Fire Hydrant bid document.pdf

15B21220B00000001 Page 1 of 26

SOLICITATION,OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

15B21220B00000001

X SEALED BID (IFB)

NEGOTIATED (RFP)

2. TYPE OF SOLICITATION 3. DATE ISSUED

03/10/2020

IMPORTANT -The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

2D4L

CODE 15B212

Federal Bureau of Prisons FCI Ray Brook 128 Ray Brook Road

RAYBROOK, NY 12977-0300

7. ISSUED BY

Mark Allen 128 Ray Brook Road

(O) 518-897-4075

(F) 518-897-4210 mallen@bop.gov

8. ADDRESS OFFER TO

9. FOR INFORMATION CALL: a. NAME b. TELEPHONE NO. (Include area code)(NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

11. The Contractor shall begin performance calendar days and complete it within calendar days after receiving10 105 award, X notice to proceed. This performance period is X mandatory negotiable. (See __________________________.)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS? (If "YES," indicate within how many calendar days after award in Item 12b).

X YES NO

12b. CALENDAR DAYS

Sealed offers in original and copies to perform the work required are due at the place specified in item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

17:00EDTa.

05/29/2020

b. An offer guarantee X is, is not required.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.c.

90d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

13. ADDITIONAL SOLICITATION REQUIREMENTS:

NSN 7540-01-155-3212 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

The solicited contractor shall provide all materials, labor, and equipment required to complete the Replace Fire Hydrants project at FCI Ray Brook in accordance with the requirements of this solicitation.

INCLUDE THE FOLLOWING INFORMATION WITH BIDS:

TAX ID #:

DUNS#:

EMAIL ADDRESS:

CAGE CODE:

15B21220B00000001 Page 2 of 26

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ___________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

17.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY 15B212

Federal Bureau of Prisons FCI Ray Brook 128 Ray Brook Road

RAYBROOK, NY 12977-0300

Federal Bureau of Prisons FCI Ray Brook 128 Ray Brook Road

RAYBROOK, NY 12977-0300

Travis Cayea

(O) 518-897-4055 TCayea@bop.gov

27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return __________ copies to issuing office) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a.NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

Mark Allen

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 4-85)BACK

15B21220B00000001 Page 3 of 26

Table of Contents

Section Description Page Number

1 Solicitation, Offer and Award 2 Commodity or Services Schedule 3 Special Contract Requirements

FAO-0001 Bonds FAO-0002 Magnitude FAO-0003 Required Insurance FAO-0004 Pre-Construction Conference FAO-0005 Submittals FAO-0006 Contractor Use of Premises FAO-0007 Payment Services FAO-0008 Request for Final Inspection FAO-0009 Contract Security (Program Statement 3000.03 Human Resource Management Manual) FAO-0010 Assignment of Contract Administration Office and Functions FAO-0011 Schedule of Values FAO-0012 Progress Meetings FAO-0013 Contract Closeout Procedures (for construction contracts exceeding $150,000)

4 Contract Clauses 52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984) 52.252-6 Authorized Deviations in Clauses (Apr 1984) 52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data-Modifications (Oct 2010) 52.222-36 Equal Opportunity for Workers with Disabilities (Jul 2014)

BOP 2852.242-71 EVALUATION OF CONTRACTOR PERFORMANCE UTILIZING CPARS (APR

2011) 52.211-12 Liquidated Damages-Construction (Sept 2000) 52.204-21 Basic Safeguarding of Covered Contractor Information Systems (June 2016) FAO-0015 Changes 52.225-9 Buy American-Construction Materials (May 2014) 52.222-35 Equal Opportunity for Veterans (Oct 2015) FAO-0016 Equitable Adjustments: Waiver and Release of Claims

5 Attachments 6 Solicitation Provisions

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (Feb 1999) 52.225-10 Notice of Buy American Requirement-Construction Materials (May 2014) 52.233-2 Service of Protest (Sept 2006) 52.236-27 Site Visit (Construction) (Feb 1995)

