2.03b Attachment II - Solicitation N0018926QL178.pdf

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

Created On:

23 Jun 2026, 13:03 PM Greenwich Mean Time

Solicitation/Contract Form Continuation

NCDOC Switchgear Removal/ Modernization and Diesel Fuel Tank Installation

N0018926QL178

Continuation of Supplies or Services and Prices/Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

Switchgear Controls Modernization (Retrofit), provided IAW the SOW provided herein.

Period of Performance: Completion within 180 days from contract award.

Pricing Arrangement: Firm Fixed Price

1 Job

Fuel Tank Installation IAW the SOW included herein.

Period of Performance: Completion within 180 days from contract award.

Pricing Arrangement: Firm Fixed Price

1 Job

Continuation of Description

STATEMENT OF WORK

1. Period of Performance:

The period of performance is completion within 180 days from contract award date.

Place of Performance:2.

DoD Suffolk Compound, NCDOC, 112 Lakeview Parkway, Suffolk, VA., 23435

3. Background:

Contract N0018926PL068, which was awarded to Carter Machinery Company, Inc., covers the preventative maintenance and warranty coverage for existing Caterpillar generators, ZAF00120 and CMJ01586, that service NCDOC Suffolk. The current switchgear controls on ZAF00120 and CMJ01586 are at end of life and require a modernized switchgear to prevent failure. To support the aforementioned generators, installation and supply of a 10,000-gallon diesel fuel tank which will supply the existing Caterpillar generators is required. Currently, NCDOC maintains one 9000-gallon diesel fuel tank which can supply the generators for an estimated 7 days in an emergency. However, due to current NCDOC mission security parameters and incoming Artificial Intelligence server demands, an additional tank is required to support these surging operations in the event of an extended electrical grid power failure.

4. Scope NCDOC requires the supply and service of the below two integrated items:

1.) Generator Switchgear Control retrofit:

a.) Develop Project Plan b.) Coordinate work dates with NCDOC and establish Plan of Action and Milestone c.) Remove the existing Modicon Momentum processors (PLC's), Lynxblock transducers, Touchscreen Processor (TSP), and Touchscreen.

Those components will be replaced with Schneider Electric Ethernet PLC processors running Control Expert software, PowerPlex II transducers, Windows OS HMI Touchscreen Processor programmed with FactoryTalk graphics software and a Kepware software interface with the PLC network. This system will be internally networked together via an ethernet communications network which will replace the existing ModBus + network.

d.) Remove existing system four (4) x circuit breakers (52F1, 52F2, 52F3, 52F8) that are racked out and not in use. Those breakers will be removed from the switchgear and their corresponding door will be replaced with solid a door.

e.) Prepare and provide complete As-Built drawing package (in "E" size printed, as well as in AutoCAD electronic format) to include Breaker & Lug Schedules, Complete new Front Elevation & Single-Line Diagram, Equipment Dimensions, Network Diagram, Breaker Control One-Line Schematics, Control Conduit Detail, Sequence of Operations, Bill of Material, and Main Component Data Sheets.

f.) Remove and replace existing (1) x 850 Utility Protective Relay. To include programming and testing.

g.)Provide onsite ready spare parts to include two (2) x Schneider Electric Ethernet PLC processors, a PowerPlex II transducer, Widescreen Touchscreen and a managed ethernet switch.

h.) Perform System Operational Verification Testing (SOVT) on operational system i.) Provide on site training for NCDOC Facilities personnel in regards to the operation of newly installed components j.) Provide recommendation for Preventative Maintenance schedule on newly installed components

2.) Installation and interface of 10,000 Gallon ancillary fuel tank:

a.) Develop Project Plan b.) Coordinate work dates with NCDOC and establish Plan of Action and Milestone c.) Coordinate with NCDOC, Colliers (Building Owner's Maintenance Firm), and Utility locating services to locate and further ensure that no utilities are present in the proposed fuel tank laydown area d.) Site grading as required for placement of fuel tank concrete mounting pad e.) Install fuel tank concrete mounting pad f.) Provide crane service required to lift fuel tank onto mounting pad g.) Install fuel polishing system and associated power h.) Install ground level filling connection(s) i.) Install fuel transfer system(s) operated automatically by fuel level sensors in the base tanks of the two generators, including fuel supply and return pumps that will fill the tanks as required as well as return fuel to the AST in the event the base tanks fuel quantity rises above a safe level (fuel thresholds TBD during the project engineering phase) j.) Power for the fuel transfer pumps k.) Pull all required city, county or state permits as required

Technical Point of Contact: 5.

