24_052 Addendum1.pdf

F I N A N C E P.O. BOX 447 ALBANY, GA 31702 | PHONE: 229.431.3211 | FAX: 229.431.2184 | www.albanyga.gov

04/15/2024

TO: All Potential Bidders

SUBJECT: Rental Unit Renovation

Bid Ref. #24-052

Bid Opening Date & Time: April 30, 2024 at 2:30 p.m.

ADDENDUM NO. 1

The items contained in this addendum are added to and/or deleted from and become part of the specifications and proposal documents for the above-referenced Invitation to Bid. Bidders must acknowledge receipt of the Addendum on the Bid Form, located in the invitation to bid, when the bids are submitted.

Add: Special instructions (included) for bid reference #24-052.

End of Addendum 1

Takeshia Martin Takeshia Martin, Buyer

Cc: Curtis Dixon, DCED

ADD/DELETE:

http://www.albanyga.gov/

SPECIAL INSTRUCTIONS

Rental Unit Renovation

BID REF. #24-052

1. General Information: The project consists of all work required to renovate Apartment #17 at 215 Broadway in accordance with the specifications, terms and conditions contained within the bid documents.

2. Contractor's bid shall include all necessary labor, materials, tools, equipment, and all other items necessary to complete the contract requirements in accordance with specifications, general conditions, special instructions to bidders and all other provisions included in this invitation to bid.

3. Bidder shall be responsible to visit the job site and familiarize himself with the local conditions.

4. No bid may be withdrawn for a period of sixty (60) days from the bid opening date.

5. The Owner reserves the right to reject any and all bids and to waive any informalities in the bidding process.

6. The Owner of this project is the City of Albany.

7. Contract Time: Contract (base bid) must be completed within thirty (30) calendar days following the issuance of the Notice to Proceed. Performance will be monitored and documented by the Project Manager. Not completing this contract within the time specified may hamper the contractor’s ability to secure future contracts with the City.

8. Liquidated Damages: Time is an essential element of the Contract, and any delay in the prosecution of The Work may inconvenience the public, obstruct traffic, or interfere with business.

In addition to the aforementioned inconveniences, any delay in completion of The Work will always increase the cost of engineering. For this reason, it is important that the work be pressed vigorously to completion. Should the Contractor fail to complete the work within the time stipulated in the Contract or within such extra time that may be allowed, charges shall be assessed against any money due or that may become due the Contractor in accordance with the rate of one hundred dollars ($100) per calendar day.

9. Bid Form: Bid form must be submitted on the bid form provided by the City of Albany. Bid is for a lump sum contract and will be awarded to the responsive and responsible bidder submitting the lowest total base bid and selected options and alternates.

10. General Insurance Requirements: Contractor shall maintain insurance with companies licensed to do business in the State of Georgia acceptable to the City for the protection of the City and name it as an additional insured, against all claims, losses, costs or expenses arising out of injuries or death of persons whether or not employed by contractor, whether arising from the acts or omission, negligence or otherwise of contractor or any of its agents, employees, patrons, or other persons, and growing out of work being done by Contractor on behalf of City, such policies to provide for a liability limit on account of each accident resulting in the bodily injury or death of not less than One Million ($1,000,000) Dollars, a liability limit of not less than One Million ($1,000,000) Dollars for each accident for property damage. Contractor shall also carry product/completed operations liability insurance for personal injuries and/or death in the amount not less than five hundred thousand ($500,000) dollars for any one person. Contractor shall maintain a combined single liability limit of five hundred thousand ($500,000) dollars covering owned, non-owned, leased, and hired vehicles. Contractor shall furnish to the City satisfactory evidence that it carries Worker’s Compensation Insurance in the statutory limits of Georgia and Employers’ Liability with limits of liability of no less than One Hundred Thousand ($100,000) Dollars of each accident/disease. These polices must also contain a waiver of subrogation in favor of the City of Albany. Contractor shall furnish evidence to the City of the continuance in force of said policy’s declaration page (s) to the Procurement Agent. Acceptable proofs of insurance: (i) a Certificate of Insurance with Additional Insured Endorsement (a Certificate of Insurance by itself is not acceptable) or (ii) Declaration Pages of the insurance policies listed below which show the City of Albany as additional insured. All insurance policies must provide that the City of Albany will be notified within 30 days of any changes, restrictions, and/or cancellation. The City’s sole judgment shall control as to the sufficiency of the coverage.

