36C25218B0230-001.docx

Solicitation #: 36C252-18-B-0230

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT

NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV.

8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that t ime. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government accepta nce after the date offers are due will not be considered and will be rejected.

36C25218B0230 X 02-13-2018 695-18-2-6920-0001 695-15-116 36C252 Department of Veterans Affairs Great Lakes Acquisition Center (GLAC) 115 S 84th Street, Suite 101 Milwaukee WI 53214-1476 Great Lakes Acquisition Center (GLAC) Department of Veteran Affairs 115 S 84th Street, Suite 101 Milwaukee WI 53214-1476 Anne Vossler anne.vossler@va.gov

695-15-116: Replace 3 Boilers, Building 112

Replace 3 Boilers, Building 112 at the Clement J. Zablocki VA Medical Center, 5000 W. National Ave, Milwaukee, WI, 53295 Contractor shall furnish all labor, materials, equipment, and supervision in accordance with specifications & drawings to complete Project # 695-15-116, Replace 3 Boile rs, Building 112. This project includes demolition, site prepartion, removal and new constuction for the replacement of three existing 30,000 lb boilers with three new 50,000 lb water tube steam boilers with economizers and associated support equipme

nt. Work also includes installation of new deaerator tank and pumps, condensate tank and pumps and new reverse osmosis system. Architectural work includes limited mezzanine structural modifications, installation of new overhead door, and construction of a new electrical equipment room.

All work shall be completed within 630 calendar days from issuance of the Notice to Proceed. This project has a specific phasing plan that must be adhered to.

Project magnitude range: $5,000,000 and $10,000,000 NAICS 238220: Plumbing, Heating, and Air Conditioning Contractor s / SBA Size Standard: $15.0 million

This procurement is a 100% set-aside for CVE-Verified Service-Disabled Veteran-Owned Small Business Firms (SDVOSB) per the authority 38 U.S.C. 8127 ( Public Law 109-461). In accordance with VAAR 819.7003(b), at the time of submission of bid, the bidder must represent that it is a SDVOSB concern, a small business concern under the NAICS code assigned to this acquisition, and is CVE-verified for eligibility in the VIP database.

Submit all questions regarding the solicitation, specifications, and/or drawings in writing to the Contracting Officer, Anne Vossler, no later than 2:00 PM (Local Time) on March 2, 2018. No questions will be accepted after that date and time. See 52.236-27 SITE VISIT for information on organized site visit. Steel Toe Shoes & Safety Glasses required.

TELEPHONE INQUIRES WILL NOT BE ACCEPTED.

If submitting as a joint-venture, offerors must include a copy of the joint-venture agreement.

NOTICE: VA and/or a third party (support contractor) will require access to VA contractor records to assess contract compliance with the lim itations on subcontracting requirements included in VAAR 852.219-10. See LIMITATIONS ON

SUBCONTRACTING AND COMPLIANCE (JUNE 2011).

All bidders are responsible for monitoring and downloading any amendments from FedBizOpps at the following website:

https://www.fbo.gov/ Award is subject to the availability of funds. Only one award will be issued X X 52.211-10 X 0 (zero) 2:00 pm CT 03-14-2018 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and paym ent bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28.

NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL

COMPLETE ITEM 28 OR 29 AS APPLICABLE

See Bid Schedule 695-3680162-6920-854200-3220

23NR5MC06

36C252 Department of Veterans Affairs Great Lakes Acquisition Center (GLAC) 115 S 84th Street, Suite 101 Milwaukee WI 53214-1476 Department of Veterans Affairs Financial Services Center PO Box 149971 Austin TX 78714-9971 877-353-9791 512-460-5540

BID SCHEDULE

Solicitation Number 36C252-18-B-0230 695-15-116: Replace 3 Boilers, Building 112 Clement Zablocki VAMC, Milwaukee, WI

Base Bid: Contractor shall provide for and furnish all labor, materials, equipment, qualified supervision, and other items designated in this contract in accordance with the specifications and drawings to complete Project # 695-15-116: Replace 3 Boilers, Building 112 at the Clement J. Zablocki VA Medical Center in Milwaukee, Wisconsin.

