Solicitation No.: B-2094260

Form 33.401 (03/25) Page 1 of 8 Exhibit F

DALLAS AREA RAPID TRANSIT

EXHIBIT F

GENERAL PROVISIONS

(SERVICES CONTRACT)

TABLE OF CONTENTS

1. Definitions (6-302.01, OCT 24)

2. Additional Bond Security (6-202.08, OCT 24JUN 86)

3. Assignment (6-202.14, OCT 24)

4. Authority Designated Holidays (D-200.11E, OCT 24)

5. Changes (6-302.05, OCT 24)

6. Composition of Contractor (6-302.03, OCT 24)

7. Compliance with the Law (6-302.10, OCT 24)

8. Disputes (6-302.07, OCT 24)

9. Drawings and Other Data (6-302.08, OCT 24)

10. Equal Opportunity (6-302.14, OCT 24)

11. Equal Opportunity Reporting (6-303.13, OCT 24)

12. Examination and Retention of Records (6-303.14, OCT 24)

13. Excusable Delays (6-303.11, OCT 24)

14. Federal, State, and Local Taxes (6-302.17, OCT 24)

15. Governing Law (6-302.15, OCT 24)

16. Indemnification (6-303.15, OCT 24)

17. Independent Contractor (6-302.02, OCT 24)

18. Interest of Public Officials (6-302.13, OCT 24)

19. Inspection (6-303.05, OCT 24)

20. Permits and Responsibilities (6-402.04, OCT 24)

21. Interest on Contractor Indebtedness (6-203.10, OCT24)

22. Notice of Labor Disputes (6-303.03, OCT 24)

23. Order of Precedence (6-302.16, OCT 24)

24. Payment of Interest on Contractor's Claims (6-302.11, OCT 24)

25. Pricing of Adjustments (6-203.01, OCT 24)

26. Prompt Payment (F-129, NOV 99)

27. Publicity Releases (6-303.12, OCT 24)

28. Substantial Completion (6-303.17, OCT 24)

29. Removal of Contract Personnel (D-200.27, APR 03)

30. Standards of Performance (6-302.09, OCT 24)

31. Subcontractors and Outside Consultants (6-302.04, OCT 24)

32. Suspension of Work (6-302.12, OCT 24)

33. Termination (6-302.06, OCT 24)

1. Definitions (6-302.01, OCT 24) As used throughout this contract, the following terms shall have the meaning set forth below:

(a) The term "the Authority" means the Dallas Area Rapid Transit Authority; and the term "duly authorized representative" means any person or persons or board (other than the Contracting Officer) authorized in writing to act for the Authority.

(b) The term "Contracting Officer" means the person executing this contract on behalf of the Authority or his duly appointed successor; and the term includes, except as otherwise provided in this contract, the authorized representative of the Contracting Officer acting within the limits of his authority.

(c) Except as otherwise provided in this contract, the term "subcontracts" includes purchase orders under this contract.

(d) In computing any period of time established under this contract, "days" means calendar days, and the day of the event from which the designated period of time begins to run shall not be included, but the last day shall be included unless it is a Saturday, Sunday, or Federal or State of Texas holiday, in which event the period shall run to the end of the next business day.

Form 33.401 (03/25) Page 2 of 8 Exhibit F

2. Additional Bond Security (6-202.08, OCT 24JUN 86) The Contractor shall promptly furnish additional security required to protect the Authority and persons supplying labor or materials under this contract if --

(a) any surety upon any bond, or issuing financial institution for other security, furnished with this contract becomes unacceptable to the Authority;

(b) any surety fails to furnish reports on its financial condition as required by the Authority;

(c) the contract price is increased so that the penal sum of any bond becomes inadequate in the opinion of the

Contracting Officer.; or

(d) an irrevocable letter of credit (ILC) used as security will expire before the end of the period of required security. If the Contractor does not furnish an acceptable extension or replacement ILC, or other acceptable substitute, at least 30 days before an ILC’s scheduled expiration, the Contracting Officer has the right to immediately draw on the ILC

3. Assignment (6-202.14, OCT 24) The Contractor shall not assign the whole or any part of this contract or any monies due or to become due hereunder without the prior written consent of the Contracting Officer.

