards from states not meeting the Act's minimum standards.

In absence of a compliant state issued driver's license or ID, one of the following federally approved forms of identification must also be provided in addition to the non-compliant driver's license or ID:

1. U.S. Passport

2. U.S. Passport Card

3. U.S. Coast Guard Merchant Mariner Card

4. Personal Identity Verification (PIV) Card

SECTION 01 14 00 Page 1

5. Personal Identity Verification - Interoperable (PIV-I)

6. U.S. State Department Driver's License

7. Veteran's Health Identification Card (Issued by the U.S. Department of Veterans Affairs)

8. U.S. Permanent Resident Card (Form I-551)

9. U.S. Certificate of Naturalization or Certificate of Citizenship (Form N-550)

10. Department of Homeland Security Employment Authorization Document (Form I-766)

1.3.1 Activity Regulations

Ensure that Contractor personnel employed on the Activity become familiar with and obey Activity regulations including safety, fire, traffic and security regulations. Keep within the limits of the work and avenues of ingress and egress. Wear hard hats in designated areas. Do not enter any restricted areas unless required to do so and until cleared for such entry. Mark Contractor equipment for identification.

1.3.1.1 Subcontractors and Personnel Contacts

Provide a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.3.1.2 Installation Access

Obtain access to Navy and Marine Corps installations through participation in the Defense Biometrics Identification System (DBIDS). Requirements for Contractor employee registration, and transition for employees currently under Navy Commercial Access Control System (NCACS), are available at https://www.cnic.navy.mil/om/dbids.html. No fees are associated with obtaining a DBIDS credential.

Participation in the DBIDS is not mandatory, and Contractor personnel may apply for One-Day Passes at the Base Visitor Control Office to access an installation.

1.3.1.2.1 Registration for DBIDS

Registration for DBIDS is available at https://www.cnic.navy.mil/om/dbids.html. Procedure includes:

a. Present a letter or official award document (i.e. DD Form 1155 or SF 1442) from the Contracting Officer, that provides the purpose for access, to the Base Visitor Control Center representative.

b. Present valid identification, such as a passport or Real ID Act-compliant state driver's license.

c. Provide completed SECNAV FORM 5512/1 to the Base Visitor Control Center representative to obtain a background check. This form is available for download at https://www.cnic.navy.mil/om/dbids.html.

d. Upon successful completion of the background check, the Government will complete the DBIDS enrollment process, which includes Contractor employee photo, finger prints, base restriction and several other assessments.

SECTION 01 14 00 Page 2

e. Upon successful completion of the enrollment process, the Contractor employee will be issued a DBIDS credential, and will be allowed to proceed to worksite.

1.3.1.2.2 DBIDS Eligibility Requirements

Throughout the length of the contract, the Contractor employee must continue to meet background screen standards. Periodic background screenings are conducted to verify continued DBIDS participation and installation access privileges. DBIDS access privileges will be immediately suspended or revoked if at any time a Contractor employee becomes ineligible.

An adjudication process may be initiated when a background screen failure results in disqualification from participation in the DBIDS, and Contractor employee does not agree with the reason for disqualification. The Government is the final authority.

1.3.1.2.3 DBIDS Notification Requirements

a. Immediately report instances of lost or stolen badges to the Contracting Officer.

b. Immediately collect DBIDS credentials and notify the Contracting Officer in writing under the following circumstances:

(1) An employee has departed the company without having properly returned or surrendered their DBIDS credentials.

(2) There is a reasonable basis to conclude that an employee, or former employee, might pose a risk, compromise, or threat to the safety or security of the Installation or anyone therein.

1.3.1.2.4 One-Day Passes

Personnel applying for One-Day passes at the Base Visitor Control Office are subject to daily mandatory vehicle inspection, and will have limited access to the installation. The Government is not responsible for any cost or lost time associated with obtaining daily passes or added vehicle inspections incurred by non-participants in the DBIDS.

1.3.1.3 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installation, except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.3.2 Working Hours

Regular working hours must consist of an 8 1/2 hour period , between 7 a.m.

and 3:30 p.m., Monday through Friday, excluding Government holidays.

