191N6526Q0093 training.pdf

Unclassified SENSITIVE BUT UNCLASSIFIED SENSITIVE BUT UNCLASSIFIED SENSITIVE BUT UNCLASSIFIED

American Embassy, New Delhi, India Shanti Path, Chanakyapuri, New Delhi-110021 Phone No. 91-11-24198728 Fax No. 91-11-24198278

Unclassified SENSITIVE BUT UNCLASSIFIED SENSITIVE BUT UNCLASSIFIED SENSITIVE BUT UNCLASSIFIED

TABLE OF CONTENTS

SF 1449-COVER SHEET

A. PRICING

B. STATEMENT OF WORK

C. PACKAGING AND MARKING

D. INSPECTION AND ACCEPTANCE

E. DELIVERIES AND PERFORMANCE

F. CONTRACT ADMINISTRATION DATA

G. SPECIAL TERMS AND CONDITIONS

H. CLAUSES

I. LIST OF ATTACHMENTS

Attachment 1: Specifications / scope of work (attached separately with this RFQ)

J. INSTRUCTIONS ON HOW TO SUBMIT A QUOTATION

K. EVALUATION CRITERIA

L. REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS

WOMEN-OWNED SMALL

BUSINESS (WOSB)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NUMBER 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NUMBER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

REQUEST

FOR QUOTE

(RFQ)

INVITATION

FOR BID

(IFB)

REQUEST

FOR

PROPOSAL

(RFP)

SEE ADDENDUM

19.

ITEM NUMBER

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Government Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH

AND DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND

ON ANY ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS

SPECIFIED

29. AWARD OF CONTRACT: REFERENCE OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 11/2021)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NORTH AMERICAN

INDUSTRY CLASSIFICATION

STANDARD (NAICS):

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

THE DEFENSE PRIORITIES

AND ALLOCATIONS

SYSTEM - DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FREE ON

BOARD (FOB) DESTINATION

UNLESS BLOCK IS MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE (FEDERAL ACQUISITION REGULATION) FAR 52.212-1, 52.212-4. FAR 52.212-3

AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8(A)

ECONOMICALLY

DISADVANTAGED

WOMEN-OWNED SMALL

BUSINESS (EDWOSB)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

(SDVOSB)

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

NOTE: OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30.

191N6526Q0093

Royce M. Branch II

+91-11-2419-8000

American Embassy, New Delhi Gate C, Chandragupta Marg Chankayapuri

American Embassy, New Delhi 9000 New Delhi Pl Washington DC 20521-9000

American Embassy, New Delhi 9000 New Delhi Pl Washington DC 20521-9000

HVAC & Electrical Power Generation and Transmission Tr 1 LS

Royce M. Branch II

July 24, 2026

Aug 6, 2026 1400 hrs

American Embassy, New Delhi 9000 New Delhi Pl Washington DC 20521-9000

Unclassified

SENSITIVE BUT UNCLASSIFIED SENSITIVE BUT UNCLASSIFIED SENSITIVE BUT UNCLASSIFIED

SECTION A - PRICING

A. PRICE

The Contractor shall complete all work, including furnishing all labor, material, equipment, and services required under this purchase order for the following firm fixed price and within the time specified. This price shall include all labor, materials, all insurance, overhead and profit.

LABOUR COST IN INR

MATERILA COST IN INR

TOTAL PRICE (including all labor, materials, overhead and profit)

GST @

GRAND TOTAL INCLUDING GST@

A.1 GOODS AND SERVICES TAX (GST)

In order to enable the U.S. Government to claim GST refunds, the Contractor will include GST as a separate charge on the Invoice and as a separate line item.

Offeror, registered with GST authority, should submit a copy of GST registration certificate along with the offer. This is a mandatory requirement for evaluation purposes. Acceptability will be determined by assessing the offeror's compliance with the terms of the solicitation. The

The government will determine contractor responsibility by analyzing whether the apparent successful offeror complies with the requirements of FAR 9.1.

