RFQ_69727619Q000004_TS_RUDDER_FY19_Drydock_and_Special_Survey_7.pdf

SEE ADDENDUMIS CHECKED

CODE 18a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

MARAD-00093

NEW ORLEANS LA 70130-3396

HALE BOGGS BUILDING

MAR 3803

GULF ACQUISITION OFFICE

USDOT MARITIME ADMINISTRATION

00093-TV GEN RUDDER CODE 16. ADMINISTERED BYCODE

X

X

X

336611

SIZE STANDARD:

100.00 % FOR:SET ASIDE:UNRESTRICTED ORMARAD-00093

RFPIFB

10. THIS ACQUISITION ISCODE

RFQ

14. METHOD OF SOLICITATION

13b. RATING

NAICS:

SMALL BUSINESS

01/31/2019

GLEN SPEARS

(No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIME

02/28/2019 1400 CT

b. TELEPHONE NUMBERa. NAME

4. ORDER NUMBER3. AWARD/ 6. SOLICITATION

69727619Q000004

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 88 MAPR61619000188OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

500 POYDRAS STREET SUITE 1223

TELEPHONE NO.

17a. CONTRACTOR/

GALVESTON TX 77553

1001 TEXAS CLIPPER ROAD

TEXAS MARITIME ACADEMY

TV GENERAL RUDDER

15. DELIVER TO

NEW ORLEANS LA 70130-3396

500 POYDRAS STREET SUITE 1223

HALE BOGGS BUILDING

MAR 3803

GULF ACQUISITION OFFICE

9. ISSUED BY

7.

2. CONTRACT NO.

EFFECTIVE DATE

1,250

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

ISSUE DATE

DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

11.

SEE SCHEDULE

12. DISCOUNT TERMS

THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13a.

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

8(A)

USDOT MARITIME ADMINISTRATION

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

GENERAL RUDDER - FY19 DRYDOCK and SPECIAL SURVEY

NO. 7

The U.S. Department of Transportation, U.S.

Maritime Administration, New Orleans, LA, requires a contractor to dry dock the Training Ship (TS) GENERAL RUDDER which is homeported at the Texas A&M Maritime Academy, Galveston, TX.

The contractor shall provide all requested supplies and services in accordance with the attached TS GENERAL RUDDER FY19 Repair and

(Use Reverse and/or Attach Additional Sheets as Necessary)

HEREIN, IS ACCEPTED AS TO ITEMS:

X

XX

DATED

Carolyn Quinn

. YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER

ARE

ARE

31c. DATE SIGNED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print)

ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL

SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

OFFER

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

ARE NOT ATTACHED.

ARE NOT ATTACHED.

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

30b. NAME AND TITLE OF SIGNER (Type or print)

30a. SIGNATURE OF OFFEROR/CONTRACTOR

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

25. ACCOUNTING AND APPROPRIATION DATA

29. AWARD OF CONTRACT:

REF.

(757) 593-3540

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32c. DATE 32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

40. PAID BY39. S/R VOUCHER NUMBER38. S/R ACCOUNT NUMBER

37. CHECK NUMBER

FINALPARTIAL

36. PAYMENT

FINALPARTIAL

35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER33. SHIP NUMBER

COMPLETE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

42d. TOTAL CONTAINERS42c. DATE REC'D (YY/MM/DD)

42b. RECEIVED AT (Location)

42a. RECEIVED BY (Print)

41c. DATE41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

STANDARD FORM 1449 (REV. 2/2012) BACK

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

Drydock Specifications. Work performed will be subject to a Service Contract Act Wage

Determination applicable to the locale of the awardee¿s dry dock facility.

Terms and conditions are set forth in the attached document, Solicitation Provisions

Clauses.

IT Related Pur: NO

Delivery: 04/19/2018

Period of Performance: 03/08/2019 to 04/19/2019

00101 GENERAL RUDDER - FY19 DRYDOCK PACKAGE (SPECIAL

CONTINUOUS SURVEY NO. 7)

SEE ATTACHED SPECIFICATION AND WORK ITEM LIST.