52.27-103-71 FAITH-BASED AND COMMUNITY-BASED ORGANIZATIONS (AUG 2005)

2852.233-70 Protests Filed Directly with the Department of Justice (Jan 1998) 52.216-1 Type of Contract (Apr 1984) 52.222-5 Construction Wage Rate Requirements - Secondary Site of the Work (May 2014)

7 Representations and Certifications 52.209-13 Violation of Arms Control Treaties or Agreements-Certification (Jun 2018) FAO-0020 List of References and Bank Information

15B21220B00000001 Page 4 of 26

Section 2 - Commodity or Services Schedule

SCHEDULE OF SUPPLIES/SERVICES

CONTINUATION SHEET

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE FEES AMOUNT

0001 Firm Fixed Price

The selected contractor shall provide all materials, labor, & equipment to complete the Replace Fire Hydrants Project at FCI Ray Brook in accordance with solicitation 15B21220B00000001.

PSC: Z2FF

1.000000 JB $___________ $_________ $___________

15B21220B00000001 Page 5 of 26

Section 3 - Special Contract Requirements

Clauses By Full Text

FAO-0001 Bonds

(a) Bid Guarantee. Each bidder shall submit with his bid a Bid Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government, or other security as provided in provision 52.228-1, in the form of twenty percent (20) of the bid price or not to exceed $3,000,000. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be expressed in dollars and cents. A bid bond is not required for bids of $150,000 or less. (FAR 28.102-1)

(b) Performance and Payment Bonds. Within 10 days after award the contractor shall execute and submit to the Contracting Officer two bonds, each with good and sufficient surety or sureties acceptable to the Government, as follows; a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25A). The penal sums of such bonds will be as follows: (Not required for contracts of $150,000 or less)

(1) Performance Bond: The penal sum of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bond: The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(c) For construction contracts greater than $30,000 but not greater than $150,000, the Contracting Officer shall select two or more of the following payment protections, giving particular consideration to inclusion of an irrevocable letter of credit as one of the selected alternatives (FAR 28.102-1(b)(1)):

(1) A Payment Bond;

(2) An irrevocable letter of credit (ILC);

(3) A tripartite escrow agreement;

(4) A Certificate of Deposit; or

(5) A deposit of the types of security listed in 28.204-1 and 28.204-2.

(d) Individual Sureties.

(1) Bidders may elect to furnish individual surety bonds. If individual surety bonds are furnished for bid guarantees, payment or performance bonds, the individual sureties must submit their bonds proof of ownership and value of the assets which they claim in their net worth at time of bid opening. The Government's preferred method of proof is to have a statement of net worth prepared by a Certified Public Accountant (CPA) in accordance with Generally Accepted Accounting Principles (GAAP). Statements from a CPA that contain disclaimers are not acceptable. The statement of net worth on the Standard Form 28, Affidavit of Individual Surety, is insufficient and will not be accepted without additional proof of value and ownership.

(2) Bidders are cautioned that individual sureties must provide complete and detailed information in Block 9 of Standard Form 28 concerning other contracts on which they have provided bonds. This information shall include contract number, contract location, amount, and type of bond and telephone number of the involved contracting office. Failure to provide the proof and information required may result in rejection of the bid or termination of the contract for failure to provide adequate bonds.

FAO-0002 Magnitude

The magnitude of this project is between $100,000.00 and $150,000.00.

FAO-0003 Required Insurance

See FAR 52.228-5, Insurance - Work on a Government Installation.

The Contractor shall, at its own expense, provide and maintain during the entire performance

15B21220B00000001 Page 6 of 26 period of this contract, at least the kinds and minimum amounts of insurance required in the

Schedule or elsewhere in the contract.

TYPE AMOUNT

(1) WORKERS COMPENSATION & EMPLOYER'S LIABILITY $100,000

The required Workmen's Compensation Insurance shall extend to cover employee's liability for accidental bodily injury or death and for occupational disease with a minimum liability of $100,000.