1.3.3 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

SECTION 01 14 00 Page 3

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work must be lighted in a manner approved by the Contracting Officer. Make utility cutovers after normal working hours or on Saturdays, Sundays, and Government holidays unless directed otherwise.

1.3.4 Occupied Building

The Contractor shall be working in an existing building which is occupied.

The existing buildings and their contents must be kept secure at all times. Provide temporary closures as required to maintain security as directed by the Contracting Officer.

1.3.5 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in paragraph WORK OUTSIDE REGULAR HOURS.

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Interruption to water, sanitary sewer, storm sewer, telephone service, electric service, air conditioning, heating, fire alarm, compressed air, are considered utility cutovers pursuant to the paragraph WORK

OUTSIDE REGULAR HOURS.

1.4 SECURITY REQUIREMENTS

1.4.1 Station Regulations

No employee or representative of the contractor will be admitted to the work site without an Identification Badge or is specifically authorized admittance to the work site by the FEAD, Facilities Engineering & Acquisition Division.

IMPORTANT NOTE: FEAD personnel (Construction Managers, Engineers/Architects, Engineering Technicians, Contract Specialists, or Contract Surveillance Representatives) will not receive, process, re-transmit or otherwise handle IN ANY WAY Personally Identifiable Information (PII) related to the badging process. Do NOT forward any of this information to the FEAD.

1.4.2 Contractor Access to MCAS Cherry Point and Outlying Areas

1. Documentation requirements for granting access to MCAS Cherry Point for commercial and contract employers and employees. This document is an aid in meeting ASO 5560.6A requirements and is not a substitute for the order.

2. The Pass & Identification Office at Building 251 will issue credentials to authorized contractors. Sub-Contractors and suppliers must coordinate through the Prime-Contractor:

3. Criminal Activity. In accordance with ASO 5560.6A, the below list of criminal activities within an applicant's record are considered not in the

SECTION 01 14 00 Page 4 best interest of the Marine Corps and will be grounds for automatic denial of access aboard the Installation:

a. Conviction of any felony offense.

b. Conviction of any misdemeanor offense, which was the result of a plea bargain of a felony offense.

c. Conviction of any offense involving a weapon.

d. Conviction of any drug offense involving manufacturing or trafficking.

e. More than one misdemeanor conviction of drug related offenses over the applicant's lifetime or one misdemeanor drug related offense within the last five years.

f. Conviction of any assault charge.

g. Conviction of any offense involving theft or larceny.

h. Conviction of any offense of domestic violence.

i. Conviction of any offense related to the abuse/neglect of a child.

j. Conviction of any sexual in nature related offense or registration as a sex offender.

k. Commission of any grievous criminal offense/misconduct while aboard any Federal installation, including blatant disregard for rules and regulations of the Installation, but excluding minor traffic offenses.

l. Other than Honorable, Bad Conduct, and Dishonorable discharges from the U.S. Military.

m. Those identified as undocumented citizens.

n. Those on the National Terrorist Watch List.

o. Any individual who attempts to hide or purposely fails to disclose all past criminal history during the vetting process.

p. Any individual that the Provost Marshal's Office determines to present a risk to the security and safety of the Installation and whose access is deemed not in the best interest of the Marine Corps.

q. Any individual who has been debarred from the Installation by the Installation Commander or is currently listed as debarred from any other Federal installation.

r. Any individual with an outstanding warrant for their arrest or apprehension.

s. Any individual with a pending criminal court case that, if convicted, would result in access denial in accordance with the criteria listed above.

SECTION 01 14 00 Page 5

1.4.3 FLIGHTLINE SECURITY REQUIREMENTS

Work involved under this contract is in the Flightline Security Area. No employee or representative of the Contractor will be admitted to the work site unless they (1) are specifically authorized admittance by the FEAD, and (2) have a security badge. The Contractor shall obtain clearance and flightline security badges for all personnel required to be on the project site prior to performing any work. The Contractor shall submit a written request for security badges to the FEAD and to Pass & ID. Each employee will be required to go to PASS & ID at Building 251 to obtain his security badge with flightline access. A limited number of Contractor vehicles will be allowed access to the site of work subject to meeting regular Station access requirements. No personal vehicles will be allowed behind the security fence. Parking of vehicles shall be restricted to the immediate project site as determined by the FEAD. The security badges issued under this contract are valid for this specific project and are not transferable to another project.