ATTACHEMENTS TO THIS SOLICITATION INCLUDE:

1. RFQ 69727619Q000004 SF-1449

Solicitation/Contract/Order for Commercial Items

2. TSGR Quotation Pricing Sheet

3. Solicitation Provisions Clauses

4. TSGR FY19 DD Repair Specifications

5. 27 PDF Files containing Reference Drawings (Separate Attached File)

32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

88 2 of

TS GENERAL RUDDER FY19 DRY DOCK QUOTATION PRICING SHEET

Solicitation RFQ 69727619Q000004

Item Number Description Quantity Unit Price Unit Total Amount

00101 OFFICE AND ADMINISTRATIVE SERVICES 1 LS

00102 SHORE POWER SERVICES 1 LS

00103 WHARFAGE AND LINEHANDLERS 1 LS

00104 POTABLE WATER 1 LS

00105 BILGES AND DRAIN WELLS 1 LS

00106 GARBAGE AND TRASH REMOVAL 1 LS

00107 PROTECTIVE FLOOR COVERING 1 LS

00108 SECURITY/WATCHMAN 1 LS

00109 GAS FREE INSPECTIONS AND CERTIFICATES 1 LS

00110 FIRE PROTECTION 1 LS

00111 PORTABLE TOILETS/TEMPORARY FACILITIES 1 LS

00112 COOLING WATER 1 LS

00113 TEMPORARY LIGHTING 1 LS

00114 CRANE SERVICE 1 LS

00115 STAGING REQUIREMENT 1 LS

00116 OFF LOAD OF LIQUIDS AND STORAGE 1 LS

00201 DRYDOCKING AND UNDOCKING OF VESSEL 1 LS

00202 DOCK TRIALS 1 LS

00203 HULL PREPARATION AND COATING 1 LS

00204 RENEW ZINC ANODES 1 LS

00205 ANTI BIOFOULING SYSTEM MAINTENANCES 1 LS

00206 RUDDER AND STERN FRAME EXAMINATION 1 LS

00207 PROPELLER INSPECTION, MAINT & REP (ABS) 1 LS

00208 PROPELLER SHAFT WEAR DOWN READINGS 1 LS

00209 PORT AND STBD TAIL SHAFTREMOVAL AND INSPECTION 1 LS

00210 TANK CLEANING AND INSPECTIONS 1 LS

00211 SEA VALVES: INSPECTION AND REPAIR, (ABS & USCG) 1 LS

00212 ANCHOR CHAIN AND CHAIN LOCKER INSPECTION 1 LS

00213 BOW THRUSTER EXAMINATION AND MAINTENANCE (ABS) 1 LS

00214 ULTRASONIC/AUDIO HULL GAUGING 1 LS

00215 WASTER PIECE: EXAMINATION 1 LS

00216 SWITCHBOARD METER CALIBRATION 1 LS

00217 PRESSURE VESSEL INSPECTIONS 1 LS

00218 THRUST BEARING(S) INSPECTION/RENEWAL 1 LS

00219 RESCUE BOAT: FALL REPLACEMENT 1 LS

00301 TOP END OVERHAUL #3 MAIN GENERATOR 1 LS

00302 TOP END OVERHAUL #4 MAIN GENERATOR 1 LS

00303 REPLACE LAUNDRY ROOM DECK 1 LS

00304 BLAST AND COAT BALLAST TANK 4‐24‐3 1 LS

00305 REPLACE AFT DECK PIPING 1 LS

00306 BLAST AND COAT 01, AND 02 DECK PASSAGEWAYS AND FOCSLE 1 LS

00307 REPLACE SEWAGE TANK PIPING 1 LS

00401 SUPPLEMENTAL WORK: MANHOURS LABOR 1000 HR

00402 SUPPLEMENTAL WORK: MATERIAL ALLOWANCE $50,000.00

00403 OPTIONAL DRYDOCK AND WET BERTH DAYS

HAUL DAY PER 403 3.1 1 DAY

DRYDOCK LAY DAY PER 403 3.2 1 DAY

WET DOCK LAY DAY PER 403 3.3 1 DAY

GRAND TOTAL

Solicitation 69727619Q000004 TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 1

The following Federal Acquisition Regulations (FAR) provisions and clauses apply to this solicitation and are incorporated by reference.