4. Authority Designated Holidays (D-200.11E, OCT 24) The Authority designated holidays are: New Year’s Day (January 1); Martin Luther King, Jr., Day (third Monday in January); Presidents' Day (third Monday in February); Memorial Day (last Monday in May); Juneteenth (June 19) Independence Day (July 4); Labor Day (first Monday in September); Thanksgiving Day (fourth Thursday in November);

the day after Thanksgiving (fourth Friday in November); and Christmas Day (December 25). Holidays that fall on a Saturday are observed on the Friday before the holiday. Holidays that fall on a Sunday are observed the following Monday.

5. Changes (6-302.05, OCT 24)

(a) The Contracting Officer may, at any time, by written order, make changes within the general scope of the contract in the services to be performed. If such changes cause an increase or decrease in the Contractor's cost of, or time required for, performance of any services under this contract, whether or not changed by any order, an equitable adjustment shall be made and the contract shall be modified in writing accordingly. Any claim of the Contractor for adjustment under this clause must be asserted in writing within 30 days from the date of receipt by the Contractor of the notification of change unless the Contracting Officer grants a further period of time before the date of final payment under the contract.

(b) No services for which an additional cost or fee will be charged by the Contractor shall be furnished without the prior written authorization of the Contracting Officer.

6. Composition of Contractor (6-302.03, OCT 24)

If the Contractor hereunder is comprised of more than one legal entity, each such entity shall be jointly and severally liable hereunder.

7. Compliance with the Law (6-302.10, OCT 24)

The Contractor shall perform all work hereunder in compliance with all applicable federal, state, and local laws and regulations. The Contractor shall use only licensed personnel to perform work required by law to be performed by such personnel.

8. Disputes (6-302.07, OCT 24)

(a) Except as otherwise provided in this contract, any dispute concerning a question of fact or law arising under or related to this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce the decision to writing and mail or otherwise furnish a copy thereof to the Contractor. The decision of the Contracting Officer shall be final and conclusive unless, on or before the 90th day from the date of receipt of such copy, the Contractor mails or otherwise furnishes a written appeal addressed to the Authority. The decision of the Authority or its duly authorized representative on such appeal shall be final and conclusive as to questions of fact unless determined by a court of competent jurisdiction to have been fraudulent, capricious, arbitrary, so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence. The decision of the Authority or its duly authorized representative shall not be final and conclusive as to questions of law. No action challenging such decision shall be brought more than two years from the date of the Contractor's receipt of such decision. In connection with any appeal of the Contracting Officer's decision, the Contractor shall

Form 33.401 (03/25) Page 3 of 8 Exhibit F be afforded an opportunity to be heard and to offer evidence in support of its appeal. Pending the final resolution of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision.

(b) If it is determined, on appeal, that the Contracting Officer's interpretation of the contract, direction to the Contractor, or any other action required by the Contracting Officer's decision was an erroneous determination of the rights and obligations of the parties under the contract, the Contractor's remedy shall be the same as if such action were a change order under the Changes Clause of this contract.

9. Drawings and Other Data (6-302.08, OCT 24) All designs, drawings, specifications, notes and other works developed in the performance of this contract shall become the sole property of the Authority and may be used in any manner by the Authority and without additional compensation to the Contractor. The Authority shall be considered the “person for whom the work was prepared” for the purpose of authorship in any copyrightable work under Section 201(b) of Title 17, United States Code. With respect thereto, the Contractor agrees not to assert or authorize others to assert any rights or establish any claim under the design patent or copyright laws. The Contractor, for a period of three years after completion of the project, agrees to retain all works developed in the performance of the contract and to furnish all retained works to the Authority on the request of the Contracting Officer. Unless otherwise provided in this contract, the Contractor shall have the right to retain copies of all works beyond such period.