(2) COMPREHENSIVE GENERAL LIABILITY with a minimum limit of:

PER ACCIDENT OR

OCCURRENCE FOR BODILY INJURY $500,000

This insurance shall include contractor's protective and contractual liability.

(3) COMPREHENSIVE AUTOMOBILE LIABILITY with the following minimum limits:

PER PERSON $200,000

PER OCCURRENCE FOR BODILY INJURY $500,000

PER OCCURRENCE FOR PROPERTY DAMAGE $ 20,000

FAO-0004 Pre-Construction Conference

(a) Prior to the start of construction, Contracting Officers shall call a conference with the contractor, subcontractor(s), Warden, Controller/Business Administrator, Safety Manager, Facilities Administrator, Project Representative, A&E firm, Captain and other interested personnel to discuss the statutory labor standards, prevailing wage requirements, submission of the contractor's payrolls, subcontractor's responsibilities, institution work schedules, local policies, contraband, parking, storage of vehicles and equipment, etc.

Minutes of the conference shall be recorded, listing the names and titles of all attendees, and the subject matter of all items covered.

The minutes shall be signed by the contractor and the Contracting Officer, and a signed copy placed in the contract file.

(b) The Contractor shall familiarize himself/herself with all procedures involved in normal institution routines. Any requirements which may constitute a problem or result in conflict, will be brought to the attention of the Contracting Officer or his representative for determination.

15B21220B00000001 Page 7 of 26

FAO-0005 Submittals

Within 10 calendar days after commencement of work or as otherwise established by the Contracting Officer, all materials and articles requiring approval, as contemplated by the Materials and Workmanship clause, shall be submitted by the contractor.

The submittal process is in place to allow the Government the opportunity to determine whether materials or procedures used by the contractor are in accordance with contract requirements. It is ultimately the Contractor's responsibility via the quality control process to ensure submittal items installed under the contract and work performed on site are in accordance with industry standards and general practices.

(a) The types of submittal requirements specified in this contract may include, but is not limited to; shop drawings, product data, samples, certificates of conformance or compliance, certified test or inspection reports, equipment, materials, and miscellaneous work related submittals for construction. Individual submittal requirements are generally specified in applicable sections for each unit of work in the specifications and/or as a whole in one section in the statement of work.

(b) The Bureau of Prisons (BOP) Contracting Officer’s Representative (COR) shall act for the Contracting Officer in the review and acceptance of all submittals. The Contractor shall submit submittals as required by the contract/specifications to the COR for transmittal to the Contracting Officer. Fabrication of any work or purchase or use of any submittals (such as materials for which samples are required or equipment, etc.) shall not take place until written acceptance is given by the COR, except at the Contractor's own risk.

(c) The Contractor shall submit all shop drawings and submittals sufficiently in advance (unless otherwise specified in the specifications) of the construction requirements to allow ample time for checking, re-submitting, and re-checking.

(d) Failure of any materials to pass their specified tests shall be sufficient cause for refusal to consider, under this contract, any further samples of the same brand or make of that material. The Government reserves the right to disapprove any material or equipment which has previously proven unsatisfactory in service.

(e) The Contracting Officer’s or designee’s approval or acceptance of submittals is not to be construed as a complete check.

Approval or acceptance will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor is responsible for the satisfactory construction of all work. The Contractor is responsible for delivering a final product/system that is operational as intended by the contract requirements, regardless of any Government approvals or acceptance of submittals. The Government assumes no liability during the submittal approval/acceptance process. It is the sole responsibility of the Contractor to deliver a properly functioning product or system.

FAO-0006 Contractor Use of Premises

Work Hours The project schedule is based on a normal forty (40) hour work week, eight (8) hours per day, Monday through Friday, excluding Federal holidays. The Contracting Officer’s Representative (COR) shall establish the work hour time frames for the duration of the project, subject to the approval of the Contracting Officer. Work hours and work days may be altered only with a 48 hour advance approval of the Contracting Officer.