52.252-2 Clauses Incorporated by Reference (Feb 1998) This contract incorporates one or more clauses by reference with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at the following Internet addresses:

Federal Acquisition Regulations (52.) https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses

52.204-7 Central Contractor Registration;

52.212-1 Instructions to Offerors-Commercial Items;

52.212-3 Alt I Offeror Representations and Certifications - Commercial Items (Offerors are required to include a completed copy of this provision with their offer or a statement stating that it is available via the ORCA website, http://orca.bpn.gov.)

52.212-4 Contract Terms and Conditions-Commercial Items;

52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders- Commercial Items (Oct 2018)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub.

L. 115-91).

(2) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(4) 52.233-3, Protest After Award (Aug 1996) (31U.S.C.3553).

(5) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check with “X” as appropriate.]

X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C.4704 and 10 U.S.C.2402).

(2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C.

3509)).

(3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

X (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note).

(5) [Reserved].

https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 2

X (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

(7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

X (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

X (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim).

(10) [Reserved].

(11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C.657a).

(i) Alternate I (Nov 2011) of 52.219-3.

(12)

(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

(ii) Alternate I (Jan 2011) of 52.219-4.

(13) [Reserved] X (14) X (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C.644).

(ii) Alternate I (Nov 2011).

(iii) Alternate II (Nov 2011).

(15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C.

644).

(ii) Alternate I (Oct 1995) of 52.219-7.

(iii) Alternate II (Mar 2004) of 52.219-7.

X (16) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)).

(17) (i) 52.219-9, Small Business Subcontracting Plan (Aug 2018) (15 U.S.C. 637(d)(4))

(ii) Alternate I (Jan 2017) of 52.219-9.

(iii) Alternate II (Nov 2016) of 52.219-9.

(iv) Alternate III (Nov 2016) of 52.219-9.

(v) Alternate IV (Aug 2018) of 52.219-9

(18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

X (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C.637(a)(14)).

(20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

(21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f).

X (22) 52.219-28, Post Award Small Business Program Re-representation (Jul 2013) (15 U.S.C. 632(a)(2)).

(23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec2015) (15 U.S.C. 637(m)).

X (25) 52.222-3, Convict Labor (June 2003) (E.O.11755).

X (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2018) (E.O.13126).

X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 3

X (28) X (i) 52.222-26, Equal Opportunity (Sept 2016) (E.O.11246).

(ii) Alternate I (Feb 1999) of 52.222-26.

X (29) X (i) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(i) Alternate I (July 2014) of 52.222-35.

X (30) X (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C.793)

(ii) Alternate I (July 2014) of 52.222-36.

X (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

X (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

X (33) X (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C.

chapter 78 and E.O. 13627).

(ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

(35) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

(ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

(36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

(37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun2016) (E.O. 13693).

X (38) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

(i) Alternate I (Oct 2015) of 52.223-13.

(39) (i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

(ii) Alternate I (Jun2014) of 52.223-14.

(40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

(41) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

(i) Alternate I (Jun 2014) of 52.223-16.

(42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513).

(43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

(44) 52.223-21, Foams (Jun2016) (E.O. 13693).

(45) 52.224-3 Privacy Training (Jan2017) (5 U.S.C. 552a).

(i) Alternate I (Jan 2017) of 52.224-3.

(46) 52.225-1, Buy American-Supplies (May 2014) (41 U.S.C. Chapter 83).

(47) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C.

3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

(ii) Alternate I (May 2014) of 52.225-3.

(iii) Alternate II (May 2014) of 52.225-3.

(iv) Alternate III (May 2014) of 52.225-3.

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 4

X (48) 52.225-5, Trade Agreements (Aug 2016) (19 U.S.C.2501, et seq., 19 U.S.C.

3301 note).

X (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov2007) (42 U.S.C. 5150).

(52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov2007) (42 U.S.C. 5150).

(53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C.4505, 10 U.S.C.2307(f)).

X (54) 52.232-30, Installment Payments for Commercial Items (Jan2017) (41 U.S.C.4505, 10 U.S.C.2307(f)).