NCDOC N4/N8 Department Head, GG14 Tim Bilbrey, timothy.l.bilbrey2.civ@us.navy.mil, 757.203.0666.

DELIVERABLES

- Contractor will provide all parts and materials necessary to provide new Switchgear Control Modernization

Contractor will provide all parts and materials necessary to provide new 10,000 gallon auxiliary fuel tank-

Test/operate newly installed Switchgear Control System-

- Test/operate newly installed 10,000 gallon fuel tank and associated fuel transfer system

Provide training on newly installed systems to NCDOC N/8 Departmental personnel-

Provide drawings of newly installed systems to NCDOC N/8 Departmental personnel-

N0018926QL178

mailto:timothy.l.bilbrey2.civ@us.navy.mil

NCDOC has responsibility for Government Inspection and will provide final acceptance. The inspection shall be performed at the place -of performance by the NCDOC appointed representative(s)

Requirements NCDOC Switchgear Removal / Modernization and Diesel Fuel Tank Installation

Continuation of Packaging and Marking

Continuation of Inspection and Acceptance

Overall Contract Inspection/Acceptance Locations

Inspection and Acceptance Location

Both Destination Instructions: Acceptance and Inspection will be conducted in accordance with contract terms and conditions.

DoDAAC: N3029A CountryCode: USA

NAVY CYBER DEFENSE OPS COMMAND

112 LAKEVIEW PARKWAY, SUFFOLK VA 23435

SUFFOLK, VA 23435

UNITED STATES

Tim Bilbrey, Navy Cyber Defense Operations Command N4/N8 Department Head Email: timothy.l.bilbrey2.civ@us.navy.mil Telephone: 757.203.0666

Inspection and Acceptance Location

Both Destination Instructions: Acceptance and Inspection will be conducted in accordance with contract terms and conditions.

DoDAAC: N3029A CountryCode: USA

NAVY CYBER DEFENSE OPS COMMAND

112 LAKEVIEW PARKWAY, SUFFOLK VA 23435

SUFFOLK, VA 23435

UNITED STATES

Tim Bilbrey, N4/N8 Department Head Email: timothy.l.bilbrey2.civ@us.navy.mil Telephone: 757.203.0666

Continuation of Deliveries or Performance

Overall Contract Delivery Period

Contractor Destination

Line Item Delivery Schedule Quantity Address and POC

Period of Performance From 06 Jul 2026 To 02 Jan 2027

1 Job Place of Performance DoDAAC: N36001 CountryCode: USA

NAVIFOR

115 LAKE VIEW PARKWAY, SUFFOLK VA 23435

SUFFOLK, VA 23435

UNITED STATES

Tim Bilbrey, Navy Cyber Defense Operations Command N4/N8 Department Head Email: timothy.l.bilbrey2.civ@us.navy.mil Telephone: 757.203.0666

Period of Performance From 06 Jul 2026 To 02 Jan 2027

1 Job Place of Performance DoDAAC: N36001 CountryCode: USA

NAVIFOR

115 LAKE VIEW PARKWAY, SUFFOLK VA 23435

SUFFOLK, VA 23435

UNITED STATES

Tim Bilbrey, Navy Cyber Defense Operations Command N4/N8 Department Head Email: timothy.l.bilbrey2.civ@us.navy.mil Telephone: 757.203.0666

Continuation of Accounting and Appropriation Data

Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.204-13 System for Award Management-Maintenance. (Deviation 2026-O0038) Feb 2026 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. Jan 2017 52.219-8 Utilization of Small Business Concerns. (Deviation 2026-O0038) Feb 2026 52.219-16 Liquidated Damages-Subcontracting Plan. (Deviation 2026-O0038) Feb 2026 52.222-35 Equal Opportunity for Veterans. (Deviation 2026-O0038) Feb 2026 52.222-36 Equal Opportunity for Workers with Disabilities. (Deviation 2026-O0038) Feb 2026 52.222-37 Employment Reports on Veterans. (Deviation 2026-O0038) Feb 2026