In order to enable the U.S. Government to claim GST refunds, the offeror shall indicate GST separately. The contractor shall furnish tax invoices in accordance with New Delhi GST regulations. GOI registered vendors must print the Embassy’s UID 0717USA00138UNS on the invoice otherwise their invoice shall be rejected by the Embassy.

52.216-27 Single or Multiple Awards (Oct 1995)

The Government may elect to award a single delivery order contract or task order contract or to award multiple delivery order contracts or task order contracts for the same or similar supplies or services to two or more sources under this solicitation.

(End of provision)

SECTION B - STATEMENT OF WORK

STATEMENT OF WORK

Part 1 GENERAL:

1.01 Summary

The U.S. Embassy New Delhi Facility Management requires the services of the awarded contractor to provide specific technical skill training courses for Locally Employed (LE) staff to be delivered at U.S. Embassy New

Delhi, for three weeks (40 hrs/week), to be scheduled any time between July 2026 and December 2026. The

Contractor shall provide all specified training materials to teach the technical fundamental skill sets that are required for workers to effectively operate and maintain equipment at the U.S. Embassy New Delhi. The

Contractor shall perform skill assessments of LE staff to assess the workers' comprehension based on the courses delivered through a post-training assessment.

1.02 Course Objective

The Contractor shall provide fundamental knowledge with level skill sets to enhance the workers' understanding and performance to maintain building systems and equipment, and to understand the importance of meeting general preventative maintenance standards. The course is intended to be part of a long-term commitment to providing different levels of continuous professional skill-set development training.

Part 2 COURSE REQUIREMENTS:

2.01 Summary

The LE staff have varying degrees of experience and expertise; foremen and team leads are the primary audience for this training initiative. Highlights of each course are to be constructed and delivered to acceptable

U.S. Standards for Job Site Safety, Electrical Power Generation, and HVAC. Materials are to be prepared in the

English language in advance to be translated by post to Hindi. At the conclusion of each subject, a quiz shall be administered, and the contractor shall administer a final assessment exam consisting of skill-set subject matter questions to validate the workers' understanding of the subject matter concepts. The quizzes, final assessment exam, answer sheets along with an assessment matrix to indicate each LE staff's training performance results are to be presented to the Office of Facility Management upon completion of all the courses for each training group. The contractor shall indicate the worker's name, the course title, the trainer's name, the date/time of the course for each quiz, and final assessment exam with actual scores achieved.

2.02 Learning Objectives

The contractor shall provide a detailed lesson plan for classroom training delivery and hands-on application at an 8th grade reading level, include time required for each delivery event and provide troubleshooting techniques. All the learning objectives below are to be covered and can be supplemented with O&M specific assets provided by post. The contractor shall add additional topics to transition related topics for continuity.

At the conclusion of each week, a written test shall be administered to validate the workers' understanding of the concepts taught.

The basic course curriculum shall cover at a minimum:

ELECTRICAL POWER GENERATION & SWITCH GEAR (40 hrs) – Learning Objectives:

1. Basic overview of Electrical power generation, Transformers and switchgear

2. Safety at work; lock-out tag out; block out

3. Main components of a generator, switchgear and transmission, and energy efficiency.

4. Generating electricity in simple generators and powerplants (MV and LV)

5. Motors – single phase vs three phase

6. Wye/Delta configuration in both high and low voltage

7. VFDs and soft starters

8. Load bank and power banks

9. Batteries and UPS

10. Wiring procedures and schematic examples for commercial buildings

11. Troubleshooting of Electrical Power Generation Systems

HVAC (40 hrs) - Learning Objectives:

1. Overview and basics of HVAC systems including Heating, Ventilation, and Air Conditioning, refrigeration cycles, refrigeration safety, pressure and temperature

2. Basic Thermodynamics

3. Components within the HVAC system and basic operation

4. Common accessories for HVAC systems

5. Basic wiring for refrigeration systems

6. Chillers and their components

7. Heat pumps; boilers; and electric, gas, and oil furnaces

8. Energy Efficiency

9. Troubleshooting of HVAC systems

PRACTICAL APPLICATION AND TROUBLESHOOTING (40 hrs)

1. Conduct hands-on troubleshooting of residential/commercial HVAC systems at U.S. Embassy New

Delhi (20 Hours)

2. Conduct hands-on troubleshooting of residential/commercial power generation and transmission at

U.S. Embassy New Delhi (20 Hours)

Part 3 PRODUCT REQUIREMENTS:

3.01 Training Event

The contractor shall conduct the training at the U.S. Government workplace located at U.S. Embassy New

Delhi. The contractor shall provide a lesson plan, estimate of delivery time with a training outline, and student materials in English to be translated to Hindi at post level, which incorporates the learning objectives and team building activities.

