6933A217Q00028_-_Purchase_and_Delivery_of_Tug_Boat.pdf

SEE ADDENDUMIS CHECKED

CODE 18a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

MARAD-00092

NORFOLK VA 23505-1204

7737 HAMPTON BLVD

MAR-3802

ATLANTIC DIV ACQUISITION OFFICE

U S DOT MARITIME ADMINISTRATION

MARAD-00092-JRIVR RF CODE 16. ADMINISTERED BYCODE

X

X

X

SIZE STANDARD:

% FOR:SET ASIDE:UNRESTRICTED ORMARAD-00092

RFPIFB

10. THIS ACQUISITION ISCODE

RFQ

14. METHOD OF SOLICITATION

13b. RATING

NAICS:

SMALL BUSINESS

08/23/2017 1300 ET

08/08/2017

757-322-5820Monique Leake (No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIMEb. TELEPHONE NUMBERa. NAME

4. ORDER NUMBER3. AWARD/ 6. SOLICITATION

6933A217Q00028

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 31 MAPR615-5170091OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

BUILDING 19 SUITE 300

TELEPHONE NO.

17a. CONTRACTOR/

FORT EUSTIS VA 23604

2606 HARRISON ROAD

JAMES RIVER RESERVE FLEET

15. DELIVER TO

NORFOLK VA 23505-1204

BUILDING 19 SUITE 300

7737 HAMPTON BLVD

MAR-380-2

ATLANTIC ACQUISITION OFFICE

9. ISSUED BY

7.

2. CONTRACT NO.

EFFECTIVE DATE

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

ISSUE DATE

DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

11.

SEE SCHEDULE

12. DISCOUNT TERMS

THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13a.

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

8(A)

US DOT MARITIME ADMINISTRATION

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

The purpose of this solicitation is for potential offerors to provide pricing for the purchase and delivery of towing (pushing) marine vessel capability to move the fleet's crane barge and other barges from the facility to fleet. The boat shall be constructed to comply with the standards of 46 CFR Subchapter M and in accordance with the salient characteristics listed in the attached specification.

Estimated Delivery: 60 Days After Award Continued ...

(Use Reverse and/or Attach Additional Sheets as Necessary)

HEREIN, IS ACCEPTED AS TO ITEMS:

XX

DATED . YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER

ARE

ARE

31c. DATE SIGNED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print)

ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL

SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

OFFER

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

ARE NOT ATTACHED.

ARE NOT ATTACHED.

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

30b. NAME AND TITLE OF SIGNER (Type or print)

30a. SIGNATURE OF OFFEROR/CONTRACTOR

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

25. ACCOUNTING AND APPROPRIATION DATA

29. AWARD OF CONTRACT:

REF.

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32c. DATE 32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

40. PAID BY39. S/R VOUCHER NUMBER38. S/R ACCOUNT NUMBER

37. CHECK NUMBER

FINALPARTIAL

36. PAYMENT

FINALPARTIAL

35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER33. SHIP NUMBER

COMPLETE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

42d. TOTAL CONTAINERS42c. DATE REC'D (YY/MM/DD)

42b. RECEIVED AT (Location)

42a. RECEIVED BY (Print)

41c. DATE41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

STANDARD FORM 1449 (REV. 2/2012) BACK

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

00001 JRRF: TUGBOAT (PUSH BOAT)

JRRF: PURCHASE TUGBOAT (PUSH BOAT) IN ACCORDANCE

WITH ATTACHED SPECS.

NOTE: It is the policy of the JRRF to promote the

Green Procurement of items with the highest recycled content practicable. It is also desirable for contractors to use/install green products in the performance of their work. This includes recycled content, energy saving, bio-based products.

In order for an invoice to be processed for payment, it must include your Federal ID Number, Purchase Order Number, and Invoice Number.

Without these numbers, your invoice will be returned and payment will be delayed.

32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

31 2 of

Specifications for Tugboat (Push boat) for the

James River Reserve Fleet

July 2017

Tugboat Specifications

Table of Contents

VESSEL SPECIFICATIONS

GENERAL

STEEL

SUBDIVISION BULKHEADS

HULL FRAMING

ENGINE ROOM HOUSE

PILOTHOUSE

POWER TRAIN

MACHINERY INSTALLATIONS

ENGINE INSTRUMENTATION

ENGINE COOLING

ELECTRICAL SYSTEM

FUEL SYSTEM

HYDRAULIC STEERING SYSTEM

ENGINE CONTROLS

DECK HARDWARE

COATING

ADDITIONAL CONSTRUCTION INFORMATION

VESSEL WEIGHT AND TRANSPORT

VESSEL SPECIFICATIONS

Length – 25’-30 Width – 14’ – 16’ Draft - 5' 6" – 6’

GENERAL

The basic requirement shall be to provide towing (pushing) capability to move the fleet’s crane barge and other barges from the facility to fleet. The boat shall be constructed to comply with the standards of 46 CFR Subchapter M. The specific required construction details shall be as follows:

STEEL

Deck constructed of 5/16" steel plate. Sides, bottom, and transom constructed of 3/8" steel plate. Head log constructed of 7/16" steel plate. All steel shall meet ASTM A36/A36M steel specifications.