NOTE: Access to the site will be available during normal working hours except during emergencies. It shall be the responsibility of the Contractor to familiarize himself, his employees, and his subcontractors of the working hours and conditions in the correctional facility, as working hours may not constitute a full eight hour day. The Government assumes no responsibility to the Contractor, nor to any of his subcontractors, for shorter hours due to institutional emergencies or entry and/or exit of workers necessitated by normal institution routines. The procedures and institutional entrance/exit routines applicable to this project will be explained at both the pre-bid conference/site visit and the pre-construction meeting.

Contraband The Contractor shall inform his employees that intoxicating beverages, drugs, weapons, etc., will not be allowed on the site.

Introduction of contraband shall be subject to the penalties prescribed by Title 18 USC-1791.

Explosives The use of explosives is absolutely forbidden without written authorization from the Contracting Officer.

Parking and Temporary Office

15B21220B00000001 Page 8 of 26

Parking will be available at the site to the extent it does not interfere with construction activities. Otherwise, parking shall be provided for by the Contractor, at his expense, off the site for workmen employed on the project. Any temporary field office used by the Contractor shall be located in an area approved by the COR.

Safety and Accident Prevention In performing work under this contract the contractor shall:

(a) Conform to the specific safety requirements established by this contract;

(b) Comply with the safety rules of the Government institution that concern related activities not directly addressed in this contract;

(c) Take all reasonable steps and precautions to prevent accidents and preserve the life and health of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(d) Take such additional immediate precautions as the Contracting Officer and/or COR may reasonably require for safety and accident prevention purposes.

FAO-0007 Payment Services

(a) Original application for payment shall be prepared on AIA (American Institute of Architects) Form G-702 "Application and Certificate for Payment" and submitted to the Contracting Officer. The contractor may use another form; however, it shall contain similar information as the AIA Form G-702. The Contracting Officer will approve the amount of payment by signing and forwarding the application and certificate as follows: Original to Accounting; Copy for Contract Award File.

(b) All small business contractors are required to self-certify on all invoices their small business status.

FAO-0008 Request for Final Inspection

The Contractor shall give the Contracting Officer’s Representative (COR) a minimum of ten (10) working days advanced written notice of the date on which the work will be fully completed and ready for the Government’s final inspection.

FAO-0009 Contract Security (Program Statement 3000.03 Human Resource Management Manual)

The following security measures will be applied to all contract employees who will be working under the terms of the contract:

National Crime Information Center (NCIC) Check Name Check Fingerprint Check (FD-258) OF-306, Declaration for Federal Employment, and Appropriate Resume or Optional Application Contract Pre-employment Form Release of Information

FAO-0010 Assignment of Contract Administration Office and Functions

Pursuant to FAR 42.201 and 42.202, the assigned Contract Administration Office is listed in Block 26 of the Standard Form 1442 Back. This assignment carries with it the authority to perform all of the contract administration functions listed in FAR 42.302(a) and 42.302(b) to the extent that those functions apply to the contract.

FAO-0011 Schedule of Values

The Contractor shall prepare a Schedule of Values (SOV) for the project and submit to the Contracting Officer for approval prior to submitting the first application for payment. The SOV shall be correlated with the construction schedule. The SOV shall be formatted per the Construction Specification Institute Master Format structure. The Contractor may propose an alternate organizational format to the Contracting Officer for approval.

(a) The SOV shall include:

(1) Project name, location, and contract number;

15B21220B00000001 Page 9 of 26

(2) Contractor’s name and address;

(3) Date of submittal.

(b) The SOV shall be arranged in a tabular form with separate columns to indicate the following for each item listed:

(1) Description of Work or Material;

(2) Related specification section, if applicable;

(3) Name of subcontractor, if applicable;

(4) Name of manufacturer or fabricator, if applicable;

(5) Name of supplier, if applicable;

(6) Change orders (modifications) that have affected value, if applicable;

(7) Dollar value;

(8) Percentage of Contract sum rounded to the nearest percent, adjusted to total 100 percent.

(c) The SOV shall breakdown the contract sum in sufficient detail to facilitate continued evaluation of applications for payment and progress reports. The contractor should separate principal subcontract amounts down into several line items.

