3-References 07.15 Fillable.pdf

REFERENCES - $500,000 or more: For bidders to be responsive each must provide information on the most recent five (5) projects with similar scope of work as well as other information to determine experience and qualifications.

$499,000 and less: Provide references from owners of at least three (3) projects of various sizes. Include government owners if possible. If the contractor has performed any work for the Chatham County Board of Commissioners within the last five (5) years, at least one (1) of the three (3) owner references must be from the appropriate party within the Chatham County Government.

Failure to provide the information may result in your firm’s bid being rejected and ruled as non-responsive.

REFERENCE #1

a. Project Name:

Location:

Owner:

Address:

City and State:

Contact:

Phone & Fax:

*Architect or Engineer:

Contact:

Phone & Fax:

b. The awarded bid amount and project start date._____________________________

c. Final cost of project and completion date._________________________________

d. Number of change orders.______________________________________________

e. Contracted project completion in days.____________________________________

f. Project completed on time. Yes No Days exceeded .

g. List previous contracts your company performed for Chatham County by Project Title, date and awarded/final cost.

h. Has contractor ever failed to complete a project? Yes ____ No ___ If so, provide explanation.

i. Have any projects ever performed by contractor been the subject of a claim or lawsuit by or against the contractor? Yes___ No___ If yes, please identify the nature of such claim or lawsuit, the court in which the case was filed and the details of its resolution.

REFERENCE #2

a. Project Name:

Location:

Owner:

Address:

City and State:

Contact:

Phone & Fax:

*Architect or Engineer:

Contact:

Phone & Fax:

b. The awarded bid amount and project start date. ____________________________

c. Final cost of project and completion date. ________________________________

d. Number of change orders. ____________________________________________

e. Contracted project completion in days. __________________________________

f. Project completed on time. Yes No Days exceeded .

g. List previous contracts your company performed for Chatham County by Project

Title, date and awarded/final cost.

h. Has contractor ever failed to complete a project? Yes___ No___ If so, provide explanation.

i. Have any projects ever performed by contractor been the subject of a claim or lawsuit by or against the contractor? Yes___ No___ If yes, please identify the nature of such claim or lawsuit, the court in which the case was filed and the details of its resolution.

REFERENCE #3

Location:

Owner:

Address:

City and State:

Contact:

Phone & Fax:

*Architect or Engineer:

Contact:

Phone & Fax:

b. The awarded bid amount and project start date. ____________________________

c. Final cost of project and completion date._________________________________

d. Number of change orders.______________________________________________

e. Contracted project completion in days. ___________________________________

f. Project completed on time. Yes No Days exceeded .

g. List previous contracts your company performed for Chatham County by Project Title, date and awarded/final cost.

h. Has contractor ever failed to complete a project? Yes___ No___ If so, provide explanation.

i. Have any projects ever performed by contractor been the subject of a claim or lawsuit by or against the contractor? Yes___ No___ If yes, please identify the nature of such claim or lawsuit, the court in which the case was filed and the details of its resolution.

REFERENCE #4

Location:

Owner:

Address:

City and State:

Contact:

Phone & Fax:

*Architect or Engineer:

Contact:

Phone & Fax:

b. The awarded bid amount and project start date. ____________________________

c. Final cost of project and completion date. ________________________________

d. Number of change orders. _____________________________________________

e. Contracted project completion in days.___________________________________

f. Project completed on time. Yes No Days exceeded .

g. List previous contracts your company performed for Chatham County by Project

Title, date and awarded/final cost.

h. Has contractor ever failed to complete a project? Yes___ No___ If so, provide explanation.

i. Have any projects ever performed by contractor been the subject of a claim or lawsuit by or against the contractor? Yes___ No___ If yes, please identify the nature of such claim or lawsuit, the court in which the case was filed and the details of its resolution.

REFERENCE #5

Location:

Owner:

Address:

City and State:

Contact:

Phone & Fax:

*Architect or Engineer:

Contact:

Phone & Fax:

b. The awarded bid amount and project start date. ____________________________

c. Final cost of project and completion date. ________________________________

d. Number of change orders. _____________________________________________

e. Contracted project completion in days. ___________________________________

f. Project completed on time. Yes No Days exceeded .

g. List previous contracts your company performed for Chatham County by Project

Title, date and awarded/final cost.

h. Has contractor ever failed to complete a project? Yes___ No___ If so, provide explanation.

i. Have any projects ever performed by contractor been the subject of a claim or lawsuit by or against the contractor? Yes___ No___ If yes, please identify the nature of such claim or lawsuit, the court in which the case was filed and the details of its resolution.