10. Equal Opportunity (6-302.14, OCT 24) During the performance of this contract, the Contractor agrees that it will, in good faith and in every work relationship, afford equal opportunity required by applicable federal, state, or local law to all employees and applicants for employment , without regard to their race, color, religion, sex, disability or national origin, age, veteran status, sexual orientation, political opinion/affiliation, or any other characteristic protected by law and to fully comply with all applicable laws for establishing ad implementing anti-discrimination policies. The Contractor further agrees to afford equal opportunity required by applicable federal, state, or local law to subcontractors and vendors which are "disadvantaged business enterprises" or "women owned enterprises" (both as defined by federal law or regulation in effect on the date of this contract). The Contractor agrees to insert the substance of this clause in all subcontracts and purchase orders.

11. Equal Opportunity Reporting (6-303.13, OCT 24) The Contractor agrees that, in connection with the award of any subcontracts in excess of $5,000 under this contract, the Contractor will require the subcontractor to certify to the Contractor (on a form furnished or approved by the Authority) if the subcontractor is, or is not, a Disadvantaged Business Enterprise (“DBE”) or Women Business Enterprise (“WBE”) (as defined, in both cases, by the Authority). As a condition to final payment under this contract, the Contractor shall submit to the Authority and certify a list of all DBE and WBE subcontractors, which list shall include a description of the item, work, or services provided by such subcontractors and the dollar amount of each subcontract.

12. Examination and Retention of Records (6-303.14, OCT 24)

(a) The Contracting Officer and his representatives shall have the audit and inspection rights described in the applicable paragraphs (b) and (c), below.

(b) Examination of Costs. If this is a cost-reimbursement type, incentive, time and materials, labor hour, or price re-determinable contract, or any combination thereof, the Contractor shall maintain, and the Contracting Officer and his representatives shall have the right to examine, all books, records, documents, and other evidence and accounting procedures and practices sufficient to reflect properly all direct and indirect costs of whatever nature claimed to have been incurred and anticipated to be incurred for the performance of this contract. Such right of examination shall include inspection at all reasonable times at the Contractor's plants, or such parts thereof, as may be engaged in or maintain records in connection with the performance of this contract.

(c) Certified cost or pricing data. If the Contractor submitted certified cost or pricing data in connection with the pricing of this contract or if the Contractor's cost of performance is relevant to any change or modification to this contract, the Contracting Officer and his representatives shall have the right to examine all books, records, documents, and other data of the Contractor related to the negotiation, pricing, or performance of such contract, change, or modification for the purpose of evaluating the costs incurred and the accuracy, completeness, and currency of the cost or pricing data submitted. The right of examination shall extend to all documents necessary to permit adequate evaluation of the costs incurred and the cost or pricing data submitted, along with the computations and projections used therein.

(d) The materials described in (b) and (c), above, shall be made available at the office of the Contractor at all reasonable times for inspection, audit, or reproduction until the expiration of three (3) years from the date of final payment under this contract, except that:

Form 33.401 (03/25) Page 4 of 8 Exhibit F

(1) if this contract is completely or partially terminated, the records relating to the work terminated shall be made available for a period of three (3) years from the date of any final settlement; and

(2) records which relate to appeals under the Disputes Clause of this contract or litigation, or the settlement of claims arising out of the performance of this contract, shall be made available until such appeals, litigation, or claims have been resolved.

(e) The Contractor shall insert a clause containing all the provisions of this clause, including this paragraph (e), in all subcontracts exceeding $10,000 hereunder, altered to reflect the proper identification of the contracting parties and the Contracting Officer under the prime contract.

13. Excusable Delays (6-303.11, OCT 24)

(a) Except for defaults of subcontractors at any tier, the Contractor shall not be in default because of any failure to perform this contract under its terms if the failure arises from causes beyond the control and without the fault or negligence of the Contractor. Examples of these causes are (1) acts of God or of the public enemy, (2) acts of the Authority in either its sovereign or contractual capacity, (3) fires, (4) floods, (5) epidemics, (6) quarantine restrictions mandated by an authority having jurisdiction, (7) strikes, (8) freight embargoes, and (9) unusually severe weather. In each instance, the failure to perform must be beyond the control and without the fault or negligence of the Contractor. "Default" includes failure to make progress in the work so as to endanger performance.