(d) SOV amounts shall be rounded to the nearest whole dollar. The total of all SOV amounts shall equal the total contract amount.

(e) The contractor shall progress the percentage of completion, with the concurrence of the Contracting Officer’s Representative, for each value in conjunction with the preparation of each monthly application for payment. The progressed value percentages shall directly correlate to the calculated total amount due for each monthly progress payment.

(f) The SOV shall remain fixed for the duration of contract performance. Any revisions to the SOV must be requested in writing, with justification, for approval by the Contracting Officer.

FAO-0012 Progress Meetings

The Administrative Contracting Officer (ACO) shall conduct progress meetings at the project site on a monthly basis, or at intervals as determined by the ACO.

(a) At a minimum, the attendees shall include but is not limited to:

(1) FBOP: Administrative Contracting Officer, Contracting Officer’s Representative (COR), Facility Administrator/ Manager, Architect/Engineer (if applicable), Other Personnel (Executive Staff, Captain, Safety Manager, etc.).

(2) Contractor: Project Manager, Superintendent, and technical support disciplines as appropriate (Subcontractors, Manufacturers, Suppliers, etc.).

(b) The meeting should include, but is not limited to issues such as:

Administrative Contracting Officer:

(1) Old business from previous progress meeting(s);

(2) Status of modifications, certified payrolls, submittals, requests for information (RFI);

(3) Review of payments made to date and review/approve current payment request;

(4) Status of modification proposal requests;

(5) Discuss new business.

COR:

(1) Status of escort coverage;

(2) Review gate or sallyport entrance/exit issues;

15B21220B00000001 Page 10 of 26

(3) Discuss other delays contractor may be experiencing;

(4) Discuss performance/quality issues.

Contractor:

(1) Review/discuss updated progress schedule;

(2) Provide 30 day outlook;

(3) Discuss other issues affecting performance.

FAO-0013 Contract Closeout Procedures (for construction contracts exceeding $150,000)

Contract Closeout must be completed within six (6) months of physical completion of the work.

Prior to payment of final invoice:

The contractor shall submit the following documents:

(1) Contractor’s Affidavit of Release of Liens (AIA Document G706A);

(2) Contractor’s Affidavit of Payment of Debts and Claims (AIA Document G706);

(3) All as-built drawings/shop drawings, if applicable;

(4) Contractor’s final invoice;

(5) Release of Claims (GSA Form 1142);

(6) Consent of Surety to Final Payment (AIA Document G707);

(7) Letter establishing warranty dates;

(8) Complete list of subcontractors with telephone numbers and points of contact;

(9) Guarantees and warranties;

(10) All balance and test reports;

(11) All operation/maintenance manuals;

(12) All permits and certifications.

AIA forms can be obtained from The American Institute of Architects at www.aiabookstore.com.

GSA forms can be obtained from the General Services Administration at www.gsa.gov (click on the “Forms Library” link).

15B21220B00000001 Page 11 of 26

Section 4 - Contract Clauses

Clauses By Full Text

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 105.* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.252-6 Authorized Deviations in Clauses (Apr 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any ____________________. [insert regulation name] (48 CFR __________) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of clause)

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data-Modifications (Oct 2010)

(a) Exceptions from certified cost or pricing data.

(1) In lieu of submitting certified cost or pricing data for modifications under this contract, for price adjustments expected to exceed the threshold set forth at FAR 15.403-4 on the date of the agreement on price or the date of the award, whichever is later, the Contractor may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable--

(i) Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office.

(ii) Information on modifications of contracts or subcontracts for commercial items.

(A) If--

(1) The original contract or subcontract was granted an exception from certified cost or pricing data requirements because the price agreed upon was based on adequate price competition or prices set by law or regulation, or was a contract or subcontract for the acquisition of a commercial item; and

(2) The modification (to the contract or subcontract) is not exempted based on one of these exceptions, then the Contractor may provide information to establish that the modification would not change the contract or subcontract from a contract or subcontract for the acquisition of a commercial item to a contract or subcontract for the acquisition of an item other than a commercial item.

