24Z4AW6 Revised SOW FAO.pdf

Federal Bureau of Prisons FCI Oxford, B&F Project #24Z4AW6 24 Replace Dishwasher Asset#DW002OXF

February 7, 2025

Specification B&F Project #24Z4AW6 24 Replace Dishwasher

Asset#DW002OXF United States Department of Justice

Federal Bureau of Prisons FCI Oxford

Table of Contents Division 01 - General Requirements 01 11 00 Summary of Work and Bureau Procedures

1.1 Summary of Work

1.2 Contractor Use of Premises

1.3 Contractor Personnel and Equipment Security

1.4 Execution of Work and Clarification of Information

1.5 Definitions

1.6 Project Meetings

1.7 Supply and install Submittals

1.8 Supply and install Contract Management Requirements

1.9 Temporary Supply and install Facilities and Controls

1.10 Health and Safety

1.11 Supply and install Cleaning

1.12 Submittals for Substitution

1.13 Quality Assurance

1.14 Product Delivery/Storage/Handling

1.15 Warranties (Guarantees)

1.16 Project Closeout

PROPERTY OF THE UN ITED STATES GOVERNMENT

COPYING, DISSEM INATION, OR DISTRIBUTION OF THESE

DRAWINGS, PLANS, SPECIFICATIONS OR INFORMATION TO

UNAUTHORIZED USERS IS PROHIBITIED.

Do not remove this notice.

Properly destroy documents when no longer needed.

February 7, 2025

SECTION 01 11 00 - Summary of Work & Bureau Procedures

PART 1 GENERAL

1.1 SUMMARY OF WORK

A. All work described in these documents and all work necessary to complete the work as described or shown is to be executed in a thoroughly substantial and workmanlike manner. All work shall be done by persons who are thoroughly experienced in their particular trade or craft. The work includes, but is not necessarily limited to the following description:

FCI Oxford proposes to have an outside contractor replace the current dishwasher with a flight type dishwasher. The new dishwasher must be able to wash a minimum of 10,000 dishes per hour. It will feature an Automatic Soil Removal (ASR) system, Energy Recovery, steam booster heater, insulated cabinet doors, door interlocks, door and drain indicators, capless wash arms with anti-clogging nozzles, delime system, low temperature alert, and dual rinse.

The conveyor system will be 30 inches wide and designed for plates and trays.

The conveyor system will have a maximum rod spacing of 2.5 inches and a minimum finger height 3 inches. It will have a maximum water usage of 60 gph.

The dishwasher will be a vented unit. Lastly, the new dishwasher will have a minimum 1 year manufactures warranty.

The contractor will ship and deliver all equipment and materials need to install the dishwasher. The new dishwasher will be installed according to the manufactures recommendations. The contractor will furnish all plumbing connections, drains, drain piping, steam connections, stainless steel venting, pipe insulation, stainless steel junction box, and circuit breaker. The contractor will provide labor for all new plumbing, electrical, HVAC, and steam fitting work needed. All parts and materials furnished will be installed according to the manufactures recommendations and connect the new dishwasher to the existing source. They will disconnect all plumbing lines, steam lines, and electrical wiring to existing dishwasher. The contractor will be responsible for disassembling, removing, and properly disposing of the existing dishwasher.

The contractor will perform a startup to ensure the new dishwasher is performing properly. Finally, the contractor will provide FCI Oxford Food Service Staff with a short course on how to operate all new equipment.

The access route to the Food Service Dish Room is outlined in the prints. All room, hall, and door measurements are located on the prints.

FCI Oxford Staff will be responsible for the removal of any chemical equipment attached to the current dishwasher prior to the installation date. In the event that the food service door (see prints for door and location) is not wide enough for

SUMMARY OF WORK & BUREAU PROCEDURES

Sensitive But Unclassified - SBU

01 11 00 - 1

February 7, 2025 reasonable accommodation the required door modifications or replacement will be made by FCI Oxford Facilities Staff

The project shall comply with all appropriate State and Federal Codes and regulations, including the latest editions of the International Building Code, International Plumbing Code, International Mechanical Code, National Electrical Code (NFPA 70), Life Safety Code (NFPA 101), applicable NFPA standards, and environmental regulations.

Project Name: # 24Z4AW6 24 Replace Dishwasher Asset#DW002OXF

Location: FCI Oxford

Address: 350 Elk Ave Oxford, WI 53952

Owner: U.S. Department of Justice, Federal Bureau of Prisons

(FBOP)

1.2 CONTRACTOR USE OF PREMISES

A. The Contractor shall limit its use of the premise to the work indicated, to allow for Government occupancy and use. During the entire supply and install period, the Contractor shall coordinate use of the premises for supply and install operations with the FBOP Project Representative.