X (55) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct2018) (31 U.S.C. 3332).

(56) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C.3332).

(57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C.3332).

(58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

(59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C.

637(d)(12)).

X (60) X (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.Appx.1241(b) and 10 U.S.C. 2631).

(ii) Alternate I (Apr 2003) of 52.247-64.

(iii) Alternate II (Feb 2006) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check with “X” as appropriate.] X (1) 52.222-17, Non-displacement of Qualified Workers (May 2014) (E.O. 13495).

X (2) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

X (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). This statement is for information only:

Employee Class Monetary Wage—Fringe Benefits Electrostatic Spray Painter WG-9 $22.84/hr Quality Control Inspector WL-10 $25.28/hr Shipfitter Supervisor I WS-10 $36.98/hr Shipfitter WG-9 $27.50/hr Welder, Combination, Maintenance WG-10 $26.15/hr Sheet-Metal Worker, Maintenance WG-10 $26.15/hr

(4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 5

X (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C.206 and 41 U.S.C. Chapter 67).

(6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. Chapter 67).

(7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. Chapter 67).

X (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

X (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

(10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iv) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C.637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 6 subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(v) 52.222-17, Non-displacement of Qualified Workers (May2014) (E.O. 13495).

Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vii) 52.222-26, Equal Opportunity (Sept 2015) (E.O.11246).

(viii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C.4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul2014) (29 U.S.C.793).

(x) 52.222-37, Employment Reports on Veterans (Feb2016) (38 U.S.C.4212)

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (Aug2014) (41 U.S.C. chapter 67).

(xiii)

1. (A) (52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627).

2. (B) Alternate I (Mar2015) of 52.222-50(22 U.S.C. chapter 78 and E.O 13627).

3. xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May2014) (41 U.S.C. Chapter 67).

4. (xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May2014) (41 U.S.C. Chapter 67).

5. (xvi) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O.

12989).

6. (xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

7. (xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

8. (xix) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

9. (A) Alternate I (Jan 2017) of 52.224-3.

10. (xx) 52.225-26, Contractors Performing Private Security Functions

Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C.

2302 Note).

11. (xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

12. (xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx.1241(b) and 10 U.S.C.2631). Flow down required in accordance with paragraph (d) of FAR clause52.247- 64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 7

52.211-11 Liquidated Damages - Supplies, Services, or Research and Development (Sept 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $4,635.00 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default -- Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default -- Fixed-Price Supply and Service clause in this contract.

52.215-5 Facsimile Proposals: (504) 589-6593 52.223-18 Contractor Policy to Ban Text Messaging While Driving 52.232-18 Availability of Funds (Apr 1984)

Funds are not presently available for this contract. The Government’s obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

(End of clause) Transportation Acquisition Regulations 1252 Clauses

1252.223-73 Seat Belt Use Policies and Programs

In accordance with Executive Order 13043, Increasing Seat Belt Use in the United States, dated April 16, 1997, the contractor is encouraged to adopt and enforce on-the-job seat belt use policies and programs for its employees when operating company-owned, rented, or personally-owned vehicles. The National Highway Traffic Safety Administration (NHTSA) is responsible for providing leadership and guidance in support of this Presidential initiative. For information on how to implement such a program or for statistics on the potential benefits and cost-savings to your company or organization, please visit the Buckle Up America section of NHTSAs website at www.nhtsa.dot.gov. Additional resources are available from the Network of Employers for Traffic Safety (NETS), a public-private partnership headquartered in the Washington, D.C. metropolitan area, and dedicated to improving the traffic safety practices of employers and employees. NETS is prepared to help with technical assistance, a simple, user friendly program kit, and an award for achieving the Presidents goal of 90 percent seat belt use. NETS can be contacted at 1-888-221-0045 or visit its website at www.trafficsafety.org.

(End of clause)

MARAD Clauses

MCL.G-3 Invoice Submission Instructions The Contractor may submit invoices in either electronic or paper format. Electronic submission is preferred.

