B09_Attach_3_Site_Visit_Tri_Fold_SEKI_Lodgepole_(1)_0002.docx

QUESTIONS AFTER PREPROPOSAL CONFERENCE

· Direct all questions to both Natasha DiPietro, Contracting Officer, and Seth Mercil, Contracting Specialist. Please submit all questions not later than 4/28/22.

· Questions directed to any other Government team member will be redirected to Ms. DiPietro or Mr. Mercil. No answers will be provided by any other team member. All questions and answers will be provided to all prospective offerors by amendment to the solicitation.

· Request for Proposal (Solicitation Document) shall only be changed by formal amendment issued by the Contracting Officer at the website – www.SAM.gov Award of a Contract:

Best Value Trade Alternate proposals shall not be accepted or evaluated The government intends to evaluate proposals and award a contract without discussions with offerors, therefore the offeror’s initial proposal should contain the offeror’s best terms from a cost or price and technical standpoint. The government reserves the right to conduct discussions if the CO later determines them to be necessary.

Project Location:

Lodgepole is on the Marble Fork of the Kaweah River. SEKI 172423 – Replace Non-Compliant Lodgepole Water Treatment System, Sequoia & Kings Canyon National Park

Questions asked during site visit must be submitted in writing and will be responded to by formal written amendment

Responses or discussion on site will not change the solicitation document

Changes to the solicitation document shall be made by formal written amendment only

Preproposal Conference/ Site Visit- Tuesday, April 26, 2022 at 2:00 p.m. PDT

Request for Proposals No. 140P2022R0102 CO: Natasha DiPietro natasha_dipietro@nps.gov

CS: Seth Mercil seth_mercil@nps.gov

Clauses 52.211-10 Commencement, Prosecution, and Completion of Work - Commence work within 10 days after NTP. Complete not later than 365 days after NTP.

52.211-12 Liquidated Damages – Construction - If contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1482.00 for each calendar day of delay until the work is completed or accepted.

Special Clause 2 – Key Personnel: Project Manager, Job-site Superintendent, Quality Control Manager, Safety Officer. Contractor shall not be allowed to change key personnel during the first 60 days of performance.

DIAR 1452.228-70 – Liability Insurance: The contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the CO by an insurance company which is acceptable to the CO. The amounts of insurance shall be not less than:

$100,000 each person $500,000 each occurrence $1,000,000 property damage

52.225-11 Buy American – Construction Materials (NOV 2021) – Refer to Clause for specific requirements

52.236-1 Performance of Work by the Contractor (APR 1984) – Contractor shall self-perform at least fifteen (15) percent of total amount of work to be performed under the contract.

Submission and Evaluation Section L Instructions for the Submission of Offers

· Proposals Due May 5, 2022 12:00 MDT

· Volume I – Non-Price Proposal

· Volume II - Business and Price Proposal

· Send electronic proposals to: CS_DSC_Proposal_Submission@nps.gov CO, and CS

· Submissions shall contain the solicitation number, park-PMIS, and number of total emails (example in solicitation) Evaluation Factors:

The evaluation factors correlate to the proposal preparation instructions.

Factors 1- 8 are listed in descending order of importance.

Overall: All evaluation factors other than price, when combined, are approximately equally important to price.

FACTOR 1 – Technical Approach FACTOR 2 – Schedule FACTOR 3 – Management Approach FACTOR 4 – Safety FACTOR 5 – Project Experience FACTOR 6 – Key Personnel Experience FACTOR 7 – Past Performance FACTOR 8 – Small Business Participation

Refer to solicitation for specific information on submission requirements and evaluation

Overview of project This project rehabilitates a non-compliant surface water treatment system with a compliant system. The scope of work includes construction services associated with rehabilitation to a non-compliant surface water treatment system to a compliant system, which located in Lodgepole developed area of Sequoia National Park. Additionally, the rehabilitated surface water treatment facility will meet current and projected surface water quality requirements, and a reliable, efficient and code compliant water system will allow the park to meet the challenges of climate change with dryer weather and increased fire danger likely to continue in the future. to a non-compliant surface water treatment system to a compliant system, which located in Lodgepole developed area of Sequoia National Park. Additionally, the rehabilitated surface water treatment facility will meet current and projected surface water quality requirements, and a reliable, efficient and code compliant water system will allow the park to meet the challenges of climate change with dryer weather and increased fire danger likely to continue in the future.

image1.png image2.emf image20.emf