1. All visitors to the supply and install site shall register with the FBOP site officials. The Contractor shall not allow employees to have personal visitors on site.

2. The project site will be open to the Contractor from Monday through Friday, with exception of federal holidays, for the duration of the project. The project schedule is to be based on a normal 40-hour work week. The Contractor shall establish a normal work week schedule for the duration of the project.

a. Work outside the secure perimeter of the institution will be allowed between the hours of 6:30 AM to 4:00 PM. This will allow the Contractor's work force to arrive on-site in the morning and prepare for entering the secure perimeter of the institution. It will also allow the Contractor's work force to button-up their lay-down/staging area after exiting the secure perimeter at the end of the workday.

b. Work inside the secure perimeter of the institution will be allowed between the hours of 6:30 AM to 3:00 PM. Work inside the secure perimeter is restricted to the operation of the institution's rear gate. The Contractor's work force will be allowed to enter the rear gate at approximately 6:30 AM each workday. At this time, the FBOP staff will begin personnel and tool security check-in procedures. Once the check-in procedures are completed, the Contractor will be escorted by an FBOP escort to the work area. The rear gate closes at 3:00 PM;

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 2

February 7, 2025 therefore, the Contractor's work force will be escorted back to the rear gate by FBOP staff no later than approximately 2:30 PM, to allow enough time for the completion of security check-out procedures prior to exiting the secure perimeter.

3. Contraband: The Contractor shall inform his/her employees that intoxicating beverages, drugs, weapons, etc .. , will not be allowed on the site. Introduction of contraband shall be subject.to the penalties prescribed by Title 18 USC 1791.

4. Explosives: The use of explosives is absolutely forbidden without written authorization from the FBOP Contracting Officer upon no less than thirty

(30) days advance written request.

5. Cell phones, pagers, and radios are not allowed within the secure perimeter.

6. Parking: Parking areas, either on or off-site will be furnished for workmen by the Contractor at a location approved by the FBOP Project Representative.

7. Temporary Office: Any temporary field office used by the Contractor shall be located in an area approved by the FBOP Project Representative.

8. The Contractor shall review his or her site layout plan for staging, stockpiles, etc .. , with the FBOP Project Representative. The Contractor shall maintain all staging and supply and install areas in a neat and orderly fashion.

9. The Contractor shall provide protection of the work against weather, rain, wind, storms, frost, cold, or heat so as to maintain all work, materials, apparatus and fixtures free from injury or damage.

1.3 CONTRACTOR PERSONNEL AND EQUIPMENT SECURITY

A. Contractor employees working at a FBOP facility will be subject to a background investigation after award of the contract. Contractor employees must complete the applicable forms provided by the FBOP Project Representative. Following the investigation, the FBOP will provide the Contractor with a list of employees approved to work atthe institution. If a Contractor's employee is not approved, only that fact will be communicated to the Contractor. No additional justification will be released, in compliance with Privacy Act requirements.

B. Contractor employees working within the secure perimeter shall wear a clearance badge issued by the institution at all times, and shall be escorted by an institution staff member.

C. Tools brought into the institution's secure perimeter will be inventoried at the beginning and end of each work day by FBOP staff.

1. All tools used by the Contractor working within the secure perimeter shall be under constant supervision. Loss of a tool shall be reported immediately to the escorting FBOP staff.

2. No explosive action tools shall be used on the property at anytime.

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 3

. Federal Bureau of Prisons

February 7, 2025

3. Materials brought inside the secure perimeter of the institution shall be limited to a one-day supply. Surplu& materials that are not installed in on work day must be moved outside the secure perimeter at the end of the day.

D. Contractor employees working on the FBOP site shall be required to undergo a general institution orientation on responsibilities, procedures and laws governing conduct when working at an FBOP institution. These rules include, but are not limited to the following:

1. Weapons and ammunition of any kind are not allowed on Federal property, including the parking lot.

2. Do not give, or offer to give, anything to an inmate.

3. Do not bring any correspondence into or out of the institution.

4. Do not accept gifts or favors from inmates.

5. Leave personal items locked in your vehicle or secure them at the

Contractor's lay-down area.

6. A form of photo ID is required to enter the facility.

7. Revealing clothing is not acceptable attire and work attire is required at all times.

8. Conduct yourself in a responsible, mature manner.

9. Report an unusual action(s) or behavior to FBOP staff.

1.4 EXECUTION OF WORK AND CLARIFICATION OF INFORMATION

A. The Contractor's execution of the Contract represents that the Contractor has visited the site and become familiar with the local conditions under which the Work is to be performed; and correlated personal observations with the Contract requirements.