SUBDIVISION BULKHEADS

The boat shall be divided into four separate spaces. Each bulkhead shall be constructed of 1/4" steel plate with bow and stern voids, accessible via at least 18" diameter flush mount hatches. The center space and engine room spaces will provide adequate accommodations for their intended purposes. Depending on options exercised, adequate access will be provided depending on the intended service.

HULL FRAMING

Deck and sides shall be framed longitudinally. Acceptable deck shall be 3" x 4" x 5/16" angle on 24" centers. Acceptable sides shall be 3" x 4" x 5/16" angle on 22" centers and bottom shall be transversely framed with 3" x 4" x 5/16" angles set on 18" centers.

ENGINE ROOM HOUSE

The ER House shall be of 1/4" steel plate. Overhead engine removable hatch of 5/16" steel plate suitably framed. Stairway entrance in aft of house with overhead self-locking hatch, at least 6'6” head room. The engine room house shall be protected by a suitable fixed CO2 system equipped with an alarm and 20 second time delay and automatic ventilation shut-offs.

PILOTHOUSE

Pilot house shall be approximately 5' 0" long by 5' 6" wide with 7' 0" of headroom and shall be constructed of 1/4" steel plate. Pilot house shall rest on a removable structure creating at least eye level of 10’ - 15' from inside pilot house. Front pilot house window shall be 5' x 3' aluminum framed horizontal slide, sides and back window shall be sealed windows. The front window of pilot house slanted forward to reduce glare. Steel entry door located on aft wall of pilot house, with the upper portion a sealed window. Front and sides of pilot house have at least an 18" wide exterior walkway. Rear of house shall have at least a 27" walkway. The walkway shall have hand rails around entire house. Access to pilot house stairway if elevated. Air conditioner (13500 BTU) with heat strip overhead mount in pilot house.

POWER TRAIN

Any engine package shall be international maritime organization (IMO) compliant. The engines shall be compliant with IMO emission standards for the year 2000 as defined by Regulation 13 of Annex VI to international convention for the prevention of pollution from ships as modified by protocol of 1978.

engines shall have the following characteristics:

• Two new U.S. manufactured, Tier III compliant marine engines each developing 250- 300 horsepower, rated for at least 2000-4000 hours of annual use. Engines shall have at least a one year unlimited hours’ manufacturer’s warranty. [Extended warranty shall be available from manufacturer.]

• Two new Twin Disc model MG 5061 transmissions with 3.82:1 reduction, twin disc factory warranty or similar suitable transmissions.

• Two stainless steel propeller shafts with at least 3” diameter fitted with two four blade bronze propellers.

• Shaft seals shall be of dripless design and suitable for the application.

MACHINERY INSTALLATIONS

All machinery installations shall comply with 46 CFR 143f requirements or ABYC H-2, ABYC H-22, ABYC H-24, ABYC H-25, ABYC H-32, ABYC H-33, ABYC P-1, and ABYC P-4 as applicable. Exhausts and similar sources of ignition must be kept clear of and suitably insulated from combustible material.

ENGINE INSTRUMENTATION

All engines sha l l be equipped with full instrumentation. Including, tachometers, water temperature gauge, oil pressure gauge, hour meter, and voltage meter. All engines equipped with engine starter switches in pilot house. Alarms for low oil pressure, high water temperature, low voltage, and water in fuel, shall be included. All engines shall be equipped with fuel/water separator filters.

ENGINE COOLING

Main engines and generator cooled by water circulated through closed system using either a heat exchanger or a keel cooler.

ELECTRICAL SYSTEM

Electrical power shall be supplied for the vessel from a 7-10 kw 110/240 Volt single-phase generator. Engine starting will be provided by two heavy duty 12 volt marine batteries in U.S.C.G. approved battery cases per engine. A breaker panel shall be located in pilot house supplying switches for electrically powered items. All lighting will be 110 volt AC.