Contractor shall deliver training to approximately 30 participants each weeks. Primary training delivery days are Monday – Friday. Classroom training schedule may start at 0830 and end at 1700 daily with two short breaks and one lunch break.

The training classroom will have Microsoft Teams capability so that supervisors can join the training virtually as needed. U.S. Embassy New Delhi will record sessions for future reference by technicians.

The contractor shall complete training requirements and conform to the specific contract and quality standards established herein. Contractor costs shall include all student materials, shipping expenses, travel expenses, and accommodation. Contractor shall be responsible for coordinating all travel and hotel arrangements.

3.02 Post Training Assessment and Performance Evaluation

The contractor shall evaluate each participant's performance and provide comprehensive reports as outlined below.

Weeks 1 & 2 - Classroom Training Assessment:

Week 1 (Electrical Power Generation) and Week 2 (HVAC) will have different participant groups (approximately

30 participants each week). The contractor shall assess each group based on:

Assessment Components:

• Written quiz scores from the training module

• Weekly assessment exam results

• Quality and frequency of participation in Q&A sessions

• Classroom engagement and involvement

• Attendance and punctuality

Overall Rating: The contractor shall assign each participant an overall performance rating using one of the following designations:

• Pass - Excellent: Demonstrates mastery of all learning objectives

• Pass - Satisfactory: Demonstrates adequate understanding of learning objectives

• Needs Improvement: Requires additional training or practice

• Fail: Does not meet minimum competency standards

A separate report shall be submitted for each training week to the Office of Facility Management within three working days of completing each week's training.

Week 3 - Practical Application and Final Assessment: (approximately 30 participants)

Week 3 will focus on New Delhi technicians who previously completed either Week 1 (Electrical) or Week 2

(HVAC) classroom training. The hands-on training will be divided as follows:

• Days 1-3: HVAC hands-on troubleshooting and assessment (20 Hours)

• Days 3-5: Electrical hands-on troubleshooting and assessment (20 Hours)

Assessment Components:

• Hands-on troubleshooting performance and technique

• Application of classroom knowledge to real-world scenarios

• Problem-solving approach and methodology

• Safety protocol adherence

• Attendance and punctuality

Cumulative Assessment: For technicians who completed both classroom training (Weeks 1 & 2) and hands-on training (Week 3), the contractor shall provide a cumulative performance evaluation that includes:

• Combined classroom assessment scores

• Hands-on practical assessment results

• Overall performance trajectory and improvement

• Final overall rating

• Specific recommendations for continued professional development

Reporting Requirements:

• Week 3 hands-on assessment reports shall be submitted within three working days of completing the practical training.

• Cumulative assessments for technicians who completed multiple training weeks shall be submitted within five working days of completing all training activities

3.03 Course Materials/Tools/Equipment

Contractor shall provide extra copies above expected student attendance of all courseware, delivery aids, reference guides, and evaluation materials. The following materials shall be submitted 30 days prior to travel to the Office of Facility Management for review: student manual, all quizzes, final exam test materials along with answer sheets, student assessment matrix, and post-training assessment. The embassy shall provide classrooms for training and training within the shops, tools required and equipment for the execution of hands-on applications.

3.04 Training Presentation/Qualifications

The contractor shall provide trainer(s) that have at least ten years of experience conducting technical training and at least twenty years of operations and maintenance experience on equipment and systems that they shall train. Equipment/system experience includes generators (MV & LV), AVRs, transformers, switchgears, chillers, split pack HVAC systems, VRV systems, boilers, and DX systems. The contractor's selected personnel shall be qualified and dedicated masters in their trade with prior overseas industry training experience. The trainers shall be skilled to adapt to the learning environment to accommodate workers that may have English as their second language.