B. It is the intention of the Supply and install Documents to provide a complete project. The Contractor shall be responsible for this result. The Contractor shall verify all measurements and be responsible for the correctness of same. The Contractor shall layout their work and be responsible for all lines, elevations, and measurements of buildings, utilities, and other work executed by them. This includes verification of existing conditions, if any, that affect their work or to which their work is to be fitted.

C. The Contractor shall carefully study and compare Contract Documents before proceeding with fabrication and installation of work. Coordinate scheduling, submittals and work to ensure efficient and orderly sequence of installation.

D. Should it appear that the work intended to be described is· not sufficiently detailed or explained by the Supply and install Documents, the Contractor shall issue a Request for Information (RFI) to the FBOP Contracting Officer. RFl's shall be used by the Contractor to clarify information in the Supply and install Documents only. Each RFI shall be numbered sequentially, dated and indicate a reasonable date for the Contracting Officer's written reply. All RFI questions

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 4

February 7, 2025 shall be thoroughly researched by the Contractor, prior to presenting them as RFl's. In no case shall any work proceed in uncertainty.

1.5 DEFINITIONS

A. Contracting Officer: The officer who executes the contract on behalf of the United States; this shall include a duly appointed successor. The Contracting Officer is the only official authorized to administer, modify, and/or terminate the contract. The Contracting Officer makes related approvals, determinations, and findings pertaining to the contract and is the only individual on the project staff who can obligate funds on behalf of the Government and is registered with the Department of Justice.

B. FBOP Project Representative: The FBOP representative, located at the supply and install project site, or authorized representative(s) who has overall responsibility (except for contractual matters) for the administration of the operations and activities at the supply and install project site. References to "Government Representative11 or "Contracting Officer's Representative (COR)" shall mean the FBOP Project Representative. The FBOP Project Representative represents the Contracting Officer for all technical matters that arise under the contract. The FBOP Project Representative shall be specifically responsible for the following areas as they relate to the administration of the supply and install contract. This delegation of duties and responsibilities does not preclude the Contracting Officer from also performing these duties.

1. Monitor and review the progress of the work. This will include the conduct of onsite observations of the work as it is in progress. The FBOP Project Representative shall issue reports concerning deficiencies and/or omissions observed in the work. .

2. Receive submittals to verify conformance with the Contract Documents.

3. Review requests for information from the Contractor. This does not include the authority for any change that may result from the approval of the request for information. Authorization for any change can come only from the Contracting Officer.

4. Monitor that all tests required by the Contract Documents are performed.

This may include the documentation of the test procedures and results.

5. Review sample supply and install and job site mockups for conformance with the Contract Documents.

6. Review and sign the application and certificates for payment as submitted by the Contractor. Approval of the certification must be made by the Contracting Officer.

7. Evaluate the Contractor's performance and prepare a performance report at the completion of the Contract.

8. Review and recommend final approval of the Contractor's schedule for the Contracting Officer as required by the Contract Documents. This process would include the Schedule of Values.

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 5

February 7, 2025

9. The FBOP Project Representative shall approve the placement of the Contractor's trailers and general administration of the supply and install site as it relates to the supply and install work.

10. The FBOP Project Representative shall not, and has no authority to:

a. Re-delegate any authority to any other person.

b. Change any of the terms of the Contract or sign any modification to the

Contract. •

c. Obligate the payment of any money by the Government.

d. Cause the Contractor to incur cost not otherwise covered by the

Contract.

C. Contractor: The sole proprietorship, partnership, joint venture, corporation, or other legal entity that agrees to provide all labor, material, and services required in the contract. In order to administer and supervise the Contract Work, the Contractor shall provide the following minimum supervisors:

1. Contractor's Project Manager: The Contractor's Representative experienced in administration, supervision and quality control of all supply and install work required by the Contract. This includes, but is not limited to enforcing all applicable federal, state and local standards.

2. Project Field Superintendent: The Contractor's Representative experienced in general field supervision of all supply and install work required by the Contract. Supervise, direct, inspect and coordinate the supply and install work of the Contractor, subcontractors, suppliers, and installers, and to assure compliance with the Supply and install Schedule.

D. Subcontractor: The term, as employed herein, includes a business having a direct contract with the Contractor, and it includes one who furnishes material according to the Drawings and Specifications of this work. This definition also includes businesses having contracts with subcontractors. Subcontractors are considered to be Contractor employees.

E. Approve: Only the Contracting Officer can approve or disapprove Contract actions. Even if the Specifications indicate that an individual other than the Contracting Officer (such as the "FBOP Project Representative") will approve or disapprove an action, it is understood that only the Contracting Officer has this authority. In no case will "approval" by the Contracting Officer be interpreted as a release of the Contractor from responsibility to fulfill the requirements of Contract Documents.