(1) Electronic invoices shall be address to MARADinvoices@faa.gov Electronic invoices shall conform to the following criteria, or be subject to rejection:

a. Invoice and supporting documentation shall be in Adobe Acrobat (pdf) format.

http://www.trafficsafety.org/ mailto:MARADinvoices@faa.gov

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 8

b. The e-mail subject shall include the following information: Name of Contractor; Invoice date and number; Invoice amount; Contract number and, if applicable, the order or modification number; Terms of any discount for prompt payment offered; Payment instructions (i.e., financial institution, ABA routing#, account #)

(2) Paper invoices shall be submitted to one of the following addresses. Multiple copies are not required.

MARAD A/P CR Invoices Branch

AMZ-160

PO Box 25710 Oklahoma City, OK73125

If a street address is required for delivery (i.e., Federal Express), the following address may be used in lieu of the post office box:

MARAD A/P CR Invoices Branch

AMZ-160

6500 S. MacArthur Blvd.

Oklahoma City, OK73169

MCL.G-4 Applicable Service Contract Wage Determination (Multiple Locations) The Service Contact Act wage determination applicable to this requirement is to be obtained on line. To obtain the wage determination for your locale, follow the procedure below:

• Go online to: https://www.wdol.gov/

• On the webpage, click on Selecting SCA WDs

• Use the drop-downs to select the State and County or City for the location of your dry dock facility. For example, if your facility is in Houston, TX, you would choose the following drop-down selections and then click on the Continue button:

• Click on the “No” box for the next two selections.

• Scroll to the bottom of the webpage and click on “Printer Friendly Version” to see the applicable wage determination which you can print.

MCL.H-2 Supplemental Work Requests

(a) In the complex world of ship repairs, supplemental work often emerges as a result of test, inspection, or discovery of unknown or otherwise differing conditions. The extent and nature of such supplemental work can neither be identified in bid, proposal or quotation specifications, and both parties recognize the possibility that such work may arise. Notwithstanding the possibility of the identification of such work, MARAD does not guarantee the award of any supplemental work during contract performance.

(b) Although MARAD shall be under no obligation to award supplemental work during contract performance, MARAD has provided an estimate for labor (in labor hours) and material (in dollars) for such work in the Schedule (Section B of the solicitation under applicable supplemental work contract line item numbers (CLIN or CLINs)). The offeror shall specify an hourly composite billing rate in its bid, proposal or quotation for supplemental work labor. The composite labor-billing rate shall be the rate applicable to labor for all supplemental work that MARAD orders under the applicable supplemental CLIN of the resulting contract. Any supplies or subcontracts required to complete supplemental work will be charged as a direct cost https://www.wdol.gov/ https://www.wdol.gov/sca.aspx

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 9 reimbursable under the applicable supplemental work CLIN; additional indirect charges for materials and subcontracts will not be allowed.

(c) During the performance of the contract, when conditions indicate a need for supplemental work, the Contracting Officer's Technical Representative (COR) is empowered to provide technical direction, negotiate the amount of labor and material, and authorize the contractor to perform supplemental work through the issuance of a written authorization. The COR will issue authorizations for supplemental work in accordance with the following:

(1) When conditions make supplemental work appropriate, the COR shall submit to the contractor a supplemental work request that identifies the work to be accomplished.

(2) The Contractor shall promptly review each supplemental work request upon receipt and shall, within seventy-two (72) hours of issuance, or sooner, as specified by the COR, provide the COR with a proposed price for the supplemental work. Price quotations for all supplemental work must be broken down by labor hours, materials, and subcontracts and allocated to the applicable supplemental work CLIN as appropriate. The contractor shall price the supplemental work to be performed in accordance with the composite labor rate bid or proposed under the supplemental work CLIN in the contract. If necessary, the Contractor shall submit prices for subcontractors, which will be negotiated and treated as direct materials. Once the COR and contractor agree on the technical direction and price to accomplish the supplemental work, the contractor and COR shall sign the authorization for supplemental work, which shall be final and binding on the contractor and MARAD. Subject to paragraphs (c.)(3.) through (c.)(6.), if urgent circumstances do not permit waiting for a written authorization, the parties may orally agree and follow up with written confirmation.