1.4.4 FLEET READINESS CENTER, EAST (FRC EAST) REQUIREMENTS

Work involved under this contract is in the FRC East Maintenance Depot and Flightline Area. No employee or representative of the Contractor will be admitted to the work site unless they (1) are specifically authorized admittance by the FEAD, and (2) has a security badge. The Contractor shall obtain clearance and FRC East security badges for all personnel required to be on the project site prior to performing any work. The Contractor shall submit a written request for security badges to the FEAD and to FRC East Security. Each employee will be required to go to Trailer 32 to obtain his security badge with FRC East access. A limited number of Contractor vehicles will be allowed access to the site of work subject to meeting regular access requirements. No personal vehicles will be allowed behind the security fence. Parking of vehicles shall be restricted to the immediate project site as determined by the FRC East Security. The security badges issued under this contract are valid for this specific project and are not transferable to another project.

FRC East is registered to the ISO 9001, AS 9110, ISO 14001, and OSHAS 18001 standards. In addition to these, registration under the Occupational Safety and Health Administration's Voluntary Protection Program is in progress. To adhere to the standards required of these programs, FRC East must ensure that all individuals accessing the facility are aware of the conditions and factors that affect the well-being of all employees, temporary workers, contractor personnel, visitors, and any other person in the workplace.

The following are requirements for granting access to Fleet Readiness Center East (FRC East) for commercial and contract employers and employees.

a. The Contractor shall complete a "Contractor Work Notice- Form FRC-East 5000/10" and provide the Notice to the appropriate shop supervisor for signature and leave the top part of the Notice with the shop supervisor to post in a prominent location in the work area. The Contractor shall keep the bottom portion of the "Contractor Work Notice" for his records and provide a copy to the Contracting Officer. For projects occurring on facility roofs (roofing repair, HVAC replacement, or similar work), the Contractor shall complete a "Contractor Work Notice" form and provide the Notice to the shop directly under the area being

SECTION 01 14 00 Page 6 worked, even if no direct impact to the shop is anticipated. A blank copy of this form is included at the end of this section.

b. In the event of an emergency, including hazardous material spills, the individual discovering the emergency shall call 911 from any FRC East phone. Relay the grid number listed on the phone for location assistance. If you are calling from a cell phone, call 252-466-3616 - Fire Department Dispatch.

c. Badges will be displayed at all times and shall be returned upon completion of visit/work. Every badge is considered Government Property and all lost badges will be reported to the FRC East Badge and Decal Office located in Trailer 32.

d. The facility must be kept clean and orderly at all times.

Ensure that you place all waste in proper receptacles so that the facility is maintained in a "Clean as you go" condition.

e. When in the FRC East industrial areas, wear the personal protective equipment (PPE) required for that area. PPE requirements are generally marked but if there is uncertainty, check with the area supervisor. Typically, safety glasses with side shields and steel toed shoes are required in most shops.

f. Smoking is NOT authorized while traveling from one facility location to another while walking or in a vehicle being operated anywhere within the FRC East compound. ABSOLUTELY NO SMOKING on the property except in Designated Smoking Areas.

g. Extra caution shall be taken around the flight line and aircraft turn-up areas to control trash, debris, and materials.

Additionally, all personnel on the flight line must be continuously alert and stay clear of helicopter and jet operations in progress.

h. Vehicles must not obstruct aircraft movement or other daily operations.

i. If an emergency situation occurs which would endanger the health or safety of personnel, the area shall be evacuated.

Re-entry to affected buildings will be at the discretion of uniformed guards, fire department, or safety office personnel only.

j. Decisions to evacuate will be from the FRC East Commanding Officer or his/her representative. Visitors/contractors, along with non-essential facility personnel, south of Harrison Drive, adjacent to Building 4224, will evacuate the facility first.

Fifteen minutes later, the visitors/contractors south of Curtis Road, between Buildings 83 & 84, will evacuate the facility.