F. Industry Standards and General Applicability of Standards: Except where more explicit or more stringent requirements are written directly into the Contract Documents, applicable standards of the supply and install industry have the same force and effect (and are made a part of Contract Documents by reference) as if copied directly into Contract Documents, ·or as if published copies were bound herein. Any materials, equipment, or workmanship specified by references to published manufacturer's specifications, industry standards, SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 6

February 7, 2025 building codes, or other referenced published standard shall comply with the requirements of the latest editions or revisions thereof and any amendment or supplements in effect on the date of the Invitation for Bid, except as limited to type, class, grade, or modification in the Specification. The Contractor, if requested, shall furnish an affidavit from the manufacturer certifying that material or product delivered to the project site meets requirements specified.

1. "Federal Specification", "Commercial Standards", and "Simplified Practice

Recommendations" can be purchased from the Superintendent. of Documents, U.S. Government Printing Office, Washington, DC 20402.

2. Standards of associations, institutes, or similar organizations referred to in the Specifications may be obtained directly from th~ organization.

G. Substantial Completion: The stage in the progress of the work or designated portion thereof is sufficiently complete in accordance with the contract documents so the Government can occupy or utilize the work for its intended use.

1.6 PROJECT MEETINGS

A. Pre-Supply and install Meeting: The Contracting Officer shall schedule and conduct a pre-supply and install conference and organizational meeting at the project site or other convenient location prior to or at the time of receipt of the Notice to Proceed for the Supply and install Contract. Contracting Officer shall arrange for a record of the meeting to be taken and distributed to all concerned.

Instructions given that are supported in the Contract Documents are considered binding on all contracting parties. The attendees shall be:

1. The attendees shall include: the Contracting Officer, the FBOP Project

Representative, the Contractor's Project Manager, the Project Field Superintendent, and major subcontractors and other technical support disciplines as appropriate. Attendees will also include representatives from the correctional institution, as deemed necessary by the Contracting Officer.

2. The meeting itinerary shall include, but not be limited to issues such as:

a. Introductions and coordination of the various parties in attendance.

b. Use of premises and security procedures.

c. Supply and install scheduling and work sequencing.

d. Processing of shop drawings, product data, samples, request for information, contract modifications, and applications for payment.

e. Contract closeout requirements.

B. Supply and install Progress Meetings: The Contracting Officer and the FBOP Project Representative shall co-conduct progress meetings at the project site on a monthly basis, or at intervals as determined by the Contracti.ng Officer.

The attendees shall be:

SUMMARY OF WORK & BUREAU PROCEDURES

Sensitive But Unclassified - s·eu

01 11 00 - 7

February 7, 2025

1. The attendees shall include:

a. FBOP: Contracting Officer, FBOP Project Representative, Institution

Representatives, and technical support disciplines as appropriate.

b. Contractor: Project Manager, Project Field Superintendent, and technical s_upport disciplines as appropriate (Subcontractors, Manufacturers, Suppliers, etc ... ).

2. The meeting itinerary shall include, but not be limited to issues such as:

.a. Progress since previous meeting, and completion date confirmation.

b. Field observations and the supply and install schedule.

c. Corrective measures necessary to maintain the project standards, resolve current_ problems, or head-off anticipated conflicts.

d. The status of: project submittals, request for information, and contract modifications.

1.7 SUPPLY AND INSTALL SUBMITTALS

A. The types of submittal requirements specified in these requirements include shop drawings, product data, samples, certificates of conformance or compliance, certified test or inspection reports, and miscellaneous work-related submittals for supply and install. Individual submittal requirements are specified in applicable Sections for each unit of work. Provide a standard transmittal form with each submittal.

B. The Contractor shall ensure submittals (product data, shop drawings, etc.)

produced by subcontractors, vendors, or other entities are reviewed for adequacy of coordination and meeting the design intent of the supply and install documents prior to the submission to the Government. The Contractor shall stamp and certify that each submittal was reviewed, approved, and coordinated with the requirements of Work and the Contract documents. Failure on the part of the Contractor to indicate review and approval on submittals, ·prior to submission to the FBOP Project Representative, will result in the submittals not being accepted and returned to the Contractor. The FBOP Project Representative shall return the submittals to the General Contractor within approximately fifteen (15) calendar days.

C. Preparation of Submittals: Provide permanent marking on each submittal to identify project, date, Contractor, Subcontractor, submittal name, Specification section number, and similar information to distinguish it from other submittals.

Number resubmittals with original number and an alphabetic suffix.