(B) For a commercial item exception, the Contractor shall provide, at a minimum, information on prices at which the same item or similar items have previously been sold that is adequate for evaluating the reasonableness of the price of the modification. Such information may include--

15B21220B00000001 Page 12 of 26

(1) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities.

(2) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market.

(3) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item.

(2) The Contractor grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this clause, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the Contractor's determination of the prices to be offered in the catalog or marketplace.

(b) Requirements for certified cost or pricing data. If the Contractor is not granted an exception from the requirement to submit certified cost or pricing data, the following applies:

(1) The Contractor shall submit certified cost or pricing data, data other than certified cost or pricing data, and supporting attachments in accordance with the instructions contained in Table 15-2 of FAR 15.408, which is incorporated by reference with the same force and effect as though it were inserted here in full text. The instructions in Table 15-2 are incorporated as a mandatory format to be used in this contract, unless the Contracting Officer and the Contractor agree to a different format and change this clause to use Alternate I.

(2) As soon as practicable after agreement on price, but before award (except for unpriced actions), the Contractor shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2.

(End of clause)

52.222-36 Equal Opportunity for Workers with Disabilities (Jul 2014)

(a) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.

(b) Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order in excess of $15,000 unless exempted by rules, regulations, or orders of the Secretary, so that such provisions will be binding upon each subcontractor or vendor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs of the U.S. Department of Labor, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

(End of clause)

BOP 2852.242-71 EVALUATION OF CONTRACTOR PERFORMANCE UTILIZING CPARS (APR 2011)

The services, although not directly supervised, shall be reviewed by Federal Bureau of Prisons (BOP) staff to ensure contract compliance. The contractor's performance will be evaluated in accordance with FAR 42.15. Contract monitoring reports will be prepared by the Contacting Officer's Representative (COR) and maintained in the contract file.

In accordance with FAR 42.1502 and 42.1503, agencies shall prepare an evaluation of contractor performance and submit it to the Past Performance Information Retrieval System (PPIRS). The BOP utilizes the Department of Defense (DOD) web-based Contractor Performance Assessment Reporting System (CPARS) to provide contractor performance evaluations. The contractor shall provide and maintain a current e-mail address throughout the life of the contract. The contractor will receive an e-mail from the Focal Point thru the following website address webptsmh@navy.milwhen the contract is registered in CPARS. The e-mail will contain a "user ID" and temporary password to register in the CPARS system. The contractor must be registered to access and review its evaluation and/or provide a response. If assistance is required when registering, please contact the Contracting Staff/Focal Point.

15B21220B00000001 Page 13 of 26

(End of Clause)

52.211-12 Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of 785.36 [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.204-21 Basic Safeguarding of Covered Contractor Information Systems (June 2016)

(a) Definitions. As used in this clause--

"Covered contractor information system" means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

"Federal contract information" means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public Web sites) or simple transactional information, such as necessary to process payments.

"Information" means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction

(CNSSI) 4009).

"Information system" means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

"Safeguarding" means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

15B21220B00000001 Page 14 of 26

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

FAO-0015 Changes

(a) Changes will be in accordance with the Changes clause 52.243-4 or Changes and Changed Conditions clause 52.243-5 whichever applies to this contract.

(b) When changes are made in the work that requires an equitable adjustment to the contract, the Contractor shall submit to the Contracting Officer, through the Contracting Officer’s Representative (COR), a written proposal for adjustment of the amount of increase or decrease. With the proposal, the Contractor shall submit an itemized breakdown in at least the following detail:

(1) Material quantities and unit cost

(2) Labor costs by material item

(3) Construction equipment cost

(4) Workmen's compensation and public liability insurance

(5) Overhead

(6) Profit or commission

(7) Employment taxes (FICA and FUTA)

(c) The maximum allowable overhead, profit and commission percentages are contained below. The percentages for overhead, profit and commission shall be negotiated and may vary according to the nature, extent and complexity of the work involved, but in no case shall exceed the following:

(1) To the Contractor, on work performed by other than his own forces. The commission is 10% in the first $20,000, 7 1/2% on the next $30,000, 5% on the balance over $50,000.