(b) If the failure to perform is caused by the failure of a subcontractor at any tier to perform or make progress, and if the cause of the failure was beyond the control of both the Contractor and subcontractor and without the fault or negligence of either, the Contractor shall not be deemed to be in default, unless -

(1) the subcontracted supplies or services were obtainable from other sources;

(2) the Contracting Officer ordered the Contractor in writing to purchase these supplies or services from the other source; and

(3) the Contractor failed to comply reasonably with this order.

(c) Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of the failure. If the Contracting Officer determines that any failure to perform results from one or more of the causes above, the delivery schedule shall be revised, subject to the rights of the Authority under the Termination Clause of this contract.

14. Federal, State, and Local Taxes (6-302.17, OCT 24) The contract price includes all applicable federal, state, and local taxes and duties. The Authority is exempt from Texas state and local sales and use taxes, and any such taxes included on any invoice or voucher received by the Authority shall be deducted from the amount of the invoice or voucher for purposes of payment.

15. Governing Law (6-302.15, OCT 24) The rights, obligations, and remedies of the parties shall be governed by the laws of the State of Texas. Whenever there is no applicable state statute or decisional precedent governing the interpretation of, or disputes arising under or related to, this contract, then federal common law, including the law developed by federal boards of contract appeals, the United States Claims Court (formerly the Court of Claims), and the Comptroller General of the United States, shall govern. Venue for any action shall lie exclusively in Dallas County, Texas. This is the complete agreement between the parties. If any provision of the contract is found to be invalid or unenforceable, the remaining provisions shall not be impaired.

16. Indemnification (6-303.15, OCT 24) THE CONTRACTOR SHALL DEFEND FULLY INDEMNIFY AND HOLD HARMLESS THE AUTHORITY AND ALL OF ITS DIRECTORS, OFFICERS, EMPLOYEES, AND AGENTS FROM ANY AND ALL CLAIMS, DEMANDS, CAUSES OF ACTION, DAMAGES, LOSSES, AND EXPENSES (INCLUDING ATTORNEY'S FEES) OF WHATSOEVER NATURE, CHARACTER, OR DESCRIPTION THAT ANY PERSON OR ENTITY HAS OR MAY HAVE ARISING OUT OF OR RELATED TO THE BREACH OF OR FAILURE TO PERFORM THE CONTRACT OR ANY SUBAGREEMENTS THEREUNDER OR RESULTING FROM ANY NEGLIGENT ACT, OMISSION, MISCONDUCT, OR FAULT OF THE CONTRACTOR OR SUBCONTRACTORS

AND THEIR EMPLOYEES AND AGENTS.

17. Independent Contractor (6-302.02, OCT 24) The Contractor at all times shall be an independent contractor. The Contractor shall be fully responsible for all acts and omissions of its employees, subcontractors, and their suppliers, and shall be specifically responsible for sufficient supervision and inspection to ensure compliance in every respect with the contract requirements. There shall be no

Form 33.401 (03/25) Page 5 of 8 Exhibit F contractual relationship between any subcontractor or supplier of the Contractor and the Authority by virtue of this contract.

No provision of this contract shall be for the benefit of any party other than the Authority and the Contractor.

18. Interest of Public Officials (6-302.13, OCT 24) The Contractor represents and warrants that no employee, official, or member of the Board (Executive Committee) of the Authority is or will be pecuniarily interested or benefited directly or indirectly in this contract. The Contractor further represents and warrants that it has not offered or given gratuities (in the form of entertainment, gifts, or otherwise) to any employee, official, or member of the Board (Executive Committee) of the Authority with a view toward securing favorable treatment in the awarding, amending, or evaluating the performance of this contract. For breach of any representation or warranty in this clause, the Authority shall have the right to annul this contract without liability and/or have recourse to any other remedy it may have at law.