All work shall be completed within 630 calendar days after receipt of the notice to proceed.

Base Bid LUMP SUM: _______________________________

NOTICE TO BIDDERS: Award will be made to the responsible bidder who submitted the lowest responsive bid. A single award will be made on Base Bid.

NOTICE TO BIDDERS: The contractor will be working in an active hospital, and often-congested parking and driving area adjacent to an operating hospital. The contractor will be sharing roadways with patients, visitors, staff, vendors, delivery vehicles, and other contractors during the normal work day. Significant amounts of or large materials should be delivered off normal working hours or on week-ends to mitigate congestion and interference.

The contractor will be required to keep all other non-impacted roads, walks and entrances to grounds, parking, and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles. Submittals regarding staging of equipment, crane placement, storage of supplies, etc. are required. Off-hours and/or week-end deliveries of construction equipment or materials may be required.

NOTICE TO BIDDERS: Work shall not commence until all required submittals are approved by the Contracting Officer or the Contracting Officer’s Representative (COR). An approved cost-loaded, Critical Path Method (CPM) construction schedule is required prior to commencement of construction. See specifications for details. CPM schedule shall be approved by the Contracting Officer or the Contracting Officer’s Representative. See specifications for details.

NOTICE TO BIDDERS: Additional information regarding the general and specific scope of work is defined in the specifications and drawings. This BID SCHEDULE and the attached Scope of Work are in addition to and augment the specifications and drawings. ONLY ONE AWARD WILL BE MADE AS A RESULT OF THIS SOLICITATION.

Scope of Work:

Furnish all labor and materials for all demolition, site preparation, removal and new construction for the replacement of three (3) existing 30,000 lb boilers with three (3) new 50,000 lb. water tube steam boilers with economizers and associated support equipment. Work also includes installation of new deaerator (DA) tank & pumps, condensate tank & pumps and new reverse osmosis system. Architectural work includes limited mezzanine structural modifications, installation of new overhead door, and construction of a new electrical equipment room.

1. All work shall be completed within 630 days after receiving Notice to Proceed.

· Phase 1: Pre-construction (kick-off) Meeting is anticipated to be scheduled on the effective date identified in the Notice to Proceed (NTP).

· Phase 2: Pre-Construction Period duration is NTP + 45 calendar days (not to exceed). Within this period the contractor shall submit the following (as applicable per the specification requirements):

1. Logistics Plan.

2. Construction Security Plan.

3. Construction Phasing Plan.

4. Submittal Registry.

5. Accident Prevention Plan.

6. Activity Hazard Analyses.

7. Construction Schedule.

8. Schedule of Values.

9. Existing Conditions Survey.

10. Infection Control Plan.

11. Quality Control Plan.

12. Environmental Protection Plan.

13. Document Submissions.

14. Demolition Debris Management Plan.

15. Certificates, Licenses, and Training Documents.

16. Obtain PIV badges

· Phase 3: Boiler Procurement and Staging Period duration is NTP + 366 Days. All applicable documentation listed in Phase 2 and any necessary submittals required to mobilize must be approved by the COR prior to commencing work.

· Phase 4: Construction Period – Phase duration is to be 168 days, to be completed no later than NTP+578; Existing boilers must remain operational during heating seasons in accordance with contract drawing phasing notes (Sheet G004 Note 8).

Phase 3 must be completed prior to Phase 4 start. Construction is to begin no earlier than May 1st 2019 and be completed no later than October 15th 2019. All applicable documentation listed in Phase 2 and any necessary submittals required to mobilize must be approved by the COR prior to commencing work. No demolition or construction shall be started without COR review and approval of those items listed in the Pre-Construction Period unless authorized in writing by the COR or the CO.

Should naturally occurring weather delays occur, the contractor shall restart construction immediately once conditions permit.