Electrical items include:

• one 16" trumpet horn,

• one 500 watt quartz halogen flood light forward, and

• 600 watt electrical spotlight, with on/off switches mounted on dash.

The navigation lights will be configured as required by U.S.C.G. regulations. There shall be a suitable overhead light in pilot house. The engine room shall be equipped with two 1100 gph bilge pumps powered by electrical system, operated by an operator controlled on/off switch properly labeled. Engine room equipped with 12" high speed blower equipped with an emergency shutoff outside the space.

In general the electrical installation shall meet the following American Boat and Yacht Council (ABYC) Projects where applicable:

• E-8, “Alternating Current (AC) Electrical Systems on Boats;”

• E-9, “Direct Current (DC) Electrical Systems on Boats;” and

• A-16, “Electrical Navigation Lights.”

FUEL SYSTEM

The boat shall have a steel fuel tank holding 500-800 gallons. The fuel system shall comply with the requirements of 46 CFR 143 and ABYC 25. An exterior emergency fuel shut off shall be fitted.

HYDRAULIC STEERING SYSTEM

The steering system shall comply with 46 CFR 143.550. The boat shall be equipped with four flanking rudders in addition to the main steering rudders. The steering controls (helm) shall be a stick design for both main and flanking rudders.

ENGINE CONTROLS

Two twin single lever controls connected with cables mounted in pilot house.

DECK HARDWARE

The vessel shall be equipped with four quarter bits which shall be 24" kevels, one 24" kevel welded to bow deck with 3/8" steel plate doublers. The stern will have one tow bit constructed of 6" pipe fitted through deck and welded with the pipe extending to the interior bottom of hull and shall be welded. The vessel shall be equipped with two new hand operated 20 ton winches, with hand wheels. Winches shall be welded to 5/16" doublers located on port and starboard bow. The vessel will be fitted with push knees approximately 9' tall and 15" wide (top 36" of push knees shall be removable for shipping.). The push knees shall be constructed of 3/18" steel plate welded to bow and shall be faced with 13 w' x 36" x 3" rubber pads. The vessel shall be equipped with four permanent lifting eye pads, with one eye mounted in each quarter of vessel. Rub rails of 6" x 8.2 pound per foot channel shall be welded continuous down sides of hull 4" below deck line. The vessel shall be equipped with bull rails constructed of 1/4" steel plate extending 12" above deck line, continuous around vessel.

COATING

All surfaces to be coated shall be sand blasted, prepped, and primed as required and in accordance with the manufacturer’s instructions for the top coating to be applied. Paint with similar characteristics to that shown below may be substituted with the approval of the government. The specific areas shall be coated as follows:

• The exterior of deck and lower house shall have two coats of Sherwin Williams Sea Guard 5000 medium gray or equivalent. The main deck will have non-skid surface.

• The exterior of hull above the waterline shall have two coats of Sherwin Williams Sea Guard 5000 black or equivalent.

• The submerged section of the hull shall have two coats of Sherwin Williams SeaGuard Vinyl Antifoulant red or other non-ablative antifouling equivalent.

• The interior of hull and lower house have two coats of Sherwin Williams Sea Guard 5000 medium gray or equivalent.

• The pilot house interior and exterior shall have two coats of Sherwin Williams Micropoxy 646 spar color or equivalent.

• Caps of bits & bulwarks, fuel fill & vent, and hand rails shall be painted safety red.

• The draft marks shall be indicated by welding the lines and numbers and marked with white paint

• The characters “TD – 208” shall be painted in 6 inch block lettering across the stern and on either side of the bow on the bulwarks. The words “JAMES RIVER RESERVE FLEET” shall be painted in two-inch block letters below the name characters indicated above.

ADDITIONAL CONSTRUCTION INFORMATION

The boat shall comply with 46 CFR 144 construction and arrangement standards. The boat is not intended to be classed, but shall meet class rules when specified in the regulations. The boat will not need a load line. Other additional design details are as follows:

• The rudder rack (the area above the rudder, rams, hoses, tiller, etc.) shall have a 1" galvanized steel serrated grating that covers the entire area.

• The boat shall have a rudder angle indicator installed in the pilot house of the main and flanking rudders.

• The boat shall have rubber bumper pads cut and fitted around the perimeter of vessel’s hull and pushing knees. The pads shall be of sturdy construction and suitable for use on a tugboat. The pads if bolted on, shall be designed to protect the bolts or other connecting fasteners from damage.

VESSEL WEIGHT AND TRANSPORT

WEIGHT OF VESSEL must be transportable via over the road truck transportation.