(3) Notwithstanding the preceding, the COR shall not authorize and the contractor shall not accept individual supplemental work authorizations from the COR in excess of the price ceiling established by the Contracting Officer pursuant to paragraph (d.)(10.). In addition, the COR shall not authorize and the contractor shall not accept a supplemental work authorization from the COR that, when combined with all previously authorized supplemental work under the contract, exceeds the amount of labor hours and materials specified in the applicable supplemental work CLINs.

(4) If the contractor requests an adjustment to the contract completion date in its quotation for the supplemental work, the COR must refer the issue to the Contracting Officer for resolution, which could include modifying the performance period of the contract. All supplemental work must be accomplished within the contract performance period. The COR shall not authorize and the contractor shall not accept supplemental work authorizations from the COR that cannot be completed within the contract performance period.

(5) If the COR and contractor cannot agree upon the price, the time required, or any other term of a supplemental work request, the matter shall be referred to the Contracting Officer who may resolve the issue in accordance with the procedures contained in the Changes clause incorporated in the contract. Specifically, the Contracting Officer shall have the option of (i) directing that the Contractor perform the work at a price and within a time period determined by the Contracting Officer to be reasonable, or (ii) withdrawing said supplemental work request. The Contractor's refusal to perform the work as directed by the Contracting Officer shall constitute an event of default under the default clauses of the contract. Disputed issues resulting from supplemental work unilaterally directed by the Contracting Officer may be handled under the disputes clause of the contract.

(6) If the Contracting Officer directs the Contractor to perform the work at a price and within a time period determined by the Contracting Officer to be reasonable, the Contractor shall maintain and submit to MARAD on a daily basis, report sheets itemizing materials used, the costs and man hours of all labor (direct, indirect, and impact), production schedule activities affected by and/or related thereto, and charges for equipment, whether furnished by the Contractor, subcontractors or others. Material charges shall be substantiated by valid copies

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 10 of materials and/or supplier’s invoices. Such invoices shall be submitted with the daily report sheets or, if not available, as soon as reasonably practicable thereafter. Said daily reports shall also include an indication as to which specific schedule activity(ies) are affected by the order which are the subject of the daily report sheets. To the extent the contractor fails or refuses to submit the aforementioned daily report sheets on a daily basis, such failure or refusal shall constitute a basis for the Contracting Officer to suspend payment for work completed under the supplemental work until appropriate documentation required by the contract is provided.

(d) The following rules apply to supplemental work authorizations:

(1) The COR shall authorize supplemental-work only during the period of performance of the contract.

(2) All authorizations for supplemental work are subject to the terms and conditions of the contract and must be within the scope of the contract.

(3) If mailed, an authorization is considered "issued" when MARAD deposits the order in the mail. Authorizations may also be issued orally, or by written communications, that is hand-delivered or sent by facsimile or electronic transmission. Oral orders must be followed up by written confirmation as soon as practicable thereafter.

(4) Unless otherwise explicitly noted in the authorization for supplemental work, all authorizations for supplemental work are firm fixed price. The agreed upon price shall cover all costs including, but not limited to, direct and indirect labor and material, overhead, delay, acceleration, and disruption caused by the supplemental work. Where the parties are unable to agree that an order establishes mutually agreeable terms, the parties shall note the specific differences that are not agreed upon in the text of the proposed work authorization and refer the matter to the Contracting Officer for resolution pursuant to paragraph (c.)(5.).

(5) Unless the contractor otherwise explicitly notes in the supplemental work authorization, in consideration of the price of the order, the Contractor remises, releases, and forever discharges MARAD, its officers, agents, employees, and sureties from any and all civil claims and requests for equitable adjustment whatsoever, relating to, arising out of, or connected with said supplemental work authorization. Such release is full and final settlement of all claims and requests for equitable adjustment relating to, arising out of, or connected with the work authorization, as modified, including, but not limited to, all impact claims such as delay, acceleration, disruption, and cumulative effects of the instant and all previously issued supplemental work authorizations. The executed work authorization constitutes a complete and final adjustment of the price and the delivery schedule.

(6) When MARAD requires supplies or services covered by the contract in an amount less than the total value of the contract, MARAD is not obligated to award supplemental work for the balance of the price bid or proposed for supplemental work. The Contractor is not obligated to honor additional supplemental work in excess of the estimated labor hours identified in the Schedule. This subparagraph does not affect or change the Contracting Officer's authority under the changes clause of the contract.