Fifteen minutes later the visitors/contractors north of Curtis Road will evacuate the facility.

k. Cellular phones and photographic equipment are not authorized within FRC East unless they are approved in advance by the Security Office (252-464-7999). Cellular phones may be used on roof areas for emergency purposes only.

l. All vehicles must have proper passes, and no pass may be transferred between vehicles.

SECTION 01 14 00 Page 7

m. All vehicles will follow posted speed limits, which are: "Do not exceed 5 MPH on the outside of buildings, nor 3 MPH inside of any building".

n. Vehicle headlights must be on at all times within the facility.

o. All vehicles are required to slow down, sound horn, and proceed with caution at all cross aisles and other locations where vision is obstructed.

p. Personnel are strictly forbidden to introduce any substance into the storm drain system including catch basins, roof drains, and floor drains.

q. All facility entrants are responsible for all materials they bring into the facility and shall handle them in such a manner to ensure they are not left as "foreign objects" anywhere in the facility.

r. In case of a utility emergency on weekends or after normal work hours, call the Public Works Department trouble call desk at 252-466-4363.

s. The use of gasoline is prohibited for any purpose other than fueling motor vehicles. All gasoline-powered vehicles are prohibited inside FRC East buildings.

1.4.5 Mandatory Contract Performance Requirements for FRC East

a. All personnel working on site at FRC East under this contract must document their receipt and review of the information listed in FRCEASTINST 5000.1A, enclosure (1), annually. The Security Department will provide a means of completing initial review prior to FRC East entrance.

b. Foreign object (FO) is defined as any article or substance alien to the aircraft or assembly which is allowed to invade the product. Foreign Object Damage (FOD) is the damage that occurs due to these FOs. All FRC East work sites will be maintained in such a manner as to prevent FOD to aircraft and/or aircraft components. Work sites shall be kept clean at all times. All debris, scrap material, tools, and equipment will be cleared from the work site as work progresses. At no time will hoses, power cords, materials, etc. be permitted to create tripping hazards in areas of the work site.

c. In those cases where a contractor supervisor determines that solving a safety or health problem is beyond their control, but within the control of FRC East, the contractor shall notify the Contracting Officer.

d. All contractor employees performing work on site at FRC East shall immediately report any safety, security, or environmental violation to the Contracting Officer, who will notify the cognizant FRC East Safety/Security/Environmental Office. The initial FRC East notification can be made via phone or e-mail and should include as many applicable details as possible (date, time, identification numbers, tags, company, etc.). This initial

SECTION 01 14 00 Page 8 notification will be made as soon as possible. A safety incident will require the contractor to complete and submit an incident memo to the Contracting Officer, who will forward a copy to the FRC Safety Office within 24 hours of the accident/incident. This incident memo will include the full name of the person involved in the incident, their age, sex, job title, the name of the employing company, and the contract number/title. In addition, this memo will include the severity of the illness or injury, indirect cause(s) of the accident, and whether personal protective equipment was available and used.

e. All contractors and sub-contractors working within FRC East must develop and operate effective safety and health programs.

1.4.5.1 Additional Contract Performance Requirements for FRC East

a. Work above or anywhere near aircraft or passageways shall be avoided whenever possible. If this is not possible, the cognizant shop supervisor will be informed so arrangements can be made to protect, move, or evacuate assets from the area to minimize foreign object debris potential. The area below the elevated work area will be adequately marked and barricaded at all times. Under no circumstances will work be performed over unprotected spaces.

b. Constant control of tools and materials is required at all times in the following critical areas: Shop 94304 (Rotor Head Shop); Shop 94601 (Ordinance/Survival Shop); Shop 93117 (Aircraft Paint Shop); Shop 93111 (Aircraft Clean Shop); Shop 96552, 96555, and 96556 (Aircraft Engine Shops); all shops in Building 4225 (Blade Vane); and all Shop 95000 Aircraft Hangars.

c. Buildings 131, 137, 188, 245, 4224, and 4247 are classified as hazardous areas and have special requirements. Do not utilize any ignitable items powered by electric motors or internal combustion engines unless they are determined to be suitable to the conditions of the buildings.

d. The recharging of mobile equipment shall not take place inside any FRC-East building.