11. Indemnity Agreement: An executed copy of this form should accompany your bid and must be completed for contract award. (See attached).

12. Governing Law & Venue: An executed copy of this form should accompany your bid. (See attached).

13. Certificate of Non-Collusion: An executed copy of this form should accompany your bid. (See

14. Drug Free Workplace: An executed copy of this form should accompany your bid. (See

15. Debarred Bidders Integrity Form: An executed copy of this form should accompany your bid.

(See attached).

16. Permits & Fees: Within five (5) days following the issuance of the Notice to Proceed, the contractor shall apply for all permits. Failure to do so may result in award of this contract to the next lowest bidder and the original contractor may be billed for the difference in price. The contractor shall secure all permits, license certificates, inspections (permanent and temporary) and occupational tax certificate(s) before any work can commence. This documentation should be on file in the Procurement Office prior to the start of any work associated with this contract. The contractor is required to contact the Project Manager, Curtis Dixon at 229-483-7650 within five (5) days of completion for a final inspection. Contractor as well as any and all known subcontractors must possess or will be required to obtain a City of Albany Occupational Tax Certificate or Registration prior to commencement of work.

17. Compliance: The contractor is responsible for knowledge of and compliance with all laws, codes, ordinances, and regulations that are applicable to this type of work.

18. Superintendent: The contractor shall have a superintendent or representative on the site at all times while work is being performed. He will represent the contractor and all communications given to him shall be binding as if given to the contractor.

19. Preservation of Property: The contractor shall carry out his work with such care and by the proper methods to prevent damage to the property adjacent to the work or within streets, easement locations to the extent the owner may have rights therein, or other property of the owners or of others, whether adjacent to the work site or not, the removal, relocation, or destruction of which is not called for by the provisions of the contract documents; it being a condition of the execution of the contract that the work be performed in such manner that the property of others and other property of the owner shall not be damaged in any way. The word PROPERTY, as used, is intended to include among other types of property, public street improvements, storm and sanitary sewers, water lines and appurtenances, or other structures.

Should any property be damaged or destroyed, the contractor at his own expense shall promptly, or within reasonable time, repair or make such restoration as is practical and acceptable to the owner of the damaged or destroyed property. In case of failure on the part of the contractor to repair or restore such property, or make good such damage or injury, the Building Inspector may within forty-eight (48) hours notice, proceed to repair, rebuild, or otherwise restore such property as may be necessary, and the cost thereof will be deducted from any monies due or which may become due the contractor under this contract agreement. The contractor shall, at all times in performance of the work, employ approved methods and exercise reasonable care and skill so as to avoid delay, damage, injury or destruction of existing public service installations and structures;

and shall at all times in the performance of the work avoid interference with, or interruption of, public utilities services, and shall cooperate fully with the owners thereof to the end.

20. Public Convenience and Safety: Fire hydrants on or adjacent to the street shall be kept accessible to the fire apparatus at all times and no material or obstructions shall be placed within ten (10) feet of any hydrant. Adjacent premises must be given access at all times and gutters shall not be obstructed. Materials shall not be stored along the streets. Traffic on streets shall be maintained at all times. Dust and debris shall not create a hazard or a nuisance.

21. Barricades and Warnings: The contractor shall provide erect and maintain all necessary barricades, suitable and sufficient number of watchmen to direct traffic, and take all necessary precautions for the protection of the work and safety of the public. Barricades and obstructions shall be illuminated at night and lights shall be kept burning from sunset to sunrise.

22. Removal of Trash and Rubbish: The contractor shall be responsible for the removal and legal disposal of all waste, trash, and rubbish resulting from the work under this contract. Work site shall be kept clean and orderly during construction; trash shall be removed from the site or adequately containerized daily.

23. Termination for Convenience: This contract may be terminated in whole or in part by the City of Albany with the consent of the contractor in which case the two parties shall agree upon the termination conditions, including the effective date in the case of partial termination, the portion to be terminated or by the contractor upon written notification to the City of Albany setting forth the reasons for such termination, the effective date, and in the case of partial termination, the portion to be terminated. However, if in the case of partial termination, the City of Albany determines that the remaining portion of the award will not accomplish the purposes for which the contract was awarded, the City of Albany may terminate the contract in its entirety.