D. Coordination and Sequencing: Coordinate preparation and processing of submittals with performance of the work so that work will not be delayed by submittals. Coordinate and sequence different categories of submittals for the same Work, and for interfacing units of Work, so that one will not be delayed for coordination of review with another. The Contractor shall promptly notify the

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 8

February 7, 2025

Contracting Officer and the FBOP Project Representative when submittal action is delayed for any reason, citing the cause for delay.

1.8 SUPPLY AND INSTALL CONTRACT MANAGEMENT REQUIREMENTS

(Supply and install Scheduling, Schedule of Values, Pay Applications, Contract Modifications)

A. Supply and install Scheduling: The Contractor shall provide a detailed Supply and install Schedule with activity entries for each portion of the supply and install work, in chronological order, cumulatively indicating the entire Contract Performance Period. The Supply and install Schedule shall include the initial detailed supply and in.stall schedule, and all subsequent supply and install schedule updates and revisions, as required over the life of the contract.

1. The entire contract performance period as established by the Contract shall establish a Final Contract Completion Date and shall be utilized in the planning and presentation of the Contractor's Supply and install Schedule.

As the Supply and install Schedule is being developed, the Contractor may project an earlier completion date. The government may elect to accept a schedule that projects an earlier completion date; however, this acceptance shall not modify the Final Contract Completion Date. The time difference between the Contractor's projected completion date and the Final Contract Completion Date shall be owned and for the mutual use of both the Contractor and the Government. The Government reserves the right not to accept any schedule it determines to be unrealistic in length.

2. The purpose of the Supply and install Schedule shall be to:

a. Assure adequate planning, staffing, scheduling and reporting during execution of the work by the Contractor.

b. Assure coordination of the work among the Contractor, subcontractors, manufacturers and suppliers.

c. Assist the Contractor and Contracting Offi~er in monitoring the progress of the work and evaluating proposed changes to the Contract and the Supply and install Schedule.

d. Assist the Contracting Officer and the Contractor in the preparation and evaluation of the Contractor's monthly progress payments.

3. The Supply and install Schedule shall be updated on a monthly basis throughout the entire Contract time and until Project Completion. The Contractor and the Contracting Officer shall review the actual progress made during each Supply and install Progress Meeting. The Contractor shall inform the Contracting Officer of any current or anticipated conditions which may delay the work, and provide any additional written information necessary to support these conditions. The Contractor shall update the Supply and install Schedule to reflect the actual progress of the· project, as of the date directed by the Contracting Officer. If it appears the Supply and install Schedule no longer represents the actual prosecution and progress of the work, the Contracting Officer will direct the Contractor to revise the Supply and install Schedule. .

SUMMARY OF WORK & BUREAU PROCEDURES

01 • 11 00 - 9.

February 7, 2025

4. The Supply and install Schedule shall:

a. Show the sequence of supply and install by activity, with dates for beginning and completion of each element of supply and install.

b. Identify each item by specification section number.

c. Show accumulated percentage of completion for each item.

d. Coordinate with the Schedule of Values (See Item B, below).

e. Provide sub-schedules to define critical portions of the entire Supply and install Schedule.

f. Include a narrative report to discuss issues of importance, such as, but not limited to: anticipated delays, contract modifications, revisions, etc.

B. Schedule of Value: The Contractor shall prepare a Schedule of Value (SOV) for the total project. The SOV shall be correlated to the Supply and install Schedule. The SOV shall be formatted per the CSI Master Format structure.

The Contractor may propose an alternate organizational format to the Contracting Officer for approval.

1. The Schedule of Values shall include:

a. Project name, location, and contract number.

b. Contractor's name and address.

c. Date of submittal.

2. The SOV shall be arranged in a tabular form with separate columns to indicate the following for each item listed:

a. Generic name.

b. Related specification section, if ~pplicable.

c. Name of subcontractor, if applicable.

d. Name of manufacturer or fabricator, if applicable

e. Name of supplier, if applicable.

f. Change orders (modifications) that have affected value, if applicable.

g. Dollar value.

h. Percentage of Contract sum rounded to the nearest percent, adjusted to total 100 percent.

3. The SOV breakdown shall breakdown the Contract sum in sufficient detail to facilitate continued evaluation of applications of payment and progress reports. Break principal subcontract amounts down into several line items.

4. SOV amounts shall be rounded to the nearest whole dollar. The total of all SOV amounts shall equal the Contract sum.

C. Contractor Applications for Payments: The Contracting Officer shall provide the Contractor with his/her requirements for submitting applications for payment.

The application for payment may include, but is not limited to: lien waivers for work paid to date, receipts or vouchers for payment of labor, budget cost report, listing of stored materials, and any other supporting data requested by the Contracting Officer.