(7) Except for limitations of labor hours estimated in the Schedule, there is no limit to the number of supplemental work authorizations that may be issued. MARAD may issue supplemental work authorizations requiring delivery or performance in multiple locations, if the contract contemplates multiple locations.

(8) In the event a supplemental work authorization covers a series of related procedures, the Contracting Officer may request the Contractor to furnish separate prices for each item of the work.

(9) If not otherwise provided, the Contracting Officer may request at any time during performance of supplemental work a list of subcontractors performing work covered by the supplemental work, the dollar value of the respective subcontracts, and a description of the subcontracted work and the contractor shall promptly provide the requested information.

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 11

(10) The COR shall not issue and the contractor shall not accept supplemental work authorizations from the COR that exceeds (Contracting Officer fills in amount up to $5000.)

MCL.H-3 Indemnity and Insurance The Contractor shall indemnify and save and keep harmless the Government against any or all loss, cost, damage, claim, expense or liability whatsoever because of accident or injury to persons or property of others occurring in connection with the operations under this contract. The Contractor shall secure, pay the premiums for and keep in force until the expiration of this contract, and any renewal thereof, adequate insurance. Such insurance to specifically include liability assumed by the Contractor under this contract.

Each policy of insurance shall contain an endorsement that any cancellation or material change in the coverage adversely affecting the Government's interest shall not be effective unless the insurer or the Contractor gives written notice of cancellation or change as required to the Contracting Officer. When the coverage is provided by self-insurance, the Contractor shall not change or decrease the coverage without the Administrative Contracting Officer's prior approval.

A certificate of each policy of insurance shall be furnished to the Contracting Officer within ten (10) days after notice of award certifying, among other things, that the policy contains the aforesaid endorsement.

The insurance companies providing the above insurance shall be satisfactory to the Government. Notices of policy changes shall be furnished to the Contracting Officer.

The contractor shall provide at the Contractor's expense, within five days of request from the MARAD contracting officer, a copy of all original insurance policies. These may be sent by mail or facsimile machine.

MCL.H-4 Indemnity and Insurance (Additional)

(a) INDEMNITY

(1) The Contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property in and about the work, and to the vessel or portion thereof upon which work is done.

(2) Except as provided elsewhere in this contract, including any guarantee clause, the MARAD assumes the risk of physical loss or damage to any part of the vessel, its machinery, equipment, stores, and other property including cargo if owned by the Government except to the extent that such loss or damage is caused by the negligence, fault, error, act or omission of the Contractor, its subcontractors, agents, or employees. The burden of proving freedom from fault shall be borne by the Contractor. Unless the loss or damage was caused by the willful misconduct of the Contractor, its executive officers, or superintendents the Contractor's liability under this Contract shall not exceed total damage to the ship or ships including total loss up to $1,000,000 per accident or occurrence per vessel, and shall not exceed in the aggregate per accident or occurrence the sum of total damage to the ship or ships including total loss up to $1,000,000 multiplied by the number of MARAD's vessels in the care, custody or control of the Contractor at the location and at the time of the accident or occurrence giving to the loss or damage.

(3) As to third parties, including, but not limited to, agents, employees or servants of the Contractor, or any subcontractor, the Contractor will defend, indemnify and hold harmless the Government, the vessel, its owners and charterers, from all claims, actions, suits, costs, demands and expense of all descriptions arising out of disease, illness, personal injury, death or property damage to any third party in any way related to or arising out of the performance of work under this contract except to the extent caused by the fault, error, act or omission, or negligence of the Government, its agencies or employees. The burden of proving fault of the Government, its agencies or employees shall be borne by the Contractor.