(2) To the Contractor, and/or the Subcontractors for that portion of the work performed with their respective forces. The commission is 10% overhead and 10% profit on the first $20,000, 7 1/2% overhead and 7 1/2% profit on the next $30,000, and 5% overhead and 5% profit on the balance over $50,000.

Not more than three (3) percentages, not to exceed the maximum percentage amounts shown above, will be allowed regardless of the number of Subcontractors (i.e., the mark up on work subcontracted by the Subcontractor will be limited to the overhead

15B21220B00000001 Page 15 of 26 percentage and one profit percentage in addition to the prime Contractor's commission percentage). On proposals covering both increases and decreases in the amount of the contract, overhead, profit and commission will be allowed on the net increase only.

(d) When certified cost or pricing data are required under FAR 15.403-4 for proposals over $700,000, the cost or pricing data shall be submitted in accordance with FAR 15.408, Table 15-2. No itemized breakdown will be required for proposals amounting to less than $1,000.

(e) When the necessity to proceed with a change does not allow sufficient time to negotiate a modification or because of failure to reach an agreement, the Contracting Officer may issue a change order instructing the contractor to proceed on the basis of a tentative price based on the best estimate available at the time, with the firm price to be determined later. Furthermore, when the change order is issued, the contractor shall submit a proposal for cost of changes in work within 30 calendar days.

(f) The Contracting Officer will consider issuing a settlement by determination to the contract, if the contractor's proposal required by paragraphs (a) and (b) of this clause is not received within 30 calendar days, or if agreement has not been reached.

(g) Where a change involves credit items only, a proper measure of the amount of downward adjustment in the contract price is the reasonable cost to the contractor if he/she had performed the deleted work. A reasonable allowance for overhead and profit are properly includable as part of the downward adjustment for a deductive change. The amount of such allowance is subject to negotiation.

(h) Overhead and contractor's fee percentages shall be considered to include insurance other than mentioned herein, field and office supervisors and assistants, security police, use of small tools, incidental job burdens, and general home office expenses and no separate allowance will be made therefor. Assistants to office supervisors include all clerical, stenographic and general office help.

Incidental job burdens include, but are not necessarily limited to, office equipment and supplies, temporary toilets, telephone and conformance to OSHA requirements. Items such as, but not necessarily limited to, review and coordination, estimating and expediting relative to contract changes are associated with field and office supervision and are considered to be included in the contractor's overhead and/or fee percentage.

(i) The Contractor shall submit with his proposal a request for time extension, if applicable.

(j) The COR shall review the proposal and check estimates in detail, utilizing unit prices where specified or agreed upon. If they are in agreement, the COR shall forward the proposal to the Contracting Officer. The Contracting Officer will forward copies to the Architect-Engineer (if applicable) and the Regional Project Manager for their review and recommendations. After their review, the Architect-Engineer and Project Manager will forward their comments to the Contracting Officer.

(k) If the Contracting Officer determines that an equitable adjustment is to be made, the contract shall be modified in writing utilizing the prescribed Standard Form 30 (Amendment of Solicitation/Modification of Contract)(SF-30). After the SF-30 has been signed by the Contractor and executed by the Contracting Officer, distribution shall be made as follows:

(1) Original: Contract file

(2) Copy to: Contractor Regional Project Manager Contracting Officer’s Representative (COR) Architect-Engineer Firm (if applicable) Accounting Supervisor Contracting Officer

52.225-9 Buy American-Construction Materials (May 2014)

(a) Definitions. As used in this clause--

"Commercially available off-the-shelf (COTS) item"--

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

15B21220B00000001 Page 16 of 26

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

"Cost of components" means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

"Domestic construction material means"--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

"Foreign construction material" means a construction material other than a domestic construction material.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

##None [Contracting Officer to list applicable excepted materials or indicate "none"]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that--

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

15B21220B00000001 Page 17 of 26

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of…