Solicitation Amendment 47PH0623R0023_0001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

INSTRUCTIONS (Back Page):

Instructions for items other than those that are self-explanatory, are as follows:

Item 1 (Contract ID Code). Insert the contract type identification code that appears in the title block of the contract being modified.

Item 3 (Effective date).

(1)

(2)

(3)

(4)

(5)

For a solicitation amendment, change order, or administrative change, the effective date shall be the issue date of the amendment, change order, or administrative change.

For a supplemental agreement, the effective date shall be the date agreed to by the contracting parties.

For a modification issued as an initial or confirming notice of termination for the convenience of the Government, the effective date and the modification number of the confirming notice shall be the same as the effective date and modification number of the initial notice.

For a modification converting a termination for default to a termination for the convenience of the Government, the effective date shall be the same as the effective date of the termination for default.

For a modification confirming the contracting officer's determination of the amount due in settlement of a contract termination, the effective date shall be the same as the effective date of the initial decision.

(a)

(b)

(c)

(d)

(e)

(f)

Item 6 (Issued By). Insert the name and address of the issuing office. If applicable, insert the appropriate issuing office code in the code block.

Item 8 (Name and Address of Contractor). For modifications to a contract or order, enter the contractor's name, address, and code as shown in the original contract or order, unless changed by this or a previous modification.

Items 9, (Amendment of Solicitation Number - Dated), and 10, (Modification of Contract/Order Number - Dated). Check the appropriate box and in the corresponding blanks insert the number and date of the original solicitation, contract, or order.

Item 12 (Accounting and Appropriation Data).

When appropriate, indicate the impact of the modification on each affected accounting classification by inserting one of the following entries:

(2) Accounting classification Net decrease $

Include subject matter or short title of solicitation/contract where feasible.

Item 16B. The contracting officer's signature is not required on solicitation amendments. The contracting officer's signature is normally affixed last on supplemental agreements.

(i)

NOTE: If there are changes to multiple accounting classifications that cannot be placed in block 12, insert an asterisk and the words "See continuation sheet".

Item 13. Check the appropriate box to indicate the type of modification. Insert in the corresponding blank the authority under which the modification is issued. Check whether or not contractor must sign this document. (See FAR 43.103.)

Item 14 (Description of Amendment/Modification).

Organize amendments or modifications under the appropriate Uniform Contract Format (UCF) section headings from the applicable solicitation or contract. The UCF table of contents, however, shall not be set forth in this document.

Indicate the impact of the modification on the overall total contract price by inserting one of the following entries:

(i) Total contract price increased by $

(ii) Total contract price decreased by $

(iii) Total contract price unchanged.

State reason for modification.

When removing, reinstating, or adding funds, identify the contract items and accounting classifications.

(g)

(h)

When the SF 30 is used to reflect a determination by the contracting officer of the amount due in settlement of a contract terminated for the convenience of the Government, the entry in Item 14 of the modification may be limited to --

(i) A reference to the letter determination; and

(ii) A statement of the net amount determined to be due in settlement of the contract.

(1)

(2)

(3)

(4)

(5)

(6)

STANDARD FORM 30 (REV. 11/2016) BACK

(1) Accounting classification Net increase $

Description of Modification Continuation Page

Attachments included in this amendment:

1.) RFI responses 2.) Justification for the use of MAD MosaicONE VMS 3.) Wage Determination NM20230044 dated 03/31/2023 4.) Site Visit Sign In Sheet

47PH0623R0023/0001

RFIs for GSA Solicitation No. 47PH0622R0018 – Elevator Replacement

RFI’s specific to specification number 122722 “section 14210” (Questions 1-13)

1.) General: 1.2: Please define DBA levels that will be acceptable when it comes to “noise”

It’s whatever the Courts decide it is. This building is empty now, as long as no Court is being held, it’s not an issue.

2.) Maintenance: 9.1: When one of the elevators that are being modernized is complete, would you like TK to reinstate that elevator on our current elevator maintenance contract with GSA?

We (GSA) will move them in and out of the maintenance contract.

3.) Maintenance: 9.4: TK asks if “1 hour” response time can apply to weekday callbacks and a “2 hour” response time be granted for weekend callbacks.

One hour response is the standard. Having said that, the building is unoccupied, and no one is there on weekends even when occupied, 4.) Instructions: 10.4-A: Will GSA allow TK to replace this section with “Owner’s Training” which provides GSA within person tutorials on how to utilize independent service, phase 1-2 fire life safety, cab fan/lights?

No, but the training you describe above is exactly the intent of the training we expect.

5.) Power Supply: 11.3: Will GSA confirm where the main power supply is within the building?