e. Tools and hardware will be controlled at all times to prevent migration out of the work site. Lost tools shall be reported to the Contracting Officer who will then notify the FRC East Tool Control Manager at 252-464-9741. Tools found unattended will be confiscated and reported to the Contracting Officer.

f. Personnel working on the flight line must be continuously alert, and stay clear of helicopter and jet operations in progress.

g. Work requiring any modification to an air pollution control device must be approved in advance by the Contracting Officer, who will obtain approval from the FRC East Air Quality Program Manager. These devices are marked with a 5" x 9" red placard and a contact number, 252-464-8412.

h. Work accomplished that will impact industrial ventilation systems or fans will require prior notification of the Contracting Officer, who will then notify the FRC East Air Quality Program Manager at 252-464-8412. These systems are continuously monitored.

SECTION 01 14 00 Page 9

1.4.6 TRANSPORTATION TO AND FROM PINEY ISLAND

Contractor shall be required to provide everything for his personnel such as transportation to and from site, toilet facilities, dining facilities, etc. Use of Government transportation to and from Piney Island (BT-11) will not be permitted.

Contractor will be allowed to off-load and load barges at the current barge facility at Piney Island (BT-11) (next to Control Bldg) A barge may be parked there as long as it is not hampering government or other contractor's activities. Due to limited space, the contractor should keep amount of equipment at site to a minimum. It may be permitted to have a crane barge pull up to the dock at the fuel facility to load and off-load heavy material. The contractor shall determine channel depths prior to construction to verify the channel is deep enough to accommodate the contractor's equipment barges and cranes.

1.4.7 Staging Area

As indicated on the plans, the Contractor staging area will be (PM to coordinate). Amount of material on site shall be kept to a minimum and shall only be material that is pertinent to the work currently being performed. All stockpiling of equipment and materials shall be closely coordinated with the Government and shall not disrupt activities at the site.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 14 00 Page 10

SECTION 01 20 00.00 20

PRICE AND PAYMENT PROCEDURES

11/11

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EP-1110-1-8 (2009) Construction Equipment Ownership and Operating Expense Schedule

1.2 SUBMITTALS

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

Schedule of Prices

1.3 SCHEDULE OF PRICES

1.3.1 Data Required

Within 15 calendar days of notice of award, prepare and deliver to the Contracting Officer a Schedule of Prices (construction contract) as directed by the Contracting Officer. Provide a detailed breakdown of the contract price, giving quantities for each of the various kinds of work, unit prices, and extended prices. Costs shall be summarized and totals provided for each construction category.

1.3.2 Schedule Instructions

Payments will not be made until the Schedule of Prices has been submitted to and accepted by the Contracting Officer. Identify the cost for site work, and include incidental work to the 5 ft line. Identify costs for the building(s), and include work out to the 5 ft line. Work out to the 5 ft line shall include construction encompassed within a theoretical line 5 ft from the face of exterior walls and shall include attendant construction, such as pad mounted HVAC cooling equipment, cooling towers, and transformers placed beyond the 5 ft line.

1.4 CONTRACT MODIFICATIONS

In conjunction with the Contract Clause "DFARS 252.236-7000, Modification Proposals-Price Breakdown," and where actual ownership and operating costs of construction equipment cannot be determined from Contractor accounting records, equipment use rates shall be based upon the applicable provisions of the EP-1110-1-8.

SECTION 01 20 00.00 20 Page 1

1.5 CONTRACTOR'S INVOICE AND CONTRACT PERFORMANCE STATEMENT

1.5.1 Content of Invoice

Requests for payment will be processed in accordance with the Contract Clause FAR 52.232-27, Prompt Payment Construction Contracts and FAR 52.232-5, Payments Under Fixed-Price Construction Contracts. The requests for payment shall include the documents listed below.

a. The Contractor's invoice, on NAVFAC Form 7300/30 furnished by the Government, showing in summary form, the basis for arriving at the amount of the invoice. Form 7300/30 shall include certification by Contractor and Quality Control (QC) Manager.

b. The Estimate for Voucher/Contract Performance Statement on NAVFAC Form 4330/54 furnished by the Government, showing in detail: the estimated cost, percentage of completion, and value of completed performance.