19. Inspection (6-303.05, OCT 24)

(a) "Services," as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Authority covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Authority during contract performance and for as long afterwards as the contract requires.

(c) The Authority has the right to inspect and test all services called for by the contract, to the extent practicable, at all times and places during the term of the contract. The Authority shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Authority performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Authority may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Authority may (1) require the Contractor to take necessary action to ensure that future performance conforms to contract requirements and (2) reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails promptly to perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Authority may (1) by contract or otherwise, perform the services and charge to the Contractor any cost incurred by the Authority that is directly related to the performance of such service or (2) terminate the contract for default.

20. Permits and Responsibilities (6-402.04, OCT 24) The Contractor shall, without additional expense to the Authority, be responsible for obtaining any necessary licenses, and permits and for complying with any federal, state, county, and municipal, laws, codes, and regulations applicable to the performance of the work, including, but not limited to, any laws or regulations requiring the use of licensed contractors to perform parts of the work. The Contractor also shall be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence and shall take proper safety and health precautions to protect the work, the workers, the public, and the property of others. The Contractor also shall be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work which may have been accepted under the contract.

21. Interest on Contractor Indebtedness (6-203.10, OCT24)

(a) Notwithstanding any other clause of this contract, all amounts that become payable by the Contractor to the Authority under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in Section 12 of the Contract Disputes Act of 1978 (Public Law 95-563), which is applicable to the period in which the amount becomes due, as provided in paragraph (b) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid. In no event shall the interest charged or payable hereunder exceed that allowable under Texas law.

(b) Amounts shall be due at the earliest of the following dates:

(1) the date fixed under this contract;

(2) the date of the first written demand for payment consistent with this contract, including any demand resulting from a default termination;

Form 33.401 (03/25) Page 6 of 8 Exhibit F

(3) the date the Authority transmits to the Contractor a proposed supplemental agreement to confirm completed negotiations establishing the amount of debt (unless a later date is set forth therein); or

(4) if this contract provides for revision of prices, the date of written notice to the Contractor stating the amount of refund payable in connection with a pricing proposal or a negotiated pricing agreement not confirmed by contract modification.

22. Notice of Labor Disputes (6-303.03, OCT 24)

(a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor immediately shall give notice, including all relevant information, to the Contracting Officer.

(b) The Contractor agrees to insert the substance of this clause, including this paragraph (b), in any subcontract under which a labor dispute may delay the timely performance of this contract; except that each subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the subcontractor shall immediately notify the next higher tier subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.

23. Order of Precedence (6-302.16, OCT 24) In the event of any inconsistency between the provisions of the solicitation (including any resulting contract), the inconsistency shall be resolved by giving precedence in the following order: (a) the Schedule; (b) Special Solicitation Instructions and Conditions; (c) Solicitation Instructions and Conditions; (d) Special Provisions; (e) General Provisions; (f) other provisions of the contract whether incorporated by reference or otherwise; and (g) the specifications or statement of work.

Note: The clause above may exist in Exhibits C and F if both are included in the solicitation.

24. Payment of Interest on Contractor's Claims (6-302.11, OCT 24)

(a) If an appeal is filed by the Contractor from a final decision of the Contracting Officer under the Disputes Clause of this contract, denying a claim arising under the contract, simple interest on the amount of the claim finally determined to be owed by the Authority shall be payable to the Contractor. Such interest shall be at the rates determined by the United States Secretary of the Treasury from time to time pursuant to Public Law 92-41, 85 Stat. 97, from the date the Contractor furnishes to the Contracting Officer his written appeal under the Disputes Clause of this contract, to the date of (1) a final judgment by a court of competent jurisdiction, or (2) mailing to the Contractor of a supplemental agreement for execution either confirming completed negotiations between the parties or carrying out a decision of the Authority or its duly authorized representative. In no event shall the interest charged or payable hereunder exceed that allowable under Texas law.

(b) Notwithstanding (a), above, (1) interest shall be applied only from the date payment was due, if such date is later than the filing of appeal, and (2) interest shall not be paid for any period of time that the Contracting Officer determines the Contractor has unduly delayed in pursuing his remedies under this contract or before a court of competent jurisdiction.