· Phase 5: Construction Closeout Period duration is NTP + 630 calendar days. The contractor shall provide all required materials to include the following within 30 days of completion of Phase 4:

1. Inspection and Approval by the COR and/or the CO.

2. Final Approval and Beneficial Occupancy when applicable.

3. Warranties documents and O&M Manuals.

4. As-built drawings and record submittals.

5. Staff training when applicable.

6. Waste Reports.

7. Existing Conditions Re-survey.

8. Release of Claims

End of SOW

CONTRACTING OFFICER SPECIAL INSTRUCTIONS AS FOLLOWS

PROJECT 695-15-116: Replace 3 Boilers, Building 112 Requests for information or clarifications to solicitation documents shall be submitted to the Contracting Officer at anne.vossler@va.gov for action no later than March 2, 2018.

After compiling all required information, submit the information in accordance with the "Bid Due Date" in Block 13 of the SF 1442. Return the original and specified number of copies to the issuing office listed in Block 8 of the SF 1442.

INQUIRIES:

Inquiries and all correspondence concerning this solicitation document should be submitted in writing to the Contracting Officer referenced in the solicitation. YOU ARE INSTRUCTED SPECIFICALLY TO CONTACT ONLY THE CONTRACTING OFFICER ISSUING THE SOLICITATION ABOUT ANY ASPECT OF THIS REQUIREMENT PRIOR TO CONTRACT AWARD.

CONTRACTOR'S SIGNATURE:

In accordance with Federal Acquisition Regulations Part 4, contractual documents (e.g. bids, proposals, awards, modifications, etc.) shall be completed and signed by the Contractor as follows:

(a) Individuals: Signed by the individual.

(b) Individual doing business as a firm. Signed by that individual, and the signature shall be followed by the individual's typed, stamped, or printed name and the words, "an individual doing business as __________________ (insert name of firm)".

(c) Partnership: Signed in the partnership name. Prior to award, provide list of all partners and designate which partners have authority to bind the partnership.

(d) Corporations: Signed in the corporate name followed by the word "by" and the signature, and title of the person authorized to sign. Prior to award, provide list of individuals who have authority to bind the corporation.

(e) Joint Ventures: Signed by each participant in the joint venture in the manner prescribed in (a) through (d) above.

(f) Agents: When an agent is to sign the contract, other than as stated in paragraph (a) through (e) above, the agent's authorization to bind the principal must be established by evidence satisfactory to the contracting officer.

ADDITIONAL PRIME CONTRACTOR INFORMATION - Safety or Environmental Violations and Experience Modification Rating Information Information provided below shall be applicable to solicitation 36C252-18-B-0230 1.) All Bidders/Offerors shall submit information pertaining to their past Safety and Environmental record. The information must contain a certification that the bidder/offeror has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years. If such certification cannot be made, a Bidder/Offeror shall explain why and submit as much information as possible regarding the circumstances of its past safety and environmental record, including the number of EPA violations and/or the number of serious, repeat, and/or willful OSHA violations, along with a detailed description of those violations.

2.) All Bidders/Offerors shall submit information regarding their current Experience Modification Rate (EMR). This information shall be obtained from the Bidder’s/Offeror’s insurance carrier and be furnished on the insurance carrier’s letterhead. If a Bidder/Offeror’s EMR is above 1.0, Bidder/Offeror must submit a written explanation of the EMR from its insurance carrier furnished on the insurance carrier’s letterhead, describing the reasons for the elevated EMR and the anticipated date the EMR may be reduced to 1.0 or below.

3.) Self-insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self-insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR shall obtain their EMR rating from their state run worker’s compensation insurance rating bureau.

4.) If the NCCI cannot issue an EMR because the Bidder/Offeror lacks insurance history, Bidder/Offeror shall submit a letter indicating so from its insurance carrier furnished on the insurance carrier’s letterhead, and include a letter from the NCCI indicating that is has assigned Bidder/Offeror a Unity Rating of 1.0.

5.) The above information, along with other information obtained from Government systems, such as the OSHA and EPA online inspection history databases, will be used to make an initial Determination of Responsibility.

6.) This requirement is applicable to all subcontracting tiers, and prospective prime contractors are responsible for determining the responsibility of their prospective subcontractors.