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 10

February 7, 2025

1. Initial Application for Payment: Actions and submittals that must precede or coincide with submittal of the first application for payment include the following:

a. List of subcontractors.

b. List of principal suppliers and fabricators.

c. Schedule of Values.

d. Contractor's supply and install schedule.

e. Submittal schedule.

2. Final Payment Application: Actions and submittals that must precede or coincide with submittal of the final application for payment include the following:

a. Completion of project closeout requirements.

b. Completion of items specified for completion after substantial completion.

c. Transmittal of Record Documents and other required project supply and install records to Government.

d. Proof that taxes, fees and similar obligations have been paid.

e. Removal of temporary facilities and services.

f. Removal of surplus materials, rubbish, and similar elements.

g. Release of claims.

D. Request for Information (RFI): If a question, information, or clarification regarding any part of the Contract or FBOP Requirements is needed, the Contractor will submit a Request for Information (RFI) to the Contracting Officer in accordance with the following RFI submission process:

1. The Contractor shall submit a written, signed and dated RFI to the

Contracting Officer.

2. Each RFI shall be numbered sequentially using a unique series of numbers for document control purposes.

3. The Contractor shall allow a reasonable amount of time from the date of receipt, for the Contracting Officer's review and written reply to the RFI.

E. Contract Modifications (Change Orders): When changes are made in the work that requires an equitable adjustment to the Contract, the Contractor shall submit to the Contracting Officer a written proposal for adjustment of the amount of increase or decrease. Each Contract Modification Proposal (Change Order) shall be numbered sequentially using a unique series of numbers for document control purposes. With the proposal, the Contractor shall submit an itemized breakdown in at least the following detail:

1. Material quantities and item cost.

2. Labor costs by material item.

3. Supply and install equipment cost.

4. Workmen's compensation and public liability insurance.

5. Overhead.

6. Profit or commission.

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 11

FC/ Oxford, B&F Project #24Z4AW6 24 Replace Dishwasher Asset#DW002OXF

February 7, 2025

7. Employment taxes (FICA and FUTA); no overhead, profit or commission will be allowed on employment taxes.

8. Request for time extensions (calendar days) if applicable.

If the Contracting Officer determines that an equitable adjustment in time and dollars is to be made, the contract shall be modified in writing using the prescribed Standard Form provided by the Contracting Officer.

1.9 TEMPORARY SUPPLY AND INSTALL FACILITIES AND CONTROLS

A. The Contractor shall provide the following temporary provisions for the duration of the contract.

1. Temporary heating and ventilating as necessary to protect materials, products, and finishes from damage due to temperature or humidity, and to maintain specified conditions during supply and install. •

2. Temporary barriers, barricades, and similar devices as necessary for safety and protection of supply and install personnel and public.

3. Temporary utilities, as necessary to complete the contract:

a. Water Service: Water from the FBOP institution's existing water system is available for use without metering and without payment of use charges. The Contractor shall provide connections and extensions of services as required for supply and install operations, and. protect the temporary service from freezing. The Contractor shall exercise measures to conserve water, and regulate the temporary system to prevent interference with the Institution's normal usage.

b. Electric Power Service: Electric power from the FBOP institution's existing system is available for use without metering and without payment of use charges. The Contractor shall provide connections and extensions of services as required for supply and install operations.

The Contractor shall exercise measures to conserve electricity, and regulate the temporary system to prevent interference with the Institution's normal usage.

4. Temporary dust and sediment controls. These include keeping drives and walks adjacent to the work site clean and free of dirt, debris and litter caused by supply and install operations.

1.10 SAFETY AND HEALTH

A. The Contractor is responsible for safety and health on the project. In performing the work under this contract the Contractor shall:

1. Conform to the specific ·safety requirements established by this contract;

2. Comply with the safety rules of the FBOP institution that concern related activities not directly addressed in this contract;

3. Take all reasonable steps and precautions to prevent accidents and preserve the life and health of Contractor and Government personnel

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 12

February 7, 2025 performing or in any way coming in contact with the performance of this contract;

4. Take such additional immediate precautions as the Contracting Officer may reasonably require for safety and accident prevention purposes.

1.11 SUPPLY AND INSTALL CLEANING

A. The Contractor shall execute continual cleaning to keep building, site and adjacent properties free from accumulations of waste materials, litter, debris, rubbish, windblown debris and foreign substances resulting from supply and install operations. The entire work area must be kept free from all debris. The soils must be free of nails, wires, re-bar and other supply and install materials.

During and after the supply and install process there must be no burying of any supply and install debris.

B. Remove waste materials, debris, and rubbish from premises and dispose off site in a lawful manner. Do not dispose of volatile waste such as mineral spirits, oil, paint thinner in storm or sanitary drains. Do not dispose of wastes into streams or waterways.