The contractor shall conduct training centered on the learning objectives to ensure the strategy for combining, sequencing, and presenting will support course delivery to enhance workers' transfer of knowledge.

The trainers will hold certifications in mechanical and refrigeration systems from a U.S. certification agency like EPA Section 608, NATE, HVAC Excellence, or equivalent.

3.05 Key Subject Matter Experts, Company Experiences with Referrals

The contractor shall provide a brief biography for each Subject Matter Expert and a summary of the company's history with three (3) referrals.

3.06 Security Requirements: Unclassified

The contractor shall execute all activities in accordance with this contract and Statement of Work requirements. The contractor shall be responsible for supervising, directing, or otherwise controlling their personnel as well as themselves. Post security policy must be adhered at all the times.

SECTION C - PACKAGING AND MARKING

RESERVED

SECTION D - INSPECTION AND ACCEPTANCE

The COR, or his/her authorized representatives, will inspect from time to time the services being performed and the supplies furnished to determine whether work is being performed in a satisfactory manner, and that all supplies are of acceptable quality and standards.

The Contractor shall be responsible for any countermeasures or corrective action, within the scope of this contract, which may be required by the Contracting Officer because of such inspection.

D.1 SUBSTANTIAL COMPLETION

Use and Possession upon Substantial Completion - The Government shall have the right to take possession of and use the work upon substantial completion. Upon notice by the Contractor that the work is substantially complete (a Request for Substantial Completion) and an inspection by the Contracting Officer or an authorized Government representative (including any required tests), the Contracting Officer shall furnish the

Contractor a Certificate of Substantial Completion. The certificate will be accompanied by a Schedule of

Defects listing items of work remaining to be performed, completed, or corrected before final completion and acceptance. Failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The Government's possession or use upon substantial completion shall not be deemed an acceptance of any work under the contract.

D.2 FINAL COMPLETION AND ACCEPTANCE

"Final completion and acceptance" means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

SECTION E - DELIVERIES AND PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

(APR 1984)

The Contractor shall be required to:

(a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and,

(c) complete the entire work ready for use not later than 40 working days after issuance of NTP.

The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000)

Reserve

CONTRACTOR'S SUBMISSION OF CONSTRUCTION SCHEDULES

(a) The time for submission of the schedules referenced in FAR 52.236-15, "Schedules for

Construction Contracts", paragraph (a), is hereby modified to reflect the due date for submission as " 5 calendar days after receipt of an executed contract".

(b) These schedules shall include the time by which shop drawings, product data, samples and other submittals required by the contract will be submitted for approval.

(c) The Contractor shall revise such schedules (1) to account for the actual progress of the work,

(2) to reflect approved adjustments in the performance schedule, and (3) as required by the Contracting

Officer to achieve coordination with work by the Government and any separate contractors used by the

Government. The Contractor shall submit a schedule, which sequences work so as to minimize disruption at the job site.

(d) All deliverables shall be in the English language and any system of dimensions (English or metric) shown shall be consistent with that used in the contract. No extension of time shall be allowed due to delay by the Government in approving such deliverables if the Contractor has failed to act promptly and responsively in submitting its deliverables. The Contractor shall identify each deliverable as required by the contract.

(e) Acceptance of Schedule: When the Government has accepted any time schedule; it shall be binding upon the Contractor. The completion date is fixed and may be extended only by a written contract modification signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:

(1) Extend the completion date or obligate the Government to do so,

(2) Constitute acceptance or approval of any delay, or

(3) Excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

NOTICE OF DELAY

If the Contractor receives a notice of any change in the work, or if any other conditions arise which are likely to cause or are causing delays which the Contractor believes may result in late completion of the project, the

Contractor shall notify the Contracting Officer. The Contractor’s notice shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule, or the completion date should be revised. The Contractor shall give such notice promptly, not more than ten (10) days after the first event giving rise to the delay or prospective delay. Only the Contracting

Officer may revise the approved time schedule.