PRE-AWARD CONTRACTOR SAFETY AND ENVIRONMENTAL RECORD EVALUATION FORM

Company Name: ______________________________________________ Address: _____________________________________________________ Telephone: ______________________ Fax: ________________________ Email: _______________________________________________________ DUNS Number: ________________________________________________ Contact: ______________________________________________________

1. Utilizing your OSHA 300 Forms, please complete the following information:

Number of man hours (jobsite and office).

Number of cases involving days away from work, restricted activity, or both (Column H and I of OSHA 300).

Days away, restricted, or transferred rate (# of days away, restricted, or transferred cases x 200,000/# of man hours) (DART Rate).

Number of serious, willful, or repeat violations from OSHA within the last 3 years. Please attach explanation for any violations.

Please attach copies of the following documents: OSHA 300 and 300a Forms. These forms can be accessed through the OSHA publications search page: http://www.osha.gov/pls/publications/publication.html.

CONTRACTOR INFORMATION:

TAX ID Number:

DUNS Number:

Past Performance Point of Contact (within your company), include name and email address:

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE AND BONDS

(a) This solicitation & all associated bid documents are available to interested parties in electronic file format from www.fedbizops.gov. No hard copy documents will be provided by the government.

(b) A bid guarantee is required in an amount not less than 20 percent of the bid price but shall not exceed $3,000,000. Failure to furnish the required bid guarantee on form SF 24, in the proper amount, by the time set for opening of bids, will result in rejection of the bid in all cases except those listed in FAR 28.101-4, and may be cause for rejection even then.

(c) The bidder to whom a contract is awarded will be required to furnish a Payment Bond, on form SF 25A, and a Performance Bond, on form SF 25. Each bond shall be issued for a penal sum equal to the value of the awarded contract. Copies of forms SF 25 and 25A may be obtained from the Contracting Officer upon request.

(d) Bidders are to ensure the most current version of SF24, SF25, and SF25A bond forms are used. Current versions of these forms can be found and downloaded from the GSA Forms Library (https://www.gsa.gov/portal/forms/type/TOP).

Description of Work: Replace 3 Boilers, Building 112 Cost Range: $5,000,000 - $10,000,000

A.1 52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS, FPMR PART 101-29 (AUG 1998)

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to— GSA Federal Supply Service Specifications Section, Suite 8100 470 East L'Enfant Plaza, SW Washington, DC 20407 Telephone (202) 619-8925 Facsimile (202) 619-8978.

(b) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision. Additional copies will be issued for a fee.

(End of Provision) A.2 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS (JUN 1988) The specifications cited in this solicitation may be obtained from:

Activity: Refer to Specification Section 01 42 19 Complete Address: NA Telephone Number: NA Person to be Contacted: NA Time(s) for Viewing: NA The request should identify the solicitation number and the specification requested by date, title, and number, as cited in the solicitation.

(End of Provision) A.3 52.211-4 AVAILABILITY FOR EXAMINATION OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS (JUN 1988) The specifications cited in this solicitation are not available for distribution. However, they may be examined at the following location(s):

Activity: Refer to Specification Section 01 42 19 Complete Address: NA

Telephone Number: NA Person to be Contacted: NA Times(s) for Viewing: NA (End of Provision)

A.4 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

(End of Provision) A.5 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision) A.6 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is State of Wisconsin, Milwaukee County, City of Milwaukee

(End of Provision)

A.7 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be Twenty (20) percent of the bid price or $3,000,000, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision)

A.8 52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

NCO 12 Contracting Officer:

Anne Vossler Hand-Carried Address:

Department of Veteran Affairs

GLAC (36C252)

115 South 84th Street, Suite 101 Milwaukee WI 53214-1476

Mailing Address:

Department of Veterans Affairs

GLAC (36C252)

115 South 84th Street, Suite 101 Milwaukee WI 53214-1476

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

A.9 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 8:30am, Tuesday, February 20, 2018

(c) Participants will meet at Boiler House Building 112. Wear Steel toe shoes and safety glasses (End of Provision)

A.10 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Provision)

A.11 VAAR 852.214-70 CAUTION TO BIDDERS--BID ENVELOPES (JAN 2008)

It is the responsibility of each bidder to take all necessary precautions, including the use of proper mailing cover, to insure that the bid price cannot be ascertained by anyone prior to bid opening. If a bid envelope is furnished with this invitation, the bidder is requested to use this envelope in submitting the bid. The bidder may, however, use any suitable envelope, identified by the invitation number and bid opening time and date. If an Optional Form (OF) 17, Sealed Bid Label, is furnished with this invitation in lieu of a bid envelope, the bidder is advised to complete and affix the OF 17 to the lower left corner of the envelope used in submitting the bid.