Use NAVFAC Form 43300/54 on NAVFAC contracts when a Monthly Estimate for Voucher is required.

c. Updated Project Schedule and reports required by the contract.

d. Contractor Safety Self Evaluation Checklist.

e. Other supporting documents as requested.

f. Updated copy of submittal register.

g. Invoices not completed in accordance with contract requirements will be returned to the Contractor for correction of the deficiencies.

h. Contractor's Monthly Estimate for Voucher and Contractors Certification (NAVFAC Form 4330/54) with Subcontractor and supplier payment certification.

i. Materials on Site.1.5.2 Submission of Invoices

If DFARS Clause 5252.232-7006 is included in the contract, provide the documents listed in paragraph CONTENT OF INVOICE in their entirety as attachments in Wide Area Work Flow (WAWF) for each invoice submitted. The maximum size of each WAWF attachment is two megabytes, but there are no limits on the number of attachments. If a document cannot be attached in WAWF due to system or size restriction, provide it as instructed by the Contracting Officer.

Monthly invoices and supporting forms for work performed through the anniversary award date of the contract shall be submitted to the Contracting Officer within 5 calendar days of the date of invoice. For example, contract award date is the 7th of the month, the date of each monthly invoice shall be the 7th and the invoice shall be submitted by the 12th of the month.

1.5.3 Final Invoice

a. A final invoice shall be accompanied by the certification required by DFARS 252.247.7023 TRANSPORTATION OF SUPPLIES BY SEA, and the Contractor's Final Release. If the Contractor is incorporated, the Final Release shall contain the corporate seal. An officer of the corporation shall sign and the corporate secretary shall certify the

SECTION 01 20 00.00 20 Page 2

Final Release.

b. For final invoices being submitted via WAWF, the original Contractor's Final Release Form and required certification of Transportation of Supplies by Sea must be provided directly to the respective Contracting Officer prior to submission of the final invoice. Once receipt of the original Final Release Form and required certification of Transportation of Supplies by Sea has been confirmed by the Contracting Officer, the Contractor shall then submit final invoice and attach a copy of the Final Release Form and required certification of Transportation of Supplies by Sea in WAWF.

c. Final invoices not accompanied by the Contractor's Final Release and required certification of Transportation of Supplies by Sea will be considered incomplete and will be returned to the Contractor.

1.6 PAYMENTS TO THE CONTRACTOR

Payments will be made on submission of itemized requests by the Contractor which comply with the requirements of this section, and will be subject to reduction for overpayments or increase for underpayments made on previous payments to the Contractor.

1.6.1 Obligation of Government Payments

The obligation of the Government to make payments required under the provisions of this contract will, at the discretion of the Contracting Officer, be subject to reductions and suspensions permitted under the FAR and agency regulations including the following in accordance with FAR 32.503-6:

a. Reasonable deductions due to defects in material or workmanship;

b. Claims which the Government may have against the Contractor under or in connection with this contract;

c. Unless otherwise adjusted, repayment to the Government upon demand for overpayments made to the Contractor; and

d. Failure to provide up to date record drawings not current as stated in Contract Clause "FAC 5252.236-9310, Record Drawings."

1.6.2 Payment for Onsite and Offsite Materials

Progress payments may be made to the contractor for materials delivered on the site, for materials stored off construction sites, or materials that are in transit to the construction sites under the following conditions:

a. FAR 52.232-5(b) Payments Under Fixed Price Construction Contracts.

b. Materials delivered on the site but not installed, including completed preparatory work, and off-site materials to be considered for progress payment shall be major high cost, long lead, special order, or specialty items, not susceptible to deterioration or physical damage in storage or in transit to the construction site. Examples of materials acceptable for payment consideration include, but are not limited to, structural steel, non-magnetic steel, non-magnetic aggregate, equipment, machinery, large pipe and fittings,precast/prestressed concrete products, plastic lumber (e.g., fender piles/curbs), and

SECTION 01 20 00.00 20 Page 3 high-voltage electrical cable. Materials not acceptable for payment include consumable materials such as nails, fasteners, conduits, gypsum board, glass, insulation, and wall coverings.

c. Materials to be considered for progress payment prior to installation shall be specifically and separately identified in the Contractor's estimates of work submitted for the Contracting Officer's approval in accordance with Schedule of Prices requirement of this contract.