NOTICE TO PROCEED

(a) After receiving and accepting any bonds or evidence of insurance, the Contracting Officer will provide the Contractor with a Notice to Proceed. The Contractor must then prosecute the work, commencing and completing performance not later than the time period established in the contract.

(b) It is possible that the Contracting Officer may elect to issue the Notice to Proceed before receipt and acceptance of any bonds or evidence of insurance. Issuance of a Notice to Proceed by the Government before receipt of the required bonds or insurance certificates or policies shall not be a waiver of the requirement to furnish these documents.

WORKING HOURS

All work shall be performed during normal working hours between 0830 to 1700 hours from Monday to

Friday. Other hours, if requested by the Contractor, may be approved by the Contracting Officer's

Representative (COR). The Contractor shall give 24 hours in advance to COR who will consider any deviation from the hours identified above. Changes in work hours, initiated by the Contractor, will not be a cause for a price increase.

PreTraning Conference

A pretraining conference will be held 10 days after the contract to discuss the schedule, submittals, notice to proceed, mobilization and other important issues that affect construction progress. See FAR 52.236-26, Pretraining Conference.

DELIVERABLES - The following items shall be delivered under this contract:

Description Quantity Deliver Date Deliver

To

Section E. Training Schedule 1

10 days after award COR

Section E. Training 1

10 days after award COR

Section G. Certifications as stated

TECHNICAL EVALUATION CRITERIA 1

10 days after award COR

SECTION F – CONTRACT ADMINISTRATION DATA

652.242-70 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (AUG 1999)

(a) The Contracting Officer may designate in writing one or more Government employees, by name or position title, to take action for the Contracting Officer under this contract. Each designee shall be identified as a Contracting Officer’s Representative (COR). Such designation(s) shall specify the scope and limitations of the authority so delegated; provided that the designee shall not change the terms or conditions of the contract, unless the COR is a warranted Contracting Officer, and this authority is delegated in the designation.

(b) The COR for this contract is FAC office.

Payment: The Contractor's attention is directed to Section H, 52.232-5, "Payments Under Fixed-Price

Contracts". The following elaborates on the information contained in that clause.

Partial payment is authorized under this contract as per the milestones fixed in the Scope of Work. Requests for payment may be made no more frequently than monthly. Payment requests shall cover the value of labor and materials completed and in place, including a prorated portion of overhead and profit.

After receipt of the Contractor's request for payment, and based on an inspection of the work, the Contracting

Officer shall decide as to the amount, which is then due. If the Contracting Officer does not approve payment of the full amount applied for, less the retainage allowed by in 52.232-5, the Contracting Officer shall advise the Contractor as to the reasons.

Under the authority of 52.232-27(a), the 14-day period identified in FAR 52.232-27(a)(1)(i)(A) is hereby changed to 30 days.

INVOICE SUBMISSION INSTRUCTIONS:

Invoices must be submitted via email to MissionIndiaPayments@state.gov with the Purchase Order number in the subject line. Physical invoices will not be accepted and may lead to payment being delayed. It is mandatory to submit electronic/scanned/digital image invoices only. You will receive an auto acknowledgement once the invoice is received. Please do not submit duplicate emails.

• Invoices from Indian businesses must be a proper Tax Invoice. The US Embassy's GST number is

0717USA00138UNS.

• Partial payment authorized as per payment milestones.

• Subject line while submitting invoice must mention; PO#, Invoice#, Amount.

• Electronic / scanned invoice must be labelled as “Tax Invoice”. The invoice must have GST number of the vendor and American Embassy’s UNI number 0717USA00138UNS.

• Electronic / scanned invoice must list GST rate percentage for each category of goods or services.

• Electronic / scanned invoices must be either typed or handwritten, handwriting on a typed invoice is not acceptable.

• Vendor should only submit invoice after delivering goods or services.