C. If a dispute arises between the Contractor and the Government as to the responsibility under this Contract for maintaining the premises and surrounding area free from waste materials, litter and so on; the Government may clean up;

and the Contracting Officer will allocate the cost to the Contractor via modification to the Contract.

1.12 SUBMITTALS FOR SUBSTITUTION

A. General Requirements: Unless otherwise specifically provided in this contract, reference to any equipment, material, article, or patented process, by trade name, make, or catalog number, shall be regarded as establishing a standard· of quality and shall not be construed as limiting competition. Subject to compliance with specified requirements, the Contractor may, at its option,· use any equipment, material, article, or process, which in the judgment of the Contracting Officer is equal to that named.

B. Request for Substitutions_ prior to execution of the Contract: Requests for substitutions during the solicitation period shall be made by submitting completed substitution request a minimum of twenty (20) calendar days prior to the proposal/bid due date.

1. Submit four (4) copies, fully identified for product or method being proposed for substitution, including related Specification Section and drawing number(s), and fully documented to show compliance with requirements for substitutions. Include project data/drawings, descriptions of methods, SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 13

FCI Oxford, B&F Project #24Z4AW6 24 Replace Dishwasher Assef#.DW002OXF

February 7, 2025 samples where applicable, detailed comparison of significant qualities between specified item and proposed substitution, statement of effect on supply and install time and coordination with other affected cost information or proposal, and statement to the effect that proposed substitution will result in overall work equal to or better than work originally indicated.

2. Document each request with supporting data substantiating compliance of proposed substitution with contract documents, including:

a. Manufacturer's name and address, product, trade name, mode, or catalog number, performance and test data, and reference standards.

b. Itemized point-by-point comparison of proposed substitution with specific product, listing variations in quality, performance, and other pertinent characteristics.

c. Changes required in other.Work.

d. Availability of maintenance service and source of replacement parts, as applicable.

e. Certified test data to show compliance with performance characteristics specified.

f. Samples, when applicable or requested.

g. Other information as necessary to assist in Contracting Officer's evaluation.

3. Properly submitted substitutions that are acceptable to the Contracting

Officer will be included in Contract Documents by amendment.

4. Substitutions will not be considered for acceptance when:

a. They are indicated or implied on shop drawings or product data submittals without a formal request for Contractor.

b. Acceptance will require substantial revision of contract documents.

c. Submittal for substitution request does not include point-by-point comparison of proposed substitution with specified product.

d. In judgment of Contracting Officer, submittal does not include adequate information necessary for a complete evaluation.

e. • If requested directly by a subcontractor or supplier.

5. Substitute products shall not be ordered or installed without written acceptance of Contracting Officer.

6. Contracting Officer will determine acceptability of proposed substitutions.

7. No substitutions are permitted after execution of the Contract, except as allowed by Change Order.

1.13 QUALITY ASSURANCE

A. Source Limitations: To the greatest extent possible for each unit of Work, and subject to the restrictions of the Buy American Act, provide products, materials, or equipment of a singular generic kind from a single source.

B. Compatibility of Options: Where more than one choice is available an options for Contractor's selection of a product or material, select an option that is

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 14

February 7, 2025 compatible with other products and materials already selected. Total compatibility among options is not assured by limitations within contract documents, but must be provided by Contractor. Compatibility is a basic general requirement of product/material selections.

1.14 PRODUCT DELIVERY/STORAGE/HANDLING

A. General: Deliver, handle, and store products in accordance with manufacturer's recommendations and by methods and means that will prevent damage, deterioration, and loss, including theft, and protect against damage from climatic conditions. Control delivery schedules to minimize long-term storage of products at site and overcrowding of supply and install spaces. In particular, provide delivery/installation coordination to ensure minimum holding or storage times for products recognized to be flammable, hazardous, easily damaged, or sensitive to deterioration, theft, and other sources of loss. Damaged or defective items, in the opinion of the Project Representative, shall be replaced at no cost to the Government.

1.15 WARRANTIES (GUARANTEES)

A. General:· The warranty and guarantee provisions of the Contract Clauses apply to all Work of the contract. In accordance with FAR 52.246.21 Warranty of Supply and install, and in addition to any other warranties in this contract, the Contractor warrants that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or workmanship performed by the contractor or any subcontractor or supplier at any tier. The warranty shall continue for a period of one (1) year from the date of Project Substantial Completion.

B. Refer to individual specification sections for the determination of units of Work that are required to be specifically or individually warranted, and for the specific requirements and terms of those warranties (or guarantees) in excess of what is required by the Contract Clauses.

1. Submit Special Project Warranty (Guarantee): A warranty specifically written and signed by Contractor for a defined portion of the Work and, where required, countersigned by subcontractor, installer, manufacturer, or other entity engaged by Contractor.