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (Deviation 2026-O0038)

Feb 2026

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving. May 2024 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Mar 2023 52.233-3 Protest after Award. (Deviation 2026-O0038) Feb 2026 52.233-4 Applicable Law for Breach of Contract Claim. (Deviation 2026-O0038) Feb 2026 52.242-5 Payments to Small Business Subcontractors. Jan 2017 52.203-3 Gratuities. Apr 1984

52.212-4 Terms and Conditions-Commercial Products and Commercial Services. (Deviation 2026- O0038)

Feb 2026

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. (Deviation 2026-O0038)

Feb 2026

52.229-12 Tax on Certain Foreign Procurements. Feb 2021

52.222-44 Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment.

(Deviation 2026-O0038)

Feb 2026

52.222-55 Minimum Wages for Contractor Workers Under Executive Order 14026. (Deviation 2026- O0038)

Feb 2026

52.222-62 Paid Sick Leave Under Executive Order 13706. (Deviation 2026-O0038) Feb 2026 52.222-41 Service Contract Labor Standards. (Deviation 2026-O0038) Feb 2026

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.225-7052 Restriction on the Acquisition of Certain Magnets, Tantalum, and Tungsten. May 2024 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023 252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region. Jun 2023 252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023

252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns.

Jan 2023

252.246-7008 Sources of Electronic Parts. Jan 2023 252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Dec 2022 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. Jan 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2023

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

May 2019

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018 252.232-7010 Levies on Contract Payments. Dec 2006 252.243-7002 Requests for Equitable Adjustment. Dec 2022 252.247-7023 Transportation of Supplies by Sea. Oct 2024

FAR Clauses Incorporated by Full Text

52.219-28 Postaward Small Business Program Rerepresentation. (Deviation 2026-O0038) (Feb 2026)

Postaward Small Business Program Rerepresentation (Feb 2026) (Deviation 2026-O0038)

(a) . As used in this clause-Definitions

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(2) , as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or Affiliates a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was a small business concern, a small disadvantaged business concern, or a joint venture that was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(d) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation(s) required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code assigned to contract number.____ ____

(2) [ .] The Contractor represents that Complete only if the Contractor represented itself as a small business concern in paragraph (g)(1) of this clause it [ ] is, [ ] is not, a small disadvantaged business concern as defined in .13 CFR 124.1001

(3) . The Contractor represents that it [ ] is, [ ] is not a joint Women-owned small business (WOSB) joint venture eligible under the WOSB Program venture that complies with the requirements of 13 CFR 127.506(a) through (c). [ The Contractor shall enter the name and unique entity identifier ____ of each party to the joint venture: __.]

(4) . The Contractor represents that it [ ] is, [ ] is not a joint Economically disadvantaged women-owned small business (EDWOSB) joint venture venture that complies with the requirements of 13 CFR 127.506(a) through (c). [ The Contractor shall enter the name and unique entity identifier ____ of each party to the joint venture: __ .]

(5) . The Contractor represents that it [ ] Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program is, [ ] is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402. [ The ____ Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(6) [ ] The offeror HUBZone joint venture eligible under the HUBZone Program. Complete only if the offeror is a HUBZone small business concern.

represents, as part of its offer, that It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [

The Contractor shall enter the name and unique entity identifier of each party to the joint venture: .] Each HUBZone small business concern ____ participating in the HUBZone joint venture must be certified as a HUBZone concern. [ Contractor to sign and date and insert authorized signer's ____ name and title.]

(End of clause)

52.222-42 Statement of Equivalent Rates for Federal Hires. (May 2014)

Statement of Equivalent Rates for Federal Hires (May 2014)

In compliance with the Service Contract Labor Standards statute and the regulations of the Secretary of Labor ( ), this clause identifies 29 CFR Part 4 the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C.5341 or 5332.

This Statement is for Information Only: It is not a Wage Determination

Occupation Code - Title GS Equivalent Fringe Benefit

23430 - Heavy Equipment Mechanic WG 10 Step 3 ($30.31) 38.6% ($11.46)

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. (Jan 2023)

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)

TO BE FILLED AT TIME OF AWARD

(a) As used in this clause-Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF payment instructions.

WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial financing, submit a commercial financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF Document routing.

when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC ____

Issue By DoDAAC ____

Admin DoDAAC ____

Inspect By DoDAAC ____

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

Additional Regulation or Supplemental Clauses Incorporated by Full Text

204-9400(05-24)

SUPTXT204-9400(05-24) CONTRACTOR UNCLASSIFIED ACCESS TO

FEDERALLY CONTROLLED FACILITIES, SENSITIVE INFORMATION,

INFORMATION TECHNOLOGY (IT) SYSTEMS OR PROTECTED HEALTH (Jan 2024)

INFORMATION

(1) SUPTXT204-9400 (05-24) Prescription and Alternative Language

The following shall be inserted in full text in all solicitations and contracts (including commercial acquisitions) which require contractor unclassified access to federally controlled facilities, sensitive information, Information Technology (IT) systems or protected health information. For commercial acquisitions, this text shall be incorporated into either the SOW or PWS.

* Consult with your CSM and ISSM/IAM for local policy when Authorized User (non-sensitive) access is required for non-U.S. citizens outside the U.

S.

** Alternative language which may be included as appropriate:

Contractor and all Contractor employees with access to or responsibility for XXXXXX of this contract shall comply with DoD Directive 8500.1E IA, DoDI 8510.01 Risk Management Framework (RMF) for DoD IT, DoD Directive 5400.11 DoD Privacy Program, DoD 5200.2-R Personnel Security Program and HSPD 12

X.1 Be CAC ready at the properly designated IT System Level

X.2 At minimum, all contractor employees must possess/maintain the required background investigation as determined by the PDT and/or IT access user level. This requirement is critical in order to access the government data base systems It is the contractor's responsibility to ensure that 100% of the contractor employees have the ability to acquire a favorably adjudicated background investigation. In addition, interim approval of clearances is not authorized.

X.3 Be citizens of the U.S

X.4 If at any time, any contractor employee requiring a Common Access Card (CAC) is unable to possess/maintain the required adjudicated background investigation, the contractor shall immediately notify the NAVSUP COR to coordinate removal of such a person from work under this contract.

X.5 Contractor employees with access to or responsibility for nonpublic government data under this contract must comply with HSPD-12 Personal Identity Verification (PIV) issuance requirements, known as the CAC.

(1) SUPTXT204-9400(4-22) CONTRACTOR UNCLASSIFIED ACCESS TO FEDERALLY CONTROLLED FACILITIES, SENSITIVE

INFORMATION, INFORMATION TECHNOLOGY (IT) SYSTEMS OR PROTECTED HEALTH INFORMATION

The security text does not apply in cases where the contractor/vendor does not have access to Navy Marine Corps Intranet (NMCI) computers, is not issued a Common Access Card (CAC) and is involved in training or other short term duties of less than 30 days duration that allow for the use of a visitor request. In these cases, the government employee must submit a Visitor Access Request (VAR) to the main gate or applicable processing entity for your facility and assume responsibility to escort those without CAC Credentials.

This local text does not apply to non-United States (U.S.) Nationals (foreign nationals) who are contactor employees performing work overseas. This text is applicable to the U.S. Nationals living in the U.S. or overseas who are performing work on a Navy contract.

The investigation of a non-U.S. national at a foreign location must be consistent with a National Agency Check with Written Inquiries (NACI), to the extent possible and include a fingerprint check against the Federal Bureau of Investigation (FBI) criminal history database, an FBI investigations file (name check) search and a name check against the terrorist screening database. Also, the above cited reference notes that Foreign Nationals may not be granted CAC credentials until completion of their investigation and not in the interim.

Per Department of Defense Memorandum (DoDM) 5200.2, Department of Defense (DoD) components must initiate and ensure completion of a background investigation before applying the credentialing standards to a non-U.S. national at a foreign location. The background investigation must be favorably adjudicated before a CAC can be issued to a non-U.S. national at a foreign location. The type of background investigation may vary based on standing reciprocity treaties concerning identity assurance and information exchanges that exist between the U.S. and its allies or agency agreements with the host country.