25. Pricing of Adjustments (6-203.01, OCT 24) When costs are a factor in any determination of a contract price adjustment pursuant to the Changes Clause or any other provision of this contract, such costs shall be in accordance with Chapter 7 (Cost Principles) of the Authority's Procurement Regulations in effect on the date of this contract.

26. Prompt Payment (F-129, NOV 99) The Contractor agrees to pay each subcontractor under this Contract for satisfactory performance of its contract no later than 10 (ten) calendar days from receipt of each payment the prime receives from the Authority. The Contractor agrees further to release retainage payments (if applicable) to each subcontractor within ten (10) calendar days after the subcontractor's work is satisfactorily completed and final payment has been made to the subcontractor. Any delay or postponement of payment from the above referenced time frame may occur only for good cause following written approval from the Contracting Officer.

27. Publicity Releases (6-303.12, OCT 24) All publicity releases or releases of reports, papers, articles, maps, or other documents in any way concerning this contract or the work hereunder which the Contractor or any of its subcontractors desires to make for purposes of publication in whole or in part, shall be subject to approval by the Contracting Officer prior to release.

Form 33.401 (03/25) Page 7 of 8 Exhibit F

28. Substantial Completion (6-303.17, OCT 24)

(a) General.

(1) For the purposes of Retainage, Commencement, Prosecution and Completion of Work, and Liquidated Damages-Construction, the work shall be deemed complete when it is “substantially complete.”

(2) There may be different completion dates required for different phases or portions of the work, as established in the contract. However, the work shall be deemed “substantially complete” if and only if the Contractor has completed the work and related contract obligations in accordance with the contract documents, such that the Authority may enjoy the intended access, occupancy, possession, and use of the entire work without impairment due to incomplete or deficient work, and without interference from the Contractor's completion of remaining work or correction of deficiencies in completed work.

(3) In no event shall the work be deemed “substantially complete” if all fire and life safety systems are not tested and accepted by the authority having jurisdiction, where such acceptance is required under the contract.

(4) Unless otherwise specifically noted, or otherwise clear from context, all references in the contract to “acceptance” shall refer to issuance of a written determination of substantial completion by the Contracting Officer.

(b) Notice of Substantial Completion.

(1) With reasonable advance notice, the Contractor shall submit to the Contracting Officer a written proposal recommending a substantial completion date.

(2) If the Contracting Officer takes exception to the notice of substantial completion, the Contractor shall be entitled to a written notice of conditions precluding determination of substantial completion. The Contractor shall only be entitled to an extension of time to address such conditions if, and to the extent that, the Contracting Officer provides notice of such conditions more than 30 calendar days after receipt of the notice of substantial completion.

(c) Acceptance of Substantial Completion.

(1) The Contracting Officer shall conduct inspections and make a determination of substantial completion within a reasonable time.

(2) Substantial Completion shall be established by the Contracting Officer's issuance of a written determination specifying the date upon which the work is substantially complete.

(d) Contract Completion.

(1) The Contract is complete if and only if the Contractor has completed all work and related contract obligations, corrected all deficiencies and all punch list items, and complied with all conditions for final payment.

(2) The Contractor shall not be entitled to final payment or release of any retainage held by the Authority until after contract completion. If the Contractor does not achieve contract completion within the time required by this contract, the Authority shall be entitled, after providing notice to the Contractor, to complete any work remaining unfinished.

The Contractor shall be liable to the Authority for all costs incurred by the Authority to complete such work.

29. Removal of Contract Personnel (D-200.27, APR 03)

(a) The Contractor and any subcontractor acknowledge that any person assigned to work under this Contract must perform their duties so as to not unduly impair contract performance. By assigning a person to work under this Contract, the Contractor agrees to be responsible for the behavior of that person during contract performance.

(b) The Contractor acknowledges that the Authority has the right to require the removal of any Contractor or subcontractor employee that the Contracting Officer determines, at his sole discretion, to be negatively effecting performance of work under the contract. Examples of such behavior include: (1) conduct which poses a threat to the safety of anyone working under the contract; (2) conduct which is disruptive to contract performance; (3) careless work performance; and (4) other behavior determined by the Contracting Officer to be objectionable or unduly hindering contract performance.

Form 33.401 (03/25) Page 8 of 8 Exhibit F

(c) Upon receipt of written notice from the Contracting Officer that a person’s behavior is unduly impairing contract performance, the Contractor agrees to remove that person from doing any further work on the contract, and to cause that person to be removed from the worksite. The Contractor agrees that it is not entitled to any additional costs it may incur as a result of the removal of the person named by the Contracting Officer.

30. Standards of Performance (6-302.09, OCT 24) The Contractor shall perform all services required by this contract in accordance with high professional standards prevailing in the Contractor's field of work except that with regard to construction or repair of an improvement to real property, the architectural or engineering services must be performed with the professional skill and care ordinarily provided by competent architects or engineers practicing under the same or similar circumstances and professional license.

31. Subcontractors and Outside Consultants (6-302.04, OCT 24) Any subcontractors and outside associates or consultants required by the Contractor in connection with the services covered by the contract will be limited to such individuals or firms as were specifically identified and agreed to by the Authority in connection with the award of this contract. Any substitution in such subcontractors, associates, or consultants will be subject to the prior written approval of the Contracting Officer.

32. Suspension of Work (6-302.12, OCT 24)

(a) The Contracting Officer may order the Contractor in writing to suspend all or any part of the work for such period of time as he may determine to be appropriate for the convenience of the Authority.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended or delayed by an act of the Contracting Officer in the administration of this contract, or by his failure to act within the time specified in this contract (or, if no time is specified, within a reasonable time), an adjustment shall be made for any increase in cost of performance of this contract (excluding profit) necessarily caused by such unreasonable suspension or delay, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension or delay to the extent (1) that performance would have been suspended or delayed by any other cause, including the fault or negligence of the Contractor, or (2) for which an equitable adjustment is provided for or excluded under any other provision of this contract.

(c) No claim under this clause shall be allowed (1) for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply to a claim resulting from a suspension order), and (2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of such suspension or delay, but not later than the date of final payment. No part of any claim based on the provisions of this clause shall be allowed if not supported by adequate evidence showing that the cost would not have been incurred but for a delay within the provisions of this clause.

33. Termination (6-302.06, OCT 24)

(a) The Contracting Officer may, by written notice to the Contractor, terminate this contract in whole or in part at any time, either for the Authority's convenience or because of the failure of the Contractor to fulfill its contract obligations. Upon receipt of such notice, the Contractor shall: (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and such other information and materials as may have been accumulated by the Contractor in performing this contract, whether completed or in process.

(b) If the termination is for the convenience of the Authority and if this is a fixed price contract, an equitable adjustment in the contract price shall be made, but no amount shall be allowed for anticipated profit on unperformed services.

(c) If the termination is due to the failure of the Contractor to fulfill its contract obligations, the Authority may take over the work and prosecute the same to completion by contract or otherwise. In such case, the Contractor shall be liable to the Authority for any additional cost occasioned to the Authority thereby.

(d) If, after notice of termination for failure to fulfill contract obligations, it is determined that the Contractor had not so failed, the termination shall be deemed to have been effected for the convenience of the Authority. In such event, adjustment in the contract price shall be made as provided in paragraph (b) of this clause.

(e) The rights and remedies of the Authority provided in this clause are in addition to any other rights and remedies provided by law or under this contract. Time is of the essence for all delivery, performance, submittal, and completion dates in this contract.

(e) The Contractor shall insert a clause containing all the provisions of this clause, including this paragraph (e), in all subcontracts exceeding $10,000 hereunder, altered to reflect the proper identification of the contracting parties and the Contr...

(c) Upon request of the Contractor, the Contracting Officer shall ascertain the facts and extent of the failure. If the Contracting Officer determines that any failure to perform results from one or more of the causes above, the delivery schedule sha...