• Payment shall be processed within 30 days through EFT (electronic funds transfer) from the date of receipt of services and receipt of correct invoice. For any queries regarding payment, please contact FMC at

MissionIndiaPayments@state.gov.

mailto:MissionIndiaPayments@state.gov mailto:MissionIndiaPayments@state.gov

SECTION G – SPECIAL TERMS AND CONDITIONS

G.1.0 PERFORMANCE/PAYMENT PROTECTION – RESERVED

G.2.0 INSURANCE - The Contractor is required by FAR 52.228-5, "Insurance - Work on a Government

Installation" to provide whatever insurance is legally necessary. The Contractor shall at its own expense provide and maintain during the entire performance period the following insurance amounts:

G.2.1 GENERAL LIABILITY (includes premises/operations, collapse hazard, products, completed operations, contractual, independent contractors, broad form property damage, personal injury):

(1) BODILY INJURY, ON OR OFF THE SITE, IN U.S. DOLLARS

Per Occurrence 100,000 INR

Cumulative 1,000,000 INR

(2) PROPERTY DAMAGE, ON OR OFF THE SITE, IN U.S. DOLLARS

Per Occurrence 100,000 INR

Cumulative 1,000,000 INR

G.2.2 The foregoing types and amounts of insurance are the minimums required. The Contractor shall obtain any other types of insurance required by local law or that are ordinarily or customarily obtained in the location of the work. The limit of such insurance shall be provided by law or sufficient to meet normal and customary claims.

G.2.3 The Contractor agrees that the Government shall not be responsible for personal injuries or for damage to any property of the Contractor, its officers, agents, servants, and employees, or any other person, arising from an incident to the Contractor's performance of this contract. The Contractor shall hold harmless and indemnify the Government from all claims arising therefrom, except in the instance of gross negligence on the part of the Government.

G.2.4 The Contractor shall obtain adequate insurance for damage to, or theft of, materials and equipment in insurance coverage for loose transit to the site or in storage on or off the site.

G.2.5 The general liability policy required of the Contractor shall name "the United States of America, acting by and through the Department of State", as an additional insured with respect to operations performed under this contract.

G.3.0 DOCUMENT DESCRIPTIONS

G.3.1 SUPPLEMENTAL DOCUMENTS: The Contracting Officer shall furnish from time to time such detailed drawings and other information as is considered necessary, in the opinion of the Contracting Officer, to interpret, clarify, supplement, or correct inconsistencies, errors or omissions in the Contract documents, or to describe minor changes in the work not involving an increase in the contract price or extension of the contract time. The Contractor shall comply with the requirements of the supplemental documents, and unless prompt objection is made by the Contractor within 20 days, their issuance shall not provide for any claim for an increase in the Contract price or an extension of contract time.

G.3.1.1. RECORD DOCUMENTS. The Contractor shall maintain at the project site:

(1) a current marked set of Contract drawings and specifications indicating all interpretations and clarification, contract modifications, change orders, or any other departure from the contract requirements approved by the Contracting Officer; and,

(2) a complete set of record shop drawings, product data, samples and other submittals as approved by the Contracting Officer.

G.4.0 LAWS AND REGULATIONS – The Contractor shall, without additional expense to the Government, be responsible for complying with all laws, codes, ordinances, and regulations applicable to the performance of the work, including those of the host country, and with the lawful orders of any governmental authority having jurisdiction. Host country authorities may not enter the construction site without the permission of the

Contracting Officer. Unless otherwise directed by the Contracting Officer, the Contractor shall comply with the more stringent of the requirements of such laws, regulations, and orders and of the contract. In the event of a conflict between the contract and such laws, regulations and orders, the Contractor shall promptly advise the Contracting Officer of the conflict and of the Contractor's proposed course of action for resolution by the

Contracting Officer.

G.4.1 The Contractor shall comply with all local labor laws, regulations, customs, and practices pertaining to labor, safety, and similar matters, to the extent that such compliance is not inconsistent with the requirements of this contract.

G.4.2 The Contractor shall give written assurance to the Contracting Officer that all subcontractors and others performing work on or for the project have obtained all requisite licenses and permits.

G.4.3 The Contractor shall submit proper documentation and evidence satisfactory to the Contracting

Officer of compliance with this clause.

