Pre-Bid Meeting Minutes.pdf

PRE-BID CONFERENCE MEETING MINUTES

15B10625Q00000010 – REPLACE MEDIUM VOLTAGE SWITCHGEAR FCI II

BUTNER FCI II- PROJECT 24Z1AS1

DATE: 9:00 A.M. EST, TUESDAY, MARCH 4, 2025

Place: BUTNER FCI II

CONTRACTING OFFICER (Broguen McKeown):

I. INTRODUCTIONS:

Round table introduction of all attendees.

II. PURPOSE OF MEETING:

Indicate the purpose of this meeting is to familiarize the contractor with the unique circumstances and requirements surrounding a correctional setting. This meeting is also to explain the solicitation, as issued, and not to furnish additional information.

State - nothing said here shall be interpreted as a change to the solicitation without the issuance of a formal amendment through the Contracting Officer, Broguen McKeown.

III. MINUTES:

Advised minutes will be recorded and distributed via www.sam.gov.

IV. SITE VISIT INFORMATION:

Walk to selected site for Replace Medium Voltage Switchgear FCI II immediately following the meeting.

V. FRONT COVER PAGE FORMS AND INSTRUCTIONS:

Special instructions pertaining to electronic bid submission (FAR 14.302 and 14.304) *Submit: Quote Submission Cover Page, SF1442 Pages 1, 2, 6, and 62 thru 67 shall be uploaded as a single PDF attachment and submitted to bmckeown@bop.gov and jx2hayes@bop.gov.

Quotes submitted by mail or hand carried will not be evaluated. It is the responsibility of the quoter to confirm receipt of quotes by contacting Broguen McKeown by email bmckeown@bop.gov and Jeffrey Hayes jx2hayes@bop.gov. All quotes received after the exact time specified for receipt shall be treated as late submissions and will not be considered except under facts and circumstances allowed by the Federal Acquisition Regulation (FAR).

VI. TIME FRAMES AND LOCATION FOR SUBMISSION OF QUOTES:

State the deadline for submission of quotes for this project is March 24, 2025 by 2:00 p.m. EST.

VII. GENERAL TOPICS:

The following submission/completion items will be addressed:

1. From the solicitation, each quoter SHALL complete and submit the following forms, clauses, and statements with his/her bid. Failure to do so may cause your quote to be considered as non-responsive:

STANDARD FORM 1442 Pages 1 & 2: Please include UEI number and Tax ID# and e-mail address where indicated in block 10 and complete blocks 14-20c. If your company has a “doing business as” name reflected in you SAM registration, include this name as well in Block 14.

Ensure the address typed in block 14 matches the address in your SAM registration.

PAST PERFORMANCE SUBMISSION: Please ensure the Cover letter is reviewed and complied with its entirety. References and banking submissions must be submitted in advance to the bid opening directly to Mr. McKeown via email bmckeown@bop.gov.

COMMODITY OR SERVICES SCHEDULE (PAGE 4): Complete the Unit Price (JB = job) and

Amount blocks (these amounts will be the same). Note: The amounts listed in this section should be the same as the amount listed in block 17 of the SF-1442.

REPRESENTATIONS AND CERTIFICATIONS: All contractors submitting a quote must be registered in the System for Award Management (SAM) at www.sam.gov with the North American Industry Classification Standard code (NAICS) 238210 which is applicable to this acquisition.

FAR PROVISION 52.204-8: Pursuant to the section (b) (1) of this provision, provision 52.204-7 is included in this solicitation. Bidders should not mark either of the two options under section (b) (2). Leave these options unmarked.

FAR Provision 52.204-24: Pursuant to the section of this provision, (d). Check either will or will not.

AMENDMENTS: Amendments (if any) must be acknowledged and submitted with the bid by one of the methods as described in item eleven of the Standard Form 30.

2. Other general items to be addressed:

DAVIS BACON ACT: This contract is subject to the Davis Bacon Act. Wage Decision

NC20250003 is applicable for this area. All applicable workers must be paid according to the terms of the wage decision.

LICENSING AND PERMITS: All required licensing and permits are required to be obtained by the contractor who receives contract award.

MAGNITUDE: The magnitude of the project is between $25,000.00 and $100,000.00.

WORK HOURS: Work hours within the secure perimeter shall be between 7:00 am and 3:30 pm Monday through Friday.

COR: The contracting Officer’s Representative (COR) is Mr. Brenton Rains, General Foreman at FCI II Butner.

PERIOD OF PERFORMANCE: The completion period is 624 calendar days after issuance of notice to proceed.

TIME EXTENSIONS: Time extensions for inclement weather will not be granted unless the weather is unusually severe and abnormal in comparison to prior years.

LIQUIDATED DAMAGES: Liquidated damages for this project are in the amount of $1,531.11 per calendar day of delay after scheduled completion.

PRE-CONSTRUCTION CONFERENCE: A Pre-Construction conference is required after the contract is awarded and will be scheduled accordingly.