24. Termination of Contract for Cause: In the event that the contractor shall for any reason or through any cause be in default of the terms, conditions, or obligations of the contract documents, the City may give the contractor written notice of such default and terminate the contract. All terms, conditions, and obligations of the contract documents are considered material. The City may, in its discretion, provide the contractor an opportunity to cure the default, if curable, prior to termination. Unless a different duration is provided in the notice of default, the contractor shall have fourteen (14) calendar days to cure the default from the date such notice is mailed to the contractor, unless notification is by facsimile or personal delivery, in which case the opportunity to cure shall commence upon delivery of the notice. Upon failure of the contractor to cure the default the City may immediately terminate the contract effective as of the mailing or delivery of the default notice. If the City terminates the contract, the contractor shall remain liable for performance of all terms, conditions, and obligation through the date of termination. Termination by the City shall not constitute a waiver by the City of any other rights or remedies available to the City by law or contract.

25. Certification of Bidder’s Experience and Qualifications: The undersigned bidder certifies that he is, at the time of bidding, and shall be, throughout the period of the contract, licensed by the State of Georgia to do the type of work required under terms of the contract documents. Bidder further certifies that he is skilled and regularly engaged in the general class and type of work called for in the contract documents. The bidder represents that he is competent, knowledgeable and has special skills on the nature, extent, and inherent conditions of the work to be performed. Bidder further acknowledges that there are certain peculiar and inherent conditions existent in the construction of the particular facilities, which may create, during the construction program, unusual or peculiar unsafe conditions hazardous to persons and property. Bidder expressly acknowledges that he has the skill and experience to foresee and to adopt protective measures to adequately and safely perform the construction work with respect to such hazards.

26. Corporations: All Corporations should provide corporate seal, a copy of the Secretary of State’s

Certificate of Incorporation, and a listing of the principals of the corporation with the bid.

27. Pre-Construction Conference: Successful bidder will be required to attend a Pre-Construction Conference with the owner’s representative to discuss any details of the project, submit a proposed work program/schedule prior to the issuance of a Notice to Proceed. When work begins, contractor shall remain on this project, with normal work force, until the project is completed.

28. Georgia Security and Immigration Compliance Act: The successful contractor will provide certification that he is in compliance with the Georgia Security and Immigration Compliance Act, certifying that the provisions of GA Law, O.C.G.A 13-10-91, Chapter 300-10-1, per the Georgia Department of Labor, if applicable, have been complied with in full. Pursuant to O.C.G.A 13-10- 90(2), all subcontractors entering into a contract or agreement for hire on this Project must be registered and participate in the Federal Work Authorization Program. Complete and submit a copy of the form, applicable to your company, and applicable Subcontractor Affidavits, with your bid.

29. Contractor’s Warranty: Contractor shall guarantee all specified work performed for a period of one (1) year from the date of written acceptance of the work by the Owner’s designated representative that all materials, labor, and workmanship provided under this contract are free from defects of any kind. At no expense to the City of Albany, the contractor shall make repairs to any defects found and reported during the warranty period. Final inspection, final acceptance, and final payment shall not be construed as a waiver of this warranty. The following are excluded from this warranty:

a. Defects or failures resulting from abuse by the owner.

b. Damage caused by fire, tornadoes, hail, hurricane, Acts of God, wars, riots, civil commotion, or vandalism.

30. Bid Submittals (All items listed below must be submitted with bid):

a. Bid Form

b. Bid Bond

c. DBE Subcontractor Participation Form

d. Addendum Acknowledgement Form

The following items should be submitted with bid:

a. Indemnity Agreement

b. Governing Law and Venue Form

c. Certificate of Non-Collusion Form

d. Drug Free Workplace

e. Debarred Bidders Integrity Form

f. Corporate Seal

g. Secretary of State’s Certificate of Incorporation

h. Listing of the principals of Corporation

i. Affidavit to Comply with OCGA § 13-10-91

31. For additional information, contact Takeshia Martin, Buyer I, at (229) 431-3211. Submit all questions via email to tmartin@albanyga.gov cc: jswilliams@albanyga.gov and kross@albanyga.gov. The deadline for questions is April 30 at 2:30 pm. Replies of substance will be answered in the form of an addendum and made available to all potential bidders.