G.5.0 Training Personnel – The Contractor shall maintain discipline at the site and always take all reasonable precautions to prevent any unlawful, riotous, or disorderly conduct by or among those employed at the site. The Contractor shall ensure the preservation of peace and protection of persons and property about the project against such action. The Contracting Officer may require, in writing that the Contractor remove from the work any employee that the Contracting Officer deems incompetent, careless, insubordinate or otherwise objectionable, or whose continued employment on the project is deemed by the Contracting

Officer to be contrary to the Government's interests.

G.5.1 If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer.

G.5.2 After award, the Contractor has ten calendar days to submit to the Contracting Officer a list of workers and supervisors assigned to this project for the Government to conduct all necessary security checks.

It is anticipated that security checks will take 15 to 20 days to perform. For everyone, the list shall include:

Full Name

Place and Date of Birth

Current Address

Identification number

Failure to provide any of the above information may be considered grounds for rejection and/or resubmittal of the application. Once the Government has completed the security screening and approved the applicants a badge will be provided to the individual for access to the site. This badge may be revoked at any time due to the falsification of data, or misconduct on site.

G.5.3 The Contractor shall provide an English-speaking supervisor on site at all times. This position is considered as key personnel under this purchase order.

G.6.0 Materials and Equipment - All materials and equipment incorporated into the work shall be new and for the purpose intended, unless otherwise specified. All workmanship shall be of good quality and performed in a skillful manner that will withstand inspection by the Contracting Officer.

G.7.0 SPECIAL WARRANTIES

G.7.1 Any special warranties that may be required under the contract shall be subject to the stipulations set forth in 52.246-21, "Warranty of Construction", if they are not in conflict.

G.7.2 The Contractor shall obtain and furnish to the Government all information required to make any subcontractor's, manufacturer's, or supplier's guarantee or warranty legally binding and effective. The

Contractor shall submit both the information and the guarantee or warranty to the Government in sufficient time to permit the Government to meet any time limit specified in the guarantee or warranty, but not later than completion and acceptance of all work under this contract.

G.8.0 EQUITABLE ADJUSTMENTS

Any circumstance for which the contract provides an equitable adjustment that causes a change within the meaning of paragraph (a) of the "Changes" clause shall be treated as a change under that clause; provided, that the Contractor gives the Contracting Officer prompt written notice (within 20 days) stating:

(a) the date, circumstances, and applicable contract clause authorizing an equitable adjustment and

(b) that the Contractor regards the event as a changed condition for which an equitable adjustment is allowed under the contract

The Contractor shall provide written notice of a differing site condition within 10 calendar days of occurrence following FAR 52.236-2, Differing Site Conditions.

G.9.0 ZONING APPROVALS AND PERMITS

The Government shall be responsible for:

- obtaining proper zoning or other land use control approval for the project

- obtaining the approval of the Contracting Drawings and Specifications

- paying fees due for the foregoing; and,

- for obtaining and paying for the initial building permits.

SECTION H - CLAUSES

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. In addition, the full text of a clause may be accessed electronically at: Acquisition.gov this address is subject to change.

If the Federal Acquisition Regulation (FAR) is not available at the location indicated above, use the

Department of State Acquisition website at e-CFR to see the links to the FAR. You may also use an Internet

“search engine” (for example, Google, Yahoo or Excite) to obtain the latest location of the most current FAR.

THE FOLLOWING FEDERAL ACQUISITION REGULATION CLAUSE(S) IS/ARE INCORPORATED

BY REFERENCE (48 CFR CH. 1):

CLAUSE TITLE AND DATE

52.202-1 DEFINITIONS (JUN 2020)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS (NOV 2023)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS

(DEC 2014)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED OR PROPOSED FOR DEBARMENT OR

VOLUNTARILY EXCLUDED (JAN 2025)

52.216-7 ALLOWABLE COST AND PAYMENT (AUG 2018)

52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)