Our electrician will need to know where to pull power to/from. More specifically, the new earth ground wire that would be required by code.

The panel is found in the Basement room B5 directly across from the stairwell.

6.) Emergency Power Operation: 25.1: Please confirm if the building is currently on emergency power. In addition, will GSA confirm if they want both elevators on emergency power, if yes, what sequence. If emergency power exists, please confirm if there is an ATS switch with pre-signal capabilities.

There is no emergency generation at this facility.

7.) Group Car Control Functions: 26.5: Is there an existing lobby security console? If so, may you provide pictures of it? If there is none existing and the active shooter is still required, we will need GSA to specify which car they would want removed from the group first and, what floor landings would they want elevator to go to?

There is, at the main building entry. BM would have to provide pics. Both cars removed at the same time, remain on the 2nd floor. (Just like Phase 2 Fire Service)

8.) Group Car Control Functions: 26.5: B: Do you want the pit flood alarm? • 37. Elevator Cabs: 37.10: Will new cab shell of No 14 USS Gauge with No 4 bronze finish need to be provided?

Yes, include pit flood as specified. New cab interiors are to look like existing finishes.

9.) Elevator Cabs: 37.11: What finish do you want car doors?

New to match existing.

10.) Telephone: This code requires additional 110V outlets in the machine room or in the fire command room to accommodate the new video monitors needed for the video cameras in the elevator. These 110V outlets also need to be EP backed. Does GSA want these in the machine room or fire command room?

Machine room. There is not a fire command room to my knowledge.

11.) Passenger Elevator Hoistway Entrances: 46.1: Bronze fused to be used for entrances, will this suffice?

Entrance to match existing.

12.) Passenger Elevator Hoistway Entrances: 46.3: May we retain the existing Hoistway Doors?

Please follow specifications:

Each passenger elevator hoistway entrance for Elevator Nos. 1-2 shall be provided with new sandstone finished Fused Bronze wrap around existing door frames at all floors, and new sandstone finished Fused Bronze horizontally sliding doors at all floors to match existing picture frame decorative pattern, complete with door tracks, hanger assemblies, interlock assemblies, door pickup rollers, and gibs as herein specified.

13.) Tests: Please confirm if you would like TKE to hire a QEI to witness the CAT5 Full Load Test. In addition, please confirm if all tests required in this section may be done on regular working time (Monday – Thursday: 8AM-4:30PM, excluding Holidays) or, will overtime for all of these tests be required?

It is the expectation of GSA for GSA to provide an in house elevator QEI.

14.) Liquidated Damages: Will there be a “CAP” or “not to exceed” on the liquidated damages?

No, but excusable delays will be taken into consideration if LDs are assessed

15.) Is this a predetermined wage rate (Davis Bacon) project?

Yes, the current wage determinations for the project were included with the solicitation

16.)Will the prime contractor be responsible for coordination of getting our work by other vendors badged with GSA or, will our subcontractors work directly with GSA to get badged?

The elevator contractor will be the elevator project prime contractor. He will work with GSA for badging of the subs.

JUSTIFICATION FOR OTHER THAN FULL AND OPEN COMPETITION

47PH0623R0023 – Albuquerque Federal Building and Courthouse Elevator

Modernization PBS, Region 7

Less Than $750,000

DESCRIPTION OF THE ACTION BEING APPROVED

This action is for the purchase of communication device for the elevator modernization project at the Albuquerque Federal Building and Courthouse, 421 Gold Ave. SW, Albuquerque, NM. The purchase of these communication devices is part of the overall elevator modernization for 2 existing elevators at this federal building. This is a onetime buy, and it is anticipated that a standalone contract will be awarded. The rationale for this action is detailed in the paragraphs below.

DESCRIPTION OF SUPPLIES/SERVICES REQUIRED

The supply request is for four MAD MosaicONE VMS communication devices.

The estimated value of this procurement

IDENTIFICATION OF STATUTORY AUTHORITY

Citation: 41 U.S.C. 3304(a)(1). FAR 6.302-1: Only one responsible source and no other supplies or services will satisfy agency requirements.

DEMONSTRATION THAT THE ACQUISITION REQUIRES THE USE OF THE

AUTHORITY CITED

FAR 6.302-1 allows for the use of other than full and open competition when required supplies are available from only one source. The MAD MosaicONE VMS is the only system cleared for trial use in GSA facilities and the GSA network. Other systems are currently being reviewed by GSA IT for network and security; however, until other systems are cleared this system will be the only approved product for use at GSA facilities.