Contractor shall provide crane support and assistance to load vessel on to trailer upon delivery, and transportation to JBLE Eustis, Newport News, VA. Transportation provided by the Contractor shall include all required over the road permits along with the actual transportation of the boats. Removable sections are allowed (such as a removal pilothouse) to allow over the road transportation. The Contract shall describe the plan for transport and details of any removable sections when the bid is submitted. The Contractor will provided technical support if needed to make final assembly at the fleet.

WARRANTY

Contractor shall provide all warranty and guaranteed service information for the marine craft.

6933A217Q00028 JRRF – Purchase and Delivery of Towing (Push) Marine Vessel Applicable Provisions and Clause

The following FAR provisions apply to this solicitation

52.252-1 Solicitation Provisions Incorporated by Reference (Feb 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address:

https://www.acquisition.gov/?q=browsefar 52.204-7 System for Award Management (SAM’s) (Oct 2016) All vendors must be registered in System For Award Management at https://www.sam.gov/portal/public/SAM/ at the time of Quote submittal.

52.204-16 Commercial and Government Entity Code Reporting (Jul 2016) 52.204-17 Ownership or Control of Offeror (Jul 2016) 52.204-20 Predecessor of Offeror (Jul 2016) 52.209-2 Prohibition on Contracting with Inverted Domestic Corporations—Representation (Nov 2015)

(a) Definitions. “Inverted domestic corporation” and “subsidiary” have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10).

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.

(c) Representation. The Offeror represents that—

(1) It □ is, □ is not an inverted domestic corporation; and

(2) It □ is, □ is not a subsidiary of an inverted domestic corporation.

52.209-7 Information Regarding Responsibility Matters. (JUL 2013)

a) Definitions. As used in this provision— “Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

https://www.acquisition.gov/?q=browsefar https://www.sam.gov/portal/public/SAM/ https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1146366 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%209_1.html#wp1085903 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%209_1.html#wp1085953

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (Feb 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that—

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that—

(1) It is □ is not □ a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is □ is not □ a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.219-1 Small Business Program Representations. (Oct 2014)

(a) Definitions. As used in this provision— “Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) “Service-disabled veteran” means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (b) of this provision.

“Small disadvantaged business concern,” consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that—

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by—

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned small business concern” means a small business concern—

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition is– ________ [insert NAICS code].

(2) The small business size standard is _______ [insert size standard].

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(c) Representations.

(1) The offeror represents as part of its offer that it □ is, □ is not a small business concern.

(2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it □ is, □ is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(3) of this provision.] The offeror represents as part of its offer that—

(i) It □ is, □ is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (c)(4) of this provision.] The offeror represents as part of its offer that—

(i) It □ is, □ is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It □ is, □ is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture:

________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(6) of this provision.] The offeror represents as part of its offer that it □ is, □ is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that—

(i) It □ is, □ is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It □ is, □ is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Notice.

(1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished.

(2) Under 15 U.S.C. 645(d), any person who misrepresents a firm’s status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall—

(i) Be punished by imposition of fine, imprisonment, or both;

(ii) Be subject to administrative remedies, including suspension and debarment; and

(iii) Be ineligible for participation in programs conducted under the authority of the Act.

52.211-6 Brand Name or Equal (Aug 1999)

(a) If an item in this solicitation is identified as “brand name or equal,” the purchase description reflects the characteristics and level of quality that will satisfy the Government’s needs. The salient physical, functional, or performance characteristics that “equal” products must meet are specified in the solicitation.

(b) To be considered for award, offers of “equal” products, including “equal” products of the brand name manufacturer, must—

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by—

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate “equal” products on the basis of information furnished by the offeror or identified in the offer and reasonably available to the Contracting Officer. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

(d) Unless the offeror clearly indicates in its offer that the product being offered is an “equal” product, the offeror shall provide the brand name product referenced in the solicitation.

52.212-1 Instructions to Offerors—Commercial Items (Jan 2017) 52.212-3 Offeror Representations and Certifications—Commercial Items (Jan 2017) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision— “Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means–

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’”. The DOL Guidance was initially published in the Federal Register on August 25, 2016, and significant revisions will be published for public comment in the Federal Register. The DOL Guidance and subsequent versions can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

https://www.sam.gov/portal https://www.acquisition.gov/sites/default/files/current/far/html/www.dol.gov/fairpayandsafeworkplaces

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are–

(1) Department of Labor Wage and Hour Division (WHD) for–

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for–

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for–

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans’ Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for–

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation”, means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C.

1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that—

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by— https://www.acquisition.gov/sites/default/files/current/far/html/www.osha.gov/dcsp/osp/approved_state_plans.html http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern—

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction.

At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(…