Amendment A001 Lake Nighthorse.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

2. AMENDMENT/MODIFICATION NUMBER

*FAILURE TO ACKNOWLEDGE THIS AMENDMENT IN BLOCK 19 OF THE SF 1442 BY THE DESIGNATED DATE AND HOUR SPECIFIED IN THE SOLICITATION MAY RESULT IN REJECTION OF YOUR BID (REFER TO ITEM 11.)

FEDERAL HIGHWAY ADMINISTRATION

CENTRAL FEDERAL LANDS HIGHWAY DIVISION

12300 WEST DAKOTA AVENUE, SUITE 360

LAKEWOOD, COLORADO 80228

ATTENTION:

9A. AMENDMENT OF SOLICITATION NUMBER

5. PROJECT NUMBER (If applicable)

9B. DATED (SEE ITEM 11)

0*

*See Item 14

B-7

Solicitation Provisions

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. (SEP 2024)

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements-Representation. (JAN 2017)

52.204-5 Women-Owned Business (Other Than Small Business). (OCT 2014)

52.204-7 System for Award Management. (NOV 2024)

52.204-90 Offeror Identification (DEVIATION NOV 2025)

52.209-5 Certification Regarding Responsibility Matters. (AUG 2020)

52.209-7 Information Regarding Responsibility Matters (OCT 2018)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (FEB 2016)

52.209-13 Violation of Arms Control Treaties or Agreements – Certification (NOV 2021)

52.214-3 Amendments to Invitations for Bids. (DEC 2016)(DEVIATION OCT 2025)

52.214-4 False Statements in Bids. (APR 1984)

52.214-5 Submission of Bids. (DEC 2016)(DEVIATION OCT 2025)

52.214-6 Explanation to Prospective Bidders. (APR 1984)

52.214-7 Late Submissions, Modifications, and Withdrawals of Bids. (NOV 1999)

(DEVIATION OCT 2025)

52.214-18 Preparation of Bids - Construction. (APR 1984)

52.214-19 Contract Award - Sealed Bidding - Construction. (AUG 1996)

52.214-34 Submission of Offers in the English Language. (APR 1991)

52.214-35 Submission of Offers in U.S. Currency. (APR 1991)

52.216-1 Type of Contract. (APR 1984)

The Government contemplates award of a FIRM FIXED PRICE contract resulting from this solicitation.

(End of provision)

Amendment A001 10.07.2025

C-3

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations (NOV 2015)

52.211-12 Liquidated Damages - Construction. (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ 4,100.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 Time Extensions. (SEP 2000)

52.214-26 Audit and Records – Sealed Bidding. (JUN 2020)(DEVIATION OCT 2025)

52.214-27 Price Reduction for Defective Certified Cost or Pricing Data – Modifications – Sealed Bidding. (JUN 2020)

52.214-28 Subcontractor Certified Cost or Pricing Data – Modifications – Sealed Bidding.

(JUN 2020)(DEVIATION OCT 2025)

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns. (OCT 2022)

(a) Evaluation preference. (1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except-

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(2) The factor of 10 percent shall be applied on a line item basis or to any group of items on which award may be made. Other evaluation factors described in the solicitation shall be applied before application of the factor.

(3) When the two highest rated offerors are a HUBZone small business concern and a large business, and the evaluated offer of the HUBZone small business concern is equal to the evaluated offer of the large business after considering the price evaluation preference, award will be made to the HUBZone small business concern.

Amendment A001 10.07.2025

Remove and replace sheets B-7 and C-3 with corresponding pages.