(4) As to loss and damage which are the responsibility of the Government, the Government shall be subrogated to any claim, demand, or course of action against third parties which exists in favor of the Contractor, and the Contractor shall, if required, execute a formal assignment or transfer of such claim, demand, or course of action, and shall aid in securing information, evidence, TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 12 obtaining of witnesses, and cooperate with MARAD in all matters MARAD may deem necessary in defense of any claim, or suit or appeal from any judgment or in effecting indemnity, provided, further, that nothing contained in this paragraph shall create or give rise to any right, privilege or power in any person except the Contractor, nor shall any person (except the Contractor) be or become entitled thereby to proceed directly against the Government, its agencies or instrumentalities, or to join the Government, its agencies or instrumentalities, as a codefendant in any action against the Contractor brought to determine the Contractor's liability or for any other purpose.

(b) TYPES OF INSURANCE AND MINIMUM COVERAGE. The Contractor shall at its own expense, provide and maintain the following insurances during the entire performance of this contract.

(1) Workmen's Compensation, including Longshoremen & Harbor Worker's Act coverage - Covering all agents, servants, borrowed servants, statutory employees of Contractor for all compensation and other benefits required by applicable state and federal law or by governmental authority on account of injury, death, sickness or disease - Statutory - no minimum.

(2) Employers Liability - to cover both injury and death resulting from accident, sickness or disease - $1 million bodily injury by accident, each accident - $1 million bodily injury by disease each accident - $1 million bodily injury by disease in the aggregate.

(3) Maritime Employers Liability (Jones Act) – Not Applicable.

(4) Comprehensive General Liability to include coverage for (but not limited to) products and completed operations liability, property damage liability and contractual liability - $1 million combined single per occurrence limit for bodily injury and property damage and $1 million in the aggregate.

(5) Ship Repairers Legal Liability - coverage to be provided under the standard London or American Institute forms or their equivalent $1 million per vessel, per occurrence or such other amount as may be requested.

(6) Pollution - sudden and accidental liability - $1 Million per occurrence.

(c) All such insurance shall be subject to the approval of the Division of Marine Insurance and will contain thirty (30) calendar days advance notice of cancellation or of any non-renewal which is the option of the insurer, said notice to be provided to the U.S. Maritime Administration, Division of Marine Insurance MAR-710, 1200 New Jersey Avenue SE, Washington, DC 20590.

(d) FORM OF CONFIRMATION

(1) The pollution insurance may be a separate policy or part of the Comprehensive General Liability policy, but the coverage must be specifically shown on the required confirmation of insurance. Excess liability and umbrella liability policies may be used in the excess of primary policies to meet the minimum limit requirements. The United States of America shall be an additional assured in the Ship Repairs Legal Liability policy, Comprehensive General Liability Policy and Pollution Policy. Such policies shall contain a clause statement that there is no recourse against the United States of America for payment of premium. All such insurance shall be subject to the approval of the Division of Marine Insurance and must contain thirty

(30) calendar days advance notice of cancellation (without disclaimer) or of any non-renewal which is the option of the insurer, said notice to be provided to the U.S. Maritime Administration, Division of Marine Insurance MAR-710, 1200 New Jersey Avenue SE, Washington, DC 20590.

(2) The Contractor shall have its insurance broker provide a detailed certificate of insurance, cover note or policy confirming the above required coverage. The confirmation shall name the Contractor and United States of America as assureds and confirm the types of coverage, policy forms, policy periods, deductibles (if any) and underwriters with their percentage of participation.

The N.Y. Suable Clause or Service of Suit USA Clause must be confirmed for any Foreign underwriter placements. The policy amounts, terms and conditions, deductibles and underwriters shall at all times be satisfactory to the Maritime Administration.

(e) The contractor shall insert the substance of this clause in subcontracts under this contract that require work on a Government installation.

TS GENERAL RUDDER FY19 DRY DOCK Provisions & Clauses Page | 13

MCL.H-6 Standards of Employee Conduct The Contractor shall be responsible for maintaining satisfactory standards of employee competency, conduct, and integrity, and shall be responsible for taking such disciplinary action with respect to its employees as may be necessary.

MCL.H-11 Disposition of Removed Equipment and Scrap Any ship's equipment, fuel, lube oil, supplies, stores, furniture, fixtures, salvage, scrap and other movable property, removed from the vessel shall be and become the property of the Government and any ship's equipment, fuel, supplies, lube oil, stores, furniture, fixtures, salvage, scrap and other movable property so removed shall be disposed of in such manner as the…