52.222-19 CHILD LABOR-COOPERATION WITH AUTHORITIES AND REMEDIES (JAN 2025)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.225-5 TRADE AGREEMENTS (NOV 2023)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

https://acquisition.gov/browse/index/far https://gov.ecfr.io/cgi-bin/text-idx?SID=d9a7851186785ba2b1896db79b1b6b29&mc=true&tpl=/ecfrbrowse/Title48/48tab_02.tpl

52.225-14 INCONSISTENCY BETWEEN ENGLISH VERSION AND TRANSLATION OF

CONTRACT (FEB 2000)

52.226-8 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING

WHILE DRIVING (MAY 2024)

52.228-3 WORKERS’ COMPENSATION INSURANCE (DEFENSE BASE ACT)

(JUL 2014)

52.228-4 WORKERS’ COMPENSATION AND WAR-HAZARD INSURANCE OVERSEAS (APR

1984)

52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 PLEDGES OF ASSETS (FEB 2021)

52.228-13 ALTERNATIVE PAYMENT PROTECTION (JULY 2000)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020)

52.229-6 TAXES - FOREIGN FIXED-PRICE CONTRACTS (FEB 2013)

52.229-7 TAXES- FIXED PRICE CONTRACTS WITH FOREIGN GOVERNMENTS (FEB 2013)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-8 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)

52.232-11 EXTRAS (APR 1984)

52.232-18 AVAILABILITY OF FUNDS (APR 1984)

52.232-22 LIMITATION OF FUNDS (APR 1984)

52.232-25 PROMPT PAYMENT (JAN 2017)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER - SYSTEM FOR AWARD

MANAGEMENT (OCT 2018)

52.232-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER – OTHER THAN

SYSTEM FOR AWARD MANAGEMENT (JULY 2013)

52.233-1 DISPUTES (MAY 2014) ALTERNATE I (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

52.236-26 PRETRAINING CONFERENCE (FEB 1995)

52.242-14 SUSPENSION OF WORK (APR 1984)

52.243-4 CHANGES (JUN 2007)

52.243-5 CHANGES AND CHANGED CONDITIONS (APR 1984)

52.245-2 GOVERNMENT PROPERTY INSTALLATION OPERATION SERVICES (APR 2012)

52.245-9 USE AND CHARGES (APR 2012)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

52.246-17 WARRANTY OF SUPPLIES OF A NONCOMPLEX NATURE (JUN 2003)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.246-26 REPORTING NONCONFORMING ITEMS (AUG 2024)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR

2012)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.249-14 EXCUSABLE DELAYS (APR 1984)

I. FAR CLAUSES INCORPORATED IN FULL TEXT

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT

(NOV 2021)

(a) Definitions. As used in this clause—

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network).

Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People’s Republic of China.

Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation

(or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology

Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the

International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal

Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the

Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal

Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening.

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal

Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control

Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019

(Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the

Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year

2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in

FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting

Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known);

supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any https://www.acquisition.gov/far/part-4#FAR_4_2104 https://www.acquisition.gov/far/part-4#FAR_4_2104 https://dibnet.dod.mil/ https://dibnet.dod.mil/ further available information about mitigation actions undertaken or recommended. In addition, the

Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products or commercial services.

(End of clause)

52.213-4 TERMS AND CONDITIONS—SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES) (OCT 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan

2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(iii) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance

Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(iv) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328), unless the agency grants an exception - see paragraph (b) of 52.204-27.

(v) 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) (Pub. L.

115–390, title II).

(vi) 52.222-3, Convict Labor (Jun 2003) (E.O. 11755).

(vii) 52.222-21, Prohibition of Segregated Facilities (Oct 2025).

(viii) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(ix) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(x) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C.

3903 and 10 U.S.C. 3801).

(xi) 52.233-3, Protest After Award (Aug 1996) ( 31 U.S.C. 3553).

(xii) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) ( Pub. L. 108-77 and 108-78 ( 19

U.S.C. 3805 note)).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (Apr 1984).

https://www.acquisition.gov/far/part-52#FAR_52_203_19 https://www.acquisition.gov/far/part-52#FAR_52_204_23 https://www.acquisition.gov/far/part-52#FAR_52_204_25…