Requests for progress payment consideration for such items shall be supported by documents establishing their value and that the title requirements of the clause at FAR 52.232-5 have been met.

d. Materials are adequately insured and protected from theft and exposure.

e. Provide a written consent from the surety company with each payment request for offsite materials.

f. Materials to be considered for progress payments prior to installation shall be stored either in Hawaii, Guam, Puerto Rico, or the Continental United States. Other locations are subject to written approval by the Contracting Officer.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 20 00.00 20 Page 4

SECTION 01 30 00

ADMINISTRATIVE REQUIREMENTS

08/15

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

1.2 SUBMITTALS

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

List of contact personnel

1.2.1 Contract Personnel

Furnish a list of contact personnel of the Contractor and subcontractors including addresses and telephone numbers for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists.

1.3 MINIMUM INSURANCE REQUIREMENTS

Provide the minimum insurance coverage required by FAR 28.307-2 LIABILITY, during the entire period of performance under this contract. Provide other insurance coverage as required by North Carolina State law.

1.4 SUPERVISION

1.4.1 Minimum Communication Requirements

Have at least one qualified superintendent, or competent alternate, capable of reading, writing, and conversing fluently in the English language, on the job-site at all times during the performance of contract work. In addition, if a Quality Control (QC) representative is required on the contract, then that individual must also have fluent English communication skills.

1.4.2 Superintendent Qualifications

The project superintendent must have a minimum of 10 years experience in construction with at least 5 of those years as a superintendent on projects similar in size and complexity. The individual must be familiar with the requirements of EM 385-1-1 and have experience in the areas of hazard identification and safety compliance. The individual must be capable of

SECTION 01 30 00 Page 1 interpreting a critical path schedule and construction drawings. The qualification requirements for the alternate superintendent are the same as for the project superintendent. The Contracting Officer may request proof of the superintendent's qualifications at any point in the project if the performance of the superintendent is in question.

1.4.2.1 Duties

The project superintendent is primarily responsible for managing and coordinating day-to-day production and schedule adherence on the project.

The superintendent is required to attend NAVFAC Red Zone meetings, partnering meetings, and quality control meetings. The superintendent or qualified alternative must be on-site at all times during the performance of this contract until the work is completed and accepted.

1.4.3 Non-Compliance Actions

The Project Superintendent is subject to removal by the Contracting Officer for non-compliance with requirements specified in the contract and for failure to manage the project to insure timely completion. Furthermore, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. No part of the time lost due to such stop orders is acceptable as the subject of claim for extension of time for excess costs or damages by the Contractor.

1.5 PRECONSTRUCTION MEETING

After award of the contract but prior to commencement of any work at the site, meet with the Contracting Officer to discuss and develop a mutual understanding relative to the administration of the value engineering and safety program, preparation of the schedule of prices, shop drawings, and other submittals, scheduling programming, prosecution of the work, and clear expectations of the "Interim DD Form 1354" Submittal. Major subcontractors who will engage in the work must also attend.

1.6 PARTNERING

To most effectively accomplish this contract, the Government requires the formation of a cohesive partnership within the Project Team whose members are from the Government, the Contractor and their Subcontractors. Key personnel from the Supported Command, the End User (who will occupy the facility), the Government Design and Construction team and Subject Matter Experts, the Installation, the Contractor and Subcontractors, and the Designer of Record will be invited to participate in the Partnering process. The Partnership will draw on the strength of each organization in an effort to achieve a project that is without any safety mishaps, conforms to the Contract, and stays within budget and on schedule.

The Contracting Officer will provide Information on the Partnering Process and a list of key and optional personnel who should attend the Partnering meeting.

1.6.1 Informal Partnering

The Contracting Officer will organize the Partnering Sessions with key personnel of the project team, including Contractor personnel and Government personnel.