PROGRESS SCHEDULE: A copy of the progress schedule is to be provided to the Contracting

Officer and Contract Monitor as soon as possible. Each time the progress schedule is changed, it must be provided to both the Contracting Officer and COR. It is suggested an updated document be provided by the Prime Contractor at the mandatory monthly progress meeting.

PROGRESS MEETINGS: Progress meetings are mandatory and will be scheduled monthly.

PAYMENT REQUESTS: Application for payments are to be submitted on AIA G702(Continuation) or the contractors own form as long as the information is similar to the G702. Contactors can get these forms from the following website www.aiabookstore.com

QUESTIONS: Oral questions asked at Site Visit of a technical nature are not acceptable due to the possibility of misunderstanding or misinterpretation. All questions must be sent in WORD FORMAT to Broguen McKeown, FCC Butner Lead Contract Specialist, via email at bmckeown@bop.gov. In order to provide sufficient response time prior to the quote due date, the Government has established that questions be submitted no later than March 21, 2025 by 9:00 a.m. EST.

ACCESS TO SITE/PARKING OF VEHICLES: Only public parking will be available for contractor work vehicles.

STORAGE OF MATERIALS: Storage of materials will be coordinated with the COR.

CONTRACTOR TEMPORARY OFFICE: No temporary office space will be provided.

INSPECTIONS: "Punch List" items generated by inspections will be corrected and discrepancy items re-inspected and approved before contract closure takes place. Should any work be covered without proper notification, the contractor shall uncover that work for inspection at his own expense.

SAFETY MANAGER:

3. SAFETY POINTS:

The contractor is responsible for providing required protective gear to all contractor workers, should it be required. Contractor will ensure that all workers have proper safety gear at all times.

Contractor is responsible for the prevention of accidents on the project site and has spill kit onsite and containment procedures. OSHA requirements will be adhered to.

The Contractor will have a Safety Representative on site at all times during the completion of this project.

Proper storage of any chemicals in lay down yard with SDS present.

The safety department can stop any project if unsafe acts occur.

CAPTAIN:

4. SECURITY

ADVERSE WEATHER: Whenever adverse weather conditions or other institution emergency contingencies are in effect, contract workers will not be permitted passage into the secure institution. Should emergency conditions be implemented while contract workers are inside the secure perimeter, they will be required to secure their tools, remove vehicles and equipment, and leave the institution grounds until the emergency situation has been resolved.

Depending upon the nature of the emergency, this normally will not affect any construction outside of the secure perimeter. Contractor is reminded that fog days will be treated like rain days. The performance period of 624 days will allow adequate time to complete the job, and no consideration will be allowed for normal rain days and normal fog days. The normal rain, snow or fog days will be based on the average over the last ten (10) years for the local community.

SECURITY CLEARANCES: Contract workers are subject to security investigative procedures.

Please refer to the contract for details. Please refer to Page 19 of the contract.

EMPLOYEE IDENTIFICATION: Contractor personnel working on project site must bring valid photo identification to the institution each day. The identification will be surrendered upon entry to, and returned upon exit from institution property.

TOOL ACCOUNTABILITY: Strict accountability and control of all contractor tools and hazardous materials must be maintained at all times. All contractor tools to be used inside the secure perimeter must be inventoried and accounted for at the conclusion of the work day Contractor tools may not be stored on-site overnight. The contractor should provide for enough time at the conclusion of the work day for the return and accounting of all tools issued during the work day. Lost or missing tools must be reported to the COR the Captain immediately.

ILLEGAL ITEMS ON FEDERAL PROPERTY: Firearms, ammunition, knives, other weapons, drugs, narcotics, and alcoholic beverages are not permitted inside/outside the secure perimeter or anywhere else on Federal property at any time. This includes the private vehicles of contract workers. Violators will be subject to criminal prosecution. All persons, vehicles, and equipment are subject to search by institution authorities at any time.

NO CONTACT WITH INMATES: Contract workers are not to have any contact with inmates at any time. No photographs may be taken of inmates.

CONTRACTOR EMPLOYEE WORK DRESS: Green or khaki-colored clothing is not allowed, as inmates wear these colors.

PHOTOGRAPHS: The institution’s Facilities Department maintains a digital camera that will be utilized by FBOP staff to document the project work. The Contractor may request copies of these photos and may request that photos be taken for specific conditions. Cellular telephones equipped with photographic capabilities are prohibited on the project construction site.

VIII. ADDITIONAL NOTES:

Meeting minutes recorded by:

Broguen McKeown, Lead Contract Specialist FCC Butner

NOTICE:

MEETING MINUTES ARE PROVIDED FOR INFORMATIONAL PURPOSES ONLY. THEY ARE NOT

INTENDED TO CHANGE ANY SPECIFICATIONS, TERMS OR CONDITIONS OF THE

SOLICITATION. ANY AND ALL CHANGES TO THE SOLICITATION SHALL BE ISSUED IN

SUBSEQUENT AMENDMENTS ISSUED BY THE CONTRACTING OFFICER ON A STANDARD

FORM 30 (SF-30).

BROGUEN

MCKEOWN

Digitally signed by BROGUEN

MCKEOWN

Date: 2025.03.07 13:12:06 -05'00'