CONTRACTOR UNCLASSIFIED ACCESS TO FEDERALLY CONTROLLED FACILITIES, SENSITIVE INFORMATION, IT

SYSTEMS OR PROTECTED HEALTH INFORMATION

Executive Order 13467, Reforming Processes Related to Suitability for Government Employee, Fitness for Contractor Employees and Eligibility for Access to Classified National Security Information, Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The 5 CFR 32 Part 157 in concert with DoD Manual 1000.13, Vol 1, implements the Federal Standards.

APPLICABILITY

This text applies to all DoD sponsored individuals who require CAC eligibility (or login and P/W if acceptable per contract) for: Physical access to DoD facilities or non-DoD facilities on behalf of DoD; Logical access to information systems (whether on site or remotely); or remote access to DoD networks that use only the CAC logon for user authentication, or access to sensitive and protected information. This applies to the Office of the Secretary of Defense (OSD), the Military Departments, the Office of the Chairman of the Joint Chiefs of Staff and the Joint Staff, the Combatant Commands, the Office of the Inspector General of the DoD, the Defense Agencies, the DoD Field Activities and all other organizational entities within the DoD (hereinafter referred to collectively as the "DoD Components").

Each contractor employee providing services at a Navy command under this contract is required to obtain a DoD CAC. Additionally, depending on the level of computer/network access, the contract employee will require a successful investigation as detailed below.

ACCESS TO FEDERAL FACILITIES

Definition. As used in this clause - Military installation means a base, camp, post, station, yard, center, or other activity under the jurisdiction of the Secretary of a military department, or, in the case of an activity in a foreign country, under the operational control of the Secretary of a military department or the Secretary of Defense (see 10 U.S.C. 2801(c)(4)).

Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Command's Security Manager (CSM) upon arrival to the command and shall out-process prior to their departure at the completion of the individual's performance under the contract.

Training. Contractor employees who require routine physical access to a Federally controlled facility or military installation shall complete "Level I Antiterrorism Awareness Training" prior to gaining access to a facility and annually thereafter in accordance with DoDI O-2000.16 Vol. 1. In accordance with Department of Defense Instruction O-2000.16 Volume 1, DoD Antiterrorism (AT) Program Implementation: DoD AT Standards, Level I Antiterrorism Awareness Training shall be completed by:

1. Completion of "Level I Antiterrorism Awareness Training" available at https://jkodirect.jten.mil/pdf/atl1/launch.html; or

2. Under the instruction of a qualified Level I Antiterrorism Awareness instructor; or

3. By providing a training certificate for "Level I Antiterrorism Awareness Training" training showing completion within the last calendar year.

The contractor will submit certificates of completion for each affected contractor employee and subcontractor employee to the COR or to the contracting officer, if a COR is not assigned, prior to being granted access to a Federally controlled facility or military installation.

Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in subcontracts, including subcontracts for commercial items, when subcontractor performance requires routine physical access to a Federally-controlled facility or military installation.

OPERATION SECURITY (OPSEC)

It is DoD policy according to DoD Directive 5205.02E, "DoD Operations Security (OPSEC) Program," June 20, 2012, as amended to establish and maintain OPSEC programs to ensure national security-related missions and functions are protected.

Training: Contractor employees shall comply with all DoD OPSEC requirements and complete "OPSEC Awareness for Military Members, DoD Employees and Contractor" training within 30 days of onboarding the contract and annual refresher training thereafter. Training shall be completed through a DoD sponsored and certified computer or web-based learning instruction available at https://securityawareness.usalearning.gov/opsec/index.

htm.

The contractor will submit certificates of completion for each affected contractor employee and subcontractor employee to the COR or to the contracting officer, if a COR is not assigned, within 30 calendar days after training is completed by all employees and subcontractor personnel.

START-UP PERIOD

All contractor resource onboarding documents must be submitted via the prime contractor. The prime contractor shall make all necessary preparations to assume full responsibility for productive performance as of the performance start date.

Definition of "productive":

a. OF-306 signed by contractor employee

b. FD-258 Fingerprint Card (Contingent upon availability of electronic fingerprinting submission)

c. Completed Electronic Investigation (e-QIP)

d. All contractor employees with need for a Common Access Card (CAC) must have an active Defense Information System for Security (DISS) profile.

e. Common Access Card (CAC)

f. DISS Visit Request submitted (Contingent upon classification of work being performed, Confidential, Secret, Top Secret).