The Initial Partnering session should be a part of the Pre-Construction

SECTION 01 30 00 Page 2

Meeting. Partnering sessions will be held at a location agreed to by the Contracting Officer and the Contractor (typically a conference room provided by the PWD FEAD office or the Contractor). The Initial Informal Partnering Session will be conducted and facilitated using electronic media (a video and accompanying forms) provided by the Contracting Officer. The Partners will determine the frequency of the follow-on sessions, at no more than 3 to six month intervals.

1.7 ELECTRONIC MAIL (E-MAIL) ADDRESS

Establish and maintain electronic mail (e-mail) capability along with the capability to open various electronic attachments as text files, pdf files, and other similar formats. Within 10 days after contract award, provide the Contracting Officer a single (only one) e-mail address for electronic communications from the Contracting Officer related to this contract including, but not limited to contract documents, invoice information, request for proposals, and other correspondence. The Contracting Officer may also use email to notify the Contractor of base access conditions when emergency conditions warrant, such as hurricanes or terrorist threats.

Multiple email addresses are not allowed.

It is the Contractor's responsibility to make timely distribution of all Contracting Officer initiated e-mail with its own organization including field office(s). Promptly notify the Contracting Officer, in writing, of any changes to this email address.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 3

SECTION 01 30 00 Page 4

SECTION 01 32 16.00 20

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

08/18

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for all submittals. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Baseline Construction Schedule;

SD-07 Certificates

Monthly Updates

1.2 PRE-CONSTRUCTION SCHEDULE REQUIREMENT

Prior to the start of work, prepare and submit to the Contracting Officer a Baseline Construction Schedule in the form of a Network Analysis Schedule (NAS) Bar Chart Schedule in accordance with the terms in Contract Clause FAR 52.236-15 Schedules for Construction Contracts, except as modified in this contract. The approval of a Baseline Construction Schedule is a condition precedent to:

a. The Contractor starting demolition work or construction stage(s) of the contract.

b. Processing Contractor's invoice(s) for construction activities/items of work.

c. Review of any schedule updates.

Submittal of the Baseline Construction Schedule, and subsequent schedule updates, is understood to be the Contractor's certification that the submitted schedule meets the requirements of the Contract Documents, represents the Contractor's plan on how the work will be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).

1.3 SCHEDULE FORMAT

1.3.1 Network Analysis Schedule (NAS)

Use the critical path method (CPM) to schedule and control project activities. Prepare and maintain project schedules using Primavera P6 or Microsoft Project 2010. The scheduling software that will be utilized by the Government on this project is Microsoft Project 2010 by Microsoft, Inc. Notwithstanding any other provision in the contract, schedules submitted for this project must be prepared using Microsoft Project.

Submission of data from another software system where data conversion techniques or software is used to import into Microsoft Projects scheduling software is not acceptable and will be cause for rejection of the submitted schedule. Importing data into the scheduling program using data conversion

SECTION 01 32 16.00 20 Page 1 techniques or third party software is cause for rejection of the submitted schedule.

Within 15 calendar days after approval of the Initial Schedule or approval of the final design for a design build project, submit to the Contracting Officer a final NAS schedule.

1.3.1.1 Activity Requirements

a. At a minimum, identify the following in the schedule:

(1) Design and Construction time for major systems and components

(2) Each activity assigned with its appropriate Responsibility Code

(3) Each activity assigned with its appropriate Phase and Area Codes

(4) Major submittals and submittal processing time

(5) Major equipment lead time

b. Build the Schedule as follows:

(1) Show design periods, submittals, Government review periods, material/equipment delivery, utility outages, on-site construction, inspection, testing, and closeout activities.

Government and Contractor on-site work activities must be driven by calendars that reflect Saturdays, Sundays and all Federal Holidays as non-work days for 5-day work week calendars.

(2) With the exception of the Contract Award and End Contract milestone activities, use of open-ended activities is not allowed;

each activity must have predecessor and successor ties. No activity must have open start or open finish (dangling) logic.

Minimize redundant logic ties. Once an activity exists on the schedule it must not be deleted or renamed to change the scope of the activity and must not be removed from the schedule logic without approval from the Contracting Officer. While an activity cannot be deleted, where said activity is no longer applicable to the schedule but must remain within the logic stream for historical record, it can be changed to a milestone.