(End of Provision)

A.12 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE RESOLUTION (JAN 2008)

(a) Any protest filed by an interested party shall:

(1) Include the name, address, fax number, and telephone number of the protester;

(2) Identify the solicitation and/or contract number;

(3) Include an original signed by the protester or the protester's representative and at least one copy;

(4) Set forth a detailed statement of the legal and factual grounds of the protest, including a description of resulting prejudice to the protester, and provide copies of relevant documents;

(5) Specifically request a ruling of the individual upon whom the protest is served;

(6) State the form of relief requested; and

(7) Provide all information establishing the timeliness of the protest.

(b) Failure to comply with the above may result in dismissal of the protest without further consideration.

(c) Bidders/offerors and contracting officers are encouraged to use alternative dispute resolution (ADR) procedures to resolve protests at any stage in the protest process. If ADR is used, the Department of Veterans Affairs will not furnish any documentation in an ADR proceeding beyond what is allowed by the Federal Acquisition Regulation.

(End of Provision)

A.13 VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (JAN 1998)

As an alternative to filing a protest with the contracting officer, an interested party may file a protest with the Deputy Assistant Secretary for Acquisition and Materiel Management, Acquisition Administration Team, Department of Veterans Affairs, 810 Vermont Avenue, NW., Washington, DC 20420, or for solicitations issued by the Office of Construction and Facilities Management, the Director, Office of Construction and Facilities Management, 810 Vermont Avenue, NW., Washington, DC 20420. The protest will not be considered if the interested party has a protest on the same or similar issues pending with the contracting officer.

(End of Provision) PLEASE NOTE: The correct mailing information for filing alternate protests is as follows:

Or for solicitations issued by the Office of Construction and Facilities Management:

A.14 VAAR 852.270-1 REPRESENTATIVES OF CONTRACTING OFFICERS (JAN 2008)

The contracting officer reserves the right to designate representatives to act for him/her in furnishing technical guidance and advice or generally monitor the work to be performed under this contract. Such designation will be in writing and will define the scope and limitation of the designee's authority. A copy of the designation shall be furnished to the contractor.

(End of Provision)

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238220.

(2) The small business size standard is $15 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM Web site accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

3.2 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

(a) Definitions. As used in this provision— "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of Provision)

GENERAL CONDITIONS

4.1 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

4.2 52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)

(a) The Contractor shall update the information in the Federal Awardee Performance and Integrity Information System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the System for Award Management database via https://www.acquisition.gov.

(b) As required by section 3010 of the Supplemental Appropriations Act, 2010 (Pub. L. 111-212), all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available. FAPIIS consists of two segments—

(1) The non-public segment, into which Government officials and the Contractor post information, which can only be viewed by—

(i) Government personnel and authorized users performing business on behalf of the Government; or

(ii) The Contractor, when viewing data on itself; and

(2) The publicly-available segment, to which all data in the non-public segment of FAPIS is automatically transferred after a waiting period of 14 calendar days, except for—

(i) Past performance reviews required by subpart 42.15;

(ii) Information that was entered prior to April 15, 2011; or

(iii) Information that is withdrawn during the 14-calendar-day waiting period by the Government official who posted it in accordance with paragraph (c)(1) of this clause.

(c) The Contractor will receive notification when the Government posts new information to the Contractor's record.

(1) If the Contractor asserts in writing within 7 calendar days, to the Government official who posted the information, that some of the information posted to the nonpublic segment of FAPIIS is covered by a disclosure exemption under the Freedom of Information Act, the Government official who posted the information must within 7 calendar days remove the posting from FAPIIS and resolve the issue in accordance with agency Freedom of Information procedures, prior to reposting the releasable information.