EFFORTS TO SOLICIT TO AS MANY SOURCES AS PRACTICABLE

Since this is a justification for a sole source procurement for this specific communication equipment, no other sources will be solicited.

DETERMINATION THAT THE ANTICIPATED COST WILL BE FAIR AND

REASONABLE

The anticipated cost will be considered fair and reasonable by the Contracting Officer prior to award of the contract. This determination will be conducting a price analysis based on the Government’s estimate. A written price evaluation will be included in the file.

DESCRIPTION OF THE MARKET RESEARCH CONDUCTED

There was no market research conducted as this is the only approved communications device approved by GSA IT.

OTHER FACTS SUPPORTING THE USE OF THE OTHER THAN FULL AND OPEN

COMPETITION

None.

LIST OF SOURCES THAT EXPRESSED AN INTEREST IN THE ACQUISITION

None.

STATEMENTS OF ACTION TO OVERCOME BARRIERS TO COMPETITION

Once additional communication devices are approved by GSA IT, the Contracting Officer will ensure that future contracts will be available competitively.

CONTRACTING OFFICER CERTIFICATION

This justification is limited to the scope and quantity essential to procure the requested supply. The only known source approved at this time is the MAD MosaicONE VMS communication device.

The contracting officer has determined that the actions taken under this acquisition meet the conditions described in FAR 6.302-1 and the source specified precludes full and open competition. It is in the best interest of the Government to purchase the services described above.

The information contained in the justification for other than full and open competition is accurate and complete to the best of the Contracting Officer’s knowledge.

Approved by:

Date

Contracting Officer, 7PQC

3/29/2023

"General Decision Number: NM20230044 03/31/2023

Superseded General Decision Number: NM20220044

State: New Mexico

Construction Type: Building BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

County: Bernalillo County in New Mexico.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $16.20 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2023. | |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $12.15 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2023. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/06/2023 1 01/13/2023 2 03/03/2023 3 03/17/2023 4 03/31/2023

ASBE0076-008 01/01/2023

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 35.76 11.73

CARP1505-001 06/01/2018

Rates Fringes

CARPENTER (Includes Drywall Finishing/Taping, Drywall Hanging, and Metal Stud Installation (Excludes Form Work))...........................$ 24.08 10.79

ELEC0611-022 01/01/2023

Rates Fringes

ELECTRICIAN......................$ 36.75 12.77

ELEV0131-002 01/01/2023

Rates Fringes

ELEVATOR MECHANIC................$ 48.93 37.335+a+b

PAID HOLIDAYS:

a. New Year's Day, Memorial Day, Independence Day, Labor Day, Veteran's Day, Thanksgiving Day, the Friday after Thanksgiving, and Christmas Day.

b. Employer contributes 8% of regular hourly rate to vacation pay credit for employee who has worked in business more than 5 years; 6% for less than 5 years' service.

IRON0495-002 01/01/2021

Rates Fringes

IRONWORKER, STRUCTURAL...........$ 27.35 17.30

LABO0016-002 06/01/2018

Rates Fringes

LABORER (Mason Tender - Cement/Concrete).................$ 17.25 6.01

PLAS0254-001 03/18/2021

Rates Fringes

PLASTERER........................$ 23.56 9.39

PLUM0412-014 01/01/2022

Rates Fringes

PIPEFITTER.......................$ 36.40 13.90

PLUMBER (Includes HVAC Pipe Installation)....................$ 36.40 13.90

SFNM0669-001 04/01/2021

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 32.67 23.21

* SHEE0049-004 01/01/2023

Rates Fringes

Sheet Metal Worker (Including HVAC Duct and Unit Installation)....................$ 35.44 18.42

* SUNM2016-001 09/26/2018

Rates Fringes

CARPENTER (Form Work Only).......$ 20.41 6.25

CEMENT MASON/CONCRETE FINISHER...$ 18.59 7.45

GLAZIER..........................$ 20.15 3.48

LABORER: Common or General......$ 15.70 ** 4.86

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 25.97 5.15

PAINTER (Brush and Roller).......$ 16.51 2.14

PAINTER: Spray..................$ 16.51 2.14

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

** Workers in this classification may be entitled to a higher minimum wage under Executive Order 14026 ($16.20) or 13658 ($12.15). Please see the Note at the top of the wage determination for more information.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the 10

Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISIO"

ACQUISITION NON-PROSPECTUS

1100 Commerce Street, Suite 720 Dallas, TX 75242 USA

[See Description of Modification Continuation Page]

ACQUISITION NON-PROSPECTUS

1100 Commerce Street, Suite 720 Dallas, TX 75242 USA NameandTitleSigner[0]: