140R8123R0001_v2_0001.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040585782

Bureau of Reclamation

Denver Office

Acquisition Operations Branch Building 67 - Denver Federal Center

R81

MS 84-27810

Denver CO 80225

Robert Shedrick 3034452843

1x 01/09/2023

140R8123R0001

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Construction of Project Yellowtail Fiber at Yellowtail Dam in Fort Smith, Montana

The project is issued for full and open competition.

NAICS Code: 237130 - Power and Communication Line and Related Structures Construction

Taxpayer Identification Number: _______________________________

Data Universal Numbering System: _________________________________

Commercial and Government Entity Code: ______________________________

The Small Business Size Standard is $39.5 Million.

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 365 calendar days and complete it within ________________ ________________ calendar days after receiving

See CLIN 00010

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

02/09/2023

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

Bureau of Reclamation Denver Office

Acquisition Operations Branch Building 67 - Denver Federal Center

R81

MS 84-27810

Denver CO 80225

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 3

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140R8123R0001

Please submit all quotes to Contract Specialist, Robert Shedrick at rshedrick@usbr.gov.

Delivery: 04/02/2024

Delivery Location Code: 0009910065

Bureau of Reclamation-GP-MTAO

Yellowtail

2 Avenue B

Ft. Smith MT 59035 US

Period of Performance: 04/02/2023 to 04/02/2024

00010 Trench and Install fiber optic cable

Product/Service Code: S119

Product/Service Description: UTILITIES- OTHER

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Specifications

YELLOWTAIL FIBER

1.0 Project Background

The Bureau of Reclamation, Security Division, located in Lakewood, Colorado, has a requirement for components to support an existing security system. The contractor shall supply and Install 24-strand single-mode fiber optic cable and terminate with LC connectors in a trench from the warehouse to the visitor center and from warehouse to the employee gate. Estimated trench/boring is for approximately 10,000 feet. Install correct amount of hand holes. Area may require removal of earthen materials, asphalt, etc.

Trenching must be compliant with all local, state, and other requirements.

Once installed, test all strands and provide output of test results for approval to proceed. Install building entrance conduit and mount fiber distribution panel in warehouse and visitor center. Backfill trench and re-pave trench where asphalt was removed. The location of the project is Yellowtail Dam, 2 Avenue B, Fort Smith, MT 59035.

1.2 Cost Range: In accordance with FAR 36.204, the anticipated cost range for the project is between $250,000 and $500,000.00.

1.3 Bonds: A bid, performance, and payment bond is required for any construction contract exceeding $150,000. The Offeror to whom award is made will be required to furnish two bonds, a payment bond, standard form 25A, and a performance bond, standard form 25, each in the penal sum as noted in General Conditions, 52.228-15 Performance and Payment Bonds – Construction (JUN 2020).

1.4 Sureties: Individual sureties that may be proposed will be reviewed for acceptability in accordance with the latest requirements in Subpart 28.2 of the Federal Acquisition Regulations. A copy of this subpart is available upon request to the designated contract officer.

1.5 SUBCONTRACTIN PLAN: Does not apply.

1.6 Work: The contractor shall execute on site and as parent contractor.

1.7 Construction Wages: Minimum rates of wages, required by the Davis-Bacon Act (40 U.S.C. 276a), as amended to be paid the various classes of laborers and mechanics employed on this work are set forth in the specifications (ref. FAR Clause 52.222-6 Davis Bacon Act (Jun 2020).

1.8 Caution to Offerors: Offers providing less than 365 calendars days for Government acceptance after the date offers are due will not be considered and will be rejected.

1.9 Key Personnel:

The Contractor shall assign to this contract the following key personnel:

Project Manager Project Supervisor

The Project Manager will be the primary technical point of contact with Bureau of Reclamation. The project manager will be responsible for ensuring all requirements of the contract are met. The Project Manager shall provide a resume. If the Project Supervisor is different from the Project Manager, the Project Supervisor shall also provide a resume. The responsibilities shall be defined. Include rating information (see below) required in RATING PROPOSALS:

FACTOR A: OFFEROR’S PAST PERFORMANCE

FACTOR B: OFFEROR’S EXPERIECE

FACTOR C: KEY PERSONNEL EXPERIENCE.

At any time during performance of this contract, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within fourteen (14) calendar days after the occurrence of any of these events. The contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutions should have comparable qualifications to those of the persons being replaced. The contract will be modified to reflect any approved changes in key personnel.

1.10 Time for Completion of Project: A maximum of 365 calendar days for the completion of this project.

2. Bid Submission:A. Proposal shall be based on all instructions, conditions, and notices to Offerors, provisions, general conditions, general requirements, drawings, and specifications contained in this solicitation.

B. The offeror may e-mail questions about the project on or before, but no later than 5:00 p.m. Mountain Time on January 12, 2023 to Robert Shedrick, Contract Specialist at rshedrick@usbr.gov regarding the solicitation.

C. Electronic offers are due to be submitted to the attention of Robert Shedrick, Contract Specialist, rshedrick@usbr.gov by 5:00 p.m. Mountain Time on January 30, 2023.

2.1 Evaluation/Selection Procedure: The Government intends to evaluate all proposals received and award a task order without conducting discussions, therefore the initial proposal shall conform to the solicitation requirements and should contain the best offer from a technical and price standpoint. Upon completing evaluation of all technical proposals, the Contracting Officer may, in accordance with the provisions of this solicitation and applicable regulations, evaluate price for those proposals determined to be technically acceptable. Those proposals that receive an unacceptable rating on any of the technical factors may not receive further consideration for award.

2.2 Evaluation Criteria and Basis for Award:

Intent to Award without discussion

The Government intends to evaluate all proposals received and award a contract without conducting discussions, therefore the initial proposal shall conform to the solicitation requirements and should contain the best offer from a technical and price standpoint. Upon completing evaluation of all technical proposals, the Contracting Officer may, in accordance with the provisions of this solicitation and applicable regulations, evaluate price for those proposals determined to be technically acceptable. Those proposals that receive an unacceptable rating on any of the technical factors may not receive further consideration for award.

Evaluation Criteria and Basis for Award The contract resulting from this solicitation will be awarded to that responsible Offeror whose offer, conforming to the solicitation, is determined to be the lowest evaluated price of proposals meeting or exceeding the acceptability standards for non-price factors.

I. Price Evaluation

The following techniques will be used to evaluate the total evaluated price to ensure that it is fair and reasonable.

Comparison of proposed prices received in response to the solicitation

Comparison of proposed prices with the Independent Government Estimate

The price proposal will be ranked from lowest to highest based on the evaluation criteria stated above.

The price proposal will be evaluated separately from the technical proposal. The Government will ultimately evaluate the price proposal in comparison to the relative technical quality offered. The Government has the discretion of determining which offer is most advantageous to the Government considering price and technical.

II. Technical Evaluation Factors:

The following technical evaluation factors shall be used to evaluate the technical proposals. Factor A, B, C, and D are considered of equal importance.

Factor A: Offeror’s Past Performance Factor B: Offeror’s Experience Factor C: Key Personnel Experience Factor D: Risk Assessment

Clauses

52.236-27 - Site Visit (Apr 1984)

Offerors or quoters are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

Please coordinate with the personnel below for site visit prior to submitting proposal.

Paul Latchaw

Cell: 303-907-1450

Email: platchaw@usbr.gov

52.236-3 - SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to (1) conditions bearing upon transportation, disposal, handling, and storage of materials; (2) the availability of labor, water, electric power, and roads; (3) uncertainties of weather, river stages, tides, or similar physical conditions at the site; (4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

(End of clause)

52.236-5 - MATERIAL AND WORKMANSHIP (APR 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer’s approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer’s approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor’s expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner.

The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

(End of clause)

SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1)by an act of the Contracting Officer in the administration of this contract, or (2)by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

As prescribed in 4.2105(a), insert the following provision:

Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212- 3, Offeror Representations and Certifications-Commercial Products or Commercial Services.

The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision—

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(d) Representation. The Offeror represents that—

(1) It □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that—

It □ does, □ does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services.

The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable);

or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand;

model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable);

or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

52.204-26 Covered Telecommunications Equipment or Services-Representation.

As prescribed in 4.2105(c), insert the following provision:

Covered Telecommunications Equipment or Services-Representation (Oct 2020)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c) (1) Representation. The Offeror represents that it □ does, □ does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it □ does, □ does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

(End of provision)

52.225-25 Prohibition on Contracting With Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications.

As prescribed at 25.1103(e), insert the following provision:

Prohibition on Contracting With Entities Engaging in Certain Activities or Transactions Relating to Iran— Representation and Certifications (Jun 2020)

(a) Definitions. As used in this provision-

Person—

(1) Means–

(i) A natural person;

(ii) A corporation, business association, partnership, society, trust, financial institution, insurer, underwriter, guarantor, and any other business organization, any other nongovernmental entity, organization, or group, and any governmental entity operating as a business enterprise; and

(iii) Any successor to any entity described in paragraph (1)(ii) of this definition; and

(2) Does not include a government or governmental entity that is not operating as a business enterprise.

Sensitive technology-

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically-

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

(b) The offeror shall e-mail questions concerning sensitive technology to the Department of State at CISADA106@state.gov.

(c) Except as provided in paragraph (d) of this provision or if a waiver has been granted in accordance with Federal Acquisition Regulation (FAR) 25.703-4, by submission of its offer, the offeror—

(1) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran;

(2) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act. These sanctioned activities are in the areas of development of the petroleum resources of Iran, production of refined petroleum products in Iran, sale and provision of refined petroleum products to Iran, and contributing to Iran's ability to acquire or develop certain weapons or technologies; and

(3) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds the threshold at FAR 25.703-2(a)(2) with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at https://www.treasury.gov/resource-center/sanctions/SDN-List/Pages/default.aspx).

(d) Exception for trade agreements. The representation requirement of paragraph (c)(1) and the certification requirements of paragraphs (c)(2) and (c)(3) of this provision do not apply if-

(1) This solicitation includes a trade agreements notice or certification (e.g., 52.225-4, 52.225- 6, 52.225-12, 52.225-24, or comparable agency provision); and

(2) The offeror has certified that all the offered products to be supplied are designated country end products or designated country construction material.

(End of provision)

52.233-2 Service of Protest.

As prescribed in 33.106 , insert the following provision:

Service of Protest (Sept 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from ______________________. [Contracting Officer designate the official or location where a protest may be served on the Contracting Officer.]

(b) The copy of any protest shall be received in the office designated above within oneday of filing a protest with the GAO.

(End of provision)

52.236-28 Preparation of Proposals-Construction.

As prescribed in 36.520 , insert the following provision:

Preparation of Proposals-Construction (Oct 1997)

(a) Proposals must be (1) submitted on the forms furnished by the Government or on copies of those forms; and (2) manually signed. The person signing a proposal must initial each erasure or change appearing on any proposal form.

(b) The proposal form may require offerors to submit proposed prices for one or more items on various bases, including-

(1) Lump sum price;

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of paragraphs (b)(1) through (b)(3) of this provision.

(c) If the solicitation requires submission of a proposal on all items, failure to do so may result in the proposal being rejected without further consideration. If a proposal on all items is not required, offerors should insert the words "no proposal" in the space provided for any item on which no price is submitted.

(d) Alternate proposals will not be considered unless this solicitation authorizes their submission.

(End of provision)

52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request the Contracting Officer will make their full text available. Also, the full text of a clause may be access electronically at the following address:

FAR Clauses – https://www.acquisition.gov/far/

Provision or Clause

52.203-5 Covenant Against Contingent Fees

52.203-7 Anti-Kickback Procedures

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

52.204-19 Incorporation by Reference of Representations and Certifications

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

52.211-10 Commencement, Prosecution, and Completion of Work

52.222-50 Combating Trafficking in Persons

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving

52.225-13 Restrictions on Certain Foreign Purchases

52.232-5 Payments under Fixed-Price Construction Contracts

52.232-27 Prompt Payment for Construction Contracts

52.232-39 Unenforceability of Unauthorized Obligations

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

52.233-3 Protest after Award

52.233-4 Applicable Law for Breach of Contract Claim

52.236-5 Material and Workmanship

52.236-7 Permits and Responsibilities

52.244-6 Subcontracts for Commercial Products and Commercial Services

52.203-3 Gratuities

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity

52.203-12 Limitation on Payments to Influence Certain Federal Transactions

52.203-13 Contractor Code of Business Ethics and Conduct

52.203-14 Display of Hotline Poster(s)

52.203-15 Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009

52.203-16 Preventing Personal Conflicts of Interest

52.204-2 Security Requirements - Alternate II

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

52.204-9 Personal Identity Verification of Contractor Personnel

52.204-18 Commercial and Government Entity Code Maintenance

52.215-8 Order of Precedence-Uniform Contract Format

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

52.236-12 Cleaning Up

52.252-1 Solicitation Provisions Incorporated by Reference.

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

FAR Provisions – https://www.acquisition.gov/far/

52.225-25 Prohibition on Contracting With Entities Engaging in Certain Activities or Transactions Relating to Iran Representation and Certifications

52.236-28 Preparation of Proposals-Construction

����������!"#$#%&'�(#)*+*,$�-./0#%1�2345445567�5784984544�:.;#%+#<#<�"#$#%&'�(#)*+*,$�-./0#%1�23454=5567�:>&>#1�2,$>&$&�?,$+>%.)>*,$�3@;#1�A#&B@�?,.$>*#+1�C*D�A,%$E�?&%>#%E�(&$*#'+E�(&F+,$E�G&'',$E��"&%H*#'<E�2)?,$#E�IJ*''*;+E�I,F<#%�K*B#%E�I%&*%*#E�K*)J'&$<E��K,,+#B#'>E�K,+#0.<E�:J#%*<&$E�3%#&+.%#�&$<�L*0&.M�?,.$>*#+�*$��2,$>&$&N�AOPQR�?S-:3KT?3US-�IKSVO?3:�-,>#1�?,$>%&)>+�+.0W#)>�>,�>J#�(&B*+XC&),$�P)>�&%#�D#$#%&''@�%#Y.*%#<�>,�;&@�&>�'#&+>�>J#�&;;'*)&0'#�/*$*/./�F&D#�%&>#�%#Y.*%#<�.$<#%�OM#).>*B#�S%<#%�=9547�,%�OM#).>*B#�S%<#%�=Z7[\N�I'#&+#�$,>#�>J&>�>J#+#�OM#).>*B#�S%<#%+�&;;'@�>,�),B#%#<�),$>%&)>+�#$>#%#<�*$>,�0@�>J#�H#<#%&'�D,B#%$/#$>�>J&>�&%#�+.0W#)>�>,�>J#�(&B*+XC&),$�P)>�*>+#'HE�0.>�<,�$,>�&;;'@�>,�),$>%&)>+�+.0W#)>�,$'@�>,�>J#�(&B*+XC&),$�K#'&>#<�P)>+E�*$)'.<*$D�>J,+#�+#>�H,%>J�&>�4]�?GK�[N=̂&_̂4_X̂75_N�`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀�aUH�>J#�),$>%&)>�*+�#$>#%#<����aN�OM#).>*B#�S%<#%�=9547������a�a*$>,�,$�,%�&H>#%�V&$.&%@�Z5E��a��D#$#%&''@�&;;'*#+�>,�>J#���a�a4544E�,%�>J#�),$>%&)>�*+������a��),$>%&)>N������������������a�a%#$#F#<�,%�#M>#$<#<�̂#NDNE�&$�aN�3J#�),$>%&)>,%�/.+>�;&@����a�a,;>*,$�*+�#M#%)*+#<_�,$�,%����a��&''�),B#%#<�F,%b#%+�&>�����a�a&H>#%�V&$.&%@�Z5E�45441�������a��'#&+>�c=[N55�;#%�J,.%�̂,%��a�a������������������������������a��>J#�&;;'*)&0'#�F&D#�%&>#���a�a������������������������������a��'*+>#<�,$�>J*+�F&D#��������a�a������������������������������a��<#>#%/*$&>*,$E�*H�*>�*+����a�a������������������������������a��J*DJ#%_�H,%�&''�J,.%+������a�a������������������������������a��+;#$>�;#%H,%/*$D�,$�>J#����a�a������������������������������a��),$>%&)>�*$�4544N����������a�à`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀ à̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀`̀a�aUH�>J#�),$>%&)>�F&+�&F&%<#<�,$aN�OM#).>*B#�S%<#%�=Z7[\������a�a,%�0#>F##$�V&$.&%@�=E�45=[�&$<a��D#$#%&''@�&;;'*#+�>,�>J#���a�aV&$.&%@�4]E�4544E�&$<�>J#�����a��),$>%&)>N������������������a�a),$>%&)>�*+�$,>�%#$#F#<�,%����aN�3J#�),$>%&)>,%�/.+>�;&@�&''a�a#M>#$<#<�,$�,%�&H>#%�V&$.&%@��a��),B#%#<�F,%b#%+�&>�'#&+>���a�aZ5E�45441���������������������a��c==N4[�;#%�J,.%�̂,%�>J#����a�a������������������������������a��&;;'*)&0'#�F&D#�%&>#�'*+>#<a�a������������������������������a��,$�>J*+�F&D#�<#>#%/*$&>*,$Ea�a������������������������������a��*H�*>�*+�J*DJ#%_�H,%�&''���a�

!������������������������������!��"#$%&�&'()*�'(%+#%,-).�#)��!�!������������������������������!��*"/*�0#)*%/0*�-)�12113�����!�!444444444444444444444444444444!44444444444444444444444444444!�5"(�/''6-0/76(�89(0$*-:(�;%<(%�,-)-,$,�=/.(�%/*(�=-66�7(�/<>$&*(<�/))$/66?3�@+�*"-&�0#)*%/0*�-&�0#:(%(<�7?�#)(�#+�*"(�89(0$*-:(�;%<(%&�/)<�/�06/&&-+-0/*-#)�0#)&-<(%(<�)(0(&&/%?�+#%�'(%+#%,/)0(�#+�=#%A�#)�*"(�0#)*%/0*�<#(&�)#*�/''(/%�#)�*"-&�=/.(�<(*(%,-)/*-#)B�*"(�0#)*%/0*#%�,$&*�&*-66�&$7,-*�/�0#)+#%,/)0(�%(C$(&*3�D<<-*-#)/6�-)+#%,/*-#)�#)�0#)*%/0*#%�%(C$-%(,()*&�/)<�=#%A(%�'%#*(0*-#)&�$)<(%�*"(�89(0$*-:(�;%<(%&�-&�/:/-6/76(�/*�"**'&EFF===3<#63.#:F/.()0-(&F="<F.#:(%),()*G0#)*%/0*&3�H#<-+-0/*-#)�I$,7(%�����J$76-0/*-#)�K/*(�����������2��������������2LF2MF1211�����������L��������������21F1NF1211�����������1��������������2OF1PF1211�Q�8R8S21TTG21L�2OF2LF1211�JU@RR@JV�S;WI5X�����������������������������������Y/*(&����������Z%-).(&�8R8S5Y@S@DI3333333333333333333333[�TT3\2�������13N]̂LN31\�GGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGG�Q�8R8S2NT1G2LT�2OF2LF1211�_@̀�U;YIB�SDY58YB�KDI@8RVB�KDaV;IB�ZDRR;IB�̀DYZ@8RKB�HSS;I8B�J;aK8Y�Y@b8YB�JYD@Y@8B�Y@SURDIKB�Y;;V8b8R5B�Y;V8_WKB�VU8Y@KDIB�5Y8DVWY8B�DIK�a@R_DWc�S;WI5@8V�����������������������������������Y/*(&����������Z%-).(&�8R8S5Y@S@DI3333333333333333333333[�TM3M1�������N3N]̂LP32L�GGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGGG��8Ì@2P22G2L2�2NF2LF12LT�����������������������������������Y/*(&����������Z%-).(&�J;a8Y�8dW@JH8I5�;J8YD5;YE����ef#)(�Lg��������eLg�DG+%/,(�*%$0A�S%/)(B�������������������#-6(%��e(90('*�0%/)(g33[�1T3PM������������L23P2�

�����"#$��%&'()�������*+,)&-./,,012)&-�31,,)&�������"4+&5�'(0�6&'0)�������%178'95+1($-�.'9:;1)<<<<<<<<=�#><?@������������AB<@B������">$�C)9;'(+9<<<<<<<<<<<<<<<<=�#@<>@������������AB<@B������"@$�%&'()D-�#E�51(D�F�@@�������51(D<<<<<<<<<<<<<<<<<<<<<<<<=�#G<BB������������AA<@B������"E$�%&'()D-�@E�51(D�51�'(0�������+(9,<�G@�51(D<<<<<<<<<<<<<<<=�#H<BB������������AA<@B������"I$�%&'()D-�GE�51(D�51�'(0�������+(9,<�A@?�51(DJ�%&'()D-�������K;+&,)L�"M,,$<<<<<<<<<<<<<<<=�#?<BB������������AA<@B������"G$�%&'()D-�AEB�51(D�51�������+(9,/0+(N�#EB�51(D�"'00�������=A<BB��������������O1&�)P)&L�ABB�51(D�1P)&�������#EB�51(D$J�%&'()-�Q5+OOF������R)N�1&��������������4)&&+9:J�S),+9185)&�������S1+D5J�%&'()-�T1U)&�"',,$<<<=�>B<BB������������AA<@B�V*WX�4XYZWZTZ*WQ�Y*3�[*KX3�X\][CXWT�*[X3MT*3Q̂���T;)�21()�;1/&,L�&'5)D�'88,+9'_,)�51�)'9;�8&1̀)95�D;',,�_)���0)5)&7+()0�_L�7)'D/&+(N�5;)�&1'0�7+,)D�1P)&�5;)�D;1&5)D5���8&'95+9',�7'+(5'+()0�&1/5)�O&17�5;)�()'&)D5�%1/(5L�%1/&5���S1/D)�1O�5;)�O1,,1U+(N�,+D5)0�51U(D�51�5;)�9)(5)&�1O�5;)���̀1_̂���.ZRRZW6Q-�.*VXCMW-�.]TTX-�63XMT�YMRRQ-�SXRXWM-�aMRZQ[XRR-���CZQQ*]RM�V1()�Â���B�51�>B�7+,)D�F�.'D)�['LV1()�#̂��>B�51�IB�7+,)D�F�.'D)�['L�b�=><EB�V1()�>̂��*P)&�IB�7+,)D�F�.'D)�['L�b�=E<EB�FFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFF��Z3*WBG>#FBAH�BGcBAc#B#A�����������������������������������3'5)D����������Y&+(N)D�Z3*WK*3aX3̂��3)+(O1&9+(N�'(0����Q5&/95/&',<<<<<<<<<<<<<<<<<<<<<<<=�#?<E@������������#@<BI�FFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFF���Q]CT#BAAFBE#�B#cBHc#BAA�����������������������������������3'5)D����������Y&+(N)D�

!"#$%&'%#�()*+,�-*+.�/012344444445�67489�������������:4;9����!"#$%&'%#<�%=>1?@AB�)*+,�-*+.44445�6C4C8�������������:499����D"E/#%#F��!*,,*0�*+�GA0A+H14444445�C:4II�������������J4I9����D"E/#%#F��$KLA1H2A+444444444444445�6C4C9�������������J47M����D"E/#%#F�DH0@B>HLA�H0@����N++KOHPK*0444444444444444444444445�CJ4C7�������������C489����/$%#"'/#F��E*Q>HPRS.K@����SPAA+RS.K@�D*H@A+44444444444444445�684J8�������������;49J����/$%#"'/#F��%=>HTHP*+44444444444445�684M6�������������;49J����/$%#"'/#F��G+H@A+RE1H@A44444444445�6J477�������������;47J����/$%#"'/#F��D*H@A+�()+*0P�%0@344445�674J;�������������;49J����/$%#"'/#F��S>+HLA+4444444444444445�68499�������������M4:M����'#U!V�W#NX%#F��W?,L�'+?>.444444445�CI4II�������������J49I�YYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYYY�-%DW%#S�Y�#A>AKTA�+HPA�L+AB>+KQA@�Z*+�>+HZP�LA+Z*+,K0O�*LA+HPK*0�P*�[\K>\�[A1@K0O�KB�K0>K@A0PH14�]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]]�&*PAF�%=A>?PKTA�/+@A+�(%/3�C8:9M<�%BPHQ1KB\K0O�$HK@�SK>.�DAHTA�Z*+�)A@A+H1�!*0P+H>P*+B�HLL1KAB�P*�H11�>*0P+H>PB�B?Q̂A>P�P*�P\A�WHTKBYEH>*0�">P�Z*+�[\K>\�P\A�>*0P+H>P�KB�H[H+@A@�(H0@�H02�B*1K>KPHPK*0�[HB�KBB?A@3�*0�*+�HZPA+�_H0?H+2�C<�69C:4��NZ�P\KB�>*0P+H>P�KB�>*TA+A@�Q2�P\A�%/<�P\A�>*0P+H>P*+�,?BP�L+*TK@A�A,L1*2AAB�[KP\�C�\*?+�*Z�LHK@�BK>.�1AHTA�Z*+�ATA+2�89�\*?+B�P\A2�[*+.<�?L�P*�JM�\*?+B�*Z�LHK@�BK>.�1AHTA�AH>\�2AH+4�%,L1*2AAB�,?BP�QA�LA+,KPPA@�P*�?BA�LHK@�BK>.�1AHTA�Z*+�P\AK+�*[0�K110ABB<�K0̂?+2�*+�*P\A+�\AH1P\Y+A1HPA@�0AA@B<�K0>1?@K0O�L+ATA0PKTA�>H+À�P*�HBBKBP�H�ZH,K12�,A,QA+�(*+�LA+B*0�[\*�KB�1K.A�ZH,K12�P*�P\A�A,L1*2AA3�[\*�KB�K11<�K0̂?+A@<�*+�\HB�*P\A+�\AH1P\Y+A1HPA@�0AA@B<�K0>1?@K0O�L+ATA0PKTA�>H+À�*+�Z*+�+AHB*0B�+AB?1PK0O�Z+*,<�*+�P*�HBBKBP�H�ZH,K12�,A,QA+�(*+�LA+B*0�[\*�KB�1K.A�ZH,K12�P*�P\A�A,L1*2AA3�[\*�KB�H�TK>PK,�*Z<�@*,ABPK>�TK*1A0>A<�BA=?H1�HBBH?1P<�*+�BPH1.K0O4��"@@KPK*0H1�K0Z*+,HPK*0�*0�>*0P+H>P*+�+Aa?K+A,A0PB�H0@�[*+.A+�L+*PA>PK*0B�?0@A+�P\A�%/�KB�HTHK1HQ1A�HP�\PPLBFRR[[[4@*14O*TRHOA0>KABR[\@RO*TA+0,A0PY>*0P+H>PB4�

"#$%&'()�*$+&&%,%*+'%-#&�#(()()�,-.�/-.0�#-'�%#*$1)()�/%'2%#�'2(�&*-3(�-,�'2(�*$+&&%,%*+'%-#&�$%&'()�4+5�6(�+))()�+,'(.�+/+.)�-#$5�+&�3.-7%)()�%#�'2(�$+6-.�&'+#)+.)&�*-#'.+*'�*$+1&(&�89:;<=�>?>�8+@�8A@�8%%@@?�BBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBBB�C2(�6-)5�-,�(+*2�/+D(�)('(.4%#+'%-#�$%&'&�'2(�*$+&&%,%*+'%-#�+#)�/+D(�.+'(&�'2+'�2+7(�6((#�,-1#)�'-�6(�3.(7+%$%#D�,-.�'2(�*%'()�'53(8&@�-,�*-#&'.1*'%-#�%#�'2(�+.(+�*-7(.()�65�'2(�/+D(�)('(.4%#+'%-#?�C2(�*$+&&%,%*+'%-#&�+.(�$%&'()�%#�+$32+6('%*+$�-.)(.�-,�EE%)(#'%,%(.&EE�'2+'�%#)%*+'(�/2('2(.�'2(�3+.'%*1$+.�.+'(�%&�+�1#%-#�.+'(�8*1..(#'�1#%-#�#(D-'%+'()�.+'(�,-.�$-*+$@F�+�&1.7(5�.+'(�8/(%D2'()�+7(.+D(�.+'(@�-.�+�1#%-#�+7(.+D(�.+'(�8/(%D2'()�1#%-#�+7(.+D(�.+'(@?�"#%-#�=+'(�G)(#'%,%(.&�H�,-1.�$(''(.�*$+&&%,%*+'%-#�+66.(7%+'%-#�%)(#'%,%(.�(#*$-&()�%#�)-''()�$%#(&�6(D%##%#D�/%'2�*2+.+*'(.&�-'2(.�'2+#�EEI"EE�-.�EE"HJKEE�)(#-'(&�'2+'�'2(�1#%-#�*$+&&%,%*+'%-#�+#)�.+'(�/(.(�3.(7+%$%#D�,-.�'2+'�*$+&&%,%*+'%-#�%#�'2(�&1.7(5?�LM+43$(N�OP"QRA:SBRR>�RTURAU9RAV?�OP"Q�%&�+#�+66.(7%+'%-#�%)(#'%,%(.�-,�'2(�1#%-#�/2%*2�3.(7+%$()�%#�'2(�&1.7(5�,-.�'2%&�*$+&&%,%*+'%-#F�/2%*2�%#�'2%&�(M+43$(�/-1$)�6(�O$146(.&?�RA:S�%#)%*+'(&�'2(�$-*+$�1#%-#�#146(.�-.�)%&'.%*'�*-1#*%$�#146(.�/2(.(�+33$%*+6$(F�%?(?F�O$146(.&�P-*+$�RA:S?�C2(�#(M'�#146(.F�RR>�%#�'2(�(M+43$(F�%&�+#�%#'(.#+$�#146(.�1&()�%#�3.-*(&&%#D�'2(�/+D(�)('(.4%#+'%-#?�RTURAU9RAV�%&�'2(�(,,(*'%7(�)+'(�-,�'2(�4-&'�*1..(#'�#(D-'%+'()�.+'(F�/2%*2�%#�'2%&�(M+43$(�%&�W1$5�AF�9RAV?�"#%-#�3.(7+%$%#D�/+D(�.+'(&�+.(�13)+'()�'-�.(,$(*'�+$$�.+'(�*2+#D(&�%#�'2(�*-$$(*'%7(�6+.D+%#%#D�+D.((4(#'�8;XH@�D-7(.#%#D�'2%&�*$+&&%,%*+'%-#�+#)�.+'(?�I1.7(5�=+'(�G)(#'%,%(.&�;$+&&%,%*+'%-#&�$%&'()�1#)(.�'2(�EEI"EE�%)(#'%,%(.�%#)%*+'(�'2+'�#-�-#(�.+'(�3.(7+%$()�,-.�'2%&�*$+&&%,%*+'%-#�%#�'2(�&1.7(5�+#)�'2(�316$%&2()�.+'(�%&�)(.%7()�65�*-431'%#D�+�/(%D2'()�+7(.+D(�.+'(�6+&()�-#�+$$�'2(�.+'(&�.(3-.'()�%#�'2(�&1.7(5�,-.�'2+'�*$+&&%,%*+'%-#?��H&�'2%&�/(%D2'()�+7(.+D(�.+'(�%#*$1)(&�+$$�.+'(&�.(3-.'()�%#�'2(�&1.7(5F�%'�4+5�%#*$1)(�6-'2�1#%-#�+#)�#-#B1#%-#�.+'(&?�LM+43$(N�I"PH9RA9BRRT�>UAYU9RAV?�I"�%#)%*+'(&�'2(�.+'(&�+.(�&1.7(5�.+'(&�6+&()�-#�+�/(%D2'()�+7(.+D(�*+$*1$+'%-#�-,�.+'(&�+#)�+.(�#-'�4+Z-.%'5�.+'(&?�PH�%#)%*+'(&�

!"#�$!%!#�&'�(&)*+*%,%-�./0.�*+�!"#�1#%2�&'�+)23#1�&,�4"*5"�!"#+#�56%++*'*5%!*&,+�%,7�2%!#+�%2#�8%+#7-�9"#�,#:!�,);8#2<�//=�*,�!"#�#:%;>6#<�*+�%,�*,!#2,%6�,);8#2�)+#7�*,�>2&7)5*,?�!"#�4%?#�7#!#2;*,%!*&,-�@A0BA./0C�*,7*5%!#+�!"#�+)23#1�5&;>6#!*&,�7%!#�'&2�!"#�56%++*'*5%!*&,+�%,7�2%!#+�),7#2�!"%!�*7#,!*'*#2-�$)23#1�4%?#�2%!#+�%2#�,&!�)>7%!#7�%,7�2#;%*,�*,�#''#5!�),!*6�%�,#4�+)23#1�*+�5&,7)5!#7-�D,*&,�E3#2%?#�F%!#�G7#,!*'*#2+�H6%++*'*5%!*&,I+J�6*+!#7�),7#2�!"#�DEKL�*7#,!*'*#2�*,7*5%!#�!"%!�,&�+*,?6#�;%M&2*!1�2%!#�>2#3%*6#7�'&2�!"&+#�56%++*'*5%!*&,+N�"&4#3#2<�0//O�&'�!"#�7%!%�2#>&2!#7�'&2�!"#�56%++*'*5%!*&,+�4%+�),*&,�7%!%-�PQERS(PT�DEKLUVWU//0/�/XA.YA./0C-�DEKL�*,7*5%!#+�!"%!�!"#�2%!#�*+�%�4#*?"!#7�),*&,�%3#2%?#�2%!#-�VW�*,7*5%!#+�!"#�+!%!#-�9"#�,#:!�,);8#2<�//0/�*,�!"#�#:%;>6#<�*+�%,�*,!#2,%6�,);8#2�)+#7�*,�>2&7)5*,?�!"#�4%?#�7#!#2;*,%!*&,-�/XA.YA./0C�*,7*5%!#+�!"#�+)23#1�5&;>6#!*&,�7%!#�'&2�!"#�56%++*'*5%!*&,+�%,7�2%!#+�),7#2�!"%!�*7#,!*'*#2-�E�DEKL�2%!#�4*66�8#�)>7%!#7�&,5#�%�1#%2<�)+)%661�*,�Z%,)%21�&'�#%5"�1#%2<�!&�2#'6#5!�%�4#*?"!#7�%3#2%?#�&'�!"#�5)22#,!�,#?&!*%!#7AH[E�2%!#�&'�!"#�),*&,�6&5%6+�'2&;�4"*5"�!"#�2%!#�*+�8%+#7-�UUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUUU��������������������\ELP�]P9PFRĜE9GV̂�ESSPE($�SFVHP$$�0-J�W%+�!"#2#�8##,�%,�*,*!*%6�7#5*+*&,�*,�!"#�;%!!#2_�9"*+�5%,�8#T��̀�%,�#:*+!*,?�>)86*+"#7�4%?#�7#!#2;*,%!*&,��̀�%�+)23#1�),7#261*,?�%�4%?#�7#!#2;*,%!*&,��̀�%�\%?#�%,7�W&)2�]*3*+*&,�6#!!#2�+#!!*,?�'&2!"�%�>&+*!*&,�&,����%�4%?#�7#!#2;*,%!*&,�;%!!#2��̀�%�5&,'&2;%,5#�I%77*!*&,%6�56%++*'*5%!*&,�%,7�2%!#J�2)6*,?�V,�+)23#1�2#6%!#7�;%!!#2+<�*,*!*%6�5&,!%5!<�*,56)7*,?�2#a)#+!+�'&2�+);;%2*#+�&'�+)23#1+<�+"&)67�8#�4*!"�!"#�\%?#�%,7�W&)2�%̂!*&,%6�V''*5#�8#5%)+#�̂%!*&,%6�V''*5#�"%+�2#+>&,+*8*6*!1�'&2�!"#�]%3*+U[%5&,�+)23#1�>2&?2%;-�G'�!"#�2#+>&,+#�'2&;�!"*+�*,*!*%6�5&,!%5!�*+�,&!�+%!*+'%5!&21<�!"#,�!"#�>2&5#++�7#+52*8#7�*,�.-J�%,7�B-J�+"&)67�8#�'&66&4#7-\*!"�2#?%27�!&�%,1�&!"#2�;%!!#2�,&!�1#!�2*>#�'&2�!"#�'&2;%6�

!"#$%&&�'%&$"()%'�*%"%+�(,(-(./�$#,-.$-�&*#0/'�)%�1(-*�-*%�2".,$*�#3�4#,&-"0$-(#,�5.6%�7%-%"8(,.-(#,&9��5"(-%�-#:�������������2".,$*�#3�4#,&-"0$-(#,�5.6%�7%-%"8(,.-(#,&�������������5.6%�.,'�;#0"�7(9�7%!."-8%,-�#3�?.)#"�������������@AA�4#,&-(-0-(#,�B9�7%!."-8%,-�#3�?.)#"�������������@AA�4#,&-(-0-(#,�B…