2. Specified Project Warranty: A warranty that is required by contract documents to be provided for a manufactured product incorporated into the Work, regardless of whether manufacturer has published a similar warranty

• without regard for specific incorporation of product into the Work, or has written and executed a special project warranty as a direct result of contract document requirements.

3. Coincidental Product Warranty: A warranty that is not specifically required by contract documents (other than as specified in these Requirements), but that is available on a product incorporated into the Work, by virtue of the

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 15

February 7, 2025 fact that manufacturer of product has published warranty in connection with purchases and uses of product without regard for specific applications except as otherwise limited by terms of warranty.

1.16 PROJECT CLOSEOUT

A. Substantial Completion: When the Contractor considers the work substantially complete, submit the following to the Contracting Officer:

1. A written notice that work, or designated portion thereof, is substantially complete, and request an inspection by the FBOP Project Representative and the Contracting Officer.

2. A punch list of remaining incomplete/non-compliant items shall accompany this written notice. Prior to the Contractor requesting substantial completion, the Contractor shall develop a punch list of incomplete and non compliant items.

3. Within a reasonable time after receipt of such notice, the Contracting Officer and FBOP Project Representative shall make an inspection to determine the status of substantial completion.

4. If· the Contracting Officer determines that the work is not substantially complete:

a. . The Contracting Officer will promptly notify the Contractor in writing, giving reasons therefore.

b. The Contractor shall remedy deficiencies in the work and send a second written notice of substantial completion to the Contracting Officer.

c. The Contracting Officer and FBOP Project Representative will re inspect the work.

d. The Contractor shall be responsible for any additional inspections by the Government that are not fault of the Government.

5. When the Contracting Officer determines that the work is substantially complete, the Contracting Officer will:

a. Request the FBOP Project Representative verify the Contractor's punch list. The Contractor's punch list may be amended by the FBOP Project Representative with any open issues and any remaining items from the incomplete/non-compliant list.

b. Request the Contractor to prepare a Certificate of Substantial Completion on a form approved by the Contracting Officer, accompanied by the punch list. This form will be used to record the established start dates for warranties and guaranties. This document provides for agreement as to the time allowed for completion or correction of work remaining, the date upon which the FBOP institution will assume possession of the work. If issued after the contract completion date, the certificate establishes the date upon which liquidated damages cease.

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 16

February 7, 2025

B. Final Inspection and Acceptance: The Contractor shall diligently complete all punch list items before a Final Inspection is scheduled.

1. When the Contractor considers the work complete, he/she shall submit a written certification to the Contracting Officer stating the Work has been completed and inspected for compliance with the Contract Documents; and the Work is ready for final inspection. The Contractor shall give the Contracting Officer a minimum of ten (10) work days advanced written notice of the date on which the work will be fully completed and ready for the Government's final inspection.

2. The Contracting Officer and the FBOP Project Representative shall make an inspection to verify the status of completion with reasonable promptness· after receipt of such certification.

3. Should the Contracting Officer consider that the work is incomplete or defective;

a. The Contracting Officer will promptly notify the Contractor in writing, listing the incomplete or defective work.

b. The Contractor shall take immediate steps to remedy the stated deficiencies and send a second written certification to the Contracting Officer when the work is complete.

c. The Contracting Officer and the FBOP Project Representative will re inspect the work.

d. The Contractor shall be responsible for any additional inspections by the Government that are not fault of the Government.

e. The Contracting Officer will assign monetary value to all punch list items not completed, and to all required submittals not received, as of the date of Final Acceptance. The total value of those items shall be retained and/or deducted from the Contractor's final payment until the Contractor demonstrates to the Contracting Officer's satisfaction that such items have been completed or corrected.

4. When the Contracting Officer finds that work is acceptable under the Contract Documents, the Contracting Officer will request the Contractor to complete all remaining closeout submittals and contract requirements, including but not limited to: GSA Form 1142- Release of Claims, operating and maintenance manuals, record documents, warranties, guarantees, certificates, clearances, and bonds.

5. When all work is acceptable, the Contracting Officer will issue a Certificate _of Contract Completion, GSA Form 218, or other approved form to the Contractor for signature.

C. Final Application for Payment: After the work is fully accepted by the Contracting Officer, the Contractor shall submit the final application for payment in accordance with procedures and requirements stated in the Contract requirements. As required by the Contracting Officer, ·the final application for payment shall include affidavits that all bills have been paid. The Contractor's

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 17

February 7, 2025 submission of the final application for payment shall signify that the work is complete, and that the Contractor has vacated the Project work site.

END OF SECTION

SUMMARY OF WORK & BUREAU PROCEDURES

01 11 00 - 18