Note (1): Invoicing by the contractor will begin as of the commencement of the performance period of services and no reimbursement will be paid by the government for efforts expended during the start-up period.

Note (2): Foreign Nationals are not allowed access to the functional/system side of Enterprise Resource Planning (ERP).

ACCESS TO DOD INFORMATION TECHNOLOGY (IT) SYSTEM

In accordance with DON CIO Memorandum (IT LEVEL DESIGNATION ON DD FORM 2875 SYSTEM AUTHORIZATION ACCESS REQUEST) 08 September 2020, contractor employees who require access to Department of the Navy (DoN) or DoD networks are categorized as Privileged, Enhanced, or Authorized users. All user level accesses may include positions which require access to Controlled Unclassified Information (CUI). CUI includes sensitive information protected under the Privacy Act, to include Protected Health Information (PHI). IT System levels are determined by the requiring activity's Command Information System Security Manager (ISSM)/Information Assurance Manager (IAM).

Contractor employees requiring privileged access, (when specified by the terms of the contract) require a Tier 5 (T5) or T5R equivalent investigation, which is a higher level investigation than the Tier 3 (T3) and T3R described below. Due to the privileged system access, an investigation suitable for High Risk national security positions is required. Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance (IA) Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain.

Contractors requiring Enhanced access, (when specified by the terms of the contract) require a T3, T3R, or equivalent investigation, which is a higher level investigation than the Tier 1 (T1) described below. Due to the enhanced system access, an investigation suitable for Moderate Risk national security positions is required.

Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee's duties, such employees shall in-process with the Navy CSM and ISSM/IAM manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual's performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy IT resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-N;

therefore, the government employee with knowledge of the system/network access required or the Contracting Officers Representative (COR) shall sign the SAAR-N as the supervisor.

The SAAR-N shall be forwarded to the CSM upon contractor employee acquiring a Common Access Card (CAC) credential. Failure to obtain a CAC credential may result in delaying the individual's start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all contractor employees requiring access complete annual Cyber Awareness training, and maintain a current requisite background investigation. The contractor's security representative shall contact the CSM for guidance when reinvestigations are required.

INTERIM ACCESS

The CSM may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform.

DENIAL OR TERMINATION OF ACCESS

The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release.

ACCESS TO CONTROLLED UNCLASSIFIED INFORMATION

Safeguarding sensitive unclassified information is critical to achieve NAVSUP Modernization efforts and deliver cutting-edge and uncompromised capabilities. The Secretary of Defense's operations security (OPSEC) campaign plan stresses the importance of protecting controlled unclassified information (CUI). CUI encompasses OPSEC, critical technology, intelligence, and personally identifiable information that, if not properly identified, marked, and controlled, could impair NAVSUP's ability to conduct its mission. Contractor employees with access to Controlled Unclassified Information (CUI) shall comply with DoDI 5200.48 - Controlled Unclassified Information (CUI) and complete DoD approved initial and annual refresher CUI training.

a. Whenever Government provides CUI to, or CUI is generated by, non-DoD entities, all CUI records must be handled as required by the approved mandatory disposition authority.

b. All CUI records must follow the approved mandatory disposition authority whenever the Government provides CUI to, or CUI is generated by, non- DoD entities in accordance with Section 1220-1236 of Title 36, CFR, Section 3301a of Title 44, U.S.C., and the DoDI 5200.48.

c. Contractor employees shall monitor CUI aggregation and compilation based on the potential to generate classified information pursuant to security classification guidance addressing the accumulation of unclassified data or information

d. Contractor employees shall submit unclassified government information for review and approval for release in accordance with the Standard DoD Component Processes, DoDI 5230.09, and DoDM 5205.07, Volume 1.

CONTRACTOR'S SECURITY REPRESENTATIVE

The contractor shall designate an employee to serve as the contractor's security representative. Within three (3) work days after contract award, the contractor shall provide to the requiring activity's Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the contractor's security representative. The contractor's security representative shall be the primary point of contact on any security matter. The contractor's security representative shall not be replaced or removed without prior notice to the Contracting Officer and CSM.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR CONTRACTORS ASSIGNED TO

NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE DUTIES

Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. If the Security Office validates the contractor's position is Non-Critical Sensitive or if the IT system user level is determined to be Enhanced, at a minimum, each contractor employee must be a US citizen and have a favorably completed T3, T3R, or equivalent investigation to obtain a favorable determination for assignment to a non-critical sensitive or Enhanced position. The investigation consists of a standard National Agency Check and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or Enhanced position is required to complete:

SF-86 Questionnaire for National Security Positions (or equivalent Office of Personnel Management (OPM) investigative product)

Two FD-258 Applicant Fingerprint Cards or electronic fingerprint submission (preferred))

Original Signed Release Statements

Failure to provide the required documentation at least thirty (30) days prior to the individual's start date shall result in delaying the individual's start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than ten (10) five (5) years) throughout the contract performance period. The Contractor's Security Representative shall contact the CSM for guidance when reinvestigations are required.

Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the CSM upon arrival to the command and shall out-process prior to their departure at the completion of the individual's performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy Command's ISSM/IAM. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy IT resources. The SAAR-N shall be forwarded to the CSM upon the contractor employee acquiring a Common Access Card (CAC) credential. Failure to obtain a CAC credential or provide the required documentation shall result in delaying the individual's start date.

The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual Cyber Awareness training, and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the CSM. The CSM will review the submitted documentation for completeness prior to submitting it to the OPM. Potential suitability or security issues identified may render the contractor employee ineligible for the assignment. An unfavorable determination is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract. The CSM will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DoD Central Adjudication Facility (CAF) for a determination.

For classified contracts, if the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Access Request (VAR) via the Defense Information Security System (DISS). If the contractor employee does not have a current favorably adjudicated investigation, the contractor shall submit the Visit Access Request in DISS until the contractor employee has at a minimum an interim clearance. If the contract only requires access to unclassified information, even if the contractor takes a DISS "owning" role over the contractor employee, the Navy Command will also take a DISS "owning" role over the contractor employee during the hiring process and for the duration of assignment under that contract. If the contract requires access to classified information, the contractor's Facility Security Office (FSO) will take a DISS "ownership" role and the Navy command will take a DISS "servicing" role during the hiring process and the duration of assignment under that contract. All VARs requires annual renewal for the duration of the employee's performance under the contract.

BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR CONTRACTORS ASSIGNED TO

OR PERFORMING NON-SENSITIVE DUTIES

Contractor employee whose work is unclassified and non-sensitive (e.g., performing certain duties such as lawn maintenance, vendor services, etc...)

and who require physical access to publicly accessible areas to perform those duties shall meet the following minimum requirements:

Must be either a U.S. citizen or a U.S. permanent resident with a minimum of 3 years of legal residency in the U.S. (as required by the Deputy Secretary of Defense DTM 08-006 or its subsequent DoD Instruction (INST)) and Must have a favorably completed NACI or T1 investigation or equivalent including a FBI fingerprint check prior to installation access.

To be considered for a favorable trustworthiness determination, the CSR must submit for all employees each of the following:

SF-85 Questionnaire for Non-Sensitive Positions Two FD-258 Applicant Fingerprint Cards (or the preferred method - electronic fingerprint submission) Original Signed Release Statements The contractor shall ensure each individual employee has a current favorably completed NACI or T1 equivalent investigation, or ensure successful FBI fingerprint results have been gained and investigation has been processed with OPM.

Failure to provide the required documentation at least thirty (30) days prior to the individual's start date may result in delaying the individual's start date.

SUPTXT 203.1106-1 (3-18) NAVY USE OF ABILITYONE SUPPORT

203.1106-1(3-18) CONTRACTOR - RELEASE OF OFFEROR INFORMATION (Jan 2024)

NAVSUP FLC Norfolk may utilize contractor support through the AbilityOne Program, as needed, to perform contract closeout functions for this acquisition. Information, including business sensitive/confidential or proprietary data, that the offeror provides to the Government or information already in the possession of the Government may be viewed and utilized by the AbilityOne Program support contractor personnel during the course of its contract performance.